16. 6973GH-20-R-00062.pdf

Section A - Solicitation/Contract Form Clauses

Section B - Supplies or Services/Prices Section B - Schedule

See Section J, Attachment 1 for Section B Contract Line Items/Pricing applicable to this instrument.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE AT

THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

C.1 SCOPE OF WORK

The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project set forth below, in accordance with the specifications and drawings, and the other terms, conditions, and provisions as set forth herein.

C.2 BID VS. OFFER

References to the terms “bid”, “bidder”, etc. throughout the specification are intended to mean “offer”, “offeror”, etc.

C.3 SPECIFICATIONS AND DRAWINGS

The following specifications and/or drawings are applicable to this acquisition.

(a) Specifications titled, "Base Maintenance Building Renovation" dated December 20, 2019, 954 pages

(b) Drawings titled, "Renovation of BMB-15 (Base Maintenance Building)," dated December 20, 2019, 382 pages.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.4-1 CONTRACTOR INSPECTION REQUIREMENTS (APR 1996)

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

Section F - Deliveries or Performance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

F.1 WORKING HOURS

(a) Work at the site shall be accomplished between the hours of 6:00 a.m. and 6:00 p.m., Monday through Friday, excluding federally established holidays, except when prior approval has been obtained from the Contracting Officer. Approval for overtime work shall not be construed as an agreement for payment of overtime work. No Work, with the exception of the demolition work as described below, shall occur at night, or on Saturday’s, Sunday’s or designated government holidays unless approved by the Contracting Officer seven (7) days in advance.

(b) All demolition including the removal of the existing concrete slab, sub-soil removal below existing concrete slab, demolition and removal of interior GWB and CMU partitions, windows, floor, wall and ceiling finishes, HVAC equipment and ductwork, plumbing and waste lines and vents, electrical demolition and removal, and any or all other items related to demolition, shall be between the hours of 6:00 P.M and 6:00 A.M Monday thru Friday.

Work on the demolition may also be accomplished on weekends and approved government holidays. Work during these times (weekend and government holidays), must be pre-approved and scheduled in advance. Provide a minimum of seven (7) days prior notice to AMP-400, Project Manager, Mike Monroney Aeronautical Center, 405- 954-4574 to coordinate scheduling of any work to be done outside of the occupants normal working hours.

F.2 UTILITY OUTAGES AND SHUTDOWN

Coordinate with the Project Manager at 405-954-4574. Outages affecting FAA Operations are required to be accomplished at night, or on Saturday’s, Sunday’s or designated government holidays. Prior to any outage or shutdown, twenty-one (21) working days notification must be made to coordinate scheduling of any Work to be performed during any hours.

F.3 CONTRACTOR USE OF PREMISES

(a) General: Limit use of site and premises to allow:

(1) Owner occupancy:. The CCMS/SOD Contractor Area, Automotive Shop, Metal Shop, and Onsite Issue

(tools/parts room) on the First Floor of the building will be occupied throughout the duration of this project. During Phase One of the construction, occupants will be relocated to the North side of the building. During Phase Two of the construction, occupants will be relocated to the South side of the building. The Contractor shall make every effort to not disrupt the day to day operations of this facility. The Contractor will be responsible for providing safety barriers, temporary dust-proof partitions to demark exit travel, warnings, temporary lighting, heating, venting, air conditioning and other appurtenances necessary to keep the occupants safe.

(2) Work by others:

(A) FAA IT personnel will be installing telecommunications and security equipment.

(B) Abatement of asbestos containing material (ACM); however, ACM removal must be accommodated by the contractor in the overall construction schedule.

(b) Access to Site: Coordinate site access and staging areas with FAA project manager prior to commencement of work.

F.4 CONTRACTOR'S CONSTRUCTION SCHEDULE

The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fifteen (15) days of the date established for “Commencement of Work” in accordance with Clause 3.2.2.3-56, which is incorporated by reference.

Section G - Contract Administration Data Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL 2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

G.1 PAYMENT PROCEDURES

(a) Payment for work performed or items furnished under this contract is subject to approval by the Contracting Officer. The contractor shall submit electronic invoices, including applications for finance payments, to FAA, Facilities & Aviation Safety Contracting Section (AAQ-731).

