FAR 52.211-11 Liquidated Damages-Supplies, Services, or Research and Development
Clause Federal Acquisition Regulation Sep 2000 version
Facts
- Citation
- FAR 52.211-11
- Type
- Clause
- Current version
- September 2000
- Prescribed in
- FAR 11.503(a)
- Last amended
- 65 FR 46064 Effective Sep 25, 2000
- Text as of
- FAC 2026-01
- Official text
- acquisition.gov
Text from acquisition.gov. Federal Register history from the Federal Register's records of the rules that amended this clause.
Text
As prescribed in 11.503(a), insert the following clause in solicitations and contracts:
Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)
(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $[fill-in] per calendar day of delay [Contracting Officer insert amount].
(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.
(End of clause)
Federal Register history
| Final rule | Published | Effective |
|---|---|---|
| Federal Acquisition Regulation; Liquidated Damages |
Quick answers
What is FAR 52.211-11?
FAR 52.211-11 is a clause of the Federal Acquisition Regulation, titled "Liquidated Damages-Supplies, Services, or Research and Development".
What is the current version of FAR 52.211-11?
The current version is dated September 2000.
Where is FAR 52.211-11 prescribed?
It is prescribed in FAR 11.503(a), Contract clauses.
When was FAR 52.211-11 last changed?
The most recent final rule on record is "Federal Acquisition Regulation; Liquidated Damages" (65 FR 46064), published Jul 26, 2000 and effective Sep 25, 2000.
Are changes to FAR 52.211-11 proposed?
No proposed rule from the last 3 years is waiting on a final rule.
On GovTribe
Follow the rules behind federal contracts
- Search Federal Register rules and proposed rules for the FAR, DFARS and agency supplements
- Solicitations, awards and government files in one search
- Ask GovTribe AI about the rules that apply to a contract