Notice of Intent to Sole Source: Chenega Industrial Group LLC
Closed Solicitation Posted
- Solicitation number
- 75D301-26-R-73505
- Agency
-
CDC Office of Acquisition Services
Centers for Disease Control and Prevention, Department of Health and Human Services
- Responses due
- Set-aside
- Total Small Business
Opportunity facts
- NAICS code
- 238210 Electrical Contractors and Other Wiring Installation Contractors
- Place of performance
- Atlanta, Georgia 30329, United States
- Points of contact
Notice details come from SAM.gov. Updated .
About this opportunity
The Centers for Disease Control and Prevention seeks installation of an automatic transfer switch in UPS Room B124 at its Roybal Campus in Atlanta, Georgia, with a notice of intent to sole source to Chenega Industrial Group LLC and a response deadline of August 25. The procurement is restricted to small business, and the sole source justification rests on Chenega's specialized expertise, familiarity with CDC building structures and automated control systems, and logistics management capability to mitigate delivery delay risks.
Place of performance is Building 20, 1600 Clifton Road NE, Atlanta, Georgia 30329. The work comprises installation of the automatic transfer switch, fed by one feeder from Building 20 Unit Substation A and a second feeder from Building 20 Unit Substation B, to serve the existing SOC UPS in Room B124. The contractor must provide all materials and labor and leave the work area in a clean, operationally ready condition. The contract is valued at approximately $163,000 under a firm fixed-price structure. NAICS code 238210 applies (Electrical Contractors and Other Wiring Installation Contractors); PSC is N061. Chenega Industrial Group LLC is an SBA 8(a) program participant. The Program Office is represented by Bill Dryden (COR) and the Contracting Officer by Kourtney Marshall. The procurement request number is HCAJSBC2-2026-96065.
Notice text
The project is located at the Centers for Disease Control and Prevention’s (CDC’s) Roybal Campus, Building 20, 1600 Clifton Road NE, Atlanta, Georgia 30329. The Security Operations Center (SOC) was recently relocated from Building 21 to Roybal B20. Prior to the relocation, the UPS serving the SOC space to be renovated was replaced. The primary work of the referenced project is to install a new automatic transfer switch in UPS Room B124. The automatic transfer switch will be fed by one feeder originating from Building 20 Unit Substation A and a second feeder from Building 20 Unit Substation B. The ATS shall serve the existing SOC UPS in Room B124. The work of the Contractor comprises the performance of the installation, including but not limited to provision of all materials and labor required to perform the work and to leave the work area in a clean, operationally ready condition following completion.
Files
| File | Type | Posted |
|---|---|---|
| A13 SAP-Sole-Source-Procurement RFO Part 8 and 12 Redacted.pdf |
On GovTribe
Work this opportunity
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity