Whispering Ln Drainage

St. Tammany Parish Government in Louisiana is requesting sealed quotes for drainage improvement work on Whispering Lane in Madisonville, with quotes due September 15, 2026 at 2:00 p.m. Respondents must hold an active Louisiana State Contractor's License for Highway, Street, and Bridge Construction; licensure is mandatory for estimated project costs of $50,000 or more.

The scope includes removal and replacement of cross culverts, catch basins, and sewer tie-ins along the project corridor. The contractor must provide all labor, equipment, tools, and materials. Project completion is required within thirty calendar days from issuance of the Notice to Proceed. Respondents are required to visit the project site and familiarize themselves with all surface and subsurface conditions prior to quote submission.

For projects costing $25,000 or more, a performance bond equal to one hundred percent of the project cost is required within ten working days of request. Respondents must include all applicable taxes and costs in their quote and are responsible for obtaining necessary permits and certificates. Pricing must be firm for the contract term. Award will be made to the lowest monetary quote in compliance with the Quote Request requirements.

Liquidated damages for failure to complete work on schedule range from $500 daily for contracts valued $0–$250,000 to $3,000 daily for contracts exceeding $10 million. Questions are due September 8, 2026, and the addendum deadline is September 10, 2026. Sealed quotes will be opened publicly at St. Tammany Parish Government Procurement Department, 21454 Koop Drive, Suite 2F, Mandeville, Louisiana 70471, with only respondent names identified aloud. The Parish reserves the right to reject any or all quotes or cancel the solicitation.