04/2026

REQUEST FOR BIDS

THIS IS NOT AN ORDER RETURN ORIGINAL KEEP ONE COPY

BID # 2026-005

2026 FRONTAGE RD ASPHALT MILL & OVERLAY

Return your Bid in an envelope, sealed and clearly marked on the outside with Bid # shown:

CITY OF SPRINGVILLE

FINANCE OFFICE

ATTN: BRUCE RIDDLE

110 SOUTH MAIN STREET

SPRINGVILLE, UT 84663

Bids must be received and logged in prior to the date and time indicated. Bids will not be accepted after:

1:00 p.m. Monday, April 20, 2026

For Technical Information Contact:

Jason Riding, Streets Superintendent

Email: jriding@springville.org

Phone: (801) 489-2765

Delivery Requirement:

FAILURE TO SIGN THIS SECTION WILL DISQUALIFY YOUR RESPONSE

The undersigned agrees to furnish the products and/or services listed in this document at the prices and terms stated, subject to the requirements of this Request for Bids and the Contract Documents:

Firm Name

Signature

Printed Name

Date Phone

Fax

Email Website

This proposal is an electronic or paper-based bid. Paper-based bids require Respondents to submit their final proposal to the above address prior to the bid opening.

mailto:jriding@springville.org

BID # 2026-005

TABLE OF CONTENTS

SPRINGVILLE CITY

2026 Frontage Rd Asphalt Mill & Overlay BID

SECTION TITLE

SECTION 1 Instruction to Bidders

SECTION 2 General Terms & Conditions

SECTION 3 Requirements & Specifications

SECTION 4 Bid/Proposal Form

NOTE: The Contractor is responsible for reading the contents of this bid, including but not limited to, the Scope of Work, General Requirements, Specifications and Agreement. He is also responsible to visit the work site before presenting his bid.

SECTIONS 1 - INSTRUCTIONS TO BIDDERS

Bidders are urged and expected to inspect the site where services are to be performed and to satisfy themselves as to all general and local conditions that may affect the cost of performance of the

Agreement, to the extent such information is reasonably obtainable. In no event will a failure to inspect the site constitute grounds for withdrawal of a bid after opening or for a claim after award of the

Agreement.

Prospective bidders should submit inquiries on this invitation for bids through U3P Euna Platform.

The sealed bids will be opened by the Springville City Finance Director, Bruce Riddle, at

Springville City Hall, 110 South Main on Monday, April 20, 2026 at 1:00 p.m. Sealed bids shall be received either by electronic bid through U3P Euna Platform, by mail or hand delivered to Springville

City Civic Center, 110 South Main Street, Springville, UT 84663 (Attention: Bruce Riddle) before 1:00 p.m. on Monday, April 20, 2026. Bid number must be written on envelope of mailed or hand delivered bids to prevent them from being open prior to bid opening date. NO LATE BIDS WILL BE

ACCEPTED.

These items should be considered before filling out the bid and bidding schedule:

1. INTERPRETATION OF QUANTITIES IN THE SCHEDULE: Any quantities appearing in the

Specifications for this project are only approximate and were prepared by Springville City personnel.

These quantities will be used for bidding. The actual quantities for construction may vary and should be determined by the Contractor based on his individual analysis of conditions. In the event certain areas of the project are given a higher priority, those areas, as designated by the City’s Streets Superintendent, will receive construction attention first. In the event certain areas are deleted due to unforeseen appropriation of funds, or deemed not economically feasible, or for whatever reason, those areas will be deducted from the bid and payment amount.

2. BIDDING SCHEDULE: The bidder shall submit his bid upon the bidding schedule and bid sheets provided by Springville City. The total amount of the bid is obtained by unit priced items multiplied by the estimated quantities. All the figures shall be in ink or typed! The bid must be signed in ink by the individual who prepared the bid and by the owner of the company. The address and phone number of the individual or firm represented by the bid must be on the bid.

3. IRREGULAR PROPOSALS: Bids shall be considered irregular and may be rejected for the following:

a. If the bid is on a form other than that furnished by Springville City; or if the form is altered, or any part thereof is detached.

b. If there are unauthorized additions, conditional, multiple or alternate bids, or irregularities of any kind, which may tend to make the bid incomplete, indefinite, or ambiguous as to its meaning.

c. If the bidder adds any provisions reserving the right to accept or reject an award, or to enter into a contract pursuant to an award.

d. If the bid at the opening does not contain a signed bid, a signed bidding schedule, and all requested documents.

e. Any erasure or alteration of figures of unit prices not initialed in ink by the bidder.

g. If the Contractor is not qualified legally to contract.

4. ACCEPTANCE OF BID:

a. Springville City reserves the right to reject any or all bids or waive minor irregularities when to do so would be in the best interests of Springville City. Minor irregularities are those which will not have a significant adverse effect on overall competition or performance levels.

b. The responding party agrees that Springville City may terminate this procurement procedure at any time, and Springville City shall have no liability or responsibility to the responding party for any costs or expenses incurred in connection with this RFB, or such party's response.

5. DISPOSITION OF BIDS: All bids (and the information contained therein) shall become the property of Springville City. No bid shall be returned to the respondent regardless of the outcome of the selection process.

6. EVALUATION CRITERIA: All bids will be evaluated by authorized representatives of Springville

City for compliance with the terms and conditions contained in this RFB and the resulting contract awarded to the lowest responsive and responsible bidder. The determination of the lowest responsive and responsible Bidder may involve all or some of the following factors but not be limited to: price, Vendor

Evaluation Report, handling, storage, disposal costs, installation, conformity to specifications, financial ability to meet the contract, previous performance, facilities, equipment, experience, delivery promise, terms of payments, compatibility as required, other costs, and other objective and accountable factors.

a. Selection Criteria determined by Springville City Staff will be applied in the following order of importance:

1. Construction Bid (40)

2. Previous Project Experience (30)

3. Personnel/Project Manager/Project Engineer/Superintendent (30)

Total of 100 Points

7. GENERAL:

a. Springville City will award a contract in reliance upon the information contained in bids submitted in response to the RFB. Springville City will be legally bound only when and if there is a signed contract entered into between Springville City and the awarded bidder.

b. It is vitally important that any person who signs a bid or contract on behalf of a respondent certifies that he or she has the authority to so act. The bidder who has its bid accepted may be required to answer further questions and provide further clarification of its bid and responses.

c. Receiving this RFB or responding to it does not entitle any entity to participate in services or transactions resulting from or arising in connection with this RFB. Springville City shall have no liability to any person or entity under or in connection with this RFB, unless and until Springville

City and such person have executed and entered into a contract pursuant to the terms of this RFB.

d. By responding to this RFB each responding party acknowledges that neither Springville City nor any of its representatives is making or has made any representation or warranty, either express or implied, as to the accuracy or completeness of any portion of the information contained in this

RFB. The responding party further agrees that neither Springville City nor any of its representatives shall have any liability to the responding party or any of its representatives as a result of this RFB process or the use of the information contained in this RFB. Only the terms and conditions contained in a contract when, as, and if executed, and subject to such limitations and restrictions as may be specified therein, may be relied upon by the responding party in any manner as having any legal effect whatsoever.

SECTION 2 - GENERAL TERMS AND CONDITIONS

The Contract Documents for this Request for Bids shall include the Instructions to Bidders, General Terms & Conditions, Requirements & Specifications, and all Addenda. Bidders must base their bids on all the requirements and specifications in the Contract Documents. Bidders are responsible to understand and implement all references to federal and state government requirements as well as professional guidelines included in the Contract Documents. The Contract Documents shall become the Contract between the selected bidder and the City.

AMENDMENTS:

No oral modifications or amendments to this Agreement shall be effective, but this Agreement may be modified or amended by a written agreement signed by the parties.

ASSIGNMENT:

The parties to this Agreement shall not assign this Agreement, or any part hereof, without the prior written consent of the other party to this Agreement. No assignment shall relieve the original parties from any liability hereunder.

BINDING AGREEMENT:

This Agreement shall be binding upon the heirs, successors, administrators, and assigns of each of the parties hereto.

BONDS:

Before this Agreement is awarded by Springville City the Contractor shall furnish Springville City the following bonds:

1. A payment and performance bond satisfactory to the City in an amount equal to 100% of the price specified in the Agreement, to assure the faithful performance of the Agreement, for the protection of Springville City, to be held until final acceptance by Springville City of all aspects of this project;

The bond shall be:

1. Binding upon the award of the Agreement;

2. Executed by a surety company or companies duly authorized to do business in the State of Utah, or, in the form of cash or other certified funds;

3. Payable to Springville City;

4. Filed with the Springville City Public Works Department in a timely manner following the

Closing Date for Receipt of Bids; and

5. Increased if the contract price is increased by change order or otherwise subsequent to entering into the Agreement.

Springville City will hold the Payment Bond for 90 days subsequent to the completion of the project.

No Bid Bond is required for this bid.

COMPLETION DATE:

The completion date for the pavement work is on or before June 30, 2026.

TERMINATION:

Springville City may terminate this Agreement at any time and for any reason by giving the contractor a 30-day written notice of termination.

INDEMNIFICATION:

The Contractor shall defend, indemnify, save and hold harmless Springville City, its officers, employees, and agents, from and against any and all claims, demands, causes of action, orders, decrees, judgments, losses, damages, and liabilities (including all costs and attorney’s fees incurred in defending any claim, demand, or cause of action) occasioned by, growing out of, or arising or resulting from (a)

Contractor, its subcontractors, agents or employees performance of this Agreement or their provision of any services required herein to be performed by the Contractor or its subcontractors, agents or employees, and (b) any act or omission of Contractor, or its subcontractors, agents or employees. The Contractor shall assume sole liability for any injuries or damages caused to a third party as a result of fulfillment of this

INDEPENDENT CONTRACTOR:

Contractor states and affirms that he is acting as an independent contractor, holding himself out to the general public as an independent contractor for other work or agreements as he sees fit; that he advertises his services as he sees fit to the general public, maintains his office or place of employment separate from Springville City, and that this AGREEMENT is not exclusive of other agreements, contracts or opportunities.

The parties intend that an independent contractor relationship will be created by this

AGREEMENT. Springville City is interested only in the results to be achieved, and the conduct and control of the work will lie solely with Contractor. Contractor is not to be considered an agent or employee of Springville City for any purpose, and the employees of Contractor are not entitled to any of the benefits that Springville city provides for City's employees. It is understood that Springville City does not agree to use Contractor exclusively. It is further understood that Contractor is free to contract for similar services to be performed for others while working under the provisions of this AGREEMENT with Springville City.

Both parties agree that Contractor shall be deemed an independent contractor in the performance of this AGREEMENT, and shall comply with all laws regarding unemployment insurance, disability insurance, and workers’ compensation. As such, Contractor shall have no authorization, express or implied, to bind Springville City to any agreement, settlement, liability, or understanding whatsoever, and agrees not to perform any acts as agent for Springville City.

INSURANCE:

The Contractor agrees to carry Commercial General Liability insurance coverage equal to or greater than $1,000,000 per occurrence and $3,000,000 aggregate or as modified by the risk manager pursuant to state statute during the term of this Agreement. This coverage shall provide liability insurance to cover the activities of Contractor including Contractor’s agents, employees and subcontractors, and for all equipment and vehicles, public or private, used in the performance of this Agreement. This insurance shall name “Springville City, 110 South Main, Springville, Utah 84663" as an additional insured.

Prior to commencing any work, Contractor shall provide a Certificate of Insurance to Springville City, evidencing that the Contractor has this insurance in place and shall maintain said insurance for the duration of this Agreement.

Prior to execution of the Agreement, the selected Contractor shall provide a Certificate of

Insurance to Springville City evidencing that the Contractor has Workers Compensation Insurance for the

Contractor, all subcontractors, and all employees of the Contractor and/or subcontractors.

The Contractor shall file all required certificates of insurance with the Springville City Public

Works Department in a timely manner following the Closing Date for Receipt of Bids.

LEGAL:

The Contractor shall be responsible to provide all legal support for the project including but not limited to the preparation of contracts with subcontractors.

LICENSE:

The Contractor shall have a current “Business License”, issued by the county or city in which the

Contractor’s business is located, and shall provide proof of such license prior to the commencement of said work.

The Contractor shall be a licensed “General Contractor” through the State of Utah, Utah Division of Occupational and Professional Licensing, to perform construction work in this State. He shall provide proof of such license prior to the commencement of said work.

NON-DISCRIMINATION AND EQUAL OPPORTUNITY:

The Contractor agrees to comply with all federal statutes relating to nondiscrimination. These include but are not limited to: (a) Title VI of the Civil Rights Act of 1964 (P.L. 88-352) which prohibits discrimination on the basis of race, color or national origin; (b) Title IX of the Education Amendments of

1972, as amended (20 U.S.C. §§ 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; (c) Section 504 of the Rehabilitation Act of 1973, as amended (29 U.S.C. § 794), which prohibits discrimination on the basis of handicaps and the Americans with Disabilities Act of 1990; (d) the Age

Discrimination Act of 1974, as amended (42 U.S.C. §§ 6101-6107), which prohibits discrimination on the basis of age; (e) the Drug Abuse Office and Treatment Act of 1972 (P.L. 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; (f) the Comprehensive Alcohol Abuse and Alcoholism

Prevention, Treatment and Rehabilitation Act of 1970 (P.L. 91-616), as amended, relating to the nondiscrimination on the basis of alcohol abuse or alcoholism; (g) §§ 523 and 527 of the Public Health

Service Act of 1912 (42 U.S.C. 290 dd-3 and 290 ee-3), as amended, relating to confidentiality of alcohol and drug abuse patient records; (h) Title VIII of the Civil Rights Act of 1968 (42 U.S.C. § 3601 et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; (I) any other nondiscrimination provisions in any specific statute(s) applicable to any Federal funding for this

Agreement; and (j) the requirements of any other nondiscrimination statute(s) which may apply to this

LAWS AND ORDINANCES:

The laws of the State of Utah shall govern the Contract. Further, the place of performance and transaction of business shall be deemed to be in the Utah County, Utah, and in the event of litigation, exclusive venue and place of jurisdiction shall be Utah, and more specifically, the district court of Utah

County, Utah.

The Contractor agrees to register and participate in a Status Verification System such as E-Verify, to verify the work eligibility status of the Contractor's new employees that are employed in the state. The

Contractor further agrees to have each contractor or subcontractor who works for or under main contractor, certify by affidavit that the contractor or subcontractor has verified through a Status

Verification System the employment status of each new employee of the respective contractor or subcontractor.

NOTICES:

All notices, demands and other communications required or permitted to be given hereunder shall be in writing and shall be deemed to have been properly given if delivered by hand or by certified mail, return receipt requested, postage paid, to the parties at their addresses first above written, or at such other addresses as may be designated by notice given hereunder.

