Amendment 15BFA025B00000040 0003.pdf

15BFA025B00000040/0003 Page 1 of 17

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 17

2. AMENDMENT/MODIFICATION NUMBER

3. EFFECTIVE DATE

09/05/2025

4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

25Z1AJ1

15B102CODE

Federal Bureau of Prisons FCI Ashland

ROUTE 716

Ashland, KY 41105

6. ISSUED BY CODE7. ADMINISTERED BY (If other than Item 6)

9A. AMENDMENT OF SOLICITATION NUMBER

15BFA025B00000040

CODE FACILITY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, country, state and ZIP Code) (X)

X 9B. DATED (SEE ITEM 11)

08/01/2025

10A. MODIFICATION OF CONTRACT/ORDER

NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X XThe above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning ____copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

ORDER NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

AMENDMENT 0003 IS AS FOLLOWS:

A. Incorporate Second Site Visit Sign in Sheet and Meeting Minutes (See Attached, 7 pages).

B. Incorporate Questions, Answers from 09.03.2025-Site Visit (See Attached, 2 pages) C. Incorporate Wage Grade KY20250101 dated 08/22/2025 (See Attached, 7 pages) No other changes at this time.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Kimberly Johnson Contract Specialist

(Signature of person authorized to sign)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED

By (Signature of Contracting Officer)

16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

15B10225PR000131

PRE-BID CONFERENCE MEETING MINUTES

15BFA025B00000040– Replace Roof Storm Damage

FCI Ashland - PROJECT 25Z1AJ1

1 | P a g e

DATE: Wednesday, September 3, 2025, at 9:00 A.M. local time Place: FPC Visiting Room

LUKE BONNER, CONTRACTING OFFICER

I. INTRODUCTIONS:

Round table introduction of all attendees:

GOVERNMENT REPRESENTATIVES

Luke Bonner, Contracting Officer, BFAS North Central Region Steven Holmes, Facilities Manager/COR, FCI Ashland Tyler Boggs, General Foreman, FCI Ashland Charlie Kitts, Construction Representative, Central Office

II. PURPOSE OF MEETING:

The purpose of this meeting is to familiarize the contractor with the unique circumstances and requirements surrounding a correctional setting. This meeting is also to explain the solicitation, as issued, and not to furnish additional information.

Nothing said here shall be interpreted as a change to the solicitation without the issuance of a formal amendment through the FAO Contracting Officer, Kimberly Johnson.

III. MINUTES:

Minutes will be recorded and distributed via www.sam.gov.

IV. SITE VISIT INFORMATION:

Walk to the selected site for Replace Roof Storm Damage immediately following the meeting.

V. FRONT COVER PAGE FORMS AND INSTRUCTIONS:

Special instructions pertaining to electronic bid submission (Far 14.302 And 14.304) *Submit: Bid Submission Cover Page, SF1442 Pages 1, 2, 4, & 49 thru 58, and the Bid Bond, shall be uploaded as a single Adobe PDF attachment at JEFS APP BOX see link below:

https://jefs.app.box.com/f/5517383a9d50478d9f59ce89d05d9eb9

Bids submitted by mail or hand carried will not be evaluated. It is the responsibility of the Bidder to confirm receipt of bids by contacting Kimberly Johnson by email knjohnson@bop.gov . All Bids received after the exact time specified for receipt shall be treated as late submissions and will not be considered except under facts and circumstances allowed by the Federal Acquisition Regulation (FAR).

Electronic bid submissions must include a scanned copy of the original bid guarantee. The original bid

2 | P a g e guarantee with “wet” signature, raised seal, and bid bond number (if applicable) must be mailed to the below address and received by the bid opening time and date:

Federal Bureau of Prisons U.S. Armed Forces Reserve Complex ATTN: Kimberly Johnson 346 Marine Forces Drive Grand Prairie, TX 75051

VI. TIME FRAMES AND LOCATION FOR SUBMISSION OF BIDS:

The deadline for submission of bids for this project is September 15, 2025, by 2:00 p.m. See Instruction to Bidders for electronic bid submission guidance.

