01 YTPM 13-0015_Repair Roof MEPCOM_Specs_March 2023_Final.pdf

DESIGN SPECIFICATIONS

100% CORRECTED FINAL DESIGN SUBMITTAL

REPAIR ROOF, MEPCOM FACILITY, BUILDING 5411

Westover Air Reserve Base (WARB), Chicopee, MA

Project No.: YTPM 13-0015

Prepared for:

439th CIVIL ENGINEER SQUADRON Westover ARB, Chicopee, MA

Prepared By:

Wood-ZAPATA JV 1105 Lakewood Parkway, Suite 300

Alpharetta, GA 30009

March 2023

03.16.2023

THIS PAGE INTENTIONALLY LEFT BLANK

REPAIR ROOF, MEPCOM FACILITY CHICOPEE (WARB)

BUILDING 5411 MA

PROJECT TABLE OF CONTENTS

DI VI SI ON 00 - PROCUREMENT AND CONTRACTI NG REQUI REMENTS

00 00 10 01/23 CONTRACT LINE ITEM SCHEDULE

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 11 00 08/15, CHG 2: 08/21 SUMMARY OF WORK

01 14 00 11/11, CHG 14: 02/22 WORK RESTRICTIONS

01 14 00.01 01/23 439 AW FORM 1 APPLICATION FOR 439 AW

BIDS IDENTIFICATION CREDENTIAL

01 14 00.02 01/23 439 AW FORM 20 CONTRACTOR INFORMATION

SHEET

01 30 00 11/20, CHG 2: 05/22 ADMINISTRATIVE REQUIREMENTS

01 30 00.01 01/23 RECOVERED MATERIALS DETERMINATION FORM

01 32 16.00 20 08/18, CHG 1: 08/20 SMALL PROJECT CONSTRUCTION PROGRESS

SCHEDULES

01 33 00 08/18, CHG 4: 02/21 SUBMITTAL PROCEDURES

01 33 00.01 01/23 AF3000 MATERIAL HANDLING APPROVAL

01 33 00.02 03/23 SUBMITTAL REGISTER

01 35 26 11/20, CHG 3: 02/22 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 02/19 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.10 20 02/10, CHG 3: 02/21 QUALITY CONTROL FOR MINOR CONSTRUCTION

01 50 00 11/20, CHG 2: 08/22 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 08/22 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 02/19, CHG 3: 11/21 CONSTRUCTION WASTE MANAGEMENT AND

DISPOSAL

01 74 19.01 01/23 QUARTERLY SOLID WASTER DISPOSAL REPORT

01 78 00 05/19, CHG 1: 08/21 CLOSEOUT SUBMITTALS

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00 05/10, CHG 2: 02/19 DEMOLITION

02 82 00 11/18, CHG 1: 11/19 ASBESTOS REMEDIATION

02 82 00.01 01/23 NESHAP SURVEY REPORT

DI VI SI ON 05 - METALS

05 05 23.16 08/18 STRUCTURAL WELDING

05 30 00 05/15, CHG 2: 08/18 STEEL DECKS

DI VI SI ON 06 - WOOD, PLASTI CS, AND COMPOSI TES

06 10 00 08/16 ROUGH CARPENTRY

DI VI SI ON 07 - THERMAL AND MOI STURE PROTECTI ON

07 22 00 02/16, CHG 3: 11/18 ROOF AND DECK INSULATION

07 31 13 08/16, CHG 2: 08/18 ASPHALT SHINGLES

07 42 13 05/11, CHG 2: 02/18 METAL WALL PANELS

07 60 00 05/17, CHG 2: 11/18 FLASHING AND SHEET METAL

07 92 00 08/16, CHG 3: 11/18 JOINT SEALANTS

DI VI SI ON 08 - OPENI NGS

08 90 00 03/23 LOUVERS AND VENTS

PROJECT TABLE OF CONTENTS Page 1

DI VI SI ON 31 - EARTHWORK

31 00 00 08/08, CHG 2: 02/21 EARTHWORK

DI VI SI ON 32 - EXTERI OR I MPROVEMENTS

32 92 19 08/17, CHG 1: 08/21 SEEDING

DI VI SI ON 33 - UTI LI TI ES

33 40 00 11/21 STORMWATER UTILITIES

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 00 10

CONTRACT LINE ITEM SCHEDULE

01/23

PART 1 CONTRACT LINE ITEM SCHEDULE - BID SCHEDULE

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

DOCUMENT 00 00 10 Page 1

DOCUMENT 00 00 10 Page 2

SECTION 00 00 10

CONTRACT LINE ITEM SCHEDULE

01/23

PART 1 CONTRACT LINE ITEM SCHEDULE - BID SCHEDULE

Offeror’s Name: ________________________________________

ITEM# DESCRIPTION TOTAL

0001 Per Drawings, Specifications and as described here:

Westover Air Reserve Base Building 5411 is an existing 1-story building consisting of an exterior brick cavity wall with metal stud back up, steel structure and asphalt shingle roof. The facility currently serves as a Military Entrance Processing Command (MEPCOM) facility. This project primarily consists of the replacement of an existing 3-tab asphalt shingle roofing system and modifications to the existing conditions to update flashing and roof drainage conditions to current code requirements.

