Fire Station 52 Living Quarters Replacement

The City of San Antonio Public Works Department is issuing a Request for Competitive Sealed Proposals (RFCSP) for construction services for the Fire Station #52 Living Quarters Replacement Improvements project. The project involves the construction of a new 9,000 square foot fire station facility with one EMS bay, apparatus bays, living quarters, and supporting spaces. Key objectives include providing a fully functional station that meets the needs of the assigned area of operations. The RFCSP has a release date of September 20, 2024 and proposals are due on November 5, 2024. A non-mandatory pre-submittal conference is scheduled for October 2, 2024 and a non-mandatory site visit is scheduled for October 3, 2024. The contract will be a 610-calendar day contract with liquidated damages applicable for delays. The estimated construction cost for the project is $9,350,000. Evaluation criteria include the experience and qualifications of the respondent and key personnel (30 points), the respondent's understanding of the project and proposed management plan (20 points), the respondent's experience in the San Antonio region and past performance (15 points), the respondent's price proposal (15 points), and the respondent's SBEDA participation commitment (20 points).

The contract has a SBEDA (Small Business Economic Development Advocacy) participation requirement, indicating a focus on engaging disadvantaged enterprises. No incumbent vendors or current contractors are listed, and the RFCSP does not mention any existing infrastructure or technology that requires integration. The RFCSP does not provide a specific award value or budget range, but states the estimated construction cost for the project is $9,350,000.