(b) The contractor shall submit electronic invoices, including applications for finance payments, directly to Financial Operations Division (AMK-311), 9-AMZ-FAA-APInvoices@FAA.GOV.

(c) Each invoice, including applications for finance payments, must reflect the contract number, delivery order number, and a description of the work, services, or items being invoiced.

(d) Contract Modifications (Change Orders) that include more than one proposed change, shall itemize each change, to facilitate assessment of work progress.

(e) Points of contact for invoice submission will be provided at the Post Award Conference.

Section H - Special Contract Requirements Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2018)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

H.1 PERMITS AND RESPONSIBILITIES

The Contractor shall secure and pay for all permits, licenses, special inspections, etc., required in the execution of the work, whether of a permanent or temporary nature.

H.2 TIME EXTENSION

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

H.3 ACCIDENT AND FIRE REPORTING

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.4 CONSTRUCTION SAFETY PROGRAM

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities. Chapter 33 Construction Safety (Section J, Attachment 4) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

H.5 NOTIFICATION REUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS DISTURBED

If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

H.6 EXERCISE OF OPTIONAL CONTRACT LINE ITEMS (CLINS)

The Government may exercise none, some or all Option items at the prices established in Section B, CLINs 0002- 0005. Exercise of the option CLINs must be made in writing by the Contracting Officer within 30 days of contract award.

H.7 SUBCONTRACTOR SUBSTITUTION

a) If a subcontractor’s experience was submitted in partial satisfaction of the requirement in Section L, Factor 1, Experience, that subcontractor is considered essential to the work being performed hereunder. Any change in the subcontractor or the effort the subcontractor will perform must be reported in sufficient detail to permit evaluation of the impact on this contract directly to and approved by the CO.

b) No removing, replacing, or diversion shall be made by the Contractor without the written consent of the Contracting Officer. Replacing, substituting, or removing the proposed subcontractor prior to receiving CO consent may be means for terminating the contract by default.

c) This provision is applicable to the following subcontractor: (offer to insert name of subcontractor, if any, used to partially satisfy Experience requirement)

H.8 MAINTENANCE/DEFECT SECURITY

In accordance with Oklahoma Statute§61-113(B)(3), within 60 days of contract award, the successful contractor shall provide a bond or irrevocable letter of credit in a sum equal to the contract price to protect the Oklahoma City Airport Trust and City of Oklahoma City as public agencies to be protected against defective workmanship andmaterials for a period of one (1) year after acceptance of the project.

H.9 CITY OF OKLAHOMA CITY/OKLAHOMA CITY AIRPORT TRUST

a. In relation to 3.4.1-1 PROPOSAL GUARANTEE (JAN 2017), 3.4.1-4 PERFORMANCE BOND REQUIREMENTS (JAN 2017), and 3.4.1-5 PAYMENT BOND REQUIREMENTS (JAN 2018), is revised to read as follows:

“We, the Principal and Surety(ies) are firmly bound to the United States of America (hereinafter called the Government) as well as City of Oklahoma City and the Oklahoma City Airport Trust. . . "

b. In relation to AC3212 LIABILITY INSURANCE (JAN 1997), paragraph (3) (b) is revised to read as follows:

(b) The policy shall name ‘The United States of America, acting by and through the Federal Aviation Administration’ as an additional insured with respect to operations performed under this contract. The policy shall further name the City of Oklahoma City and the Oklahoma City Airport Trust as an additional insured with respect to operations performed under this contract.

c. In relation to AC3211 SAVE HARMLESS AND INDEMNITY AGREEMENT (JAN 1997); the first sentence is revised to read "The contractor shall save and keep harmless and indemnify the Government as well as Oklahoma City and the Oklahoma City Airport Trust. . . "

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JUL 2018)

3.1.7-5 DISCLOSURE OF CONFLICTS OF INTEREST (JUL 2018)

3.1.8-1 CANCELLATION, RESCISSION AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER

ACTIVITY (OCT 2014)

3.1.8-2 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (OCT 2019)

3.2.2.3-8 AUDIT AND RECORDS (JUL 2010)

