1202SC24Q2712 - Request for Quote - SF1449 Continuation Sheet.pdf

Solicitation No. 1202SC24Q2712 USDA Forest Service Salt Fog Prohesion Spray Testing

REQUEST FOR QUOTE - 1202SC24Q2712

SF1449 CONTINUATION SHEET

SECTION B

B-1 STATEMENT OF WORK:

Fire and Aviation Management and the National Technology and Development Program are seeking a corrosion test laboratory to conduct modified salt fog testing protocol in accordance with ASTM G85 and B117. This method would be used to help guide the testing using Long-Term Fire Retardants in place of the 5% Sodium Chloride Solution using Annex 5 of ASTM G85 as general cycle guidance. The intent is to understand the different corrosion that is experienced when the different products are exposed to the environment described in the ASTM, Annex 5.

The results of this work will help guide the use of long-term retardants and may be added in as a performance standard for future wildland fire chemical qualifications. Long-term retardants have thickeners added into their formula to improve performance – so the chambers used to perform this testing will likely require modifications to spray these products in a uniform manner.

Background:

All wildland fire chemicals currently undergo a 90-day uniform corrosion test that documents weight loss corrosion in a static environment. New findings from the field suggest a need to test these products in other ways to better understand impacts to aircraft operating in the environment of wildland firefighting. A static environment may not represent aircraft exposures to certain alloys, which is where this testing will provide results, insight, and documentation.

Requirements:

All testing being requested will be as closely conforming to ASTM B117 and G85 as possible using long-term retardants in place of the specified salt mixtures. This chamber will likely require modifications to pump and spray the gum-thickened products. These products range from 150 – 500cP. The testing will include the 8 long-term retardants listed in Table 1-1.

Table 1-1 Long-Term Retardants for Corrosion Testing Test Material

# Material Type Mix ratio Temperature

01 Phos-Chek MVP-Fx 0.96 lbs/gal

Tested at 95F per ASTM B117

02 Phos-Chek LCE20-Fx 5.2:1 03 Phos-Chek LC95A-R 5.5:1 04 Phos-Chek LC95A-Fx 5.5:1 05 Fortress FR-100 1.68 lbs/gal 06 Fortress FR-200 2.4:1 07 Fortress FR-105 1.68 lbs/gal 08 Fortress Qela 1.02 lbs/gal

A suitable Salt-Fog chamber that meets all necessary requirements of the guidance ASTMs shall be used. Each long-term retardant shall be run for the course of 7-days (168 hours) using the Annex 5 of

ASTM G85. This has a “spray” and “dry” cycle that could better replicate field applications than a constant spray. Each new cycle of a new retardant product shall incorporate a thorough cleaning of the spray chamber prior to starting a new product test cycle. A list of the test samples is identified in the following table and shall be tested using three (3) samples per material type:

Table 1-2 Material for Corrosion Testing

Test Material # Material Type Thickness (in) Specification

01 2014-T6 Bare Sheet 0.050 – 0.125 AMS 4029 02 2024-T3 Bare Sheet 0.050 – 0.125 AMS 4037 03 2024-T62 Bare Sheet <1> 0.050 – 0.125 AMS-QQ-A-250/4 04 6061-T6 Bare Sheet 0.050 – 0.125 AMS 4025 05 7075-T6 Bare Sheet 0.050 – 0.125 AMS 4045

<1> 2024-T62 material is unique in that it is not a mill supplied temper. It is procured in the -0 or -F temper from the supplier allowing the receiver to form parts with it. After forming the parts, the receiver is responsible for heat treating the material to the final temper 2024-T62. For this test plan, the 03 material must be procured in the 2024-0 condition and then heat treated to 2024-T62 temper (Heat treatment specification is AMS 2770H).

These samples shall have final metal surface roughness of 63 RHR or better, by polishing as necessary; degreasing the specimen after polishing is complete or in conformance to the ASTM preparation guidance. The four edges and the bottom of the specimen should be covered with a masking material to limit corrosion to the top test surface. A clear or transparent electroplating tape can be used on the lower surface and a clear or transparent painted on masking can be used along the edges. The test lab may recommend a different process based on their experience conducting these types of test in their laboratory.

The USFS will provide the retardants in sufficient quantities to support the testing for this program with the expected test duration of seven (7) days for each product. Recycling and reuse of the retardant in the Fog Chamber is acceptable during the testing.

• As necessary, the solution used in the fog chamber will be replaced with a new batch of retardant.

• The baseline salt solution shall be prepared per requirements in ASTM B117, Section 8.1.

• pH should be checked and recorded at time of preparation and during the tests. Each time a new batch of solution is introduced into the test, both the pH of the removed solution and the new solution should be recorded.

All necessary quality control samples shall be tested for each of the eight (8) long-term retardants, as well as a cycle using the standard 5% NaCl solution on the same 7-day (168-hour) length cycle. All testing should be performed to the best practices for handling metallurgical testing and test specimen cleaning to ASTM G1. Photos shall be taken before and after environmental exposure noting which samples were tested in each photograph. Any significant deviations will be noted in the report dialogue for record keeping purposes.

At the end of each cycle each of the following shall be measured and recorded:

• the corrosion rates (weight loss calculated to mils per year)

• the number of pits and pitting depths shall be measured in accordance with MIL-STD- 5541 and (as applicable the ASTMs).

• Any metallurgical observations shall also be noted and comparisons given across all long-term retardant products tested.

Responsibilities:

• The test laboratory selected shall have the capability to modify their existing equipment to test and analyze thickened long-term retardant products.

• The test lab is responsible for procuring all materials needed for testing to include Corrosion Coupons (estimated 96ea) and additional coupons and/or assemblies as required. The long-term retardants will be provided by the Forest Service

• All materials are to be bare and not clad material.

• All materials procured must be accompanied by the certification paperwork generated by the mill producing the original lot of material.

• The test lab is responsible for the heat treatment of the 2024-T62 material. There will be no forming required for the material. The heat treatment is to be accomplish per AMS 2770H.

If the laboratory does not have heat treatment capabilities, then the material must be sent to a subcontractor in the aerospace industry for heat treatment.

Government Furnished:

The government will provide all long-term retardants and associated SDS files that are required to perform this testing. The Technology and Development Program will ship these products to the contractors test site for testing. Disposal will be the responsibility of the contractor.

Deliverables / Schedule:

The key deliverables of this testing will be the initial and final reports documenting the performance of all products. Corrosion and pitting calculations and measurements shall be listed for each product in a table with any additional remarks or observations. All data and results generated will become property of the Government.

REQUEST FOR QUOTE - 1202SC24Q2712

SF1449 CONTINUATION SHEET

Key Deliverables Item No. Deliverable Objective Due 1 Schedule of Testing and modified test chamber

A test schedule will be developed and issued to the US Forest Service projecting the expected timeline for testing all products.

No later than 30 calendar days after contract award

2 Initial Report An initial report will be issued to the US Forest Service documenting what modifications are required to existing equipment and the make and model or recommended chamber(s) that would be able to accommodate this testing.

Within 15 working days from when long-term retardant samples are delivered to the testing site. This may be extended as method development optimization is the priority.

3 Final Report Report documenting all findings of corrosion rates and pitting in accordance with the guiding methods. Results section of the report shall also document the recommended salt spray chambers (with required modifications) to perform this testing effectively with long-term retardant products.

No later than August 30th, The contractor shall provide final report to include all quality control data and sample specimen traceability paperwork as well as the required pre- and post-exposure photos. An example of the report table is as follows (additional data can be included as this is only an example):

Test Alloy #1 Test Alloy #2 Test Alloy #3

Test Material

Corrosion Coupon #

Corrosion rate Pitting pass/fail

Corrosion rate Pitting pass/fail

Corrosion rate Pitting pass/fail

R-0001

1 mils/year depth pass mils/year depth pass mils/year depth pass

R-0002

1 mils/year depth pass mils/year depth pass mils/year depth pass

If pass/fail determinations are listed, the referenced document shall be provided that lists the performance criteria of the standard 5% NaCl solution.

Travel:

No travel is authorized as part of this contract.

Contractor’s Key Personnel:

A facility with professional technical staff and metallurgists capable of performing testing to the listed ASTMs and MIL specification.

Security Requirements:

The products distributed shall only be used for the purposes of this testing and disposed of after work is completed.

Data Rights:

**All data and results generated will become property of the Government.

Section 508 – Electronic and Information Technology Standards:

Not applicable.

Invoicing:

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform (IPP) System.

"Payment request" means any request for contractual or invoice payment by the Vendor. To constitute a proper invoice, the payment request shall comply with the requirements identified in the applicable Prompt Payment clause included in this BPA, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items. The IPP website address is: https://www.ipp.gov

The Vendor shall also submit an electronic copy of the IPP invoice to the Contracting Officer at matthew.cox2@usda.gov once the invoice has been submitted to IPP. Failure to e-mail the invoice may cause significant delay or possible rejection of payment request. The Vendor must use the IPP website to register access and use IPP for submitting requests for payment per the following website: Vendor Enrollment- Invoice Processing Platform (ipp.gov). Vendor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email IPPCustomerSupport@fiscal.treasury.gov or phone

(866) 973-3131 https://www.ipp.gov/ mailto:matthew.cox2@usda.gov https://www.ipp.gov/vendors/enrollment-vendors https://www.ipp.gov/vendors/enrollment-vendors mailto:ippcustomersupport@fiscal.treasury.gov

Contract Administration:

Any contractual issues, which may arise during the life of this contract, shall be handled in conformance with specific public laws and regulations (e.g., Federal Acquisition Regulation). Only the Contracting Officer is authorized to formally resolve such problems. Therefore, the Contracting Officer’s Representative and the Contractor are hereby directed to bring all such contractual problems to the immediate attention of the Contracting Officer.

B-2 SCHEDULE OF ITEMS:

CLIN DESCRIPTION UNIT QTY TOTAL PRICE

Services for Salt Fog Prohesion Spray Testing to ASTM G85 and B117 using long-term fire retardants.

Job

TOTAL AMOUNT: $_______________

SECTION C - CONTRACT CLAUSES

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

As prescribed in 52.107(b), insert the following clause:

Clauses Incorporated By Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR) Clauses: https://www.acquisition.gov/browse/index/far (FAR clauses begin with 52)

Department of Agriculture Acquisition Regulation (AGAR) Clauses:

https://www.acquisition.gov/agar (AGAR clauses begin with 452)

Deviations to clauses may be viewed at:

https://www.dm.usda.gov/procurement/policy/FARClassDeviations.htm

52.202-1 Definitions (JUN 2020) 52.203-3 Gratuities (APR 1984) 52.204-12 Unique Entity Identifier Maintenance (OCT 2016) 52.204-13 System for Award Management Maintenance (OCT 2018) 52.204-18 Commercial and Government Entity Code Maintenance (AUG 2020) 52.204-19 Incorporation by Reference of Representations and Certifications (DEC 2014) 52.212-4 Contract Terms and Conditions—Commercial Products and Commercial Services

(NOV 2023)

52.226-7 Drug-Free Workplace (MAY 2024) 52.229-3 Federal, State, and local taxes (FEB 2013) 52.232-1 Payments (APR1984) 52.232-8 Discounts for Prompt Payment (FEB 2002) 52.232-11 Extras (APR 1984) 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) 52.233-1 Disputes (MAY 2014) 52.253-1 Computer Generated Forms (JAN 1991)

(End Clause)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—

Commercial Products and Commercial Services (MAY 2024)

As prescribed in 12.301(b)(4), insert the following clause:

Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Products and Commercial Services (MAY 2024)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to 15 implement https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/agar https://www.dm.usda.gov/procurement/policy/FARClassDeviations.htm provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) ( 41 U.S.C. 4704 and 10 U.S.C. 4655).

__(2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509)).

__(3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

XX (4) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

XX (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__(6) [Reserved].

__(7) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/4655 https://www.acquisition.gov/far/part-52#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_203_15 https://www.acquisition.gov/far/part-52#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/part-3#FAR_3_900 https://www.acquisition.gov/far/part-52#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_204_14

__(8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

XX (9) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

__(10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (DEC 2023) ( Pub. L.

115–390, title II).

__(11) (i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (DEC 2023) ( Pub. L. 115–390, title II).

__(ii) Alternate I (DEC 2023) of 52.204–30.

__ (12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) ( 31 U.S.C. 6101 note).

__(13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) ( 41 U.S.C. 2313).

__(14) [Reserved].

__(15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) ( 15 U.S.C. 657a).

__(16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a).

__(17) [Reserved]

XX (18) (i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__(ii) Alternate I (MAR 2020) of 52.219-6.

