13431-20241023101342 Brandon

The City of Brandon, Mississippi is seeking qualified bidders for the Tennis Facilities Rehabilitation project. The contract includes the rehabilitation of tennis and pickleball courts at Shiloh Park and City Park, involving repairs to the post-tension slab, removal and replacement of nets and posts, and resurfacing and restriping of the courts. The project includes 3 tennis court batteries, a 4-court tennis battery, junior tennis courts, and pickleball courts. The contract duration is 90 calendar days, with liquidated damages of $500 per day for late completion. Sealed bids will be received until November 26, 2024 at 1:00 pm local time and will be publicly opened and read aloud. Bidders must be qualified under Mississippi law and possess a Certificate of Responsibility. A bid bond or certified check for 5% of the total bid is required, and the successful bidder must provide proof of insurance and 100% performance and payment bonds prior to starting work.

The City of Brandon encourages minority and women's business enterprises to bid as prime contractors and inquire about subcontracting opportunities. The City reserves the right to determine responsible bidders, accept the lowest and best bid, and waive any informalities in the bidding process. The project is expected to exceed $50,000, and the City has not identified any incumbent vendors or current contractors. The available budget range for this contract is not specified in the provided documentation.