Peg Keller Rd Drainage

St. Tammany Parish Government is requesting quotes for drainage improvement work on Peg Keller Road (R060031) in Abita Springs, Louisiana, with sealed quotes due November 5, 2026 at 2:00 p.m. The scope is removal and replacement of driveway pipes to improve drainage along the roadway. Site visitation is required; respondents must familiarize themselves with surface and subsurface conditions. The contract term is thirty calendar days from issuance of the Notice to Proceed.

If the estimated cost reaches $50,000 or more, the contractor must hold an active Highway, Street, and Bridge Construction license from the State of Louisiana. For projects costing $25,000 or more, a performance bond equal to 100% of the project cost is required, with the bond cost borne by the contractor. Pricing must be firm for the contract term. The Parish reserves the right to modify estimated quantities by up to 25%.

Liquidated damages apply for failure to complete work within the specified timeframe, assessed at $500 daily for contracts from $0–$250,000, and scaling to $3,000 daily for contracts exceeding $10 million. Award will go to the lowest monetary quote in compliance with the request.

Questions are due October 29, 2026. An addendum deadline is November 2, 2026. Respondents should submit a W-9 if they have not previously done business with the Parish. All materials submitted in response become the property of the Parish.