UTAH COUNTY

PUBLIC WORKS DEPARTMENT

2855 South State Street

Provo, Utah 84606

(801) 851-8600

INVITATION TO BID

For

Utah County

Spanish Fork River Park

Pipe Fence

ITB # 2026-8

CLOSING DATE

FOR RECEIPT OF BIDS:

TIME:

PLACE:

Tuesday, May 19, 2026 at 3:00 pm

3:00 p.m. (Mountain Time)

Proposals are to be submitted through the State U3P website, using the Bonfire (EUNA) eProcurement platform.

NOTE: The Contractor is responsible for reading the contents of this bid, including but not limited to, the Scope of

Work, General Requirements, Specifications, the Drawings, and Agreement. The Contractor is also responsible to visit the work sites before presenting a bid.

Privacy Notice: Pursuant to Section 63A-19-402 of Utah Code, personal data collected in documents that would be classified as a public record may be made available to the public as provided by Section 63G-2-201.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 2

TABLE OF CONTENTS

INVITATION TO BID

Intent

Procedure

Rules of Procurement

Bid Organization

Proprietary Information

Questions and Clarifications

Acceptance of Bid

Disqualification of Bid

Disposition of Bids

Interpretation of ITB

Required Experience

Evaluation Criteria

General

Bonds

GENERAL REQUIREMENTS

Alterations of Plans or Character of Work

Brand Name

Change Order

Completion Date

Liquidated Damages

Cooperation

Data Privacy

Delivery/Shipping

Inspection

Insurance

Keys

Legal

License

Payment

Safety Requirements

Sales Tax

Supervision of Work

Surveying

Utilities

Statement of Applicable Standards and Specifications

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 3

Specifications Measurement and Payment

General

General Conditions

Mobilization and Demobilization

Fence removal

2-3/8” Drill Pipe Fence……………….……………………………………………... 18

16’ Gate

Park Entrance Gate

Park Entrance Bow

PLANS “Spanish Fork River Park Pipe Fence” (the Drawings) ................... Attachment A

CONTRACTOR’S BID SCHEDULE ............................................................ Attachment B

CONTRACTOR INFORMATION FORM ............................................................ Exhibit A

CERTIFICATE OF NON-COLLUSION ............................................................... Exhibit B

SAMPLE AGREEMENT WITH STANDARD TERMS & CONDITIONS ......... Exhibit C

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 4

1. INVITATION TO BID

1.1 INTENT

Through this Invitation to Bid (ITB), Utah County intends to select a qualified contractor to provide for the construction and completion of improvements to Spanish Fork River

Park located up Spanish Fork Canyon that meet in every detail, the specifications and

Spanish Fork River Park Pipe Fence plans, herein referred to as (the Drawings), included in or referenced in this ITB.

The Contractor shall furnish all labor, materials, transportation, tools, equipment, supplies, disposal fees, and other costs required to complete the work in accordance with the terms hereof.

Pursuant to this ITB, an agreement will be executed, a sample copy of which is attached as Exhibit C. The County will not entertain changes to its Standard Terms and

Conditions.

1.2 PROCEDURE

The procedure for response to this ITB, evaluation of bids, and selection of a Contractor is as follows:

A. Interested entities will prepare and submit their bids prior to the specified Closing

Date for Receipt of Bids.

B. Utah County and/or its representatives will evaluate all submitted bids to determine acceptance or rejection of the bids.

C. The selected bidder(s) will be required to sign an agreement, a sample of which is included as Exhibit C.

1.3 RULES OF PROCUREMENT

A. This procurement shall conform to and is governed by The Utah County Division of

Purchasing, Procurement Rules and Regulations.

B. For this procurement, all bids must be submitted in the bid format outlined herein.

C. All prospective bidders must meet the required criteria as of the date of submission.

D. Respondents must provide all information requested in the Contractor Information

Form.

E. Utah County has established certain requirements with respect to bids to be submitted by respondents. The use of "shall", "must", or "will", in this ITB indicates a requirement or condition from which a material deviation will not be approved by

Utah County.

1.4 BID ORGANIZATION

A. Each respondent must submit its proposal digitally through the U3P website using the

State of Utah’s Bonfire (EUNA) account. The proposal must be submitted by

Tuesday, May 19, 2026, at 3:00pm.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 5

B. Please submit with the bid the documents listed below. Before a contract can be awarded, the selected contractor must provide all the documents listed below.

1. Completed Contractor’s Cost Proposal (Attachment B).

2. Completed Contractor Information Form (Exhibit A).

3. Completed Certificate of Non-Collusion (Exhibit B).

4. A copy of the bidder’s current local business license.

5. A copy of the bidder’s current Contractor License issued by the Utah Department of Commerce, Division of Occupational and Professional Licensing.

6. Proof of required insurance.

7. Documentation from the County Treasurer of the bidder's county showing that bidder is current on its personal property taxes.

8. Documentation of minimum of three years’ experience.

9. List of three similar projects, including contracting agency and contact information.

1.5 PROPRIETARY INFORMATION

The Contractor shall mark proprietary information contained in the bid which is not to be disclosed to the public or used for purposes other than the evaluation of the bids. Pricing and service elements of the successful bid will not be considered proprietary.

1.6 QUESTIONS AND CLARIFICATIONS

A. All questions regarding this ITB must be submitted through the Utah Procurement

Place (U3P) Bonfire (EUNA) website or to the Utah County Purchasing Manager, Robert Baxter, at RobertB@utahcounty.gov. The deadline for submission of questions is end of business day Friday, May 15, 2026.

B. Bidders are urged and expected to inspect the site where services are to be performed and to satisfy themselves as to all general and local conditions that may affect the cost of performance of the Agreement, to the extend such information is reasonably obtainable. In no event will a failure to inspect the site constitute grounds for withdrawal of a bid after opening, or for a claim after award of the agreement.

1.7 ACCEPTANCE OF BID

A. Utah County reserves the right to reject any or all bids or waive minor irregularities when to do so would be in the best interests of Utah County. Minor irregularities are those which will not have a significant adverse effect on overall competition or performance levels.

