Autumn Wind Ln Drainage

St. Tammany Parish Government is requesting sealed quotes for drainage improvement work on Autumn Wind Lane in Mandeville, Louisiana, with quotes due August 11, 2026 at 2:00 p.m. and an inquiry deadline of August 4, 2026.

The scope includes removing and replacing drainpipe and cleaning, shaping, and grading ditches along the designated roadway. Site visitation is required; interested respondents must examine all surface and subsurface conditions. The contractor must provide all labor, materials, equipment, supervision, and permits necessary for completion. Work must be completed within forty-five calendar days from issuance of the Notice to Proceed. The Parish will issue the Notice to Proceed within twenty calendar days of contract execution, and the contractor must commence work within ten calendar days of receiving it.

If the estimated cost is $50,000 or more, the contractor must hold an active Louisiana state license for Highway, Street and Bridge Construction classification. For projects costing $25,000 or more, a performance bond equal to 100 percent of the project cost is required, issued by an approved surety company and provided within ten working days of request. Liquidated damages apply for failure to complete work on time, with daily charges ranging from $500 to $3,000 depending on the original contract amount.

The contract is awarded to the lowest monetary quote in compliance with the Quote Request. Quoted prices must be firm for the contract term. Insurance requirements, indemnification provisions, and compliance with applicable federal, state, and local laws are mandatory. The Parish reserves the right to reject any or all quotes, cancel the solicitation, increase or decrease estimated quantities by up to twenty-five percent, and make changes without notice to the contractor's surety. An addendum deadline is August 6, 2026.