Repair MAU Access Platforms B907, RVKQ 25-0012
Cancelled Solicitation Posted
- Solicitation number
- FA6670-26-B-0003
- Agency
-
Reserve Command
Air Force, Department of Defense
- Responses due
- Set-aside
- Service-Disabled Veteran-Owned Small Business
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- Niagara Falls, New York 14304, United States
Notice details come from SAM.gov. Updated .
About this opportunity
The Department of the Air Force Reserve Command seeks construction repair of two Make-Up Air Unit access platforms in Hangar B907 at Niagara Falls Air Reserve Station, New York, with sealed bids due June 12 at 2:00 p.m. EST. This procurement is set-aside 100 percent Service-Disabled Veteran-Owned Small Business under FAR Subpart 19.106, foreclosing competition outside that pool.
Work is performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, New York. The contractor must design, fabricate, and install a fixed ladder system with integrated vertical rail fall protection, including a transitional platform at approximately 26.25 feet above the hangar deck and a six-foot fixed ladder with 42-inch extension reaching an existing working platform at approximately 32.25 feet. The design must include a Professional Engineer-certified structural design, selective demolition of existing platform portions, a roof hatch for underside access, and compliance with OSHA standards 1910.23, 1926 Subpart L, 1915.73, 1926.453, and 1926.502. Materials include ASTM A36 structural steel with 0.25-inch grid decking and rigid fall protection rail systems anchored to withstand 5,000 pounds of force. All personnel requesting Niagara Falls Air Reserve Station access must possess a Valid State Enhanced or Real ID or Valid United States Passport.
Performance period is 45 calendar days, beginning within 10 days of award. The contract is firm fixed-price with magnitude between $100,000 and $250,000. Liquidated damages are $565.64 per day of delay. A mandatory site visit occurred April 29 at 9:30 a.m. Performance and payment bonds are required within 10 days of award. Prevailing wage rates per Davis-Bacon determination NY20260019 apply. Minimum insurance coverage includes $500,000 general liability, $100,000 employers liability, and $200,000 per person automotive liability. Amendment 2 (June 3) extended the bid deadline from June 5 and added Attachments 5 and 6 with updated platform access drawings.
Notice text
4 versions
Update #4 · Latest ·
3 June 2026
Amendment 2, Attachment 5 and Attachment 6 posted.
Bid Closing date HAS been extended.
Please send in EAL Attachment 4, as soon as possible but NLT 11 June 2026 for base access to drop off bid or attend Bid Opening.
________________________________________________________________________
28 May 2026
Amendment 1 and revised Wage Determination posted.
Bid Closing date HAS been extended.
________________________________________________________________________
29 April 2026
Site Visit Sign In Sheet posted
________________________________________________________________________
This is a combined synopsis/solicitation for a construction requirement, being issued under the authority of FAR Part 14 - Sealed Bidding. It is being issued electronically at the Sam website https://sam.gov under the reference number FA6670-26-B-0003.
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair MAU Access Platforms B907.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0012, Repair MAU Access Platforms B907, to include the following: Repair two existing Make-Up Air Unit (MAU) platforms in hangar B907 to allow access for MAU maintenance.
Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Magnitude: Between $100,000 and $250,000.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The Site Visit will be held on Wednesday 29 April 2026 at 9:30 a.m.
Meet at: 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
Questions are due via e-mail by COB Monday 4 May 2026. Questions and Answers will be publicly posted as an attachment approx. 3 business days after questions due date, to the same notice id on SAM.gov as the solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.
Update #3 ·
28 May 2026
Amendment 1 and revised Wage Determination posted.
Bid Closing date HAS been extended.
________________________________________________________________________
29 April 2026
Site Visit Sign In Sheet posted
________________________________________________________________________
This is a combined synopsis/solicitation for a construction requirement, being issued under the authority of FAR Part 14 - Sealed Bidding. It is being issued electronically at the Sam website https://sam.gov under the reference number FA6670-26-B-0003.
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair MAU Access Platforms B907.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0012, Repair MAU Access Platforms B907, to include the following: Repair two existing Make-Up Air Unit (MAU) platforms in hangar B907 to allow access for MAU maintenance.
Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Magnitude: Between $100,000 and $250,000.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The Site Visit will be held on Wednesday 29 April 2026 at 9:30 a.m.
Meet at: 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
Questions are due via e-mail by COB Monday 4 May 2026. Questions and Answers will be publicly posted as an attachment approx. 3 business days after questions due date, to the same notice id on SAM.gov as the solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.
Update #2 ·
29 April 2026
Site Visit Sign In Sheet posted
________________________________________________________________________
This is a combined synopsis/solicitation for a construction requirement, being issued under the authority of FAR Part 14 - Sealed Bidding. It is being issued electronically at the Sam website https://sam.gov under the reference number FA6670-26-B-0003.
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair MAU Access Platforms B907.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0012, Repair MAU Access Platforms B907, to include the following: Repair two existing Make-Up Air Unit (MAU) platforms in hangar B907 to allow access for MAU maintenance.
Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Magnitude: Between $100,000 and $250,000.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The Site Visit will be held on Wednesday 29 April 2026 at 9:30 a.m.
Meet at: 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
Questions are due via e-mail by COB Monday 4 May 2026. Questions and Answers will be publicly posted as an attachment approx. 3 business days after questions due date, to the same notice id on SAM.gov as the solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.
Update #1 ·
This is a combined synopsis/solicitation for a construction requirement, being issued under the authority of FAR Part 14 - Sealed Bidding. It is being issued electronically at the Sam website https://sam.gov under the reference number FA6670-26-B-0003.
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair MAU Access Platforms B907.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0012, Repair MAU Access Platforms B907, to include the following: Repair two existing Make-Up Air Unit (MAU) platforms in hangar B907 to allow access for MAU maintenance.
Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Magnitude: Between $100,000 and $250,000.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The Site Visit will be held on Wednesday 29 April 2026 at 9:30 a.m.
Meet at: 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
Questions are due via e-mail by COB Monday 4 May 2026. Questions and Answers will be publicly posted as an attachment approx. 3 business days after questions due date, to the same notice id on SAM.gov as the solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.
Files
Show all 11
Similar open opportunities
| Opportunity | Agency | Set-aside | Responses due |
|---|---|---|---|
| Renovate Suite H8, Building 3 | Air Force Research Laboratory | Total Small Business | |
| Z1DA--528A5-27-504 Seal and Stripe Parking Lots | Veterans Integrated Service Network 2 | No set-aside | |
| Y1DA--NRM-CONST 528-CSI-102 Urology Equipment Site Prep | FY27 NRM | Veterans Integrated Service Network 2 | Service-Disabled Veteran-Owned Small Business |
On GovTribe
Work this opportunity
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity