S01 Amendment 003 - Attachment 3 - Revised Bid Schedule.pdf
PDF 143 KB Posted
- Attached to
- BARATARIA BASIN LANDBRIDGE CONSTRUCTION PROJECT - BA-27 Repair - LAFOURCHE AND JEFFERSON PARISHES, LOUISIANA
- Solicitation number
- 12FPC321B0006
About this file
This document contains an invitation for bids for a federal construction project. The Barataria Basin Landbridge Construction Project - BA-27 Repair located in Lafourche and Jefferson Parishes, Louisiana requires mobilization, construction surveys, excavation, geotextiles, lightweight aggregate, articulating concrete blocks, and lighted buoys. Bids are due by April 30, 2021 at 12 pm Central time and will be opened via teleconference. A pre-bid site visit is scheduled for April 13, 2021 at 9:30 am Central time at the Clovelly Boat Launch in Cut Off, Louisiana. The magnitude of construction is between $1,000,000 and $5,000,000 and the performance period is 124 days after notice to proceed. Davis Bacon wage rates apply. This acquisition is set aside for small businesses.
View the file
Other files
Show all 21
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Solicitation No. 12FPC321B0006
Updated thru FAC 2021-03 dated Feb 16, 2021 Page 5 of 45
Amendment 003
PART I – THE SCHEDULE
Barataria Basin Landbridge Project - BA-27 Repair
LaFourche and Jefferson Parishes, LA
B - SUPPLIES OR SERVICES AND PRICES
This solicitation requires bidding on all line items, failure to do so will disqualify the bid.
Item No. Supplies/Services Spec.
No.
Quantity Unit Unit Price
Amount
Mobilization/Demobilization
LS
XXXXXX
Construction Surveys
Excavation, Flotation/Access
Geotextile
9,216 *
SY
Lightweight Aggregate
1710 *
CY
Articulating Concrete Blocks
768 *
LF
Lighted Buoys
9 *
EA
TOTAL BID: $____________________________
SUBMITTED BY:________________________________________ DUNS#____________________
52.211-18 Variation in Estimated Quantity. (Apr 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.
(End of clause)
Quantities marked with an * above are estimated quantities and the clause FAR 52.211-18 Variation in Estimated Quantity, applies.
ONE AWARD FOR THE AGGREGATE OF ALL ITEMS WILL BE MADE AS A RESULT OF THIS SOLICITATION
File details come from the government source that posted it. Updated .