B. The responding party agrees that Utah County may terminate this procurement procedure at any time, and Utah County shall have no liability or responsibility to the responding party for any costs or expenses incurred in connection with this ITB, or such party's response.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 6

1.8 DISQUALIFICATION OF BID

The occurrence of any of the following may result in disqualification of a bid:

A. Failure to respond within the established timetable.

B. Failure to completely answer all questions presented in the ITB.

C. Use of any other type of form or format other than those indicated in the ITB.

D. Failure to provide requested documentation at the time of bid submission.

E. Illegible responses.

F. If the bidder adds any provisions reserving the right to accept or reject an award, or to enter into an agreement pursuant to an award, or any other unauthorized conditions, limitations or provisions.

G. If the bidder is unable to evidence a satisfactory record of integrity.

H. If the bidder is not qualified legally to contract.

I. If the bid at the opening does not contain a signed bid, and a signed certificate of non-collusion.

J. Utah County reserves the right to reject any or all bids.

1.9 DISPOSITION OF BIDS

All bids (and the information contained therein) shall become the property of Utah

County. No bid shall be returned to the respondent regardless of the outcome of the selection process.

1.10 INTERPRETATION OF ITB

The invalidity of any portion of this ITB shall not prevent the remainder from being carried into effect. Whenever the context of any provision shall require it, the singular number shall be held to include the plural number, and vice versa, and the use of any gender shall include all genders. The paragraph and section headings in this ITB are for convenience only and do not constitute a part of the provisions hereof.

1.11 REQUIRED EXPERIENCE

A. The Contractor must have a minimum of three (3) years’ experience in the work specified herein. Proof of experience must be submitted with each bid.

B. The Contractor shall provide a list of at least three (3) projects similar to Utah

County’s as set forth herein, including contracting agency and contact information for each.

C. The Contractor shall be the general contractor for the project and is required to have a current local business license from the jurisdiction in which their business is located.

A copy of the bidder’s current local business license must be submitted with the bid.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 7

1.12 EVALUATION CRITERIA

All bids will be evaluated by authorized representatives of Utah County for compliance with the terms and conditions contained in this ITB, and the resulting agreement awarded to the lowest responsive and responsible bidder. Utah County reserves the right to award to more than one Contractor if it is in the best interest of the County.

1.13 GENERAL

A. Utah County will award a contract in reliance upon the information contained in bids submitted in response to the ITB. Utah County will be legally bound only when and if there is a signed agreement entered into between Utah County and the awarded bidder(s).

B. It is vitally important that any person who signs a bid or agreement on behalf of a respondent certifies that he or she has the authority to so act. The bidder who has its bid accepted may be required to answer further questions and provide further clarification of its bid and responses.

C. Receiving this ITB or responding to it does not entitle any entity to participate in services or transactions resulting from or arising in connection with this ITB. Utah

County shall have no liability to any person or entity under or in connection with this

ITB, unless and until Utah County and such person have executed and entered into an agreement pursuant to the terms of this ITB.

D. By responding to this ITB each responding party acknowledges that neither Utah

County nor any of its representatives is making or has made any representation or warranty, either express or implied, as to the accuracy or completeness of any portion of the information contained in this ITB. The responding party further agrees that neither Utah County nor any of its representatives shall have any liability to the responding party or any of its representatives as a result of this ITB process or the use of the information contained in this ITB. Only the terms and conditions contained in an agreement when, as, and if executed, and subject to such limitations and restrictions as may be specified therein, may be relied upon by the respondent in any manner as having any legal effect whatsoever.

1.14 BONDS

A. Before this contract is awarded by Utah County, the Contractor shall furnish to Utah

County the following bonds:

1. A performance bond satisfactory to the County in an amount equal to 100% of the price specified in the contract, to assure the faithful performance of the contract, for the protection of Utah County, to be held until final acceptance by Utah County of all aspects of this project; and

2. A payment bond satisfactory to the County in an amount equal to 100% of the price specified in the contract, for the protection of each person supplying labor, service, equipment, or material for the performance of the work provided for in the contract.

B. Each bond shall be:

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 8

1. Binding upon the award of the contract.

2. Executed by a surety company or companies duly authorized to do business in the State of Utah, or, in the form or cash or other certified funds.

3. Payable to Utah County, A Body Corporate and Politic.

4. Filed with the Utah County Public Works Department in a timely manner following the Closing date for Receipt of Bids.

5. Increased if the contract price is increased by change order or otherwise subsequent to entering into the contract.

C. Utah County will hold the Payment Bond for 90 days subsequent to the completion of the project.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 9

GENERAL REQUIREMENTS

Alteration of Plans or Character of Work

The County Commission, after recommendation by the County Public Works Director, reserves the right to make at any time during the progress of the work, such increases or decreases in quantities and such alterations in the details of construction, and the elimination of one or more items as may be found necessary or desirable. Such alterations shall not be considered as a waiver of, nor release of, the surety. The Contractor agrees to accept the work as altered the same as if it had been a part of the original Agreement. The Contractor shall proceed with the work alterations when ordered in writing. Financial increases to this

Agreement must be approved in writing by the County Commission before additional work is authorized and constructed.

Brand Name

The use of brand names in the Specifications is for the purpose of designating the standard of quality, performance, and characteristics desired. Equivalent brand substitutions for products must be approved by Utah County.

Change Orders

Utah County may at any time, without notice to any sureties, by written order designated or indicated to be a change order, make changes to the work within the general scope of the contract, and to the contract amount and/or contract deadlines.

The overhead, profit, and commission fees included in any change order bid shall not exceed the maximum percentages of the net cost of the bid as shown in the following table:

Only the Contractor or subcontractor who actually performs or furnishes the work may charge for overhead or profit regardless of the number of tiers of subcontractors, that is, the markup on work subcontracted by a subcontractor will be limited to one charge of 10% for overhead and profit and one charge of 10% for the prime Contractor's commission.

Overhead &

Profit Commission

To prime Contractor on work performed by subcontractors 0% 10%

To prime Contractor or subcontractor for that portion of work performed with their respective forces 10% 0%

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 10

Overhead and profit includes but is not limited to:

A. Estimating.

B. Field supervision above foreman level superintendents, assistant superintendents, general foremen, engineers, accountants, timekeepers, office manager, and other staff.

C. Office supplies.

D. Drinking water.

E. Temporary heat, light, and power.

F. Field toilets.

G. Small tools.

H. Other costs of materials and/or equipment associated with performance of the contract.

On bids covering both increases and decreases in the contract amount, the overhead and profit shall be computed on the net change only.

Each change order shall be signed by the Contractor, the County Public Works Director, and the County Commission, and payment and performance bonds shall be increased by the

Contractor to reflect any increase to the contract amount before the Contractor will be authorized to proceed with the work specified therein.

Failure of Contractor and the County to agree on an adjustment of contract amount or contract deadlines shall not excuse Contractor from proceeding with prosecution and performance of work. Contractors, subcontractors, and suppliers shall handle all disputes in a manner which will permit work to proceed on schedule while the matter in dispute is being resolved.

The County shall have the right, within its sole discretion, to require the Contractor to commence performance of changes to work based on County requirements prior to the submission of a cost bid by the Contractor to the County, or approval of the cost bid by the

County. In such case, Contractor shall proceed with the work so changed upon receipt of a

Construction Change Directive from the County and thereafter submit to the County as soon as possible any cost bid required.

Completion Date

The completion date for the Spanish Fork River Park Pipe Fence is on or before October 15, 2026, regardless of weather conditions and other related problems. If the Contractor fails to complete the work on or prior to the completion date, or by extension of time granted by the County in writing, then the Contractor may forfeit his or her 5% payment retainer and shall in addition be liable for all additional costs and damages incurred by Utah County as a result of the failure of completion.

If abnormal weather conditions or other natural events totally beyond the control of the

Contractor require, in the judgment of the County, an extension of the completion date, written authorization must be given by the County for such specific extension.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 11

Liquidated Damages

It is agreed by the parties to this Agreement that in case all the work called for in accordance with this Agreement is not completed before or upon the Completion Dates set forth in this Agreement, damage will be sustained by Utah County, and that it is and will be impracticable to determine the actual damage which Utah County will sustain in the event of and by reason of such delay. It is therefore agreed that the Contractor will pay to Utah

County $500.00 per day for each calendar day between the Completion Date required herein for any specific roadway and the date of final acceptance thereof by Utah County, as liquidated damages and not as penalty. It is further agreed that the amounts stipulated are reasonable estimates of the damages that would be sustained by Utah County and the

Contractor agrees to pay such liquidated damages as herein provided. In case the liquidated damages are not paid, the Contractor agrees that Utah County may deduct the amount thereof from any money due to or that may become due to the Contractor by progress payments or otherwise in accordance with the terms of this Agreement, or if said amount is not sufficient, recover the total amount.

The Contractor will not be assessed with liquidated damages during any delay in the completion of the work caused by acts of God, acts of criminals, acts of Utah County, acts of the public utilities, fire, floods, epidemics, quarantine restrictions, labor strikes that delay the critical sequence of the work, and unusually severe weather or delays of subcontractors due to such causes, provided that Utah County is notified in writing of the causes of such delay.

Cooperation

Utah County intends to encourage cooperation with the Owner, Engineers, Supplier, Contractor and its subcontractors. The objectives are effective and efficient agreement performance, intended to achieve completion within budget, on schedule, and in accordance with the Drawings and Specifications.

Alternative Dispute Resolution (ADR) methodologies will be encouraged in place of the more formal dispute resolution procedures. ADR in this context is intended to be a voluntary, nonbinding procedure available for use by the parties to this Agreement to resolve any dispute that may arise during performance.

Data Privacy

If Contractor, as part of this agreement or transaction, will receive or work with County information, or if they will be gathering data on behalf of the County, Contractor will be required to comply with the following provisions as applicable.

A. Cyber Insurance. Contractor agrees to purchase and maintain throughout the term of this Agreement a technology and professional liability insurance policy, including coverage for network security and data protection liability insurance (also called

“cyber liability”) covering liabilities for financial loss resulting or arising from acts, errors, or omissions, in rendering technology or professional services or in connection

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 12 with the specific services described in violation or infringement of any right of privacy, including breach of security and breach of security or privacy laws, rules or regulations globally, now or hereinafter constituted or amended; data theft, damage, unauthorized disclosure, destruction, or corruption, including without limitation, unauthorized access, unauthorized use, identity theft, theft of personally identifiable information or confidential government, corporate, or public information in whatever form; transmission of a computer virus or other type of malicious code; participation in a denial of service attack on third party computer systems; loss or denial of service;

with no cyber terrorism exclusion; with a minimum limit of three million dollars

($3,000,000) for each and every claim and in the aggregate. Such coverage must include technology and professional liability including breach of contract, privacy and security liability, privacy regulatory defense and payment of civil fines, payment of credit card provider penalties, and breach response costs (including without limitation, notification costs, forensics, credit protection services, call center services, identity theft protection services, and crisis management and public relations services). Such insurance must explicitly address all of the foregoing without limitation if caused by an employee of the Contractor or an independent contractor working on behalf of the Contractor in performing services under this Agreement.

Policy must provide coverage for wrongful acts, claims, and lawsuits anywhere in the world. Such insurance must include affirmative contractual liability coverage for any data breach indemnity in this Agreement, for all damages, defense costs, privacy regulatory civil fines and penalties, and reasonable and necessary data breach notification, forensics, credit protection services, public relations and crisis management, and other data breach mitigation services resulting from a confidentiality or security breach by or on behalf of the Contractor. Contractor shall furnish evidence of coverage at the time of any bid or proposal, and upon request at any time during the term of the Agreement.

B. Protecting Personal Identifying Information. Utah Code 63A-19-101 et seq. requires governmental agencies to follow specific standards to protect personal data privacy.

Consistent with Utah Code 63A-19-401(4)(a), Contractor acknowledges that

Contractor is also required to comply with the relevant requirements of this chapter with regard to the personal data processed or accessed by Contractor as part of

Contractor’s duties under the Agreement to the same extent as required of the governmental entity.

Delivery/Shipping

The Contractor/Supplier shall be responsible for all delivery, shipping, transportation, and handling charges and shall include these costs in the bid schedule. Delivery and Shipping costs will not be paid as a separate line item

Inspection

Testing or work to determine contract compliance shall be performed by the Contractor.

Such testing shall comply with American Public Works Association (APWA) standards for all applicable materials and placement of those materials. Copies of test results must

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 13 be provided to, and approved by, the County Project Manager prior to final acceptance of project.

Final acceptance and inspection of completed work shall be performed by the County

Project Manager.

Insurance

The insurance required by the Utah County Standard Terms and Conditions shall name

"Utah County, 100 East Center, Provo, Utah 84606" as a Certificate Holder.

The Contractor shall file all required certificates of insurance with the Utah County Public

Works Department in a timely manner following the Closing Date for Receipt of Bids and prior to commencing any work.

Keys

If it becomes necessary for the County to issue the Contractor a key to County locks, final payment to the Contractor will be held until the key has been returned and documented. It is illegal to duplicate County keys.

Legal

The Contractor shall be responsible to provide all legal support for the project including but not limited to the preparation of contracts with subcontractors.

License

The Contractor shall have a current "Business License", issued by the county or city in which the Contractor's business is located, and shall provide proof of such license prior to the commencement of said work.

The Contractor shall be a licensed "General Contractor" through the State of Utah, Utah

Division of Occupational and Professional Licensing, to perform construction work in this

State. The Contractor shall provide proof of such license prior to the commencement of said work.

Payment

Payment shall be required in the manner prescribed in the Utah County Standard Terms and

Conditions. All bills must be signed and dated by both the Contractor and the County Project

Manager before the payment process can commence. Each bill shall itemize the work performed and shall show progress of the work that can be verified. Actual payment will be based upon inspection by the County Project Manager who will certify that the work has been performed in a workmanlike manner. In accordance with Utah Code §13-8-5, Utah

County may retain five percent (5%) of all payments to the Contractor or such other sums as authorized thereby until the end of the project. Final payment of any sums retained will be paid thirty (30) days after request after approval of work by final inspection.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 14

The County Project Manager will decide all questions which may arise as to the quality, quantity, and acceptability of materials furnished and work performed, and as to the rate of progress of work. He will also decide all questions which may arise as to the acceptable fulfillment of the Agreement on the part of the Contractor.

Payments may be withheld from the Contractor by the County in order to protect or offset the

County from loss due to:

A. Defective work not remedied.

B. Liens or claims filed or reasonable evidence of probable filing.

C. The Contractor's failure to promptly pay subcontractors for labor and/or materials accepted by the Contractor.

D. The County's reasonable doubt that the project can be completed for the unpaid balance of the contract price.

E. Damage to another contractor.

F. Failure to maintain scheduled progress.

G. Any other failure of the Contractor which results in liability for the County.

Safety Requirements

In order to protect the life and health of employees and the general public in the performance of this Agreement, the Contractor shall comply with the general safety orders covering Utah industries, issued by the Industrial Commission of Utah and Occupational Safety and Health

Act of 1970. Nothing in the Agreement shall relieve the Contractor of responsibility assigned in the Specifications, State Industrial Commission's requirements, or state and local laws and ordinances.

The Contractor agrees to hold Utah County and the County's Engineer free and harmless from any and all damages/claims that may occur during the construction operations of this

Agreement. The Contractor shall assume sole liability for any injuries or damages caused to a third party as a result of fulfillment of this Agreement and construction operations.

The County Public Works Director or the County Project Manager will have the authority by written order to suspend work wholly or in part due to the failure of the Contractor to correct conditions unsafe for the workmen or general public; for failure to carry out provisions of the

Agreement; for failure to carry out orders; for such periods as he may deem necessary due to unsuitable weather, for conditions considered unsuitable for the progress of the work, or for any other condition or reason deemed to be in the public interest. Written orders shall state the reason for suspension.

Sales Tax

The Contractor shall be responsible for including in their bid schedule, not as a separate line, any sales tax charges for products, materials, or other items that the Contractor will be purchasing. The Contractor will not be allowed to use the County’s sales tax exemption number to purchase products, materials or other items that the Contractor will be installing as part of the agreement on the County’s behalf.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 15

Supervision of Work

The County Public Works Director shall have full supervisory powers in determining the extent of the construction on the project. Compensation shall be based upon logbooks maintained by the County Project Manager as a percentage of work completed and payment terms described under General Requirements. All decisions concerning the extent and acceptability of the work and the quality of all materials shall rest solely with the County

Public Works Director.

Surveying

The Contractor shall be responsible for all construction staking.

The Contractor will be responsible for furnishing, maintaining, or restoring all survey monuments and reference marks within the project site. Contact the County Surveyor to obtain permits for section corners and monuments before any work begins.

Utilities

Care shall be taken to preserve and protect existing overhead and underground utilities, pole lines, signs, pipelines, and improvements from injury or damage during construction operations. The Contractor shall assume full responsibility for reimbursing the owners of the utilities for any damage to their properties, utilities, or improvements, or interference with their service caused through Contractor’s operations at no additional cost to the

County. The Contractor shall contact “Blue Stakes of Utah,” and individual utility owners as necessary, to have all underground utilities located on the work site in accordance with Utah law.

The Contractor shall be responsible to protect in place all utilities shown or not shown on this plan.

The Contractor shall be responsible for providing all water, power, sanitary facilities, and telephone services as required for the Contractor’s use during construction.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 16

STATEMENT OF APPLICABLE STANDARDS

All work performed by the Contractor shall meet or exceed all applicable specifications listed in the publications American Public Works Association – Manual of Standard Specifications and Manual of Standard Plans, current edition, published by the Utah Chapter of the American

Public Works Association, hereinafter referred to as “APWA Standard Specifications and

Standard Plans.” All work performed by the Contractor shall also comply in every respect with the plans referred to as “Spanish Fork River Park Pipe Fence” (the Drawings), which are attached hereto and incorporated herein by this reference. Where conflicts arise, the most stringent code will apply.