__(19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__(ii) Alternate I (MAR 2020) of 52.219-7.

__(20) 52.219-8, Utilization of Small Business Concerns (FEB 2024) ( 15 U.S.C. 637(d)(2) and (3)).

__(21) (i) 52.219-9, Small Business Subcontracting Plan (SEP 2023) ( 15 U.S.C. 637(d)(4)).

__(ii) Alternate I (NOV 2016) of 52.219-9.

__(iii) Alternate II (NOV 2016) of 52.219-9.

__(iv) Alternate III (JUN 2020) of 52.219-9.

https://www.acquisition.gov/far/part-52#FAR_52_204_15 https://www.acquisition.gov/far/part-52#FAR_52_204_27 https://www.acquisition.gov/far/part-52#FAR_52_204_28 https://www.govinfo.gov/link/plaw/115/public/390 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_204_30 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_6 https://www.acquisition.gov/far/part-52#FAR_52_219_7 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_7 https://www.acquisition.gov/far/part-52#FAR_52_219_8 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9

__(v) Alternate IV (SEP 2023) of 52.219-9.

__(22) (i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) ( 15 U.S.C. 644(r)).

__(ii) Alternate I (MAR 2020) of 52.219-13.

__(23) 52.219-14, Limitations on Subcontracting (OCT 2022) ( 15 U.S.C. 637s).

__(24) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) ( 15 U.S.C. 637(d)(4)(F)(i)).

__(25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran- Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (FEB 2024) ( 15 U.S.C. 657f).

XX (26) (i) 52.219-28, Post Award Small Business Program Rerepresentation (FEB 2024) ( 15 U.S.C. 632(a)(2)).

__(ii) Alternate I (MAR 2020) of 52.219-28.

__(27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (OCT 2022) ( 15 U.S.C. 637(m)).

__(28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) ( 15 U.S.C. 637(m)).

__(29) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) ( 15 U.S.C. 644(r)).

XX (30) 52.219-33, Nonmanufacturer Rule (SEP 2021) ( 15U.S.C. 637(a)(17)).

XX (31) 52.222-3, Convict Labor (JUN 2003) (E.O.11755).

XX (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (FEB 2024).

XX (33) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

XX (34) (i) 52.222-26, Equal Opportunity (SEP 2016) (E.O.11246).

__(ii) Alternate I (FEB 1999) of 52.222-26.

__ (35) (i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

__(ii) Alternate I (JUL 2014) of 52.222-35.

XX (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_13 https://www.acquisition.gov/far/part-52#FAR_52_219_14 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_16 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_27 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_28 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_28 https://www.acquisition.gov/far/part-52#FAR_52_219_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_32 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec644.htm https://www.acquisition.gov/far/part-52#FAR_52_219_33 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec637.htm https://www.acquisition.gov/far/part-52#FAR_52_222_3 https://www.acquisition.gov/far/part-52#FAR_52_222_19 https://www.acquisition.gov/far/part-52#FAR_52_222_21 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_35 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_35 https://www.acquisition.gov/far/part-52#FAR_52_222_36 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title29-section793&num=0&edition=prelim

__(ii) Alternate I (JUL 2014) of 52.222-36.

__ (37) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

XX (39) (i) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O. 13627).

__(ii) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

__(40) 52.222-54, Employment Eligibility Verification (MAY 2022) (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__(41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__(ii) Alternate I (MAY 2008) of 52.223-9 ( 42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__(42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) (E.O. 13693).

__(43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (MAY 2024) (E.O. 13693).

__(44) 52.223-20, Aerosols (MAY 2024) (E.O. 13693).

__(45) 52.223-21, Foams (May 2024) (E.O. 13693).

__(46) 52.223-23, Sustainable Products and Services (May 2024) ( E.O. 14057, 7 U.S.C. 8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l)

__(47) (i) 52.224-3 Privacy Training (JAN 2017) (5 U.S.C. 552 a).

__(ii) Alternate I (JAN 2017) of 52.224-3.

XX (48) (i) 52.225-1, Buy American-Supplies (OCT 2022) ( 41 U.S.C. chapter 83).

