page 18 corrected.pdf

12445121R0001 Culvert Installation/Road Maintenance

National Forests and Grasslands in Texas (Corrected) Page 18 of 49

SECTION F - DELIVERIES OR PERFORMANCE

FAR 52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the date indicated in individual task orders. The time stated for completion shall include final cleanup of the premises.

(End of clause)

FAR 52.242-14 Suspension of Work. (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed -

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

AGAR 452.211-74 PERIOD OF PERFORMANCE (FEB 88)

This contract is an indefinite-delivery indefinite quantity contract for a basic period of performance from date of award through March 31, 2022, plus two additional one-year option periods. Submission of an offer for the basic contract period constitutes an offer to perform in the Option Periods, if exercised.

Period of Performance Base - Date of Award through March 31, 2022 Option 1 - April 1, 2022, through March 31, 2023 Option 2 - April 1, 2023, through March 31, 2024