Where the plans or specifications describe portions of the work in general terms but not complete detail, it is understood that only the best general practice is to prevail and that only materials and workmanship of the first quality are to be used.

It is intended that these plans and specifications require all labor and materials necessary and proper for the work contemplated and that the work be completed in accordance with their true intent and purpose. The Contractor shall notify the County Project Manager immediately regarding any discrepancies or ambiguities which may exist in the plans or specifications.

The County Project Manager’s interpretation thereof shall be conclusive.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 17

SPECIFICATIONS MEASUREMENT AND PAYMENT

GENERAL

A. CONTRACTOR will adhere to all applicable standards and specifications as referenced on page 16.

B. CONTRACTOR will attend all preconstruction and construction conferences and weekly meetings.

C. CONTRACTOR will take all measurements and compute all quantities.

D. COUNTY PROJECT MANAGER will verify measurement and quantities.

E. CONTRACTOR will provide all equipment, workers, and survey crews to make measurements.

F. Units of measurement are listed in the bid schedule(s).

1. GENERAL CONDITIONS (Lump) APWA 00 72 00

Permits Section 6.7

The contractor must obtain all the necessary permits and agreements and pay all applicable fees prior to any construction activities. Contact Utah County Public Works, and other applicable agencies for permits and inspections required for any work conducted within

Utah County’s public right-of-way and utility easements.

Use of Premises Section 6.10

The Contractor agrees to:

A. Be responsible for removing and disposing of all trash, scrap and unused material at their own expense in a timely manner.

B. Be responsible for maintaining the site in a neat, safe and orderly manner at all times.

C. Be responsible for their own safety, traffic control, permits, retesting and re-inspections at their own expense.

D. Unless otherwise noted all excess soils and materials shall become the property of the Contractor and shall be lawfully disposed of offsite at the Contractor's expense.

E. Immediately remove any construction debris or mud tracked onto existing roadways.

F. Repair any excavation or pavement failures caused by his construction.

Testing & Inspections Section 13.3

Testing or work to determine contract compliance shall be performed by the

Contractor. Such testing shall comply with APWA standards for all applicable materials and placement of those materials. Copies of test results must be provided to, and approved by, the County Project Manager prior to final acceptance of project.

Payment includes all costs incidental as specified in General Conditions 00 72 00 as a lump sum.

Invitation to Bid: Spanish Fork River Park Pipe Fence P a g e | 18

2. MOBILIZATION AND DEMOBILIZATION (Lump) APWA 01 71 13

Payment includes the cost of mobilization, demobilization and installation of temporary facilities.

3. FENCE REMOVAL (LF) APWA 32 01 10

A. Payment includes all labor, equipment, and materials necessary to remove and dispose of the existing fencing, including posts, wire, rails, gates, footings, and any associated components.

B. All work shall be in accordance with APWA 32 01 10, 32 31 16, and the project drawings.

4. 2-3/8” DRILL PIPE FENCE (LF) APWA 32 31 16

Payment includes all labor, equipment, and materials necessary to construct and install the 2-3/8” drill pipe fence including posts, rails, footings, and any associated components as per the construction drawings. This bid item includes the install of the Pedestrian

Access.

5. 16’ GATE (LUMP) APWA 32 31 16

the 16’ gate as per the plan drawings and include fabrication, posts, rails, gates, footings, and all associated components.

6. PARK ENTRANCE GATES (LUMP) APWA 32 31 16

Payment includes all labor, equipment, and materials necessary to construct and install a double 12’ gate system as per the plan drawings and include fabrication, posts, rails, gates, footings, and all associated components.

7. PARK ENTRANCE BOW (LUMP) APWA 32 31 16

the gate bow as per the plan drawings and include fabrication, posts, rails, gates, footings, and all associated components.

END OF SECTION

ATTACHMENT A

PLANS “Spanish Fork River Park Pipe Fence”

UTAH COUNTY

SPANISH FORK RIVER PARK

PIPE FENCE

N

GENERAL PROJECT NOTES:

AutoCAD SHX Text

COVER

AutoCAD SHX Text

UTAH COUNTY SPANISH FORK RIVER PARK PIPE FENCE

AutoCAD SHX Text

NTS

AutoCAD SHX Text

DATE:

AutoCAD SHX Text

SCALE:

AutoCAD SHX Text

DRAWN BY: TH

AutoCAD SHX Text

REVISIONS:

AutoCAD SHX Text UTAH COUNTY PUBLIC WORKS ENGINEERING DIVISION 2855 South State Provo, Utah 84606

AutoCAD SHX Text 4/7/2026

AutoCAD SHX Text

US 6 HWY

AutoCAD SHX Text

THISTLE SLIDE RD.

AutoCAD SHX Text

THISTLE SLIDE RD.

AutoCAD SHX Text

UNION PACIFIC

AutoCAD SHX Text

16 FOOT GATE SEE DETAIL D-3

AutoCAD SHX Text

PARK ENTRANCE SEE DETAIL D-4

AutoCAD SHX Text

REMOVE EXISTING FENCE & REPLACE WITH PIPE FENCE SEE DETAIL D-1

AutoCAD SHX Text

PEDESTRIAN ACCESS SEE DETAIL D-2

AutoCAD SHX Text

SPANISH FORK RIVER

AutoCAD SHX Text

SPANISH FORK RIVER

AutoCAD SHX Text

1. CURRENT ADOPTED AMERICAN PUBLIC WORKS ASSOCIATION CURRENT ADOPTED AMERICAN PUBLIC WORKS ASSOCIATION (APWA) 2017 SPECIFICATIONS FOR UTAH COUNTY SHALL BE APPLIED TO ALL CONSTRUCTION. 2. CONTRACTOR SHALL BE RESPONSIBLE TO VERIFY LOCATION(S) CONTRACTOR SHALL BE RESPONSIBLE TO VERIFY LOCATION(S) AND DEPTH(S) OF ALL UTILITIES IN PROJECT BOUNDARIES OR AFFECTED AS PART OF THE PROJECT COMPLETION. CONTRACTOR TO VERIFY ALL UTILITY DETAILS WITH UTILITY COMPANY REPRESENTATIVE AND UTILITY MARKING SERVICES I.E. BLUE STAKES (811). 3. EXISTING FENCE, (FENCING WIRE & CONCRETED POST'S, TO BE EXISTING FENCE, (FENCING WIRE & CONCRETED POST'S, TO BE REMOVED AND DISPOSED OF BY CONTRACTOR. T-POST'S AND GATES ARE TO BE CAREFULLY REMOVED AND STORED AT A SPECIFIED LOCATION DETERMINED BY UTAH COUNTY AND TO BE KEPT BY UTAH COUNTY. 4. EACH STEP OF THE FENCING PROCESS WILL BE INSPECTED BY EACH STEP OF THE FENCING PROCESS WILL BE INSPECTED BY COUNTY PERSONNEL & SIGNED OFF WHEN COMPLETED. (DIGGING HOLES, CONCRETE MIX, SETTING POSTS, ALL WELDS, ECT.) 5. CONCRETE WASHOUT IS TO BE USED AND BE DESIGNED, LEAK CONCRETE WASHOUT IS TO BE USED AND BE DESIGNED, LEAK PROOF AND CLEARLY MARKED. MUST BE MAINTAINED. 6. ALL CONCRETE IS TO HAVE A CROWN TO HELP SHED WATER. ALL CONCRETE IS TO HAVE A CROWN TO HELP SHED WATER. NO MATERIAL ON POSTS UNTIL 7 DAYS AFTER PLACING CONCRETE. CONCRETE CLASS TO BE 4000 MINIMUM. 7. ALL WELD TYPES ARE TO REFERENCE DETAIL D-1 FOR ENTIRE ALL WELD TYPES ARE TO REFERENCE DETAIL D-1 FOR ENTIRE PROJECT. 8. PIPE FENCE LOCATION IS TO BE INSTALLED TO MATCH THAT OF PIPE FENCE LOCATION IS TO BE INSTALLED TO MATCH THAT OF THE EXISTING FENCE LOCATION.

TYP

TYP 3/16

3/16

TYP1(5/8)

2-3/8" DRILL PIPE FENCE

3/16

AutoCAD SHX Text

A-A NTS

AutoCAD SHX Text A

AutoCAD SHX Text A

AutoCAD SHX Text 4'

AutoCAD SHX Text

ALL PIPE ENDS TO BE CAPPED AND WELDED

AutoCAD SHX Text

AutoCAD SHX Text

10' MAX

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text 2'

AutoCAD SHX Text 6"

AutoCAD SHX Text 10"

AutoCAD SHX Text NOTES: 1. FENCE TO BE BUILT WITH 2-3/8" DRILL PIPE. FENCE TO BE BUILT WITH 2-3/8" DRILL PIPE. 2. WELDING RODS TO BE 6010 OR 6011 WELDED WITH AN ARC WELDING RODS TO BE 6010 OR 6011 WELDED WITH AN ARC WELDER THAT PUTS OUT 220 AMPS OR LARGER. 3. ALL OPEN END PIPE MUST BE CAPPED. ALL OPEN END PIPE MUST BE CAPPED. 4. ALL POST'S TO BE INSTALLED WITH WET CONCRETE. ALL POST'S TO BE INSTALLED WITH WET CONCRETE. 5. CONCRETE CLASS TO BE 4000 MINIMUM. CONCRETE CLASS TO BE 4000 MINIMUM. 6. HANGERS TO BE USED ON LOWER 2 RAILS AND TO BE HANGERS TO BE USED ON LOWER 2 RAILS AND TO BE 1/4" TRIANGLES. 7. RAILS TO BE EVENLY SPACED ON CENTER.RAILS TO BE EVENLY SPACED ON CENTER.

AutoCAD SHX Text NOTES: 8. TOP OF POST TO BE SADDLED/NOTCHED FOR TOP RAIL.TOP OF POST TO BE SADDLED/NOTCHED FOR TOP RAIL.

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

SHEET NUMBER

AutoCAD SHX Text

DT-1

AutoCAD SHX Text

DATE:

AutoCAD SHX Text

SCALE:

AutoCAD SHX Text

NTS

AutoCAD SHX Text

DRAWN BY: TH

AutoCAD SHX Text

REVISIONS:

AutoCAD SHX Text

UTAH COUNTY SPANISH FORK RIVER PARK PIPE FENCE

AutoCAD SHX Text

2855 SOUTH STATE PROVO, UTAH 84606

AutoCAD SHX Text

UTAH COUNTY PUBLIC WORKS

AutoCAD SHX Text

ENGINEERING DIVISION

4/7/2026

PEDESTRIAN ACCESS

NTS

AutoCAD SHX Text 16"

AutoCAD SHX Text 16"

AutoCAD SHX Text NOTES: 1. CAPPED POST SHALL HAVE NO CAPPED POST SHALL HAVE NO BURRES/EDGES AS TO CAUSE INJURIES TO THE PUBLIC.