Lot $______________

0002 Temporary Facilities-Per Drawings, Specifications and as described here:

Provide a trailer with 450 SF minumum,set onepole/transformer for temporary electric, and temporary network service from the building to the trailer. Coordinate additional requirments with the Contracting Officer.

Lot $______________

TOTAL BID $_______________

AWARD: Only one award will be made as result of this solicitation and such award will be made in the aggregate to the low responsible and responsive bidder. Bidder must bid on all items. Failure to do so shall be cause for rejection of the bid.

NOTE: Although not specifically identified in item 0001 above, all items specified in Technical Provisions and shown on the Contract Drawings are incorporated in this schedule.

PART 2 PRODUCTS

NOT USED

DOCUMENT 00 00 10 Page 3

0003 Metal Roof Deck Replacement:

Provide a unit cost per SF to replace deteriorated metal decking covered by the existing roof system up to 10% (2600 SF) of the roof deck throughout the building. This is a Not to Exceed (NTE) line item. Payment will be made based on actual square footage coordinated and replaced.

Cost/SF $______________ Lot $______________

PART 3 EXECUTION

NOT USED

-- End of Section --

DOCUMENT 00 00 10 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/ 15, CHG 2: 08/ 21

PART 1 GENERAL

1.1 SUBMITTALS

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.3 OCCUPANCY OF PREMISES

1.4 EXISTING WORK

1.5 LOCATION OF UNDERGROUND UTILITIES

1.5.1 Notification Prior to Excavation

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 11 00 Page 1

SECTION 01 11 00 Page 2

SECTION 01 11 00

SUMMARY OF WORK

08/ 15, CHG 2: 08/ 21

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval and shall be maintained by the Contractor and made available to the Government upon request.

SD-01 Preconstruction Submittals

Af Form 103; G

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes: removing and replacing the entire roof system from asphalt shingles to the top of the existing metal roof deck. The existing roof system consists of asphalt shingles, underlayment, sheathing, 2" thick rigid insulation nailers, and 3" thick rigid insulation adhered to the metal decking. The new roof system will include new asphalt shingles,underlayment, roof sheathing, air space with pressure treated wood nailers, and rigid insulation mechanically fastened to the metal roof deck. All associated flashing will be replaced. Additionally, all gutters and downspouts will be replaced. Downspouts that discharge at grade will continue to do so. Downspouts that enter the underground drainage system will be provided with new 6" cast iron downspout boots, and incidental related work.

1.2.2 Location

The work is located at 551 Airlift Drive on Westover ARB, MA, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

The building will be occupied during performance of work under this Contract. Occupancy notifications shall be posted in a prominent location in the work area. The work is required to be phased such that no more roofing is torn off than can be replaced in a single working day, and the building dried in at the end of every working day. Some coordination will be required with the COR and User Group as testing that is noise sensitive occurs in the building. This may require work outside of normal business hours.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

SECTION 01 11 00 Page 3

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

The Contractor shall submit a notification prior to excavation or any ground disturbing activity. The notification shall be AF Form 103, BCE Work Clearance Request (Dig Permit) and shall be submitted to the Contracting Officer at least 7 days prior to the planned excavation.

Additional information will be provided at the Pre-Construction Conference. The Contractor shall obtain approval prior to excavation. The government will mark out known existing underground utilities in the work area. The marked location of the existing utilities is approximate.

Excavation by power driven equipment is not permitted within 3 feet of either side of the marked utility. Hand excavate on each side of the indicated obstruction and continue until uncovered or clearance for the new grade is assured

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 11 00 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00.01

439 AW FORM 1 APPLICATION FOR 439 AW BIDS IDENTIFICATION CREDENTIAL

01/23

PART 1 GENERAL

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 14 00.01 Page 1

SECTION 01 14 00.01 Page 2

SECTION 01 14 00.01

439 AW FORM 1

APPLICATION FOR 439 AW BIDS IDENTIFICATION CREDENTIAL

01/23

PART 1 GENERAL

439 AW FORM 1 APPLICATION FOR 439 AW BIDS IDENTIFICATION CREDENTIAL

PART 2 PRODUCTS

NOT USED

PART 3 EXECUTION

NOT USED

SECTION 01 14 00.01 Page 3

SECTION 01 14 00.01 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00.02

439 AW FORM 20 CONTRACTOR INFORMATION SHEET

01/23

PART 1 GENERAL

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 14 00.02 Page 1

SECTION 01 14 00.02 Page 2

SECTION 01 14 00.02

439 AW FORM 20 CONTRACTOR INFORMATION SHEET

01/23

PART 1 GENERAL

439 AW FORM 20 CONTRACTOR INFORMATION SHEET

PART 2 PRODUCTS

NOT USED

PART 3 EXECUTION

NOT USED

SECTION 01 14 00.02 Page 3

SECTION 01 14 00.02 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00

WORK RESTRICTIONS

11/ 11, CHG 14: 02/ 22

PART 1 GENERAL

1.1 SUBMITTALS

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

1.2.1.1 Subcontractors and Personnel Contacts

1.2.1.2 439 AW Form 20 - Contractor Information Sheet

1.2.1.3 AQ-06 Construction/Demolition Notification

1.2.1.4 Base Access

1.2.1.5 No Smoking Policy

1.2.2 Working Hours

1.2.3 Work Outside Regular Hours

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 QUARTERLY REPORTS

SECTION 01 14 00 Page 1

SECTION 01 14 00 Page 2

SECTION 01 14 00

WORK RESTRICTIONS

11/ 11, CHG 14: 02/ 22

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval and shall be maintained by the Contractor and made available to the Government upon request.

SD-01 Preconstruction Submittals

List of Contact Personnel

439 AW Form 20 - Contractor Information Sheet; G

SD-06 Test Reports

Quarterly Report Demo, Debris Disposal And Recycling

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Ensure all Contractor equipment, include delivery vehicles, are clearly identified with their company name.

1.2.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.2.1.2 439 AW Form 20 - Contractor Information Sheet

Contractor shall provide a completed 439 AW Form 20 - Contractor Information Sheet. Section 01 74 19_01 439 AW Form 20 is provided following this section and must "track" substances such as toxic materials, hazardous materials, VOCs-volatile organic compounds and HAPs-hazardous air pollutants (e.g., paint, epoxy, sealants, solvents etc.). Here are a few examples (not exhaustive list): Paints, Adhesives, Cleaners/Strippers, Coatings, Degreasers/Solvents, Fuels, Oils, Refrigerants. At the Following paragraphs (a thru c)during the project, Contractor shall provide to Westover (439 MSG/CEV Environmental Office) the form called '439 AW Form 20 Contractor Information Sheet':

a. INITIAL SUBMITTAL OF FORM 20 DURING PRE-CONSTRUCTION PHASE. Prior

SECTION 01 14 00 Page 3 to breaking ground, the contractor must submit a completed 439 AW Form 20 Contractor Information Sheet with a Material Safety Data Sheet (MSDS) for each item. The AW Form 20 identifies the product and EXPECTED usage amounts for each item. Submit MSDS for any product/chemical that is stored ON-BASE. Examples of some products include, but not limited to: Paints, Adhesives, leaners/Strippers, Coatings, Degreasers/Solvents, Fuels, Oils, Refrigerants.

b. SUBMITTAL AT END OF EACH CALENDAR YEAR. If the contract crosses more than one calendar year, by 30 December of each year, contractor must report the ACTUAL annual usage amounts of each material. (Contractor may report this data to the government using any format chosen by the Contractor.)

c. SUBMITTAL AT PROJECT COMPLETION. Submit final usage amounts at project completion. (Contractor may report this data to the government using any format chosen by the Contractor.)

1.2.1.3 AQ-06 Construction/Demolition Notification

Contractor shall go on-line to https://www.mass.gov/how-to/aq-06-constructiondemolition-notification and fill out the required information for the AQ-06 form. Once filled out, the contractor shall provide confirmation of the completed and accepted form to Westover ARB.

1.2.1.4 Base Access

Every worker in need of access to the site shall submit a copy of 439 AW Form 1, Application for 439 AW DBIDS Identification Credential, at least seven days prior to the date access is needed.

1.2.1.5 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.2.2 Working Hours

Regular working hours must consist of a period established by the Contracting Officer, between 8 a.m. and 5 p.m., Monday through Friday, excluding Government holidays. No work shall be conducted on Saturdays or Sundays except for emergent situations, such as failure of temporary dry-in systems.

1.2.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer.

SECTION 01 14 00 Page 4

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.1 QUARTERLY REPORTS

Contractor shall complete and submit the Quarterly Report Westover Construction/Demo Debris Disposal & Recycling Form that is attached with the Specifications.

SECTION 01 14 00 Page 5

SECTION 01 14 00 Page 6

REPAIR ROOF, MEPCOM FACILITY, BLDG 5411

YTPM 13-0015

551 AIRLIFT DRIVE

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.01

RECOVERED MATERIALS DETERMINATION FORM

01/23

PART 1 GENERAL

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 30 00.01 Page 1

SECTION 01 30 00.01 Page 2

SECTION 01 30 00.01

RECOVERED MATERIALS DETERMINATION FORM

01/23

PART 1 GENERAL

Recovered Materials Determination Form

PART 2 PRODUCTS

NOT USED

PART 3 EXECUTION

NOT USED

SECTION 01 30 00.01 Page 3

SECTION 01 30 00.01 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/ 20, CHG 2: 05/ 22

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 COLOR BOARDS FOR AIR FORCE PROJECTS

1.4 VIEW LOCATION MAP

1.5 PROGRESS AND COMPLETION PICTURES

1.6 Recovered Materials Determination Form

1.7 SUPERVISION

1.7.1 Superintendent Qualifications

1.7.2 Minimum Communication Requirements

1.7.3 Duties

1.7.4 Non-Compliance Actions

1.8 PRECONSTRUCTION

1.8.1 Attendees

1.9 FACILITY TURNOVER PLANNING MEETINGS

1.9.1 Meetings

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 30 00 Page 1

SECTION 01 30 00 Page 2

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/ 20, CHG 2: 05/ 22

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety -- Safety and Health Requirements Manual

1.2 SUBMITTALS

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval and shall be maintained by the Contractor and made available to the Government upon request.

SD-01 Preconstruction Submittals

View Location Map

Progress and Completion Pictures

SD-04 Samples

Color Boards; G

1.3 COLOR BOARDS FOR AIR FORCE PROJECTS

Submit one set of color boards each for CE and Contracting Agent within 90 calendar days after Contract Award. Each set of boards must include samples of colors and finishes of interior surfaces, such as walls, floors, and ceilings. Present the samples on 8 by 10-1/2 inches boards (modules) with a maximum spread of 24 by 31-1/2 inches for foldouts.

Design modules to fit in a standard loose-leaf, three-ring binder. Where special finishes such as architectural concrete, carpet, or prefinished textured metal panels are required, submit samples not less than 12 inches square with the board. If more space is needed, more than one board per set may be submitted. Certify that the color samples have been reviewed in detail, and that the color samples are in strict accordance with contract drawings and specifications, except as may be otherwise explicitly stated. Submittal of color samples does not relieve the Contractor of the responsibility to submit samples required elsewhere herein.

1.4 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as

SECTION 01 30 00 Page 3 required if the locations are moved.

1.5 PROGRESS AND COMPLETION PICTURES

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600x1200x24 bit true color minimum resolution in JPEG file format showing the sequence and progress of work. Take a minimum of one (1) set of digital photographs each week throughout the entire project from a minimum of ten different viewpoints selected by the Contractor unless otherwise directed by the Contracting Officer. Provide a view sketch and digital photographs on a CD(s) for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Photographs provided are for unrestricted use by the Government.

1.6 Recovered Materials Determination Form

See Recovered Materials Determination Form attached behind this spec section for EPA-designated items included in the Comprehensive Procurement Guideline (CPG) Program.

1.7 SUPERVISION

1.7.1 Superintendent Qualifications

Provide project superintendent with a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

For projects where the superintendent is permitted to also serve as the Quality Control (QC) Manager as established in Section QUALITY CONTROL, the superintendent must have qualifications in accordance with that section.

1.7.2 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of Contract work.In addition, if a Quality Control (QC) representative is required on the Contract, then that individual must also have fluent English communication skills.

1.7.3 Duties

The project superintendent is primarily responsible for managing subcontractors and coordinating day-to-day production and schedule adherence on the project. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

SECTION 01 30 00 Page 4

1.7.4 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion.

Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.8 PRECONSTRUCTION

Prior to commencing any work at the site, coordinate with the Contracting Officer a time and place to meet for the Preconstruction Meeting. The purpose of this is to discuss and develop a mutual understanding of the administrative requirements of the Contract including but not limited to:

daily reporting, invoicing, value engineering, safety, base-access, outage requests, hot work permits, schedule requirements, quality control, schedule of prices or earned value report, shop drawings, submittals, cybersecurity, prosecution of the work, government acceptance, final inspections and contract close-out. Contractor must present and discuss their basic approach to scheduling the construction work and any required phasing.

1.8.1 Attendees

Contractor attendees must include the Project Manager, Superintendent, Site Safety and Health Officer (SSHO), Quality Control Manager and major subcontractors.

1.9 FACILITY TURNOVER PLANNING MEETINGS

Meet with the Government to identify strategies to ensure the project is carried to expeditious closure and turnover to the Client. Start planning the turnover process at the Pre-Construction Conference meeting with a discussion of the process and convene at regularly scheduled Meetings beginning at approximately 75 percent of project completion. Include the following in the facility Turnover effort:

1.9.1 Meetings

a. Conduct regular Meetings beginning at approximately 75 percent project completion, or three to six months prior to Beneficial Occupancy Date (BOD), whichever comes first.

b. The Contracting Officer will establish the frequency of the meetings, which is expected to increase as the project completion draws nearer.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 5

SECTION 01 30 00 Page 6

Westover ARB Affirmative Procurement Plan

Recovered Materials Determination Form (Adapted from EPA website form)

Instructions The procurement originator should complete this form when EPA-designated items included in the Comprehensive Procurement Guideline (CPG) Program are being purchased. For questions on whether the product counts as "EPA-designated" or what the required recycled content is, refer to product descriptions at the EPA CPG website. The completed form becomes part of the official contract file located in the Operational Contracting office.

This form is not required for items requisitioned from established Federal supply sources, for construction contracts less than $2,000 or for other purchases less than $2,500.

Project Number: YTPM xx-xxxx, Title

Complete one of the following:

Case I.

None of the items being procured for this contract are EPA designated items.

***OR***

Case II. The EPA-designated items being procured are:

___ Building insulation ___ Printing and writing papers ___ Playground surfaces ___ Structural fiberboard ___ Newsprint ___ Running tracks ___ Laminated paperboard ___ Paperboard and packaging ___ Plastic fencing (snow or

Cement & concrete containing: ___ Office recycling containers erosion control, safety barriers) ___ Coal fly ash or ___ Office waste receptacles ___ Park and recreational ___ Ground granulated blast furnace slag ___ Plastic desktop accessories furniture ___ Polyester carpet ___ Toner cartridges ___ Playground equipment ___ Carpet cushion ___ Binders (paper, solid plastic or ___ Traffic barricades ___ Floor tiles plastic covered) ___ Traffic cones ___ Patio blocks ___ Plastic trash bags ___ Parking Stops ___ Shower & restroom dividers/partitions ___ Printer ribbons ___ The following temporary ___ Latex paint ___ Plastic envelopes ___ traffic control devices:

___ Flowable fill ___ Plastic clipboards ___ Channelizers ___ Railroad grade crossings/surfaces ___ Plastic file folders ___ Delineators ___ Hydraulic mulch ___ Plastic clip portfolios ___ Flexible delineators ___ Compost from yard or food waste ___ Plastic presentation folders ___ Engine Coolants ___ Garden and soaker hoses ___ Awards and plaques ___ Re-refined lubricating oils ___ Lawn and garden edging ___ Tray liners ___ Retread tires ___ Landscaping timbers and posts ___ Commercial/industrial sanitary ___ Industrial drums ___ (plastic lumber) tissue products ___ Pallets ___ Sorbents ___ Mats ___ Signage ___ Strapping and stretch wrap

Project Proponent (Title/Signature) Date

X X

YTPM 13-0015, Repair Roof, MEPCOM Facility, Building 5411

X http://www.epa.gov/epaoswer/non-hw/procure/products.htm

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 16.00 20

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

08/ 18, CHG 1: 08/ 20

PART 1 GENERAL

1.1 SUBMITTALS

1.2 PRE-CONSTRUCTION SCHEDULE REQUIREMENT

1.3 SCHEDULE FORMAT

1.3.1 Bar Chart Schedule

1.3.2 Schedule Submittals and Procedures

1.4 SCHEDULE MONTHLY UPDATES

1.5 3-WEEK LOOK AHEAD SCHEDULE

1.6 CORRESPONDENCE AND TEST REPORTS:

1.7 ADDITIONAL SCHEDULING REQUIREMENTS

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 32 16.00 20 Page 1

SECTION 01 32 16.00 20 Page 2

SECTION 01 32 16.00 20

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

08/ 18, CHG 1: 08/ 20

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval and shall be maintained by the Contractor and made available to the Government upon request.

SD-01 Preconstruction Submittals

Baseline Construction Schedule; G

SD-07 Certificates

Monthly Updates

1.2 PRE-CONSTRUCTION SCHEDULE REQUIREMENT

Prior to the start of work, prepare and submit to the Contracting Officer a Baseline Construction Schedule in the form of a Bar Chart Schedule in accordance with the terms in Contract Clause FAR 52.236-15 Schedules for Construction Contracts, except as modified in this contract. The approval of a Baseline Construction Schedule is a condition precedent to:

a. The Contractor starting demolition work or construction stage(s) of the contract.

b. Processing Contractor's invoice(s) for construction activities/items of work.

c. Review of any schedule updates.

Submittal of the Baseline Construction Schedule, and subsequent schedule updates, is understood to be the Contractor's certification that the submitted schedule meets the requirements of the Contract Documents, represents the Contractor's plan on how the work will be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).

1.3 SCHEDULE FORMAT

1.3.1 Bar Chart Schedule

The Bar Chart must, as a minimum, show work activities, submittals, Government review periods, material/equipment delivery, utility outages, on-site construction, inspection, testing, and closeout activities. The Bar Chart must be time scaled and generated using an electronic spreadsheet program.

SECTION 01 32 16.00 20 Page 3

1.3.2 Schedule Submittals and Procedures

Submit Schedules and updates in hard copy and on electronic media that is acceptable to the Contracting Officer. Submit an electronic back-up of the project schedule in an import format compatible with the Government's scheduling program.

1.4 SCHEDULE MONTHLY UPDATES

Update the Construction Schedule at monthly intervals or when the schedule has been revised. Keep the updated schedule current, reflecting actual activity progress and plan for completing the remaining work. Submit copies of purchase orders and confirmation of delivery dates as directed by the Contracting Officer.

a. Narrative Report: Identify and justify the following:

(1) Progress made in each area of the project;

(2) Longest Path: Include printed copy on 11 by 17 inch paper, landscape setting;

(3) Date/time constraint(s), other than those required by the contract;

(4) Listing of changes made between the previous schedule and current updated schedule including: added or removed activities, original and remaining durations for activities that have not started, logic (sequence, constraint, lag/lead), milestones, planned sequence of operations, longest path, calendars or calendar assignments, and cost loading.

(5) Any decrease in previously reported activity Earned Amount;

(6) Pending items and status thereof, including permits, changes orders, and time extensions;

(7) Status of Contract Completion Date and interim milestones;

(8) Current and anticipated delays (describe cause of delay and corrective actions(s) and mitigation measures to minimize);

(9) Description of current and future schedule problem areas.

For each entry in the narrative report, cite the respective Activity ID and Activity Name, the date and reason for the change, and description of the change.

1.5 3-WEEK LOOK AHEAD SCHEDULE

Prepare and issue a 3-Week Look Ahead schedule to provide a more detailed day-to-day plan of upcoming work identified on the Construction Schedule.

Key the work plans to activity numbers when a NAS is required and update each week to show the planned work for the current and following two-week period. Additionally, include upcoming outages, closures, preparatory meetings, and initial meetings. Identify critical path activities on the Three-Week Look Ahead Schedule. The detail work plans are to be bar chart type schedules, maintained separately from the Construction Schedule on an electronic spreadsheet program and printed on 8-1/2 by 11 inch sheets as directed by the Contracting Officer. Activities must not exceed 5 working

SECTION 01 32 16.00 20 Page 4 days in duration and have sufficient level of detail to assign crews, tools and equipment required to complete the work. Provide one electronic file of the 3-Week Look Ahead Schedule to the Contracting Officer no later than 8 a.m. each Monday, and review during the weekly CQC Coordination or Production Meeting.

1.6 CORRESPONDENCE AND TEST REPORTS:

Correspondence (e.g., letters, Requests for Information (RFIs), e-mails, meeting minute items, Production and QC Daily Reports, material delivery tickets, photographs) must reference Schedule Activities that are being addressed. Test reports (e.g., concrete, soil compaction, weld, pressure) must reference Schedule Activities that are being addressed.

1.7 ADDITIONAL SCHEDULING REQUIREMENTS

Any references to additional scheduling requirements, including systems to be inspected, tested and commissioned, that are located throughout the remainder of the Contract Documents, are subject to all requirements of this section.

The work schedule shall be coordinated with the COR and Users. The building will remain occupied during construction, and the Users require advance notice of the expected area(s) of work so that they can make arrangements for temporary facilities for noise-sensitive processes.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 32 16.00 20 Page 5

SECTION 01 32 16.00 20 Page 6

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00.01

AF3000 MATERIAL HANDLING APPROVAL

01/23

PART 1 GENERAL

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 33 00.01 Page 1

SECTION 01 33 00.01 Page 2

SECTION 01 33 00.01

AF3000

MATERIAL HANDLING APPROVAL

01/23

PART 1 GENERAL

MATERIAL HANDLING APPROVAL

PART 2 PRODUCTS

NOT USED

PART 3 EXECUTION

NOT USED

SECTION 01 33 00.01 Page 3

SECTION 01 33 00.01 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00.02

SUBMITTAL REGISTER

03/23

PART 1 GENERAL

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 33 00.02 Page 1

SECTION 01 33 00.02 Page 2

SECTION 01 33 00.02

SUBMITTAL REGISTER

03/23

PART 1 GENERAL

SUBMITTAL REGISTESR

PART 2 PRODUCTS

NOT USED

PART 3 EXECUTION

NOT USED

SECTION 01 33 00.02 Page 3

SECTION 01 33 00.02 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

08/ 18, CHG 4: 02/ 21

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

1.1.2 Approving Authority

1.1.3 Work

1.2 SUBMITTALS

1.3 SUBMITTAL CLASSIFICATION

1.3.1 Government Approved (G)

1.3.2 For Information Only

1.4 PREPARATION

1.4.1 Transmittal Form

1.4.2 Submittal Format

1.4.2.1 Format of SD-01 Preconstruction Submittals

1.4.2.2 Format for SD-02 Shop Drawings

1.4.2.2.1 Drawing Identification

1.4.2.3 Format of SD-03 Product Data

1.4.2.3.1 Product Information

1.4.2.3.2 Standards

1.4.2.3.3 Data Submission

1.4.2.4 Format of SD-04 Samples

1.4.2.4.1 Sample Characteristics

1.4.2.4.2 Sample Incorporation

1.4.2.4.3 Comparison Sample

1.4.2.5 Format of SD-05 Design Data

1.4.2.6 Format of SD-06 Test Reports

1.4.2.7 Format of SD-07 Certificates

1.4.2.8 Format of SD-08 Manufacturer's Instructions

1.4.2.8.1 Standards

1.4.2.9 Format of SD-09 Manufacturer's Field Reports

1.4.2.10 Format of SD-10 Operation and Maintenance Data (O&M)

1.4.2.11 Format of SD-11 Closeout Submittals

1.4.3 Source Drawings for Shop Drawings

1.4.3.1 Source Drawings

1.4.3.2 Terms and Conditions

1.5 QUANTITY OF SUBMITTALS

1.5.1 Number of SD-01 Preconstruction Submittal Copies

1.5.2 Number of SD-04 Samples

1.6 INFORMATION ONLY SUBMITTALS

1.7 PROJECT SUBMITTAL REGISTER

1.7.1 Submittal Management

1.7.2 Preconstruction Use of Submittal Register

1.7.3 Contractor Use of Submittal Register

1.7.4 Approving Authority Use of Submittal Register

1.7.5 Delivery of Copies

1.8 VARIATIONS

SECTION 01 33 00 Page 1

1.8.1 Considering Variations

1.8.2 Proposing Variations

1.8.3 Warranting that Variations are Compatible

1.8.4 Review Schedule Extension

1.9 SCHEDULING

1.10 GOVERNMENT APPROVING AUTHORITY

1.10.1 Review Notations

1.11 DISAPPROVED SUBMITTALS

1.12 APPROVED SUBMITTALS

1.13 APPROVED SAMPLES

PART 2 PRODUCTS

PART 3 EXECUTION

ATTACHMENTS:

"01 33 00 Submittal Register

SECTION 01 33 00 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

08/ 18, CHG 4: 02/ 21

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval and shall be maintained by the Contractor and made available to the Government upon request.

SD-01 Preconstruction Submittals

Preconstruction Submittals include schedules and a tabular list of locations, features, and other pertinent information regarding products, materials, equipment, or components to be used in the work.

Certificates Of Insurance

Surety Bonds

List Of Proposed Subcontractors

List Of Proposed Products

Baseline Network Analysis Schedule (NAS)

Submittal Register

Schedule Of Prices Or Earned Value Report

Work Plan

Quality Control (QC) plan

Environmental Protection Plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, SECTION 01 33 00 Page 3 instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards ensuring work can be judged. Includes assemblies or portions of assemblies that are to be incorporated into the project and those that will be removed at conclusion of the work.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report that includes findings of a test required to be performed on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report that includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports

Daily logs and checklists

Final acceptance test and operational test procedure

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that the product, system, or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, SECTION 01 33 00 Page 4 installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits

Text of posted operating instructions

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (SDS)concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative at the job site, in the vicinity of the job site, or on a sample taken from the job site, on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must be signed by an authorized official of a testing laboratory or agency and state the test results; and indicate whether the material, product, or system has passed or failed the test.

Factory test reports.

SD-10 Operation and Maintenance Data

Data provided by the manufacturer, or the system provider, including manufacturer's help and product line documentation, necessary to maintain and install equipment, for operating and maintenance use by facility personnel.

Data required by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

Data incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

1.1.2 Approving Authority

Office or designated person authorized to approve the submittal.

SECTION 01 33 00 Page 5

1.1.3 Work

As used in this section, on-site and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction. In exception, excludes work to produce SD-01 submittals.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" classification.

Submittals not having a "G" classification are for Contractor Quality Control approval and shall be maintained by the Contractor and made available to the Government upon request.

SD-01 Preconstruction Submittals

Submittal Register; G

1.3 SUBMITTAL CLASSIFICATION

1.3.1 Government Approved (G)

Within the terms of the Contract Clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION, submittals are considered to be "shop drawings."

1.3.2 For Information Only

Submittals not requiring Government approval will be for information only. Within the terms of the Contract Clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION, they are not considered to be "shop drawings."

1.4 PREPARATION

1.4.1 Transmittal Form

Use Air Force form AF3000.

1.4.2 Submittal Format

1.4.2.1 Format of SD-01 Preconstruction Submittals

When the submittal includes a document that is to be used in the project, or is to become part of the project record, other than as a submittal, do not apply the Contractor's approval stamp to the document itself, but to a separate sheet accompanying the document.

Provide data in the unit of measure used in the contract documents.

1.4.2.2 Format for SD-02 Shop Drawings

Provide shop drawings not less than 8 1/2 by 11 inches no more than 30 by 42 inches, except for full-size patterns or templates. Prepare drawings to accurate size, with scale indicated, unless another form is required.

Ensure drawings are suitable for reproduction and of a quality to produce clear, distinct lines and letters, with dark lines on a white background.

a. Include the nameplate data, size, and capacity on drawings. Also include applicable federal, military, industry, and technical society

SECTION 01 33 00 Page 6 publication references.

b. Dimension drawings, except diagrams and schematic drawings. Prepare drawings demonstrating interface with other trades to scale. Use the same unit of measure for shop drawings as indicated on the contract drawings. Identify materials and products for work shown.

1.4.2.2.1 Drawing Identification

Include on each drawing the drawing title, number, date, and revision numbers and dates, in addition to information required in paragraph

IDENTIFYING SUBMITTALS.

Number drawings in a logical sequence. Each drawing is to bear the number of the submittal in a uniform location next to the title block. Place the Government contract number in the margin, immediately below the title block, for each drawing.

Reserve a blank space, no smaller than 1-1/2 inches on the right-hand side of each sheet for the Government disposition stamp.

1.4.2.3 Format of SD-03 Product Data

Present product data submittals for each section. Include a table of contents, listing the page and catalog item numbers for product data.

Indicate, by prominent notation, each product that is being submitted;

indicate the specification section number and paragraph number to which it pertains.

1.4.2.3.1 Product Information

Supplement product data with material prepared for the project to satisfy the submittal requirements where product data does not exist. Identify this material as developed specifically for the project, with information and format as required for submission of SD-07 Certificates.

Provide product data in units used in the Contract documents. Where product data are included in preprinted catalogs with another unit, submit the dimensions in contract document units, on a separate sheet.

1.4.2.3.2 Standards

Where equipment or materials are specified to conform to industry or technical-society reference standards of such organizations as the American National Standards Institute (ANSI), ASTM International (ASTM), National Electrical Manufacturer's Association (NEMA), Underwriters Laboratories (UL), or Association of Edison Illuminating Companies (AEIC), submit proof of such compliance. The label or listing by the specified organization will be acceptable evidence of compliance. In lieu of the label or listing, submit a certificate from an independent testing organization, competent to perform testing, and approved by the Contracting Officer. State on the certificate that the item has been tested in accordance with the specified organization's test methods and that the item complies with the specified organization's reference standard.

SECTION 01 33 00 Page 7

1.4.2.3.3 Data Submission

Collect required data submittals for each specific material, product, unit of work, or system into a single submittal that is marked for choices, options, and portions applicable to the submittal. Mark each copy of the product data identically. Partial submittals will not be accepted for expedition of the construction effort.

Submit the manufacturer's instructions before installation.

1.4.2.4 Format of SD-04 Samples

1.4.2.4.1 Sample Characteristics

Furnish samples in the following sizes, unless otherwise specified or unless the manufacturer has prepackaged samples of approximately the same size as specified:

a. Sample of Equipment or Device: Full size.

b. Sample of Materials Less Than 2 by 3 inches: Built up to 8 1/2 by 11 inches.

c. Sample of Materials Exceeding 8 1/2 by 11 inches: Cut down to 8 1/2 by 11 inches and adequate to indicate color, texture, and material variations.

d. Sample of Linear Devices or Materials: 10 inch length or length to be supplied, if less than 10 inches. Examples of linear devices or materials are conduit and handrails.

e. Sample Volume of Nonsolid Materials: Pint. Examples of nonsolid materials are sand and paint.

f. Color Selection Samples: 2 by 4 inches. Where samples are specified for selection of color, finish, pattern, or texture, submit the full set of available choices for the material or product specified. Sizes and quantities of samples are to represent their respective standard unit.

g. Sample Panel: 4 by 4 feet.

h. Sample Installation: 100 square feet.

1.4.2.4.2 Sample Incorporation

Reusable Samples: Incorporate returned samples into work only if so specified or indicated. Incorporated samples are to be in undamaged condition at the time of use.

Recording of Sample Installation: Note and preserve the notation of any area constituting a sample installation, but remove the notation at the final clean-up of the project.

1.4.2.4.3 Comparison Sample

Samples Showing Range of Variation: Where variations in color, finish, pattern, or texture are unavoidable due to nature of the materials, submit sets of samples of not less than three units showing extremes and middle

SECTION 01 33 00 Page 8 of range. Mark each unit to describe its relation to the range of the variation.

When color, texture, or pattern is specified by naming a particular manufacturer and style, include one sample of that manufacturer and style, for comparison.

1.4.2.5 Format of SD-05 Design Data

Provide design data and certificates on 8 1/2 by 11 inch paper.

1.4.2.6 Format of SD-06 Test Reports

By prominent notation, indicate each report in the submittal. Indicate the specification number and paragraph number to which each report pertains.

1.4.2.7 Format of SD-07 Certificates

Provide design data and certificates on 8 1/2 by 11 inch paper.

1.4.2.8 Format of SD-08 Manufacturer's Instructions

Present manufacturer's instructions submittals for each section. Include the manufacturer's name, trade name, place of manufacture, and catalog model or number on product data. Also include applicable federal, military, industry, and technical-society publication references. If supplemental information is needed to clarify the manufacturer's data, submit it as specified for SD-07 Certificates.

Submit the manufacturer's instructions before installation.

1.4.2.8.1 Standards

Where equipment or materials are specified to conform to industry or technical-society reference standards of such organizations as the American National Standards Institute (ANSI), ASTM International (ASTM), National Electrical Manufacturer's Association (NEMA), Underwriters Laboratories (UL), or Association of Edison Illuminating Companies (AEIC), submit proof of such compliance. The label or listing by the specified organization will be acceptable evidence of compliance. In lieu of the label or listing, submit a certificate from an independent testing organization, competent to perform testing, and approved by the Contracting Officer.