VII. GENERAL TOPICS:

The following submission/completion items will be addressed:

1. From the solicitation, each bidder SHALL complete and submit the following forms, clauses, and statements with his/her bid. Failure to do so may cause your bid to be considered as non-responsive:

• BID SUBMISSION COVER PAGE: Please include Name of Company, UEI number, and Bid

Bond mail (Fedex, UPS, USPS) tracking number.

• STANDARD FORM 1442 Pages 1, 2, 4, and 49 thru 58: Please include DUNS number and Tax ID# and e-mail address where indicated in block 10 and complete blocks 14-20c. If your company has a “doing business as” name reflected in you SAM registration, include this name as well in Block 14. Ensure the address typed in block 14 matches the address in your SAM registration.

• PAST PERFORMANCE SUBMISSION: Please ensure the Cover letter is reviewed and complied with its entirety. References and banking submissions must be submitted in advance to the bid opening directly to knjohnson@bop.gov via email. CPARS entries are also acceptable.

• COMMODITY OR SERVICES SCHEDULE (PAGE 4): Complete the Unit Price (JB = job) and

Amount blocks (these amounts will be the same). Note: The amounts listed in this section should be the same as the amount listed in block 17 of the SF-1442.

• BID GUARANTEE: See Page 5 of the solicitation. A bid bond must be submitted in original (ink signatures) with your solicitation. The penal sum of the bond must be at least 20% of the bid price, not to exceed $3 million, whichever is less. A blank bid bond was included in the solicitation. The bid bond must be from a government approved surety. A list of approved sureties can be located on the Department of Treasury, Bureau of the Fiscal Service website.

3 | P a g e

Electronic bid submissions must include a scanned copy of the original bid guarantee. The original bid guarantee with “wet” signature, raised seal and bid bond number (if applicable) must be mailed to the below and received by the bid opening time and date:

Federal Bureau of Prisons U.S. Armed Forces Reserve Complex ATTN: Kimberly Johnson 346 Marine Forces Drive Grand Prairie, TX 75051

• REPRESENTATIONS AND CERTIFICATIONS: All contractors submitting a bid must be registered in the System for Award Management (SAM) at www.sam.gov with the North American Industry Classification Standard code (NAICS) 238160 which is applicable to this acquisition.

• FAR PROVISION 52.204-8: Pursuant to the section (b) (1) of this provision, provision 52.204-7 is included in this solicitation. Therefore, bidders should not mark either of the two options under section (b)(2). Leave these options unmarked.

• FAR PROVISION 52.204-24: Pursuant to the section of this provision, (d). Check either will or will not.

• •FAR PROVISION 52.204-29: Pursuant to the section of this provision, (d). Verify bid compliance.

• FAR PROVISION 52.209-7- Complete item (b) as applicable.

• FAR PROVISION 52.209-13: Pursuant to section (b) of this provision, Certification. Bidder shall check either (1) or (2).

• FAR PROVISION 52.229-11: Pursuant to section (d) of this provision, Certification. Bidder shall Complete item (d)(1) & (2) as applicable.

• AMENDMENTS: Amendments (if any) must be acknowledged and submitted with the bid by one of the methods as described in item eleven of the Standard Form 30.

2. Other general items to be addressed:

• DAVIS BACON ACT: This contract is subject to the Davis Bacon Act. Wage Decision

KY20250101 is applicable for this area. All applicable workers must be paid according to the terms of the wage decision.

• LICENSING AND PERMITS: All required licensing, and permits are required to be obtained by the contractor who receives contract award.

4 | P a g e

• MAGNITUDE: The magnitude of the project is between $1,000,000 and 5,000,000

• WORK HOURS: Work hours within the secure perimeter shall be between 7:30 am to 3:30 pm

Monday through Friday excluding weekends and federal holidays.

• COR: The Contracting Officer’s Representative (COR) is Mr. Steven Holmes, Facilities Manager at FCI Ashland.

• PERIOD OF PERFORMANCE: The completion period is 350 calendar days after issuance of notice to proceed.