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

SHEET NUMBER

AutoCAD SHX Text

DT-2

AutoCAD SHX Text

DATE:

AutoCAD SHX Text

SCALE:

AutoCAD SHX Text

NTS

AutoCAD SHX Text

DRAWN BY: TH

AutoCAD SHX Text

REVISIONS:

AutoCAD SHX Text

UTAH COUNTY SPANISH FORK RIVER PARK PIPE FENCE

AutoCAD SHX Text

2855 SOUTH STATE PROVO, UTAH 84606

AutoCAD SHX Text

UTAH COUNTY PUBLIC WORKS

AutoCAD SHX Text

ENGINEERING DIVISION

≈16' GATE

AutoCAD SHX Text NOTES: 1. GATE TO BE BUILT WITH 2-3/8" DRILL PIPE. GATE TO BE BUILT WITH 2-3/8" DRILL PIPE. 2. WELDING RODS TO BE 6010 OR 6011 WELDED WITH AN ARC WELDING RODS TO BE 6010 OR 6011 WELDED WITH AN ARC WELDER THAT PUTS OUT 220 AMPS OR LARGER. 3. ALL OPEN END PIPE MUST BE CAPPED. ALL OPEN END PIPE MUST BE CAPPED. 4. HORIZONTAL & VERTICAL PIPE TO BE EVENLY SPACED. HORIZONTAL & VERTICAL PIPE TO BE EVENLY SPACED. 5. GATE POST'S TO BE INSTALLED WITH WET CONCRETE. GATE POST'S TO BE INSTALLED WITH WET CONCRETE. 6. HEAVY DUTY BULLET HINGES TO BE INSTALLED & MEET WEIGHT HEAVY DUTY BULLET HINGES TO BE INSTALLED & MEET WEIGHT REQUIREMENTS. 7. LATCH POST TO HAVE STOP BAR & SHELF FOR GATE. 1/4" LATCH POST TO HAVE STOP BAR & SHELF FOR GATE. 1/4" THICK. 8. A SECONDARY LATCH POST TO BE INSTALLED, COORDINATE FINAL A SECONDARY LATCH POST TO BE INSTALLED, COORDINATE FINAL LOCATION WITH UTAH COUNTY PERSONAL. 9. GATE TO BE INSTALLED TO OPEN IN TOWARDS THE PARK. GATE TO BE INSTALLED TO OPEN IN TOWARDS THE PARK. 10. GATE LENGTH MAY NEED TO BE ADJUSTED. GATE LENGTH MAY NEED TO BE ADJUSTED.

AutoCAD SHX Text 4'

AutoCAD SHX Text 4'

AutoCAD SHX Text 16'

AutoCAD SHX Text 10"

AutoCAD SHX Text A

AutoCAD SHX Text A

AutoCAD SHX Text

A-A NTS

AutoCAD SHX Text 16"

AutoCAD SHX Text 2'

AutoCAD SHX Text 2'

AutoCAD SHX Text NOTES: 11. CHAIN TO BE WELDED ONTO GATE. CHAIN TO BE WELDED ONTO GATE. 12. GATE IS TO MATCH SAME WELD TYPE OF THAT REQUIRED ON GATE IS TO MATCH SAME WELD TYPE OF THAT REQUIRED ON THE FENCE. REFER TO DETAIL DT-1 FOR REFERENCE. 13. GATE PIPE IS TO BE COPED AS ILLUSTRATED IN DETAIL, GATE PIPE IS TO BE COPED AS ILLUSTRATED IN DETAIL, VERIFY WITH UTAH COUNTY PERSONAL. 14. CONCRETE CLASS TO BE 4000 MINIMUM.CONCRETE CLASS TO BE 4000 MINIMUM.

AutoCAD SHX Text 6"

AutoCAD SHX Text 4'

AutoCAD SHX Text 6"

AutoCAD SHX Text 10"

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

SHEET NUMBER

AutoCAD SHX Text

DT-3

AutoCAD SHX Text

DATE:

AutoCAD SHX Text

SCALE:

AutoCAD SHX Text

NTS

AutoCAD SHX Text

DRAWN BY: TH

AutoCAD SHX Text

REVISIONS:

AutoCAD SHX Text

UTAH COUNTY SPANISH FORK RIVER PARK PIPE FENCE

AutoCAD SHX Text

2855 SOUTH STATE PROVO, UTAH 84606

AutoCAD SHX Text

UTAH COUNTY PUBLIC WORKS

AutoCAD SHX Text

ENGINEERING DIVISION

PARK ENTRANCE

AutoCAD SHX Text

SPANISH FORK RIVER PARK

AutoCAD SHX Text NOTES: 1. GATE'S TO BE BUILT WITH 2-3/8" DRILL PIPE. GATE'S TO BE BUILT WITH 2-3/8" DRILL PIPE. 2. BOW TO BE BUILT WITH 6"X6" PIPE & INSTALLED IN WET BOW TO BE BUILT WITH 6"X6" PIPE & INSTALLED IN WET CONCRETE. 3. GATE ENTRANCE DIMENSIONS ARE APPROXIMATE, GATE ENTRANCE DIMENSIONS ARE APPROXIMATE, CONTRACTOR IS TO VERIFY IN FIELD AND ADJUST AS REQUIRED TO MEET MINIMUM GATE DIMENSION AS COORDINATED WITH UTAH COUNTY PERSONAL. 4. HORIZONTAL & VERTICAL PIPE TO BE EVENLY SPACED ON HORIZONTAL & VERTICAL PIPE TO BE EVENLY SPACED ON GATE. 5. "SPANISH FORK RIVER PARK" LETTERING TO BE 10" TALL & "SPANISH FORK RIVER PARK" LETTERING TO BE 10" TALL & 1/4" THICK. LETTERING IS TO BE WELDED ON TOP OF BOW. 6. WELDING RODS TO BE 6010 OR 6011 WELDED WITH AN ARC WELDING RODS TO BE 6010 OR 6011 WELDED WITH AN ARC WELDER THAT PUTS OUT 220 AMPS OR LARGER. 7. ALL OPEN END PIPE MUST BE CAPPED. ALL OPEN END PIPE MUST BE CAPPED. 8. HEAVY DUTY BULLET HINGES TO BE INSTALLED & MEET HEAVY DUTY BULLET HINGES TO BE INSTALLED & MEET WEIGHT REQUIREMENTS. 9. CHAIN IS TO BE WELDED ONTO END OF GATE FOR LOCKING CHAIN IS TO BE WELDED ONTO END OF GATE FOR LOCKING CAPABILITIES. 10. GATES ARE TO MATCH SAME WELD TYPE OF THAT REQUIRED GATES ARE TO MATCH SAME WELD TYPE OF THAT REQUIRED ON THE FENCE. REFER TO DETAIL DT-1 FOR REFERENCE. 11. GATE PIPE IS TO BE COPED AS ILLUSTRATED IN DETAIL. GATE PIPE IS TO BE COPED AS ILLUSTRATED IN DETAIL. VERIFY WITH UTAH COUNTY PERSONAL. 12. GATE'S ARE TO BE INSTALLED TO OPEN IN TOWARDS THE GATE'S ARE TO BE INSTALLED TO OPEN IN TOWARDS THE PARK. 13. 2 LATCH POST'S TO BE INSTALLED, PLEASE REFERENCE 2 LATCH POST'S TO BE INSTALLED, PLEASE REFERENCE DT-3. COORDINATE FINALE LOCATION WITH UTAH COUNTY PERSONAL. 14. GATES ARE TO CENTER OFF OF CATTLE GUARD. GATES ARE TO CENTER OFF OF CATTLE GUARD. 15. CONCRETE CLASS TO BE 4000 MINIMUM. CONCRETE CLASS TO BE 4000 MINIMUM.