__(ii) Alternate I (OCT 2022) of 52.225-1.

__(49) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109- 283, 110-138, 112-41, 112-42, and 112-43.

https://www.acquisition.gov/far/part-52#FAR_52_222_36 https://www.acquisition.gov/far/part-52#FAR_52_222_37 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_40 https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.acquisition.gov/far/part-22#FAR_22_1803 https://www.acquisition.gov/far/part-52#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_223_11 https://www.acquisition.gov/far/part-52#FAR_52_223_12 https://www.acquisition.gov/far/part-52#FAR_52_223_20 https://www.acquisition.gov/far/part-52#FAR_52_223_21 https://www.acquisition.gov/far/part-52#FAR_52_224_3 https://www.acquisition.gov/far/part-52#FAR_52_224_3 https://www.acquisition.gov/far/part-52#FAR_52_225_1 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_225_1 https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.govinfo.gov/link/uscode/19/3301 https://www.govinfo.gov/link/uscode/19/3301 https://www.govinfo.gov/link/uscode/19/2112 https://www.govinfo.gov/link/uscode/19/3805 https://www.govinfo.gov/link/uscode/19/4001

__(ii) Alternate I [Reserved].

__(iii) Alternate II (DEC 2022) of 52.225-3.

__(iv) Alternate III (FEB 2024) of 52.225-3.

__(v) Alternate IV (Oct 2022) of 52.225-3.

__(50) 52.225-5, Trade Agreements (NOV 2023) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

XX (51) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__(52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

__(53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) ( 42 U.S.C. 5150).

__(54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov2007) ( 42 U.S.C. 5150).

XX (55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) (E.O. 13513).

__(56) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

__(57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

__(58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

XX (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (OCT2018) ( 31 U.S.C. 3332).

__(60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) ( 31 U.S.C. 3332).

__(61) 52.232-36, Payment by Third Party (MAY 2014) ( 31 U.S.C. 3332).

__(62) 52.239-1, Privacy or Security Safeguards (AUG 1996) ( 5 U.S.C. 552a).

__(63) 52.242-5, Payments to Small Business Subcontractors (JAN 2017) ( 15 U.S.C. 637(d)(13)).

__(64) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631).

__(ii) Alternate I (APR 2003) of 52.247-64.

https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.acquisition.gov/far/part-52#FAR_52_225_5 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section2501&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section3301&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_225_13 https://www.acquisition.gov/far/part-52#FAR_52_225_26 https://www.acquisition.gov/far/part-52#FAR_52_226_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_226_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_229_12 https://www.acquisition.gov/far/part-52#FAR_52_232_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/3805 https://www.acquisition.gov/far/part-52#FAR_52_232_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/3805 https://www.acquisition.gov/far/part-52#FAR_52_232_33 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_232_34 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_232_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_239_1 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title5-section552a&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_242_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_247_64 https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_247_64

__(iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

XX (1) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter67).

XX (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__(3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) ( 29 U.S.C. 206 and 41 U.S.C. chapter 67).

__(4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

__(5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

__(6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

__(7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

XX (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

__(9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) ( 42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

https://www.acquisition.gov/far/part-52#FAR_52_247_64 https://www.acquisition.gov/far/part-52#FAR_52_222_41 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_42 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_43 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_44 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_51 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_53 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_55 https://www.acquisition.gov/far/part-52#FAR_52_222_62 https://www.acquisition.gov/far/part-52#FAR_52_226_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-2#FAR_2_101 https://www.acquisition.gov/far/part-52#FAR_52_215_2 https://www.acquisition.gov/far/part-4#FAR_Subpart_4_7

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii) (A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (DEC 2023) ( Pub. L. 115–390, title II).

(B) Alternate I (DEC 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (FEB 2024) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(x) 52.222-26, Equal Opportunity (SEP 2015) (E.O.11246).

(xi) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

https://www.acquisition.gov/far/part-52#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/part-52#FAR_52_203_19 https://www.acquisition.gov/far/part-52#FAR_52_204_23 https://www.acquisition.gov/far/part-52#FAR_52_204_25 https://www.acquisition.gov/far/part-52#FAR_52_204_27 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_219_8 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637&num=0&edition=prelim https://www.acquisition.gov/far/part-19#FAR_19_702 https://www.acquisition.gov/far/part-52#FAR_52_219_8 https://www.acquisition.gov/far/part-52#FAR_52_222_21 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_35 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_37

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xv) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter 67).

(xvi) (A) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O 13627).

(B) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

(xix) 52.222-54, Employment Eligibility Verification (MAY 2022) (E.O. 12989).

(xx) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

(xxi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

(xxii) (A) 52.224-3, Privacy Training (Jan 2017) ( 5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) ( 42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxvi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause) https://www.acquisition.gov/far/part-52#FAR_52_222_40 https://www.acquisition.gov/far/part-52#FAR_52_222_40 https://www.acquisition.gov/far/part-52#FAR_52_222_41 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-chapter67-front&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_51 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_53 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.acquisition.gov/far/part-52#FAR_52_222_55 https://www.acquisition.gov/far/part-52#FAR_52_222_62 https://www.acquisition.gov/far/part-52#FAR_52_224_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_224_3 https://www.acquisition.gov/far/part-52#FAR_52_225_26 https://www.acquisition.gov/far/part-52#FAR_52_226_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_226_6 https://www.acquisition.gov/far/part-52#FAR_52_232_40 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/10/3801 https://www.acquisition.gov/far/part-52#FAR_52_232_40 https://www.acquisition.gov/far/part-52#FAR_52_247_64 https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm https://www.acquisition.gov/far/part-52#FAR_52_247_64

52.252-6 Authorized Deviations in Clauses (NOV 2020)

As prescribed in 52.107(f), insert the following clause in solicitations and contracts that include any FAR or supplemental clause with an authorized deviation. Whenever any FAR or supplemental clause is used with an authorized deviation, the contracting officer shall identify it by the same number, title, and date assigned to the clause when it is used without deviation, include regulation name for any supplemental clause, except that the contracting officer shall insert "(DEVIATION)" after the date of the clause.

Authorized Deviations in Clauses (Nov 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Agriculture Acquisition Regulation (48 CFR __4_) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

(End of Clause)

452.204-70 Modification for Contract Closeout (OCT 2021)

Upon contract closeout for contracts utilizing Simplified Acquisition Procedures (SAP) according to FAR 13:

(a) If unobligated funds in the amount of $1000 or less remain on the contract, the Contracting Officer (CO) shall issue a unilateral modification for deobligation. The contractor will receive a copy of the modification but will not be required to provide a signature. The CO shall immediately proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(b) If unobligated funds of more than $1000 remain on the contract, the CO shall issue a bilateral modification for deobligation. The contractor will receive a copy of the modification and will be required to provide a signature. (The CO may also request a Release of Claims be completed by the contractor, although not required for contract and orders using SAP procedures.) If the bilateral modification and Release of Claims are not returned to the CO within 60 days, the CO shall release the modification as unilateral and proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(End of Clause)

SECTION D - EXHIBITS AND ATTACHMENTS

The following attachment(s) are a part of this Purchase Order (see separate document(s)).

Attachment Number

Attachment Title Number of Pages

1 1202SC24Q2712 Standard Practice for Operating Salt Spray (Fog) Apparatus – ASTM B117-19

2 1202SC24Q2712 Standard Practice for Modified Salt Spray (Fog) Testing - ASTM G85-19

3 1202SC24Q2712 Chemical Conversion Coatings on Aluminum and Aluminum Alloys – Spec Sheet - MIL-DTL-5541F

4 Service Contract Act (SCA) Wage Determination (To be Determined based off of Contractor work location).

TBD

*5 1202SC24Q2712 Past Performance Questionnaire 5

*6 1202SC24Q2712 Offerors Information 1

* Not made part of the awarded contract.

**NOTE: Service Contract Labor Standards Statute: If this is a contract in excess of $2,500, the Contractor is required to pay certain minimum wages to all service employees working under this contract. These required minimum wages are stated in the Register of Wage Determinations under the Service Contract Labor Standards statute for county of the contractors work location. This Wage Determination for the Contractor’s location will be included and made part of the terms and conditions in the resulting contract.

SECTION E - SOLICITATION PROVISIONS

52.252-1 Solicitation Provisions Incorporated by Reference (FEB 1998)

As prescribed in 52.107(a), insert the following provision:

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR) Clauses:

https://www.acquisition.gov/browse/index/far (FAR clauses begin with 52)

Department of Agriculture Acquisition Regulation (AGAR) Clauses:

https://www.acquisition.gov/agar (AGAR…