Calender year 2018 dry-docking overhaul of the usns trenton (T-EPF-5)

The Contractor shall prepare for and accomplish the dry-docking and overhaul of the USNS TRENTON (T-EPF 5) as described in the specification package provided.



Accomplishment of the specification package includes all planning, document preparation, engineering, procurement, and production work necessary to prepare for and accomplish the repairs, maintenance and certifications covered in the specification package. These tasks include, but are not limited to the following:



(a) Provide the management, procurement, production, testing, quality assurance, technical capability and resources necessary to prepare for and accomplish the repairs in accordance with the requirements stated herein, the contract work specifications, and the additional work specifications if necessary within the availability time period specified in Section F of this solicitation and resulting award.





(b) Receipt, storage, and installation of Government Furnished items specified in the work package.



(c) Apply progress measurement systems to determine the physical progress of completed work for each of the elements in the contractor’s scheduling plan, including material and manpower control, engineering, production, tests and trials in accordance with the Contractors own Technical Proposal, and the specification package. The progress tracking system shall permit a direct comparison of the physical progress of completed work to the planned performance measurement baseline for each of the elements in the scheduling plan.



(d) Establish management procedure and systems to identify behind schedule conditions and unfavorable schedule variance, using the scheduling plan performance measurement baseline, each of the elements in the baseline, and the progress measurement systems.

The applied systems and procedures shall provide timely identification of scheduling problem areas to permit prompt management action to correct unsatisfactory conditions.



(e) Develop a performance milestone schedule/critical path chart to measure scheduled performance. Deviations from the milestone schedule / critical path chart must be submitted to and approved by the Contracting Officer. The Contractor warrants that all work required by Section C of this contract shall be completed within the performance period stated in Section F of the Contract. A performance milestone schedule and critical path chart shall be developed and submitted in accordance with the Work Item Package.



(f) Apply US Government (NAVSEA or MSC Standard) approved quality control procedures as required by this contract and the specification package to ensure procured material and performed production work conform to the required quality standards.

If a European equivalent standard is authorized, the specification package will so state.