• TIME EXTENSIONS: Time extensions for inclement weather will not be granted unless the weather is unusually severe and abnormal in comparison to prior years.

• LIQUIDATED DAMAGES: Liquidated damages for this project are in the amount of $1,446.68 per calendar day of delay after scheduled completion.

• PRE-CONSTRUCTION CONFERENCE: A Pre-Construction conference is required after the contract is awarded and will be scheduled accordingly.

• PROGRESS SCHEDULE: A copy of the progress schedule is to be provided to the Contracting

Officer and COR as soon as possible. Each time the progress schedule is changed, it must be provided to both the Contracting Officer and COR. It is suggested an updated document be provided by the Prime Contractor at the mandatory monthly progress meeting.

• PROGRESS MEETINGS: Progress meetings are mandatory and will be scheduled monthly.

• PAYMENT REQUESTS: Application for payments are to be submitted on AIA G702(Continuation) or the contractors own form as long as the information is similar to the G702. Contactors can get these forms from the following website www.aiabookstore.com

• QUESTIONS: Oral questions asked at Site Visit of a technical nature are not acceptable due to the possibility of misunderstanding or misinterpretation. All questions shall be sent in WORD FORMAT to Kimberly Johnson, FAO Contracting Officer, via email at knjohnson@bop.gov. In order to provide sufficient response time prior to the bid due date, the Government has establishing that questions be submitted no later than September 5, 2025, at 12:00 p.m.

• ACCESS TO SITE/PARKING OF VEHICLES: Only public parking will be available for contractor work vehicles.

• STORAGE OF MATERIALS: Storage of materials will be coordinated with the COR.

• CONTRACTOR TEMPORARY OFFICE: No temporary office space will be provided.

5 | P a g e

• INSPECTIONS: "Punch List" items generated by inspections will be corrected and discrepancy items re-inspected and approved before contract closure takes place. Should any work be covered without proper notification, the contractor shall uncover that work for inspection at his own expense.

LUKE BONNER, CONTRATING OFFICER:

3. SAFETY POINTS:

• The contractor is responsible for providing required protective gear to all contractor workers, should it be required. Contractor will ensure that all workers have proper safety gear at all times.

• Contractor is responsible for the prevention of accidents on the project site and has spill kit onsite and containment procedures. OSHA requirements will be adhered to.

• The Contractor will have a Safety Representative on site at all times during the completion of this project.

• Proper storage of any chemicals in lay down yard with SDS present.

LUKE BONNER, CONTRACTING OFFICER:

4. SECURITY

• ADVERSE WEATHER: Whenever adverse weather conditions or other institution emergency contingencies are in effect; contract workers will not be permitted passage into the secure institution. Should emergency conditions be implemented while contract workers are inside the secure perimeter, they will be required to secure their tools, remove vehicles and equipment, and leave the institution grounds until the emergency situation has been resolved.

Depending upon the nature of the emergency, this normally will not affect any construction outside of the secure perimeter. Contractor is reminded that fog days will be treated like rain days. The performance period of 350 days will allow adequate time to complete the job, and no consideration will be allowed for normal rain days and normal fog days. The normal rain, snow or fog days will be based on the average over the last ten (10) years for the local community.

• SECURITY CLEARANCES: Contract workers are subject to security investigative procedures.

Please refer to the contract for details. Please refer to Page 8 of the solicitation.

• EMPLOYEE IDENTIFICATION: Contractor personnel working on project site must bring valid photo identification to the institution each day. The identification will be surrendered upon entry to and returned upon exit from institution property.

6 | P a g e

• TOOL ACCOUNTABILITY: Strict accountability and control of all contractor tools and hazardous materials must be maintained at all times. All contractor tools to be used inside the secure perimeter must be inventoried and accounted for at the conclusion of the workday Contractor tools may not be stored on-site overnight. The contractor should provide for enough time at the conclusion of the workday for the return and accounting of all tools issued during the workday. Lost or missing tools must be reported to the COR the Captain immediately.