AutoCAD SHX Text

6' MIN

AutoCAD SHX Text 16'

AutoCAD SHX Text

13' 8" (TYP)

AutoCAD SHX Text 27' 10"

AutoCAD SHX Text 10"

AutoCAD SHX Text 24"

AutoCAD SHX Text 24'

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text 4'

AutoCAD SHX Text 1'

AutoCAD SHX Text

2" MIN

AutoCAD SHX Text 6"

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

SHEET NUMBER

AutoCAD SHX Text

DT-4

AutoCAD SHX Text

DATE:

AutoCAD SHX Text

SCALE:

AutoCAD SHX Text

NTS

AutoCAD SHX Text

DRAWN BY: TH

AutoCAD SHX Text

REVISIONS:

AutoCAD SHX Text

UTAH COUNTY SPANISH FORK RIVER PARK PIPE FENCE

AutoCAD SHX Text

2855 SOUTH STATE PROVO, UTAH 84606

AutoCAD SHX Text

UTAH COUNTY PUBLIC WORKS

AutoCAD SHX Text

ENGINEERING DIVISION

ATTACHMENT B

CONTRACTOR’S BID SCHEDULE

Company Name: _________________________________________________________

Address: _________________________________________________________

City, State, Zip: _________________________________________________________

Phone: _________________________________________________________

B.1 BID PRICE:

Each Bidder shall complete the line-item cost summary below. The specified “Total Cost” shall become the bidder’s “Total Bid Price” for completion of this project.

SPANISH FORK RIVER PARK PIPE FENCE

Item APWA DESCRIPTION Unit ESTIMATED

QUANTITY

UNIT

PRICE

AMOUNT

1 00 72 00 General Conditions Lump 1

2 01 71 13 Mobilization and Demobilization Lump 1

3 32 01 10 Fence Removal LF 2,642

4 32 31 16 2-3/8” Drill Pipe Fence LF 2,642

5 32 31 16 16’ Gate Lump 1

6 32 31 16 Park Entrance Gates Lump 1

7 32 31 16 Park Entrance Bow Lump 1

TOTAL COST:

Note: The quantities specified herein are only estimates used for bid evaluation purposes. Actual payment will be based upon inspection records kept by the County, and the actual work completed, approved, and accepted by the County.

B.2 CERTIFICATION

I hereby certify that I have read, understand, and agree to all sections, Exhibits, Addendums, and

Attachments of this Invitation to Bid for Spanish Fork River Park Pipe Fence. I further certify that the information submitted by me/my company in response to this Invitation, including the pricing and other information, is true and accurate, and reflect a careful examination of the site of the work, the Specifications, the Drawings and form of the agreement, all of which are made a part hereof. I/my company propose(s) to furnish all labor, equipment, tools and machinery, and to furnish and deliver all materials not specifically mentioned as being furnished by the local agency, which are required in construction.

I understand that Utah County has the right to reject any or all bids, to waive minor irregularities when to do so would be in the best interests of Utah County, and to negotiate a price for the proposed services as determined to be in the best interest of Utah County.

The undersigned further proposes to execute the attached agreement within five working days after the date of the award, and to begin work within five working days after being notified to do so by the local agency, and to complete the same on or before October 15, 2026 after the signing of the agreement by both parties. It is understood that Utah County has the right to reject this bid or to accept it at the price listed above and the prices located in the Bidding Schedule.

Signature Title

Name (please print) Date

EXHIBIT A

CONTRACTOR INFORMATION FORM

In order to receive consideration, submitted bids must contain responses to all questions.

Failure to respond to all questions may result in disqualification of the bid.

COMPANY NAME & ADDRESS: ________________________________________________

Is this an Office: __________, Home: __________, Shop: __________, Other: ____________

Telephone Number: (____) _______________, Emergency Number: (____) ______________.

Answering Machine: (____) _______________, Fax Number: (____) __________________.

COMPANY OWNER: ___________________________________________________________

COMPANY PRESIDENT: _______________________________________________________

CONTACT PERSON: _____________________________________ Phone: ______________

EMAIL ADDRESS: ____________________________________________________________

Type of Company (Partnership, Corporation, Venture etc.): ____________________________

If a Corporation, in what State Incorporated: _________________________________________

Business License Number: _______________________________________________________

State of Utah Contractor License Number: __________________________________________

Federal Tax Identification Number: ________________________________________________

UEI SAM.gov Number: _________________________________________________________

How long has this company been in business: _____________Years, and ___________ Months.

Officers authorized to execute contracts: _____________________________________________

What would happen to your company in the event of the owner’s absence or death?

Brief History of the Company: ____________________________________________________

Are there any judgments, suits or claims pending YES NO against your company? If yes, attach a written explanation. □ □

Has your company operated under any other name (s)? YES NO

If yes, attach a written explanation. □ □

CONTRACTOR INFORMATION FORM Page 2

Has your firm failed to complete a contract within the last five years? YES NO

If "yes" attach explanation. □ □

Has your firm or any partner or officers ever been involved in any YES NO bankruptcy action? If "yes" attach explanation. □ □

Has your firm ever been listed on the…