3.2.2.3-25 REDUCING THE PRICE OF A CONTRACT OR MODIFICATION FOR DEFECTIVE COST

OR PRICING DATA (JAN 2019)

3.2.2.3-27 SUBCONTRACTOR COST OR PRICING DATA (JUL 2004)

3.2.2.3-33 ORDER OF PRECEDENCE (MAR 2009)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2004)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2004)

3.2.2.3-64 DISMANTLING AND DEMOLISHING OF PROPERTY (JUL 2004)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2004)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-69 SUBCONTRACTS - CONSTRUCTION (JUL 2004)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2019)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.2.5-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (APR 2010)

3.2.5-14 DISPLAY OF HOTLINE POSTER(S) (APR 2008)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-9 INTEREST (JUL 2018)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(JUL 2018)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2019)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT 1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (JUL 2019)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED, AND

SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS CONCERNS (OCT 2019)

3.6.1-4 SMALL, SMALL DISADVANTAGED, WOMEN-OWNED AND SERVICE-DISABLED VETERAN

OWNED SMALL BUSINESS SUBCONTRACTING PLAN (JUL 2019)

3.6.1-6 LIQUIDATED DAMAGES - SUBCONTRACTING PLAN (JAN 2010)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2019)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2019)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME COMPENSATION

(OCT 2018)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (OCT 2018) - ALTERNATE I (JAN 2012)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2018)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (OCT 2018)

3.6.2-18 DAVIS BACON ACT (OCT 2018)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2017)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (JAN 2019)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (JAN 2019)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (JAN 2019)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (OCT 2018)

3.6.2-39 TRAFFICKING IN PERSONS (APR 2019)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2019)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (OCT 2016)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-17 EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (OCT 2019)

3.6.3-19 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-21 EFFICIENCY IN WATER CONSUMING PRODUCTS AND SERVICES (OCT 2018)

3.6.3-22 CONSTRUCTION WASTE MANAGEMENT (JAN 2018)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (OCT 2016)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.3-25 AEROSOLS (OCT 2016)

3.6.3-26 FOAMS (OCT 2016)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JUL 2010)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.4-23 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (OCT 2019)

3.6.5-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN OWNED ECONOMIC

ENTERPRISES (MAR 2009)

3.9.1-1 CONTRACT DISPUTES (OCT 2011)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-20 WARRANTY-CONSTRUCTION (JUL 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-26 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (APR 2013)

3.10.2-6 SUBCONTRACTS FOR COMMERCIAL ITEMS AND COMMERCIAL COMPONENTS (APR

1996)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV 1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-11 PLAIN LANGUAGE (JUL 2006)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(JAN 2018)

3.14-3 FOREIGN NATIONALS AS CONTRACTOR EMPLOYEES (JAN 2019)

3.2.2.3-37 NOTIFICATION OF OWNERSHIP CHANGES (JUL 2004)

(a) The Contractor (you) must notify FAA in writing within 30 days when you become aware that a change in ownership has occurred or will occur and that the change could affect the value of your capitalized assets in the accounting records, asset valuations, or cause any other cost changes.

(b) You must:

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the Contracting Officer (CO) access to the records on request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of your ownership changes; and

(4) Retain and maintain depreciation and amortization schedules based on the asset records maintained before each ownership change.

(c) You must include the substance of this clause in all subcontracts under this contract with a value exceeding $1,000,000 and that require cost and price data.

(End of clause)

3.2.2.3-39 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA OR OTHER INFORMATION

-MODIFICATIONS (JUL 2010)

(a) When there are price adjustments in the contract, the Contractor (you, your) must submit the following:

(1) A certificate of current cost or pricing data (CCCPD) described in paragraph (e), or

(2) For non-certified current cost or pricing data (CPD), a request for an exception to CCCPD. You must request this exception from the CO in writing with the following types of information or data that would establish the reasonableness of the prices you offer:

(i) Information on an exception you received on earlier or repetitive acquisitions;

(ii) Catalog price information including:

(A) A dated catalog with the prices;

(B) The applicable catalog pages; or

(C) A statement that the catalog is on file in the contracts office that will issue this contract modification;

(iii) Information on the current discount policies and price lists (published or unpublished), for example wholesale, original equipment manufacturer, and reseller;