• ILLEGAL ITEMS ON FEDERAL PROPERTY: Firearms, ammunition, knives, other weapons, drugs, narcotics, and alcoholic beverages are not permitted inside/outside the secure perimeter or anywhere else on Federal property at any time. This includes the private vehicles of contract workers. Violators will be subject to criminal prosecution. All persons, vehicles, and equipment are subject to search by institution authorities at any time.

• NO CONTACT WITH INMATES: Contract workers are not to have any contact with inmates at any time. No photographs may be taken of inmates.

• CONTRACTOR EMPLOYEE WORK DRESS: Green or khaki‐colored clothing is not allowed, as inmates wear these colors.

• PHOTOGRAPHS: The institution’s Facilities Department maintains a digital camera that will be utilized by FBOP staff to document the project work. The Contractor may request copies of these photos and may request that photos be taken for specific conditions. Cellular telephones equipped with photographic capabilities are prohibited on the project construction site.

VIII. ADDITIONAL DISCUSSION:

Meeting minutes recorded by:

Luke Bonner, Contracting Officer FCI Ashland

NOTICE:

MEETING MINUTES ARE PROVIDED FOR INFORMATIONAL PURPOSES ONLY. THEY ARE NOT

INTENDED TO CHANGE ANY SPECIFICATIONS, TERMS OR CONDITIONS OF THE

SOLICITATION. ANY AND ALL CHANGES TO THE SOLICITATION SHALL BE ISSUED IN

SUBSEQUENT AMENDMENTS ISSUED BY THE CONTRACTING OFFICER ON A STANDARD

FORM 30 (SF-30).

LUCAS

BONNER

Digitally signed by LUCAS BONNER Date: 2025.09.03 11:10:20 -04'00'

FCI ASHLAND-REPLACE ROOF STORM DAMAGE

PROJECT # 25Z1AJ1 QUESTIONS AND ANSWERS SECOND SITE VISIT 09.03.2025

SOLICITATON #15BFA025B00000040

SUBMITTED BY RBT ROOFING

1. LWIC Removal and Insulation- Replacement The current specifications require an R-30 value with the LWIC remaining in place. However, maintaining the LWIC would necessitate raising skylights, HVAC units, gas lines, and wall heights. This would significantly increase costs and create substantial disruptions to building operations. Would it be acceptable to fully remove the LWIC and replace it with polyisocyanurate insulation to achieve the required R-30 rating? This method would simplify installation, reduce overall project cost, and minimize operational disruption.

Clarification: Refer to Addendum Section 3.0 (A,) (d)(iv)

2. Metals – Coping and Curb Flashing- If wall heights are increased, the existing coping and curbs will be impacted. The specified “handle with care” requirement may not be feasible, as the current snap-on coping system lacks fasteners and is difficult to remove without damage. Would the installation of new coping and curb flashing, in lieu of reusing the existing materials, be acceptable? This would ensure proper fit, long-term performance, and eliminate the risk of damage to existing components during removal.

Clarification: Refer to SOW, 3. (d,) (iii.)

3. Crane Access Area- Each of the two rear buildings has two HVAC units that will need to be raised to meet the manufacturer’s requirements. Is it possible to expand the available crane access area at the rear of these two buildings to facilitate this work more safely and efficiently?

Clarification: Refer to SOW, 4. (a), (i.)

4. Tapered LWIC Across Roof Areas -Can you confirm whether all roof areas for this project are to have fully tapered LWIC or if this requirement applies only to specific sections?

Clarification: All

5. Core Sampling Locations- Could you provide detailed information regarding the specific locations where core samples were taken as referenced in the latest updated documents? This will assist us in confirming existing conditions and planning accordingly.

Clarification: Refer to photos on page 41,42 and 43 of the photo sheets. This core is located on the rear flat portion of Appalachian I and Appalachian II housing units. Refer to photos on page 41 and 44. This core was taken at the base of the north parapet wall on the Food Service Building.

6. Temporary Air Requirements- Should contractors include provisions for temporary air conditioning in their bid while the HVAC units are being disconnected and reinstalled during roofing operations?

Clarification: Refer to SOW 4. (l.)

