W912HN24B4004 Project No 097292 Construct CDC Addition

*************VIRTUAL PUBLIC BID OPENING INFORMATION********************

Virtual Public Bid Opening - W912HN24B4004 - PN 097292 Construct CDC Addition
Hosted by SRM - USACE Savannah District

https://usace1.webex.com/usace1/j.php?MTID=mae8cbcdb6f4510353fd5b466df5e0b2f
Wednesday, August 28, 2024 12:00 PM | 1 hour | (UTC-04:00) Eastern Time (US & Canada)
Meeting number: 2826 351 1572
Password: fGaNpKM2*27

Join by video system
Dial 28263511572@usace1.webex.com
You can also dial 207.182.190.20 and enter your meeting number.

Join by phone
+1-844-800-2712 US Toll Free
+1-669-234-1177 US Toll

Access code: 282 635 11572

_____________________________________________________________

AMD 0005 - Drawings and Specifications have been changed. Proposal due date is 28 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain the same.

AMD 0004 - Proposal due date has been extended to 20 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

AMD 0005 - Drawings and Specifications have been changed. Proposal due date is 28 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain the same.

AMD 0004 - Proposal due date has been extended to 20 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoDs Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

AMD 1004 - THIS AMENDMENT EXTENDS THE PROPOSAL DUE DATE, HOWEVER AMD 0005 WILL INCLUDE SPECIFICATION CHANGES THAT ANSWER THE FINAL RFI/PROJNET INQUIRIES.

FINAL PROPOSAL DUE DATE IS 28 AUG 2024 AT 1100hrs via PIEE

AMD 0004 - Proposal due date has been extended to 20 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

***************AN ADDITIONAL AMENDMENT WILL BE POSTED THE MORNING OF 20 AUGUST THAT WILL EXTEND PROPOSAL DUE DATE******************* PLEASE STAND BY

AMD 0004 - Proposal due date has been extended to 20 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

AMD 0004 - Proposal due date has been extended to 20 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

AN EXTENSION TO PROPOSAL DUE DATES IS FORTHCOMING THIS MORNING

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

***************Geotech report has been published.*********************

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

AMD 0003 - Proposal due date has been extended to 15 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 15 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project.

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

AMD 0002 – Proposal due date has been extended to 6 August 2024 at 1100hrs local time via the PIEE Solicitation Module. All other terms and conditions remain unchanged.

We are working on responses to the Projnet Inquiries at this time. Thank you.

 **********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 6 August 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

**********PRE-BID SITE VISIT ROSTER HAS BEEN PUBLISHED BELOW************

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 22 July 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/ 

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

AMD 0001 - Provided the corrected Volume 3 specifications and some administrative updates to the Liquidated Damages and Work Description within the solicitation. All other terms and conditions remain unchanged.

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 22 July 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/ 

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil

W912HN24B4004

Project No.: 097292

Construct CDC Addition

FORT EISENHOWER, GA

The U.S. Army Corps of Engineers {USACE) Savannah District is issuing an Invitation for Bid (IFB) W912HN24B4004 for Project Number: 097292, Construct CDC Addition, Fort Eisenhower Georgia.

Type of Contract & NAICS: This Acquisition is being solicited using FAR Part 14, Sealed Bid Procedures for one (1) Firm-Fixed-Price (FFP) contract. The North American Industry Classification System (NAICS) code is 236220 – Commercial and Institutional Building Construction, with a Small Business size standard of $45M.

Product Service Code: Y1CZ – Construction of other Education Buildings

Type of Set-Aside: This acquisition is being offered as a Service-Disabled Veteran Owned Small Business (SDVOSB) Set-Aside

Construction Magnitude: In accordance with DFARS 236.204, the magnitude of this construction project is anticipated to be between $10,000,000 and $25,000,000.

Proposal Due Date: 22 July 2024 - 1100 EDT via PIEE.

Site Visit: 10 July 2024 – 0900 at 1236 Lane Avenue, Fort Eisenhower Area Office

Period of Performance: The period of performance including all options is 1,350 Calendar Days after the issuance of the notice to proceed.

Project Scope: This is a new requirement to construct an Addition to Bldg. 18407 Child Development Center for approximately 120-130 children. The current building is a standard design child development center with outdoor play areas for children between the ages 6 weeks - 5 years of age. The facility addition will include developmental learning modules, activity areas, an isolation room, changing areas, patron visitor waiting area, administrative support space, staff lounge work room, kitchen, laundry, storage, supply rooms, installation of a video monitoring, alarm and intercom systems for safety, information systems, fire protection and alarm systems, Intrusion Detection System (IDS) installation, and Energy Monitoring Control Systems (EMCS) connection. In addition, the facility will include an outdoor play area with age-appropriate child development equipment, safety surfacing and fencing. Sustainability and energy enhancement measures are included. Supporting activities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping, and signage. Heating and air conditioning will be provided by self-contained system. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. Access for individuals with disabilities will be provided. Comprehensive building and furnishings related interior design services are required. Facilities will be designed to a minimum life of 40 years in accordance with DoD's Unified Facilities Criteria (UFC 1-200-02) including energy efficiencies, building envelope and integrated building systems performance and Air Conditioning (Estimated 10 Tons).

This project is fully designed, and all technical specifications and drawings will be provided at the issuance of the Solicitation.

Solicitation Website: The official solicitation, when posted, will be available free of charge by electronic posting only and may be found on the System of Award Management System {SAM) website, https://sam.gov. Paper copies of the solicitation will not be issued. Therefore, telephone and Fax requests for this solicitation will not be honored.

Project files are Portable Document Format (PDF) files and can be viewed, navigated, or printed using Adobe Acrobat Reader. Contractors must register at the SAM website at https://sam.gov to download the solicitation for this project

 Amendments will be posted to the above-referenced website for electronic downloading. This will be the only method of distributing amendments before closing; therefore, the Offerors must check the website periodically for any amendments to the solicitation.

Registrations: System for Award Management (SAM)-Offerors shall maintain an active registration in the SAM database at https://sam.gov to be eligible for a Government contract award. Suppose the Offeror is a Joint Venture (JV). In that case, the JV entity shall have valid SAM registration in the SAM database representing the JV as one business/firm/entity. If an Offeror is not actively and successfully registered in the SAM database at the time of award, the Government reserves the right to award to the next prospective Offeror.

Procurement Integrated Enterprise Environment (PIEE): The only authorized transmission method for bids in response to the forthcoming solicitation is electronic via Procurement Integrated Enterprise Environment (PIEE) Solicitation Module. No Other Transmission Method (E-mail, Facsimile, U.S. Postal Mail, Hand Carried, etc.) Will Be Accepted. Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil/.

The following link is provided to satisfy FAR 36.211(b) reporting requirements for construction contracts anticipated to be awarded to a small business. The information is accessed by clicking on “View Construction Contract Modification Process” (satisfying FAR 36.211(b)(1)) and “View Construction Contract Modification Process Past Performance Data” (satisfying FAR 36.211(b)(2)) on the website provided." https://www.usace.army.mil/Business-With-Us/Partnering/mod/129895/details/443/ 

Point of Contacts: Contracting Officer - Mr. Greg Graham - gregory.m.graham@usace.army.mil

Contract Specialist – Ms. Christina Oliver – christina.n.oliver@usace.army.mil