PAYMENT:

The Contractor shall be paid by Springville City within 30 days of the invoice. All bills must be received by the Streets Department Superintendent. Each bill shall be itemized as to work performed and shall show progress of the work that can be verified. Actual payment will be based upon inspection by the

Streets Department Superintendent who will certify that the work has been performed in a workmanlike manner. Payments may be withheld from the Contractor by the City in order to protect or offset the City from loss due to:

1. Defective work not remedied.

2. Liens or claims filed or reasonable evidence of probable filing.

3. The Contractor’s failure to promptly pay subcontractors for labor and/or materials accepted by the Contractor.

4. The City’s reasonable doubt that the project can be completed for the unpaid balance of the contract price.

5. Damage to another contractor.

6. Failure to maintain scheduled progress.

7. Any other failure of the Contractor which results in liability for the City.

LIQUIDATED DAMAGES:

The Contractor agrees to deliver services as quoted in this proposal. Failure to deliver as quoted constitutes an event of default. The actual damages to the City for the delay will be difficult or impossible to determine. Therefore, in lieu of actual damages, the Contractor shall pay the City, liquidated damages for each calendar day of delay, an amount of $300.00 per day, up to a maximum of sixty (60) calendar days. Should the Contractor be unable to complete the delivery at the end of the sixty (60) day period, the

City, at its option, may treat the contract as breached, terminate the contract, purchase substitute product else-where, and charge the full increase, if any, in cost and handling for such purchase to the defaulting

Contractor, and seek such additional relief as provided by law. The Contractor shall not be charged for liquidated damages when delay arises out of causes beyond control and without the fault or negligence of the Contractor.

UTILITIES:

Care shall be taken to preserve and protect existing utilities, pole lines, signs, pipelines and improvements from injury or damage during construction operations. The Contractor shall hold

Springville City harmless and reimburse owners and utilities for any damage to their properties, utilities, pole lines, signs, pipelines and improvements, and interference with their service caused through

Contractor’s operations. The Contractor has the responsibility for contacting "Blue Stake".

WARRANTY:

The Contractor warrants to Springville City that all materials furnished under this Agreement will be new unless otherwise specified, and that all work will be of good quality, free from faults and defects and in conformance with this Agreement. All work not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective. If required by

Springville City, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment.

If, within one year after the Date of Substantial Completion of the work, or designated portion thereof, or within one year after acceptance by Springville City, or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by this Agreement, any of the work or materials are found to be defective or does not conform with this Agreement, the

Contractor shall correct it promptly after receipt of a written notice from Springville City to do so. This obligation shall survive termination of this Agreement.

SECTION 3 - REQUIREMENTS & SPECIFICATIONS

INTENT OF AGREEMENT:

The intent of the Agreement is to provide for the construction and completion in every detail of the pavement work as described. The Contractor shall furnish all labor, materials, equipment, tools, transportation, traffic control and supplies required to complete the work in accordance with the

Specifications, General Requirements, and terms of this Agreement.

ALTERATION OF PLANS OR CHARACTER OF WORK:

The Streets Department Superintendent reserves the right to make at any time during the progress of the work, such increases or decreases in quantities and such alterations in the details of construction, and the elimination of one or more items as may be found necessary or desirable. Such alterations may include small projects for other City departments during the term of the agreement. Alterations shall not be considered as a waiver of or release of the surety. The Contractor agrees to accept the work as altered the same as if it had been a part of the original Agreement. The Contractor shall proceed with the work alterations when ordered in writing. Financial increases to this Agreement must be approved by

Springville City before additional work is authorized and constructed.

AUTHORITY OF THE CITY ENGINEER:

The City Engineer will decide all questions which may arise as to the quality, quantity and acceptability of materials furnished and work performed and as to the rate of progress of work. He will also decide all questions which may arise as to the acceptable fulfillment of the Agreement on the part of the Contractor. The City Engineer will have the authority by written order to suspend work wholly or in part due to the failure of the Contractor to correct conditions unsafe for the workmen or general public;

for failure to carry out provisions of the Agreement; for failure to carry out orders; for such periods as he may deem necessary due to unsuitable weather; for conditions considered unsuitable for the progress of the work; or for any other condition or reason deemed to be in the public interest. Written orders shall state the reason for suspension.

SPECIFICATIONS:

Springville City is accepting bids for a Contractor to Mill & Overlay the roads located in

Springville City. All work performed by the Contractor shall meet or exceed all applicable specifications listed in the publication American Public Works Association - Manual of Standard Specifications, 1997

Edition, published by the Utah Chapter of the American Public Works Association, hereinafter referred to as the “Manual of Standard Specifications”.

1. CITY ROAD LOCATIONS

A. S Frontage Rd. (2000 W) From 400 S to 700 S

Mill & Overlay work to be completed by June 30, 2026.

2. CLEANING/ROAD PREPARATION

A. The Contractor shall clean the existing asphalt road surface of all dirt, sand, oil, grease and loose materials by sweeping pavements before paving to ensure a clean surface, before tack is applied.

3. MILL AND OVERLAY

A. The Contractor shall follow Springville city Standards and specs for the following applications:

Full profile mill and overlay 2-inches of asphalt (asphalt specification is PG 64-22) on S

Frontage Rd. (2000 W) from 400 South to 700 South, s tarting on the south side of the intersection at 400 South and S Frontage Rd and ending on the south side of the intersection of

700 South and S Frontage Rd, placement of a geotextile interlayer (in travel lanes), and placement of a 2-inch overlay over the entire roadway surface, and the lowering, raising and collaring of existing manholes and water valves in the project area.

4. TRAFFIC CONTROL - (Section 01555 of the Manual of Standard Specifications)

A. The Contractor shall provide traffic control following the “Manual on Uniform Traffic Control

Devices”. The Contractor Notify all homes / businesses on the streets prior to the construction process. Related costs for ALL traffic control, warning signs and needed flagmen are the responsibility of the Contractor. (UDOT May require a separate traffic control plan as well for 400

South)

B. S Frontage Rd (2000 W) is to remain open during construction. Night work is recommended to ensure business access remains open during business hours.

SECTION 4 - SELECTION CRITERIA

BID PROPOSAL (40)

CONTRACTOR: _________________________ _____________________________

Date

Business License Number

State Contracting License Number

Name, Address, and Phone Number State License Classification Number

The undersigned, after having personally and carefully examined the site of the work, the

Specifications and form of the agreement, all of which are made a part hereof, proposes to furnish all labor, equipment, tools and machinery, and to furnish and deliver all materials not specifically mentioned as being furnished by the local agency, which are required in the construction of the:

2026 Frontage Rd Asphalt Mill & Overlay Bid for Springville City

Bid #2026-005

For the total sum of ___________________________________________________________ Dollars, ($____________.____), as detailed on the Bidding Schedule.

The undersigned further proposes to execute the attached agreement within five working days after the date of the award, and to begin work within five working days after being notified to do so by the local agency, weather pending, and to complete the same on or before June 30, 2026, after the signing of the agreement by both parties. It is understood that Springville City has the right to reject this bid or to accept it at the price listed above and the prices located in the Bidding Schedule.

Signature of the Preparer Company Seal

Title of Preparer

BIDDING SCHEDULE

LOCATION & APPROXIMATE QUANTITIES TOTAL COST

Note: Actual payment for the work shall be based upon the actual work completed, approved and accepted by the Springville City Streets Department Superintendent. Springville City reserves the right to eliminate portions of work from this bid and contract because of budget constraints or high construction costs.

Exhibit A

(Scope of Services)

Responsibilities and Duties: S Frontage Rd (2000 West) from 400 South to 700 South

ITEM DESCRIPTION

ESTIMATED

QUANTITY

UNIT UNIT COST

TOTAL

AMOUNT

1 Mobilization 1 LS

2 Provide traffic control 1 LS

3 SWPP 1 LS

4 Profile Mill 8,159 SY

5 2” Overlay 8,159 SY

6 Lower, raise and collar manholes 18 Each

7 Lower, raise and collar water valves 15 Each

BID TOTAL

PREVIOUS PROJECT EXPERIENCE (30)

Describe previous experience, showing satisfactory completion or progress on work of similar complexity and comparable in scope to that described herein. Demonstrate recent experience in Asphalt projects.

Include projects that have occurred in the last 3 years, including “in progress” and completed” Asphalt projects. Include past and current projects for Springville City. Provide the following information:

Project Experience Summary

Project Name, location, and description:

(Feel Free to use additional pages)

PERSONNEL/PROJECT MANAGER/PROJECT ENGINEER/SUPERINTENDENT (30)

Provide names for the proposed project specifically for the individuals outlined below: • Project Manager

• Alternate Project Manager • Superintendent(s) The proposed project manager assigned to the project should have at least five (5) years of experience in Asphalt projects. Submit the name of the project manager who will be assigned to the project.

Project Manager Experience Summary

Proposed Project Manager’s Name: __________________________

Years of Experience in Asphalt Maintenance: _______________

Demonstrate experience in Asphalt Maintenance.

Project name, location, and description:

(Feel Free to use additional pages)

Contractor's Signature

QUALITY CONTROL AND MATERIALS TESTING

1.01 SECTION INCLUDES

A. Responsibilities for controlling quality of materials, products and workmanship.

B. Responsibilities for manufacturer’s instructions, certificates and field service.

1.02 MATERIALS

A. All materials incorporated in the project shall be new and shall fully comply with the specifications.

Unless otherwise clearly provided in the specifications, all workmanship, equipment, materials, and articles incorporated in the work covered by the contract are to be of the best available grade of their respective kinds. Whenever, in the specifications, any material, article, device, product, fixture, form, type of construction, or process indicated or specified by patent or proprietary name, by name of manufacturer, or by catalog number, such specifications shall be deemed to be used for the purpose of establishing a standard of quality and facilitating the description of the material or process desired and shall be deemed to be followed by the words "or approved equal" and CONTRACTOR may in such case, upon receiving the ENGINEER's approval, purchase and use any item, type, or process which shall be substantially equal in every respect to that indicated or specified.

B. Materials and equipment may be used in the Work based upon receipt of a Supplier’s certificate of compliance. Certificate must be in possession of CONTRACTOR and reviewed by OWNER prior to use.

C. Quality Assurance Testing by the OWNER shall not relieve CONTRACTOR of responsibility to furnish materials and work in full compliance with Contract Documents.

1.03 MANUFACTURER’S INSTRUCTIONS

A. Should instructions conflict with Contract Documents, request clarification before proceeding.

B. When required in individual sections, submit manufacturer’s instructions in the quantity required for product data, delivery, handling, storage, assembly, installation, start-up, adjusting, balancing, and finishing, as appropriate.

1.04 MANUFACTURER’S CERTIFICATES

A. When required in individual sections, submit manufacturer’s certificate in duplicate executed by responsible officer certifying that product meets or exceeds specified requirements.

1.05 MANUFACTURER’S FIELD SERVICES

A. When required in individual sections, have manufacturer or Supplier provide qualified representative to observe field conditions, conditions of surfaces and installation, quality of workmanship, start-up of equipment, test, adjust, and balance of equipment as applicable and to make written report of observations and recommendations to OWNER.

1.06 WORKMANSHIP

A. Maintain performance control and supervision over Subcontractors, Suppliers, manufacturers, products, services, workmanship, and site conditions, to produce work in accordance with Contract

Documents.

B. Comply with industry standards except when more restrictive tolerances or specified requirements indicate more rigid standards or more precise workmanship.

C. Provide suitable qualified personnel to produce specified quality.

D. Ensure finishes match approved samples.

1.07 INSPECTION AND TESTING OF MATERIALS

A. Testing agency and testing for quality control and material testing shall be furnished by

CONTRACTOR as part of the project. Results of testing shall be reported to CONTRACTOR and

OWNER on site. Reports of the testing shall be transmitted directly to the OWNER.

B. Materials to be supplied under this contract will be tested and/or inspected either at their place of origin or at the site of the work by the testing agency. CONTRACTOR shall give the OWNER written notification well in advance of actual readiness of materials to be tested and/or inspected at point of origin so OWNER may witness testing by the testing agency. Satisfactory tests and inspections at the point of origin shall not be construed as a final acceptance of the material nor shall it preclude retesting or re-inspection at the site of the work.

C. CONTRACTOR shall furnish such samples of materials as are requested by the OWNER, without charge. No material shall be used until reports from the testing agency have been reviewed and accepted by the OWNER. See Section 01300, CONTRACTORs Submittal.

1.08 UNSATISFACTORY CONDITIONS

A. Examine areas and conditions under which materials and products are to be installed. Do not proceed with work until unsatisfactory conditions have been corrected in a manner acceptable to installer.

1.09 QUALITY CONTROL TESTING

A. OWNER’s failure to detect any defective Work or materials does not prevent later rejection when such defect is discovered nor does it obligate OWNER for acceptance.

B. CONTRACTOR shall provide 24-hours minimum notice to OWNER for all testing required by these specifications so that OWNER may be present during testing.

1.10 TESTING ACCEPTANCE AND FREQUENCY

A. Minimum Quality Control Testing Frequency: As defined in Table 01440-1, the CONTRACTOR shall be responsible to ensure that all testing is performed at the frequencies shown.

CONTRACTOR shall uncover any work at no cost to OWNER to allow the testing agency to perform required testing at the frequency shown.

MOBILIZATION

1.01 GENERAL

A. This Section is provided to cover CONTRACTOR's cost of general and miscellaneous responsibilities and operations not normally attributed to, or included in, any other single bid item. This shall include, but not necessarily be limited to, work described or enumerated in this section under the following subsections. Costs for listed work shall be included in the lump-sum price for "Mobilization".

1.02 MOVING TO AND FROM THE JOB SITE

A. This shall include CONTRACTOR's preliminary arrangement for starting and stopping construction operations, work schedules, and transportation of equipment and personnel to and from the project.

1.03 CLEAN-UP

A. The cost of all clean-up work as specified and not covered under other items shall be included in the Bid.

1.04 TEMPORARY UTILITIES

A. Any temporary services and utilities such as telephone, electrical, water, toilet facilities, etc., shall be the responsibility of the CONTRACTOR and shall be included in the Bid.

1.05 PERFORMANCE BOND, PAYMENT BOND, AND INSURANCE

A. The cost of the performance bond, payment bond, and any required insurance and/or other miscellaneous cost associated with this project shall be included with the Bid.

1.06 PERMITS

A. CONTRACTOR shall provide all necessary permits for completion of the work.

1.07 PRE-CONSTRUCTION VIDEO RECORDS

A. The Contractor shall provide a video tape record with coverage to allow accurate determination of location, size and condition, etc. of existing features and improvements within the designated work area.

PROTECTION OF EXISTING FACILITIES

A. Any existing facilities, disturbed which are located in or adjacent to the line of work such as curbs, gutters, drive approaches, sidewalks, driveways, fences, underground pipes, conduits, or utilities, shall be cleaned up and restored in kind by the Contractor and in accordance with the specifications contained herein governing the various types of services involved.

1.02 RESTORATION OF FENCES

A. Where it is necessary to remove any fence to facilitate the Contractor's operation, the Contractor shall obtain prior agreement with the Owner for removal of the fence, and shall be responsible for any damage due to negligence of the Contractor. As soon as practical, the fence shall be restored substantially to the same or improved condition as it was prior to the commencement of the work. Where livestock is present the Contractor shall provide temporary fencing to keep livestock away from the construction area.

1.03 INTERFERING STRUCTURES AND UTILITIES

A. The Contractor shall exercise all possible caution to prevent damage to existing structures and utilities, whether above ground or underground. It shall be the responsibility of the Contractor to locate and expose all existing underground and overhead structures and utilities in such a manner as to prevent damage to same. The Contractor shall notify all utility offices concerned at least 48 hours in advance of construction operations in which a utility agency's facilities may be involved. This shall include, but not be limited to, irrigation water, culinary water, telephone, gas, and electric. The Contractor shall be responsible for any and all changes to, reconnections to public utility facilities encountered or interrupted during prosecution of the work, and all costs relating hereto shall be at the

Contractor's expense. The Contractor shall contract with and pay Public Utility Agencies for work required in connection with all utility interferences and handle all necessary notifications, scheduling, coordination, and details.

The cost of public utility interferences shall be included in the Contractor's lump sum or unit price bid covering the major contract facility to which interference or changes are attributable.

B. Any damages to private property, either inside or outside the limits of the easements provided by the Owner, shall be the responsibility of the Contractor. Any roads, structures, or utilities damaged by the work shall be repaired or replaced in a condition equal to or better than the condition prior to the damage. Such repair or replacement shall be accomplished at the Contractor's expense without additional compensation from the Owner.

C. The Contractor shall remove and replace small miscellaneous structures such as fences and culverts which are damaged by the construction activity at his own expense without additional compensation from the Owner. The

Contractor shall replace these structures in a condition as good as or better than their original condition.

D. The Contractor shall saw cut the edge of existing drive approaches, where necessary, to prevent their damage during removal and replacement of the adjacent asphalt surface. Drive approaches which are damaged by the construction activity shall be repaired by the Contractor at his own expense without additional compensation from the Owner. The Contractor shall replace these structures in a condition as good as or better than their original condition.

E. At points where the Contractor's operations are adjacent to or across properties of railway, telegraph, telephone, irrigation canal, power, gas, water, or adjacent to other property (damage to which might result in considerable expense, loss, and inconvenience), no work shall be started until all arrangements necessary for the protection thereof have been made.

F. The locations of the major existing culinary water lines, gas pipes, underground electric, cable television, and telephone lines that are shown on the plans, were taken from city maps, and maps supplied by the utility owner. It should be expected that some location discrepancies will occur. Neither the Owner nor its officers or agents shall be responsible for damages to the Contractor as a result of the locations of the utilities being other than those shown on the plans or for the existence of utilities not shown on the plans.

G. The Contractor shall be solely and directly responsible to the Owners and operators of such properties for any damage, injury, expense, loss or inconvenience, delay, suits, actions, or claims of any character brought because of an injury or damage which may result from the carrying out of the work to be done under the contract.

H. In the event of interruption to either domestic or irrigation water, or to other utility services as a result of accidental breakage, or as a result of being exposed or unsupported, the Contractor shall promptly notify the proper authority. The Contractor shall cooperate with the authority in restoration of service as soon as possible, and shall not allow interruption of any water or utility service outside working hours unless prior approval is received.

1.04 RIGHTS-OF-WAY

A. The Contractor shall be required to confine construction operations within the dedicated rights-of-way for public through fares, or within areas for which construction easements have been obtained, unless they have made special arrangements with the affected property owners in advance. The Contractor shall be required to protect stored materials, cultivated trees and crops, and other items adjacent to the proposed construction site.

B. The Contractor shall submit for approval by the Engineer the type and size of equipment used, and the methods for work performed on the rights-of-way across private properties, to avoid or minimize injury to trees, shrubs, gardens, lawns, fences, driveways, retaining walls, or other improvements within the rights-of-way. Property owners affected by the construction shall be notified by the Contractor at least 48 hours in advance of the time the construction begins. During all construction operations, the Contractor shall construct and maintain such facilities as may be required to provide access by all property owners to their property. No person shall be cut off from access to his property for a period exceeding 8 hours unless the Contractor has made special arrangements with the affected persons. The Contractor shall, daily or more frequently, if necessary, grade all disturbed areas to be smooth for motor vehicle traffic.

JOB CONDITIONS

1.01 SITE INVESTIGATION

A. CONTRACTOR acknowledges that he has satisfied himself as to the nature and location of the work; the general and local conditions, particularly those bearing upon availability of transportation, access to the site, disposal, handling and storage of materials, availability of labor, water, electric power, roads, and uncertainties of weather, river stages, or similar physical conditions at the site; the conformation and conditions of the ground; the character of equipment and facilities needed preliminary to and during the prosecution of the work; and all other matters which can in any way affect the work or the cost thereof under this Contract.

CONTRACTOR further acknowledges that he has satisfied himself as to the character, quality, and quantity of surface and subsurface materials to be encountered from his inspection of the site and from reviewing any available records of exploratory work furnished by OWNER or included in these Documents. Failure by CONTRACTOR to acquaint himself with the physical conditions of the site and all the available information will not relieve him from responsibility for properly estimating the difficulty or cost of successfully performing the work.

CONTRACTOR warrants that as a result of his examination and investigation of all the aforesaid data that he can perform the work in a good and workmanlike manner and to the satisfaction of OWNER. OWNER assumes no responsibility for any representations made by any of its officers or agents during or prior to the execution of this

Contract, unless (1) such representations are expressly stated in the Contract, and (2) the Contract expressly provides that the responsibility therefor is assumed by OWNER.

B. STREET USE. Nothing herein shall be construed to entitle CONTRACTOR to the exclusive use of any public street, alleyway, or parking area during the performance of the work hereunder, and CONTRACTOR shall so conduct operations as not to interfere unnecessarily with the authorized work of utility companies or other agencies in such streets, alleyways, or parking areas. No street shall be closed to the public without first obtaining permission of the

ENGINEER and proper governmental authority.

1.02 WEATHER CONDITIONS

In the event of temporary suspension of work, or during inclement weather, the Contractor will, and will cause its

Subcontractors to, protect any project work or materials against damage from the weather. If, in the opinion of the

Engineer, any Project work or materials become damaged by reason of failure on the part of the Contractor or any of its Subcontractors to so protect its work, such work or materials shall be removed and replaced at the expense of the

Contractor.

1.04 SURFACE UTILITIES

Manholes, valve boxes and covers, survey monuments, drop inlets and other service entrances shall be protected from the mill and overlay by methods approved by the City Engineer, Public Works Inspector or designated representative.

All existing paint striping centerlines, bike lanes, crosswalks, and any and all paint existing to be marked with tabs by the contractor prior to any work, to identify existing paint markings to be re-painted.

1.05 SURFACE PREPARATION

Immediately prior applying the pavement surface, the surface shall be cleared of all loose material, silt spots, vegetation and other objectionable material. The Contractor shall maintain on the project site a “pick-up broom or street sweeper and a water truck with a minimum two thousand (2,000) gallon capacity. The Contractor shall be responsible to secure a source of water and shall obtain the necessary permission for its use.

1.06 CONTRACTOR'S WORK AND STORAGE AREA

A. CONTRACTOR shall make arrangements for any necessary offsite storage or shop areas necessary for the proper execution of the work.

1.07 MEASUREMENT AND PAYMENT

A. Job conditions shall not be measured or paid as a separate item, but shall be included as part of the various items to which it relates.

TRAFFIC CONTROL

A. The Contractor shall comply with all rules and regulations of the City, County, and State authorities regarding the closing of public streets or highways. If conditions justify, the Engineer may authorize the Contractor to conduct his work in specific areas and to specific tasks to avoid sporadic and unorganized work efforts.

B. All work performed on or within the right-of-way of state roads shall have traffic control devices in place before work begins that meet the requirements of Utah Department of Transportation's "Specifications for Excavation on State Highways".

C. No road shall be closed by the Contractor to the public except by express permission of the ENGINEER and after obtaining the required permits. Where it is necessary to close a county or city road to thru traffic, the road shall be closed to thru traffic only - not local traffic. The road shall be closed for two (2) blocks only, not over 1,500 feet.

The road shall be barricaded at each point of public access with barricades meeting the Utah Department of

Transportation's specifications.

D. Road closures for final paving purposes may be longer as negotiated with the ENGINEER.

E. Center Street & 400 East, 400 South & 400 East and 800 South& 400 East intersections: two of the three intersections must remain open at all times.

F. Variable Message Signs (VMS) are required to be placed in a location in advance of the construction zone

(both traffic directions), at a minimum of two (2) working days in advance of closures on

• 400 North – From 400 West to 860 East

• 400 East – From Main St. (1400 North) to SR89

• Center Street – From 1300 East to 1500 West

• 400 South – From 1300 East to Main Street

• 800 South – From 800 East to US 89

G. Traffic must be kept open on those roads and streets where no detour is possible. The Contractor shall, at all times, conduct his work so as to insure the least possible obstruction to traffic and normal commercial pursuits. All obstructions within traveled roadways shall be protected by approved signs, barricades, and lights where necessary for the safety of the traveling public. The convenience of the general public and residents, and the protection of persons and property is of prime importance and shall be provided for by the Contractor in an adequate and satisfactory manner.

H. Excavations on project sites from which the public is excluded shall be marked or guarded in a manner appropriate for the hazard.

1.02 TRAFFIC CONTROL

A. For the protection of traffic in public or private streets and ways, the Contractor shall provide, place, and maintain all necessary barricades, traffic cones, warning signs, lights, and other safety devices in accordance with the requirements of the "Manual of Uniform Traffic Control Devices, Part VI - Traffic Controls for Street and

Highway Construction and Maintenance Operations," published by U.S. Department of Transportation, Federal

Highway Administration (ANSI D6.1). The Contractor shall take all necessary precautions for the protection of the work and the safety of the public. All barricades and obstructions shall be illuminated at night, and all lights shall be kept burning from sunset until sunrise. The Contractor shall station such guards or flaggers and shall conform to such special safety regulations relating to traffic control as may be required by the public authorities within their respective jurisdictions. All signs, signals, and barricades shall conform to the requirements of Subpart G, Part

1926, of the OSHA…