7. Electrical Line Adjustments- Given that the new roof system must meet current code requirements, all existing electrical lines will need to be raised. What is the required advance notice period for coordinating with facility personnel before performing this work?

Clarification: Refer to Addendum 3.0 E.

8. Interior Protection During Skylight Work- Should contractors include interior protection measures in their bids for areas located beneath skylights during replacement or modification work?

Clarification: Reference SOW 4. (f.)

"General Decision Number: KY20250101 08/22/2025

Superseded General Decision Number: KY20240101

State: Kentucky

Construction Type: Building

Counties: Boyd and Greenup Counties in Kentucky.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(1).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $17.75 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2025. | |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $13.30 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2025. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/03/2025 1 02/07/2025

2 03/07/2025 3 03/14/2025 4 04/04/2025 5 04/11/2025 6 05/30/2025 7 06/06/2025 8 07/18/2025 9 08/08/2025 10 08/15/2025 11 08/22/2025

ASBE0008-011 03/01/2025

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 35.23 23.04

BOIL0040-002 01/01/2025

Rates Fringes

BOILERMAKER......................$ 43.85 28.44

BRKY0007-001 06/01/2024

Rates Fringes

INDUSTRIAL: BRICKLAYER -

REFRACTORY BRICK REPLACEMENT.....$ 41.05 21.79

BRKY0018-001 06/01/2024

Rates Fringes

BRICKLAYER.......................$ 35.00 17.13

CARP0472-005 06/01/2025

Rates Fringes

CARPENTER........................$ 37.04 26.57

ELEC0317-005 06/02/2025

Rates Fringes

ELECTRICIAN......................$ 41.15 29.35

ENGI0181-054 06/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR

(Drill)..........................$ 40.65 19.60

ENGI0181-079 06/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR

(Loader).........................$ 40.65 19.60

ENGI0181-090 06/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR

(Crane)..........................$ 41.98 19.60

CRANES WITH BOOM 150 FEET & OVER, INCLUDING JIB, SHALL

RECEIVE $.50 ABOVE THE WAGE RATE.

ENGI0181-091 06/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR

(Forklift).......................$ 41.98 19.60

ENGI0181-093 06/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR

(Oiler)..........................$ 34.99 19.60

IRON0044-017 06/01/2025

Rates Fringes

IRONWORKER, ORNAMENTAL...........$ 37.77 23.90

* LABO1445-002 06/01/2025

Rates Fringes

LABORER (Power Tool Operator)....$ 31.35 23.18

* LABO1445-003 06/01/2025

Rates Fringes

LABORER (Mason Tender - Cement/Concrete).................$ 31.20 23.18

* LABO1445-004 06/01/2025

Rates Fringes

LABORER (Fire Watch).............$ 31.20 23.18

PAIN1072-002 12/01/2024

Rates Fringes

PAINTER (Brush and Roller).......$ 31.96 23.95

PLAS0132-015 06/01/2025

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 33.60 16.05

PLUM0248-002 06/01/2025

Rates Fringes

PIPEFITTER.......................$ 42.75 25.76

PLUM0452-015 11/01/2024

Rates Fringes

PLUMBER..........................$ 41.00 21.66

ROOF0042-008 08/01/2024

Rates Fringes

ROOFER...........................$ 33.00 18.86

SFKY0669-002 04/01/2025

Rates Fringes

SPRINKLER FITTER.................$ 44.15 26.08

SHEE0024-031 06/01/2023

Rates Fringes

SHEET METAL WORKER (Includes HVAC Duct Installation)..........$ 33.53 26.71

* UAVG-KY-0016 01/01/2025

Rates Fringes

BRICKLAYER: TILE FINISHER........$ 35.40 17.66

BRICKLAYER: TILE SETTER..........$ 35.11 18.26

* UAVG-KY-0018 01/01/2025

Rates Fringes

LABORER: Carpenter Tender.......$ 30.95 21.83

SUKY2015-040 06/02/2015

Rates Fringes

IRONWORKER, REINFORCING..........$ 28.38 16.89

IRONWORKER, STRUCTURAL...........$ 25.62 18.01

LABORER: Common or General......$ 23.27 13.67

LABORER: Mason Tender - Brick...$ 21.86 9.31

LABORER: Pipelayer..............$ 20.36 9.90

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 24.66 10.81

OPERATOR: Bulldozer.............$ 19.69 4.71

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 22.52 4.00

OPERATOR: Roller................$ 23.60 12.65

PAINTER: Spray..................$ 22.81 11.87

TRUCK DRIVER: Dump Truck........$ 24.35 14.59

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (iii)).

