FAR 42.1305 Contract clauses
Section Federal Acquisition Regulation
Facts
- Citation
- FAR 42.1305
- Type
- Section
- Last amended
- 86 FR 61017 Effective Dec 6, 2021
- Text as of
- FAC 2026-01
- Official text
- acquisition.gov
Text from acquisition.gov. Federal Register history from the Federal Register's records of the rules that amended this section.
Text
(a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.
(b)
(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.
(2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its AlternateI.
(c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial products. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial products.
Federal Register history
Sections cited
- FAR 52.242-14 Suspension of Work
- FAR 52.242-15 Stop-Work Order
- FAR 52.242-17 Government Delay of Work
Quick answers
What is FAR 42.1305?
FAR 42.1305 is a section of the Federal Acquisition Regulation, titled "Contract clauses".
When was FAR 42.1305 last changed?
The most recent final rule on record is "Federal Acquisition Regulation: Revision of Definition of “Commercial Item”" (86 FR 61017), published Nov 4, 2021 and effective Dec 6, 2021.
Are changes to FAR 42.1305 proposed?
No proposed rule from the last 3 years is waiting on a final rule.
On GovTribe
Follow the rules behind federal contracts
- Search Federal Register rules and proposed rules for the FAR, DFARS and agency supplements
- Solicitations, awards and government files in one search
- Ask GovTribe AI about the rules that apply to a contract