WIN CP2000834 26CSP007 Re-Roof and Building Enclosure Repairs
Closed State & local contract opportunity Posted
- Solicitation number
- 26CSP007
- State
- Texas
- Responses due
Opportunity facts
- NIGP codes
- UNSPSC codes
- 72120000 Nonresidential building construction services
- 71122507 Stack building services
- 95121514 Ticket office
- 72121105 Shopping center and mall construction service
- 72141401 Detention facility construction service
- 95121604 Bus garage
- 95121607 Railway depot
- 95121605 Automotive repair or servicing building
- 95121711 Civic center
- 72152603 Skylight installation service
Show all 43
- 72152606 Siding installation and repair service
- 72141400 Detention facility construction and repair services
- 72121104 Restaurant construction service
- 95121712 Art gallery
- 95121608 Underground railway station
- 95121501 Shopping mall
- 95121715 Public toilet facility
- 95121506 Theater
- 95121705 Fire station
- 72100000 Building and facility maintenance and repair services
- 95121500 Commercial and entertainment buildings and structures
- 95121704 Prison building
- 95121503 Cafeteria
- 95121703 Court building
- 95121606 Railway station
- 95121701 Post office
- 72152601 Roofing service
- 72121100 Commercial and office building construction services
- 95121700 Public buildings and structures
- 72111104 New dormitory construction service
- 72111105 New hotel or motel construction service
- 72121101 Commercial and office building new construction service
- 72141128 Public square construction and or remodelling service
- 95121702 Police station
- 95121603 Bus station
- 95122106 Hostel
- 95121505 Shopping center
- 95121504 Shop building
- 95121714 Public changing room and shower facility
- 95121507 Market
- 95121706 Ambulance station
- 72152600 Roofing and siding and sheet metal services
- 72152602 Gutter and downspout service
- Point of contact
-
- Lana Beranek lana@austin.utexas.edu (512) 232-7037
Opportunity details come from txsmartbuy.com. Updated .
About this opportunity
The University of Texas at Austin is requesting proposals for re-roofing and building enclosure repairs to the F.L. Winship Drama Building under RFP WIN CP2000834 26CSP007, with proposals due September 22, 2026. A completed VetHUB subcontracting plan is a mandatory condition of responsiveness; prime contractors must demonstrate good faith efforts to award subcontracts to service-disabled veteran certified businesses, with notification to at least two state-certified VetHUB vendors per opportunity and a minimum seven-business-day response window.
Respondents must propose a construction team qualified to manage the re-roofing and envelope repair of a continuously occupied academic facility while minimizing disruption to building occupants. The Project Manager and Superintendent must hold current 30-hour OSHA certifications. Proposals must include a minimum of three customer references for similar projects completed within the past five years, detailed safety records covering OSHA Recordable Case Rate and Days Away Restricted Time rates for the prior three years, a preliminary Critical Path Method schedule, quality control and storm water management plans aligned with EPA and University of Texas System standards, and warranty and post-completion support documentation.
Evaluation is scored on a maximum of 100 points, with qualifications constituting a maximum of 60 points distributed across eight criteria: contractor ability to provide construction services; qualifications of the proposed construction team; technical and management competence; past experience with University of Texas System institutions within the past five years; safety program and record; project execution plan and scheduling; quality control and commissioning program; and project close-out capability. Proposals must include detailed information on key personnel, proposed subcontractors, and evidence of past performance on roofing and envelope projects for continuously occupied facilities such as libraries, classrooms, and executive offices. Project drawings are accessible via University of Texas Box. Winning contractors must submit a Prime Contractor Progress Assessment Report with each payment application identifying all first, second, and third-tier subcontractor payments.
Files
On GovTribe
Work this opportunity
- Track it in your pipeline
- Similar opportunities
- Ask GovTribe AI about this opportunity