The body of each wage determination lists the classifications and wage rates that have been found to be prevailing for the type(s) of construction and geographic area covered by the wage determination. The classifications are listed in alphabetical order under rate identifiers indicating whether the particular rate is a union rate (current union negotiated rate), a survey rate, a weighted union average rate, a state adopted rate, or a supplemental classification rate.

Union Rate Identifiers

A four-letter identifier beginning with characters other than ""SU"", ""UAVG"", ?SA?, or ?SC? denotes that a union rate was prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2024. PLUM is an identifier of the union whose collectively bargained rate prevailed in the survey for this classification, which in this example would be Plumbers.

0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2024 in the example, is the effective date of the most current negotiated rate.

Union prevailing wage rates are updated to reflect all changes over time that are reported to WHD in the rates in the collective bargaining agreement (CBA) governing the classification.

Union Average Rate Identifiers

The UAVG identifier indicates that no single rate prevailed for those classifications, but that 100% of the data reported for the classifications reflected union rates. EXAMPLE:

UAVG-OH-0010 01/01/2024. UAVG indicates that the rate is a weighted union average rate. OH indicates the State of Ohio.

The next number, 0010 in the example, is an internal number used in producing the wage determination. The date, 01/01/2024 in the example, indicates the date the wage determination was updated to reflect the most current union average rate.

A UAVG rate will be updated once a year, usually in January, to reflect a weighted average of the current rates in the collective bargaining agreements on which the rate is based.

Survey Rate Identifiers

The ""SU"" identifier indicates that either a single non-union rate prevailed (as defined in 29 CFR 1.2) for this classification in the survey or that the rate was derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As a weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SUFL2022-007 6/27/2024. SU indicates the rate is a single non-union prevailing rate or a weighted average of survey data for that classification. FL indicates the State of Florida. 2022 is the year of the survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. The date, 6/27/2024 in the example, indicates the survey completion date for the classifications and rates under that identifier.

?SU? wage rates typically remain in effect until a new survey is conducted. However, the Wage and Hour Division (WHD) has the discretion to update such rates under 29 CFR 1.6(c)(1).

State Adopted Rate Identifiers

The ""SA"" identifier indicates that the classifications and prevailing wage rates set by a state (or local) government were adopted under 29 C.F.R 1.3(g)-(h). Example: SAME2023-007 01/03/2024. SA reflects that the rates are state adopted. ME refers to the State of Maine. 2023 is the year during which the state completed the survey on which the listed classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination.

The date, 01/03/2024 in the example, reflects the date on which the classifications and rates under the ?SA? identifier took effect under state law in the state from which the rates were adopted.

WAGE DETERMINATION APPEALS PROCESS

1) Has there been an initial decision in the matter? This can be:

a) a survey underlying a wage determination

b) an existing published wage determination

c) an initial WHD letter setting forth a position on a wage determination matter

d) an initial conformance (additional classification and rate) determination

On survey related matters, initial contact, including requests for summaries of surveys, should be directed to the WHD Branch of Wage Surveys. Requests can be submitted via email to davisbaconinfo@dol.gov or by mail to:

Branch of Wage Surveys Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

Regarding any other wage determination matter such as conformance decisions, requests for initial decisions should be directed to the WHD Branch of Construction Wage Determinations.

Requests can be submitted via email to BCWD-Office@dol.gov or by mail to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2) If an initial decision has been issued, then any interested party (those affected by the action) that disagrees with the decision can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Requests for review and reconsideration can be submitted via email to dba.reconsideration@dol.gov or by mail to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210.

END OF GENERAL DECISION"