(iv) Evidence of substantial sales to the general public for catalog items that exceed $25,000. Your evidence may consist of verifiable records such as a sales order, contract, shipment, invoice, actual recorded sales; or sales by your affiliates, other manufacturers or vendors when your price proposal is based on sales of essentially the same commercial item. You must also explain the relationship of the offered price to the (1) established catalog price, or (2) the price of recent and substantial sales of similar quantities of the items that were sold to the general public at prices that differ from catalog or list prices;

(v) The basis for the market price including:

(A) The source, date or period of the market quotation;

(B) Any other basis for the market price, the base amount, and applicable discounts;

(C). The nature of the market for the supply or service you are offering (should be the same as or similar to the market price supply or service); or

(D) Data supporting substantial sales to the general public.

(vi) Laws or regulations that establish your offered prices. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of a controlling document that you did not previously submit to the contracting office;

(vii) Information on modifications of contracts or subcontracts for commercial items that relate to the offered price, as follows:

(A) If you received an exception based on adequate price competition, catalog or market prices of commercial items, or prices set by law or regulation under the original contract or subcontract, and this modification is not covered by these exceptions, you must provide information to establish that the modification would not change the contract or subcontract from one for a commercial item to one for a non-commercial item;

(B) For commercial items, you may provide information on selling prices of the same item or similar items in the commercial market; and

(viii) Any other information the CO requests to support your request for an exception or to conclude that your price is fair and reasonable.

(b) You give the CO the right to examine books, records, documents, or other directly pertinent records to verify your request for an exception under this clause or the reasonableness of price at any time before award.

(c) The CO will not require you to provide access to cost or price information or other data that apply to prices offered in the catalog or marketplace.

(d) Submitting information to qualify for an exception does not mean that this is the only exception that may apply.

(e) You must submit under paragraph (a):

CERTIFICATE OF CURRENT COST OR PRICING DATA

I certify that, to the best of my knowledge and belief, the cost or pricing data we submit, either actually or by specific identification in writing, to the Contracting Officer or to the Contracting Officer's representative to support [*] are accurate, complete, and current as of [**]. This certification includes the cost or pricing data supporting any advance agreements and forward pricing rate agreements between the us and the Government that are part of the proposal.

(Contractor insert the following information.)

Firm: [ ]

Signature: [ ]

Name: [ ]

Title: [ ]

Date of execution: [***]

*Contractor identify the proposal, request for price adjustment, or other submission involved, giving the appropriate identifying number (for example, SIR No.)

** Contractor insert the day, month, and year when price negotiations were concluded and price agreement was reached or, if applicable, an earlier date agreed upon between the parties that is as close as practicable to the date of a price agreement.

*** Contractor insert the day, month, and year of signing, which should be as close as practicable to the date when the price negotiations were concluded and the parties agreed on the contract price.

(End of certificate)

(End of clause)

3.2.2.3-41 PERFORMING WORK (JUL 2004)

The Contractor (you) must perform, using your own organization, work equivalent to at least fifteen (15) percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if you request a reduction and the CO determines that it would be to the Government's advantage to do so.

(End of clause)

3.2.2.3-44 PHYSICAL DATA (JUL 2004)

Data and information the FAA (we, us) provides or refers to below is for the Contractor's (your) information. We are not responsible for your interpretation of or conclusions based on the data or information. Further, we do not warrant construction methodology which may be included in these documents.

(a) The descriptions of physical conditions on the drawings and in the specifications are the result of site investigations by site surveys and soil borings..

(b) Other relevant information N/A.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 15 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 820 calendar days for the total project. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004) -

ALTERNATE I (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 15 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 820 calendar days after issuance of Notice to Proceed. . The time allowed for completion must include final cleanup of the premises.

(d) The completion date assumes that the successful offeror will receive the notice to proceed by 30 days after contract award at the earliest.. The CO will extend the completion date by the number of calendar days after the above date that you receive the notice to proceed, except to the extent that the delay in issuing the notice to proceed results from your failure to execute the contract and give the required performance and payment bonds to FAA within the time specified.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JUL 2018)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://www.vip.vetbiz.gov.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible…