Y24-162-AV_FINAL.pdf

ORANGE COUNTY, FLORIDA

PROCUREMENT DIVISION

Issue Date: December 4, 2023

NOTICE IS HEREBY GIVEN that Orange County, Florida, henceforth referred to as the County is accepting sealed proposals for:

REQUEST FOR PROPOSALS #Y24-162-AV, CONSTRUCTION COST ESTIMATION

AND SCHEDULING

TERM CONTRACT

Copies of the Request for Proposals (RFP) documents may be obtained from Orange County by download at: https://secure.procurenow.com/portal/orangecountyfl

PROPOSAL SUBMISSION DUE DATE:

Sealed Electronic offers for furnishing the above will be accepted up to 4:00 PM (local time), Tuesday, January 9, 2024, via the electronic procurement portal referenced above.

To maintain a secured sealed process electronic submissions are required to be made through the OpenGov Procurement portal only at: https://secure.procurenow.com/portal/orangecountyfl.

Firms shall not be permitted to hand-deliver, mail, telephone, fax or email offers. Responses received after the submission deadline and/or transmitted outside of the designated OpenGov Procurement portal shall be rejected.

PRE-PROPOSALS CONFERENCE:

A Non-Mandatory Pre-Proposal Conference will be held on Wednesday, December 13, 2023, 2:00 PM, virtually via WebEx. Attendance is not mandatory but is encouraged.

Interested parties may observe the meeting:

1. Virtually via WebEx Events at the following website:

https://ocfl.webex.com/ocfl/j.php?MTID=m15e2878d1b810ecb221e0b026575dca4 Access Code: 2634 919 0749 Password: Go2Meeting Audio: 1-408-792-6300

OR:

2. By telephone at the following number: 1-408-792-6300

Access Code: 2634 919 0749

NOTICE TO PROPOSERS:

To ensure that your bid is responsive, you are urged to request clarification or guidance on any issues involving this solicitation before submission of your response. Your point-of-contact for this solicitation is Ana Villalona, Contracting Agent at Ana.Villalona@ocfl.net.

https://secure.procurenow.com/portal/orangecountyfl mailto:Ana.Villalona@ocfl.net

QUESTIONS:

All questions or concerns regarding this Request for Proposals shall be submitted by email to Ana.Villalona@ocfl.net, no later than 5:00 PM Friday, December 15, 2023 to the attention of Ana Villalona, Procurement Division, referencing the RFP number.

mailto:Ana.Villalona@ocfl.net i

TABLE OF CONTENTS

DESCRIPTION PAGE

SECTION 1: GENERAL TERMS AND CONDITIONS 1-13

- INSTRUCTION TO PROPOSERS 1

- QUESTIONS REGARDING THIS RFP 1

- CONTRACT TERM 2

- INSURANCE REQUIREMENTS 2-4

- WITHDRAWAL OF PROPOSAL 5

- REFERENCE CHECKS 9

- CONFIDENTIAL INFORMATION 9

- MISTAKES 11

SECTION 2: SPECIFICATIONS/SCOPE OF SERVICES 15-21

SECTION 3: PROPOSAL SUBMISSION REQUIREMENTS 23-32

AND DOCUMENTATION

- STATEMENT OF NO PROPOSAL 23

- PREREQUISITE REQUIREMENTS 23

- PROPOSAL FORMAT 23-32

SECTION 4: SELECTION CRITERIA 1

SECTION 5: ATTACHMENTS

- FEE SCHEDULE

- PROPOSAL COVER PAGE

- ACKNOWLEDGEMENT OF ADDENDA

- AUTHORIZED SIGNATORIES/NEGOTIATORS

- DRUG-FREE WORKPLACE FORM

- CONFLICT/NON-CONFLICT OF INTEREST FORM

- E-VERIFICATION CERTIFICATION

- RELATIONSHIP DISCLOSURE FORM

- RELATIONSHIP DISCLOSURE FORM - FREQUENTLY ASKED QUESTIONS (FAQ)

- ORANGE COUNTY SPECIFIC PROJECT EXPENDITURE REPORT

- EXPENDITURE REPORT- FREQUENTLY ASKED QUESTIONS (FAQ)

- LOCATION FORM

- AGENT AUTHORIZATION FORM

- LEASED EMPLOYEE AFFIDAVIT

ii

- INFORMATION FOR DETERMINING JOINT VENTURE ELIGIBILITY

- EQUAL OPPORTUNITY WORKFORCE SCHEDULE

- SCHEDULE OF SUB-CONTRACTING - M/WBE PARTICIPATION FORM

- SCHEDULE OF SUB-CONTRACTING - SDV PARTICIPATION FORM

- DISLOCATED WORKER PROPOSED HIRING INFORMATION

- DRAFT CONTRACT

SECTION 1

GENERAL TERMS AND CONDITIONS

Section 1, General Terms and Conditions | Page 1

GENERAL TERMS AND CONDITIONS

1. INSTRUCTIONS TO PROPOSERS

Proposals shall be submitted via the electronic submission portal at:

https://secure.procurenow.com/portal/orangecountyfl. Responses will be opened per the public meeting notice.

Offers by mail, hand-delivery, e-mail, telephone, or fax shall not be accepted.

Proposals submitted outside of the designated electronic submission portal shall be rejected as non-responsive regardless of where received.

The County shall not be responsible for delays caused by any occurrence. The time/date stamp clock located in the electronic submittal portal shall serve as the official authority to determine lateness of any offer. The submission deadline shall be scrupulously observed. It is the sole responsibility of the proposer to ensure that their proposal reaches the Procurement Division. The decision to refuse to consider a proposal that was received beyond the date/time established in the solicitation shall not be the basis for a protest pursuant to the Orange County Code (Procurement Ordinance).

All proposals will be opened publicly in accordance with the public notice, and the names of all timely proposers shall be read aloud.

Public Openings are held each Wednesday at 9:30am and Friday at 9:30am. A public opening of responses will be conducted at the next posted Procurement Public Meeting following the submission deadline. In the event of a County Holiday or unforeseen delay, responses shall remain sealed until the next public meeting.

Firms will be able to attend the public opening virtually, see the following instructions:

Visit: https://ocfl.webex.com/ocfl/j.php?MTID=m59bb20319c748f1e60a933cf59c7125b Meeting number: 286 177 361 Password: Go2Meeting Join by phone Option 1: 1-408-792-6300 Access code: 286 177 361 Join by phone Option 2: 1-617-315-0740 Access code: 286 177 361 Join by phone Option 3: 1-602-666-0783 Access code: 286 177 361 The physical meeting location is 400 E. South Street, 2nd Floor, Orlando, Florida 32801

2. QUESTIONS REGARDING THIS RFP

All questions or concerns regarding this Request for Proposals must be submitted in writing, by email as indicated on the coverpage of this RFP, referencing the RFP number.

When required the Procurement Division will issue an addendum to the Request for Proposals. The addendum will be available on the Internet for access by potential proposers. Proposers are instructed not to contact the initiating division directly.

Proposers shall not direct any queries or statements concerning their proposal to the Orange County Procurement Committee or County staff during the selection process, from the time of submission of a proposal until the execution of a contract.

Any proposer who initiates any discussions with staff in any manner other than that described below is subject to disqualification from this procurement. However, you may https://ocfl.webex.com/ocfl/j.php?MTID=m59bb20319c748f1e60a933cf59c7125b

Section 1, General Terms and Conditions | Page 2 contact the Contracting Agent at any time during this process, including during the Black Out Period.

No oral interpretation of this Request for Proposals shall be considered binding. The County shall be bound by information and statements only when such statements are written and executed under the authority of the Procurement Division Manager.

This provision exists solely for the convenience and administrative efficiency of Orange County. No proposer or other third party gains any rights by virtue of this provision or the application thereof, nor shall any proposer or third party have any standing to sue or cause of action arising there from.

3. CONTRACT TERM

It is the intent of the County to enter into a three (3) year term contract, with renewal clause for two (2) additional one ( 1 ) year terms for services as described herein.

4. DRAFT CONTRACT

The contract that the County intends to use for award is enclosed for reference. Any exceptions to this standard contract must be clearly indicated by return of the standard contract with the proposal, with exceptions clearly noted. The County has the right to require the selected respondent to sign the attached contract or to negotiate revisions to the contract language prior to execution of the contract, at its sole discretion.

Modification or alteration of the documents contained in the solicitation or contract shall only be valid if mutually agreed to in writing by the parties.

5. INSURANCE

Consultant agrees to maintain on a primary basis and at its sole expense, at all times throughout the duration of this contract the following types of insurance coverage with limits and on forms (including endorsements) as described herein. These requirements, as well as the County’s review or acceptance of insurance maintained by Consultant is not intended to and shall not in any manner limit or qualify the liabilities assumed by Consultant under this contract. Consultant is required to maintain any coverage required by federal and state workers’ compensation or financial responsibility laws including but not limited to Chapter 324 and 440, Florida Statutes, as may be amended from time to time.

The Consultant shall require and ensure that each of its sub-vendors/sub-Consultants providing services hereunder (if any) procures and maintains until the completion of their respective services, insurance of the types and to the limits specified herein.

Insurance carriers providing coverage required herein must be licensed to conduct business in the State of Florida and must possess a current A.M. Best’s Financial Strength Rating of A- Class VIII or better.

(Note: State licenses can be checked via www.floir.com/companysearch/ and A.M. Best Ratings are available at www.ambest.com)

Required Coverage:

http://www.floir.com/companysearch/ http://www.ambest.com/

Section 1, General Terms and Conditions | Page 3

Commercial General Liability - The Consultant shall maintain coverage issued on the most recent version of the ISO form as filed for use in Florida or its equivalent, with a limit of liability of not less than $1,000,000 (one million dollars) per occurrence.

Consultant further agrees coverage shall not contain any endorsement(s) excluding or limiting Product/Completed Operations, Contractual Liability, or Separation of Insureds.

The General Aggregate limit shall either apply separately to this contract or shall be at least twice the required occurrence limit.

Required Endorsements:

Additional Insured- CG 20 26 or CG 20 10/CG 20 37 or their equivalents.

Note: CG 20 10 must be accompanied by CG 20 37 to include products/completed operations

Waiver of Transfer of Rights of Recovery- CG 24 04 or its equivalent.

Note: If blanket endorsements are being submitted please include the entire endorsement and the applicable policy number.

Business Automobile Liability - The Consultant shall maintain coverage for all owned; non-owned and hired vehicles issued on the most recent version of the ISO form as filed for use in Florida or its equivalent, with limits of not less than $1,000,000 (one million dollars) per accident. In the event the Consultant does not own automobiles the Consultant shall maintain coverage for hired and non-owned auto liability, which may be satisfied by way of endorsement to the Commercial General Liability policy or separate Business Auto Liability policy.

Workers' Compensation – The Consultant shall maintain coverage for its employees with statutory workers' compensation limits, and no less than $500,000 each incident of bodily injury or disease for Employers' Liability. Elective exemptions as defined in Florida Statute 440 will be considered on a case-by-case basis. Any Consultant using an employee leasing company shall complete the Leased Employee Affidavit.

Waiver of Subrogation- WC 00 03 13 or its equivalent

Additional Required Coverage:

Professional Liability- with a limit of not less than $1,000,000 per occurrence/claim

When a self-insured retention or deductible exceeds $100,000 the COUNTY reserves the right to request a copy of Consultant most recent annual report or audited financial statement. For policies written on a “Claims-Made” basis the Consultant/Consultant agrees to maintain a retroactive date prior to or equal to the effective date of this contract. In the event the policy is canceled, non-renewed, switched to occurrence form, or any other event which triggers the right to purchase a Supplemental Extended Reporting Period (SERP) during the life of this contract the Consultant agrees to purchase the SERP with a minimum

Section 1, General Terms and Conditions | Page 4 reporting period of not less than two years. Purchase of the SERP shall not relieve the Consultant of the obligation to provide replacement coverage.

By entering into this contract Consultant agrees to provide a waiver of subrogation or a waiver of transfer of rights of recovery, in favor of the County for the workers’ compensation and general liability policies as required herein. When required by the insurer or should a policy condition not permit the Consultant to enter into a pre-loss agreement to waive subrogation without an endorsement, then Consultant agrees to notify the insurer and request the policy be endorsed with a Waiver of Subrogation or a Waiver of Transfer of Rights of Recovery Against Others endorsement.

Prior to execution and commencement of any operations/services provided under this contract the Consultant shall provide the COUNTY with current certificates of insurance evidencing all required coverage. In addition to the certificate(s) of insurance the Consultant shall also provide endorsements for each policy as specified above. All specific policy endorsements shall be in the name of the Orange County. Florida.

For continuing service contracts renewal certificates shall be submitted immediately upon request by either the COUNTY or the COUNTY’s contracted certificate compliance management firm. The certificates shall clearly indicate that the Consultant has obtained insurance of the type, amount and classification as required for strict compliance with this insurance section. Consultant shall notify the COUNTY not less than thirty (30) business days (ten business days for non-payment of premium) of any material change in or cancellation/non-renewal of insurance coverage. The Consultant shall provide evidence of replacement coverage to maintain compliance with the aforementioned insurance requirements to the COUNTY or its certificate management representative five (5) business days prior to the effective date of the replacement policy (ies).

The certificate holder shall read:

Orange County, Florida Risk Management Division 109 E. Church Street, Suite 200 Orlando, FL 32801

6. LAWS AND REGULATIONS

The Respondent's attention is directed to the fact that all applicable Federal and State laws, municipal and county ordinances, and the rules and regulations of all authorities having jurisdiction over any part of the project shall apply to the Contract throughout, and they will be deemed to be included in the Contract the same as though herein written.

Respondents are hereby provided notice of the provisions of Section 287.05701, Florida

7. POST AWARD MEETING

Within ten (10) days after receipt of notification of award, Consultant shall meet with the

County’s representative(s) to discuss job procedures and scheduling.

8. ACCEPTANCE/REJECTION/CANCELLATION

The County reserves the right to accept or reject any or all proposals, with or without cause, to waive technicalities, or to accept the proposal which, in its sole judgment best serves the

Section 1, General Terms and Conditions | Page 5 interest of the County, or to award a contract to the next most qualified proposer if a successful proposer does not execute a contract within thirty (30) days after approval of the selection by the Board of County Commissioners or other competent authority.

The County also reserves the right to reject the proposal of any proposer who has previously failed in the proper performance of an award or to deliver on time contracts of a similar nature or who, in the County’s opinion, is not in a position to perform properly under this award. The County reserves the right to inspect all facilities of proposers in order to make a determination as to the foregoing.

Orange County reserves the right, and the Manager of Procurement Division has absolute and sole discretion, to cancel a solicitation at any time prior to approval of the award by the Board of County Commissioners when such approval is required. The decision to cancel a solicitation cannot be the basis for a protest pursuant to the Orange County Code.

9. DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS/

REQUIREMENTS/ STATEMENTS OF WORK

Firms and/or individuals that assisted in the development or drafting of the specifications, requirements, statements of work, or solicitation documents contained herein are excluded from competing for this solicitation.

This shall not be applicable to firms and/or individuals providing responses to a publicly posted Request for Information (RFI) associated with a solicitation.

10. CLARIFICATION

The County reserves the right to request clarification of information submitted and to request additional information of one or more proposers.

11. WITHDRAWAL OF PROPOSAL

Any proposal may be withdrawn until the date and time set above for the submission of the proposals. Any proposals not so withdrawn shall constitute an irrevocable offer, for a period of one hundred and twenty (120) days, to provide to the County the services set forth in this Request for Proposals, or until one or more of the proposals have been awarded.

12. SEALED PROPOSALS

Proposals shall be submitted via the electronic submission portal at:

https://secure.procurenow.com/portal/orangecountyfl, prior to the submission deadline. Proposals will be opened and proposer names shall be disclosed per the public meeting notice.

13. PROPOSAL PREPARATION

Costs of preparation of a response to this request for proposals are solely those of the Proposer. The County assumes no responsibility for any such costs incurred by the Proposer. The Proposer also agrees that the County bears no responsibility for any costs associated with any administrative or judicial proceedings resulting from the solicitation process.

Section 1, General Terms and Conditions | Page 6

14. ACCOUNTING SYSTEM

The Consultant shall establish and maintain a reasonable accounting system, which enables ready identification of Consultant’s cost of goods and use of funds. The accounting system shall also include adequate records and documents to justify all prices for all items invoiced as well as all charges, expenses and costs incurred in providing the goods for at least five

(5) years after completion of this contract. The County or designee shall have access to books, records, subcontract(s), financial operations, and documents of the Consultant or its subConsultants, as required to comply with this section, for the purpose of inspection or audit anytime during normal business hours at the Consultant’s place of business. This right to audit shall include the Consultant’s subConsultants used to procure goods or services under the contract with the County. Consultant shall ensure the County has these same rights with subConsultant(s) and suppliers.

15. SHORTLISTS, PROTESTS AND LOBBYING

The recommended award will be posted for review by interested parties at the Procurement Division and at: http://apps.ocfl.net/OrangeBids/AwardsRec/default.asp prior to submission through the appropriate approval process and will remain posted for a period of five (5) full business days.

Orange County Lobbyist Regulations General Information http://www.orangecountyfl.net/OpenGovernment/LobbingAtOrangeCounty.aspx

A lobbying blackout period shall commence upon issuance of the solicitation until the Board selects the Consultant. For procurements that do not require Board approval, the blackout period commences upon solicitation issuance and concludes upon contract award.

The Board of County Commissioners may void any contract where the County Mayor, one or more County Commissioners, or a County staff person has been lobbied in violation of the black-out period restrictions of Ordinance No. 2002-15.

Orange County Protest Procedures http://www.orangecountyfl.net/ConsultantServices/ConsultantProtestProcedures.as px

Failure to file a protest with the Procurement Manager by 5:00 PM on the fifth full business day, after posting, shall constitute a waiver of bid protest proceedings.

Information regarding Procurement Committee scheduling and Board approvals is available by calling the Procurement Reception Desk at (407) 836-5635.

16. PUBLIC ENTITY CRIME

Section 287.133(3)(d), Florida Statutes, provides that the Florida Department of Management Services shall maintain a list of the names and addresses of those who have been disqualified from participating in the public contracting process under this section.

http://apps.ocfl.net/OrangeBids/AwardsRec/default.asp http://www.orangecountyfl.net/OpenGovernment/LobbingAtOrangeCounty.aspx http://www.orangecountyfl.net/VendorServices/VendorProtestProcedures.aspx http://www.orangecountyfl.net/VendorServices/VendorProtestProcedures.aspx

Section 1, General Terms and Conditions | Page 7 http://www.dms.myflorida.com/business_operations/state_purchasing/Consultant_i nformation/convicted_suspended_discriminatory_complaints_Consultant_lists/conv icted_Consultant_list

A person or affiliate who has been placed on The Convicted Consultant list following a conviction for a public entity crime shall not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, shall not submit bids on leases of real property to a public entity, shall not be awarded or perform work as a Consultant, supplier, subConsultant, or Consultant under a contract with a public entity, and shall not transact business with any public entity in excess of the threshold amount provided in Florida Statute Section 287.017, for CATEGORY TWO for a period of thirty-six (36) months from the date of being placed on The Convicted Consultant List.

17. AVAILABILITY OF FUNDS

The obligations of the County under this award are subject to the availability of funds lawfully appropriated for its purpose by the State of Florida and the Orange County Board of County Commissioners, or other specified funding source for this procurement.

18. TOBACCO FREE CAMPUS

All Orange County operations under the Board of County Commissioners shall be tobacco free. This policy shall apply to parking lots, parks, break areas and worksites. It is also applicable to Consultants and their personnel during contract performance on county-owned property. Tobacco is defined as tobacco products including, but not limited to, cigars, cigarettes, e-cigarettes, pipes, chewing tobacco and snuff. Failure to abide by this policy may result in civil penalties levied under Chapter 386, Florida Statutes and/or contract enforcement remedies.

19. VERIFICATION OF EMPLOYMENT STATUS

The Consultant is required to be registered with the U.S. Department of Homeland Security’s E-Verify system prior to entering into a contract with Orange County. The Consultant shall use the E-Verify system to verify the employment eligibility of all new employees hired by the Consultant during the contract term. The Consultant shall include an express provision in all of its subcontracts requiring subConsultants, who perform work or provide services pursuant to the contract, to use the E-Verify system to verify the employment eligibility of all new employees hired by the subConsultant during the contract term. The Consultant shall obtain from its subConsultant(s) an affidavit stating that the subConsultant does not employ, contract with, or subcontract with an unauthorized alien. The Consultant shall maintain a copy of such affidavit for the duration of the contract. For more information on this process, please refer to United States Citizenship and Immigration Service site at:

http://www.uscis.gov/portal/site/uscis.

Only those employees determined eligible to work within the United States shall be employed under this contract.

By submission of a proposal in response to this solicitation, the Consultant affirms that all employees in the above categories shall undergo e-verification before placement on this http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_information/convicted_suspended_discriminatory_complaints_vendor_lists/convicted_vendor_list http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_information/convicted_suspended_discriminatory_complaints_vendor_lists/convicted_vendor_list http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_information/convicted_suspended_discriminatory_complaints_vendor_lists/convicted_vendor_list http://www.uscis.gov/portal/site/uscis

Section 1, General Terms and Conditions | Page 8 contract. The Consultant shall commit to comply with this requirement by completing the E-Verification certification, attached to this solicitation.

A public employer, Consultant, or subConsultant who has a good faith belief that a person or entity with which it is contracting has knowingly violated Section 448.09(1), Florida Statutes is obligated to terminate the contract with the person or entity pursuant to Section 448.095(5)(c)1, Florida Statutes. If Orange County terminates the contract for the foregoing reason, the Consultant may not be awarded a public contract for at least one (1) year after the date on which the contract was terminated, and the Consultant will be liable for any additional costs incurred by Orange County as a result of the termination of the contract.

20. SCHEDULE OF SUBCONTRACTING

Proposers shall list all proposed sub-Consultants to be used, regardless of racial or gender grouping. Include names, addresses, phone numbers, type of work subcontracted (discipline, trade or commodity), proposed percentage of work, and the M/WBE or Majority designation (M/WBE or Non-M/WBE).

21. EQUAL OPPORTUNITY

It is hereby declared that equal opportunity and nondiscrimination shall be the County’s policy intended to assure equal opportunities to every person, regardless of race, religion, sex, sexual orientation and gender expression/identity, color, age, disability or national origin, in securing or holding employment in a field of work or labor for which the person is qualified, as provided by Section 17-314 of the Orange County Code and the County Administrative Regulations.

Further, the Consultant shall abide by the following provisions:

A. The Consultant shall represent that the Consultant has adopted and maintains a policy of nondiscrimination as defined by applicable County ordinance throughout the term of this contract.

B. The Consultant shall allow reasonable access to all business and employment records for the purpose of ascertaining compliance with the non-discrimination provision of the contract.

The provisions of the prime contract shall be incorporate by the Consultant into the contracts of any applicable subConsultants.

22. CONFLICT OF INTEREST

The award is subject to provisions of applicable State Statutes and County Ordinances. All proposers must disclose with their offer the name of any officer, director, or agent who is also an employee of Orange County. Further, all proposers must disclose the name of any County employee who owns, directly or indirectly, an interest of ten percent (10%) or more in the Proposer’s firm or any of its branches. Should the Consultant permanently or temporarily hire any County employee who is, or has been, directly involved with the Consultant prior to or during performance of the resulting contract, the contract shall be subject to immediate termination by the County.

Section 1, General Terms and Conditions | Page 9

23. DEBRIEFING OF PROPOSERS

Not later than thirty (30) days after Board approval of a selection or shortlist, a proposer may submit a written request to the applicable contracting agent for a debriefing on the evaluation of their proposal. The contracting agent will schedule a meeting with the Proposer for the debriefing. However, at the Proposer’s request, the debriefing may be conducted via telephone conference. The debriefing shall include the following minimum information:

A. Key requirements of the solicitation.

B. The overall ranking of all proposals.

C. The significant weaknesses or deficiencies in the proposal in response to the requirements of the solicitation.

D. If requested, an explanation of the score received for each evaluation criteria will be provided, including costs, if applicable.

E. If applicable, a summary of the rationale for award.

F. Responses to any relevant questions of the Proposer.

Untimely debriefing requests will also be considered.

24. REFERENCE CHECKS

The contact person listed as a reference shall be someone who has personal knowledge of the Proposer’s performance during the referenced contract. Contact persons shall have been informed that they are being used as a reference and that the County may be contacting them. More than one person can be listed but all shall have knowledge of the project. DO NOT list principals or officers who will not be able to answer specific questions regarding the project.

Failure of references listed to respond to the County’s inquiries may negatively impact the evaluation of the Proposal. The reference shall be the owner or a representative of the owner.

25. CONFIDENTIAL INFORMATION

In accordance with Chapter 119 of the Florida Statutes (Public Records Law), and except as may be provided by other applicable State or Federal Law, all bidders/proposers should be aware that formal solicitations and the responses thereto are in the public domain.

Requests for confidential treatment will not supersede the County’s legal obligation to provide records to the public consistent with public records law. Bidders/proposers must cite specific, applicable legal grounds to support a request for confidential treatment, of any portion of a bid/proposal. Requests by bidders/proposers to keep entire bids/proposals confidential are generally not supported by public records laws. At a minimum, the County will disclose the successful bidder’s/proposer’s name, the substance of the bid/proposal, and the price.

Section 1, General Terms and Conditions | Page 10

If the bidder/proposer requests confidential treatment, bidder/proposer must submit an additional copy of the bid/proposal with the proposed confidential information redacted.

This copy must include a general description of the information redacted, and shall only be redacted in the least expansive manner necessary to effectuate the requested exemption(s).

In a separate attachment, bidder/proposer shall supply a listing of the provisions identified by section number for which it seeks confidential treatment and identify the statutory basis under Florida law, including a detailed justification for exempting the information from public disclosure.

Bidder/proposer shall hold harmless and indemnify the County for all claims, actions, suits, judgments, fines, costs or damages the County may incur as a result of bidder’s/proposer’s request for confidential treatment of its bid/proposal. Bidder/proposer agrees and understands that the County may make copies of, and distribute, the bid/proposal without any requested redactions, to facilitate evaluation. Bidder/proposer warrants that such copying will not violate the rights of any third party.

26. PUBLIC RECORDS COMPLIANCE

(APPLICABLE FOR SERVICE CONTRACTS

Orange County is a public agency subject to Chapter 119, Florida Statutes. The Consultant agrees to comply with Florida’s Public Records Law. Specifically, the Consultant shall:

1. Keep and maintain public records required by Orange County to perform the service.

2. Upon request from Orange County’s custodian of public records, provide Orange County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law.

3. Ensure that public records that are exempt or confidential and exempt from the public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Consultant does not transfer the records to Orange County.

4. Upon completion of the contract, Consultant agrees to transfer at no cost to Orange County all public records in possession of the Consultant or keep and maintain public records required by Orange County to perform the service. If the Consultant transfers all public record to Orange County upon completion of the contract, the Consultant shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Consultant keeps and maintains public records upon completion of the contract, the Consultant shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to Orange County, upon request from Orange County’s custodian of public records, in a format that is compatible with the information technology systems of Orange County.

5. A Consultant who fails to provide the public records to Orange County within a reasonable time may be subject to penalties under section 119.10, Florida Statutes.

Section 1, General Terms and Conditions | Page 11

6. IF THE CONSULTANT HAS QUESTIONS REGARDING THE

APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO

THE CONSULTANT’S DUTY TO PROVIDE PUBLIC

RECORDS RELATING TO THIS CONTRACT, CONTACT THE

CUSTODIAN OF PUBLIC RECORDS AT :

PROCUREMENT PUBLIC RECORDS LIAISON

400 E. SOUTH STREET, 2ND FLOOR, ORLANDO, FL 32801

PROCUREMENTRECORDS@OCFL.NET, 407-836-5635

27. FEDERAL AND STATE TAX

The County is exempt from Federal and State Sales and Use Taxes for tangible personal property (Certificate of Registry for tax transactions under Chapter 32, Internal Revenue Code and Florida Sales/Use Tax Exemption Certificate). The Manager, Procurement Division will sign an exemption certificate submitted by the Consultant.

Consultants doing business with the County shall not be exempted from paying sales tax to their suppliers for materials to fulfill contractual obligations with the County, nor shall any Consultant be authorized to use the County’s Tax Exemption Number in securing such materials.

28. PROPRIETARY/RESTRICTIVE SPECIFICATIONS

If a proposer considers the specification contained herein to be proprietary or restrictive in nature, thus potentially resulting in reduced competition, they are urged to contact the Procurement Division prior to bid opening. Specifications which are unrelated to performance will be considered for deletion via addendum to this Request for Proposals.

29. MISTAKES

In the event of extension error(s), the unit prices will prevail and the proposer’s total offer will be corrected accordingly. In the event of addition errors, the extended totals will prevail and the Proposer’s total will be corrected accordingly. Any discrepancy between words and numbers will be resolved in favor of the written words. Proposers must check their submissions where applicable. Failure to do so will be at the Proposer’s risk.

Proposals having erasures or corrections must be initialed in ink by the Proposer.

30. CONTRACTUAL AGREEMENT

This solicitation shall be included and incorporated in the final contract or purchase order.

The order of contract precedence will be the contract (purchase order), solicitation, and proposal. Any and all legal actions associated with this Request for Proposals and/or the resultant contract (purchase order) shall be governed by the laws of the State of Florida.

Venue for any litigation involving this contract shall be the Ninth Circuit Court in and for Orange County, Florida.

31. PAYMENT TERMS/DISCOUNTS

mailto:ProcurementRecords@ocfl.net

Section 1, General Terms and Conditions | Page 12

The County’s payment terms are in accordance with Florida Statute 218, Local Government Prompt Payment Act. Cash discounts for prompt payment will be considered in determining the lowest net cost for fee proposal evaluation purposes. Notwithstanding the above, discount payment terms shall not be less than net 30 calendar days from receipt of correct invoice.

32. CERTIFICATION OF INDEPENDENT PRICE DETERMINATION

By submission of this offer, the Proposer certifies, and in the case of a joint proposal each party thereto certifies as to its own organization, that in connection with this procurement:

A. The prices in this offer have been arrived at independently, without consultation, collusion, communication, or agreement for the purpose of restricting competition, as to any matter relating to such prices with any other proposer or with any competitor.

B. Unless otherwise required by law, the prices which have been offered in this proposal have not been knowingly disclosed by the Proposer and will not knowingly be disclosed by the Proposer prior to opening, directly or indirectly to any other Proposer or to any competitor; and, C. No attempt has been made or shall be made by the Proposer to induce any other person or Proposer to submit or not to submit an offer for the purpose of restricting competition.

33. FEDERAL REQUIREMENTS

In the event this Contract is paid in whole or in part from any federal government agency or source, the specific terms, regulations and requirements governing the disbursement of these funds shall be specified herein and become a part of this clause.

Equal Employment Opportunity: For any federally assisted construction contract, as defined in 41 CFR 60-1.3, the Consultant, subConsultant, subrecipient shall follow all of the requirements of the Equal Opportunity Clause as stated in 41 CFR 60-1.4.

Davis–Bacon Act: For any federally assisted construction contract, in excess of two thousand dollars ($2,000), the Consultant, subConsultant, subrecipient shall comply with all of the requirements of the Davis-Bacon Act (40 U.S.C. 3141 – 3148) as supplemented by Department of Labor Regulations (29 CFR Part 5, “Labor Standards Provisions Applicable to Contracts Covering Federally Financed and assisted Construction”); and the Copeland “Anti-Kickback” Act (40 U.S.C. 3145), as supplemented by Department of Labor regulations (29 CFR Part 3, “Consultants and SubConsultants on Public Building or Public Work Financed in Whole or in Part by Loans or Grants from the United States”).

For a definition of “Construction” see 48 CFR 2.101.

Contract Work Hours and Safety Standards Act: For any federally assisted contract, in excess of one hundred thousand dollars ($100,000), that involves the employment of mechanics or laborers, the Consultant, subConsultant, subrecipient shall comply with all of the requirements of the Contract work Hours and Safety Standards Act (40 U.S.C. 3702 and 3704), as supplemented by Department of Labor Regulations (29 CFR Part 5).

Section 1, General Terms and Conditions | Page 13

Byrd Anti-Lobbying Amendment (31 U.S.C. 1352) - Consultants that apply or bid for an award exceeding one hundred thousand dollars ($100,000) must file the required Certification Regarding Lobbying for Contracts, Grants, Loans, and Cooperative Agreements Appendix A. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352.

Each tier must also disclose any lobbying with non-Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the non-Federal award.

Rights to Inventions Made Under a Contract or Agreement: For any federally assisted contract, awarded to a small business firm or nonprofit organization as defined in 37 CFR

401.2 for the performance of experimental, developmental, or research work, the Consultant, subConsultant, subrecipient agrees to all of the terms in 37 CFR 401.14(a) and

(b) regarding Patent Rights and The Allocation of Principal Rights.

Clean Air Act and the Federal water Pollution Control Act: For any federally assisted contract, or subgrant, in excess of one hundred and fifty thousand dollars ($150,000), the Consultant, subConsultant, subrecipient or subgrant recipient shall comply with all of the requirements of the Clean Air Act (42 U.S.C. 7401 -7671q.) and the Federal water Pollution Control Act as amended (33 U.S.C. 1251 – 1387).

Procurement of Recovered Materials:

(1) In the performance of this contract, the Consultant shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired

a. Competitively within a timeframe providing for compliance with the contract performance schedule;

b. Meeting contract performance requirements; or

c. At a reasonable price.

(2) Information about this requirement, along with a list of EPA-designated items, is available at EPA’s Comprehensive Procurement Guidelines web site, https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program.

Awarded Consultants are required to fully comply with all requirements outlined in 2 CFR Part 200 – Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards.

https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program

SECTION 2

SPECIFICATIONS / SCOPE OF SERVICES

Section 2, Scope of Services | Page 15

SCOPE OF SERVICES

The Consultant shall provide professional cost estimating and schedule preparation and/or evaluation services for a variety of building construction projects being administered by various County departments. Such projects may include but are not limited to the construction, remodeling, renovation, repair, improvement, or extension of County government facilities and buildings, appurtenant building structures, building systems, building sites, or other public facilities.

1. OVERVIEW

The scope of services, depending on the scope, size, complexity, and composition of each assigned project, will involve total projects or multi-disciplinary elements of building projects and other public facilities, including but not limited to, Construction Specifications Institute Division/Section elements:

A. General Requirements B. Site Work C. Cast-in-Place Concrete D. Masonry E. Metals F. Wood and plastics G. Thermal and moisture protection H. Doors and windows I. Finishes J. Specialties K. Equipment L. Furnishings M. Special construction N. Conveying systems O. Mechanical P. Electrical Q. Systems

These services shall require the Consultant to prepare independent, objective, detailed cost estimates and/or schedules to be used by the County for evaluating, negotiating, and otherwise resolving requests, payment applications, and claims made by construction Consultants, and in determining the cost of changes in the work proposed by the County or required by unforeseeable or unanticipated circumstances.

2. SERVICES

The scope of such multi-disciplined services to be provided and/or performed by the Consultant for selected projects shall include, but not be limited to, providing and/or performing such services or tasks as:

A. Cost Estimating Involving:

1. Budgetary/conceptual cost estimates for proposed Capital Improvement Projects (CIP).

2. Budgetary/conceptual cost estimates for planned projects based on generally established

Section 2, Scope of Services | Page 16 project design concepts.

3. Estimates of cost based on project schematic drawings.

4. Estimates of cost based on project design development plans and specifications.

5. Estimates of cost based on final project construction plans and specifications or field survey of existing facilities.

6. Estimates of cost based on proposed changes to the final project construction plans and specification including additions, deletions, or alternative revisions thereto.

7. Estimates of cost based on Leadership in Energy and Environmental Design (LEED) initiatives to be included in projects in line with the Orange to Green initiative by Orange County.

8. Estimates of cost based on commissioning requirements included in project commissioning plan.

9. Evaluation and recommendations pertaining to proposals submitted or cost proposals made by Consultants, sub-consultants, equipment and material suppliers, and others pertaining to County construction projects.

10. Evaluation and recommendations pertaining to Consultants proposed Schedule of Values for use in establishing contract partial (progress) and final payment applications amounts.

11. Evaluation and recommendations pertaining to the dollar amounts contained in construction Consultants periodic applications for partial (progress) and final contract payments including the value of stored materials where applicable.

12. Estimates of cost based on an evaluation of alternative or substitute equipment, materials, or building systems proposed by Consultants awarded County construction contracts.

13. Comparative cost analysis of requests or claims for changes in contract compensation involving disputes, County-directed Change Orders, unforeseen conditions, changes in the work, and changes in the contract time period submitted by Consultants employed on County construction contracts.

14. In the event of proposed or actual litigation between the County and Consultants employed on County construction contracts, develop and provide expert witness testimony and related support documentation pertaining to claims for changes in contract compensation involving disputes, changes in the work, and/or changes in the contract time period.

15. The development of a detailed written report of all costs associated with the scheduled maintenance of all landscape and plant materials surrounding County property. The criteria for this maintenance, such as the frequency of lawn cutting, the type and frequency of fertilizing, tree trimming, the use of soil amendments and insecticides, and other kinds of plant care, will be given to the Consultant. This may require the services of a Sub-

Section 2, Scope of Services | Page 17

Consultant who specializes in such reporting.

16. Other cost estimates pertaining to County construction projects as the County may request.

17. Estimates to assist with emergency work or disaster relief efforts.

B. Scheduling/ Schedule Evaluation Involving:

1. Budgetary/conceptual schedule estimate for proposed Capital Improvement (CIP)

Projects.

2. Evaluation and recommendations based on construction schedules prepared and submitted by Consultants awarded County construction contracts.

3. Evaluation and recommendations pertaining to potential changes in County construction contract time periods and work schedules involving proposed and/or actual changes in the contracted construction work.

4. Evaluation and recommendations pertaining to Consultant’s requests or claims pertaining to County-directed changes in work schedules, manpower requirements, and contract time period and change(s) in contract compensation possibly caused thereby.

5. Evaluation pertaining to the cause, effect, impact, and costs pertaining to unanticipated disruptions, delays, or lack of progress on contracted construction work and recommendations of alternative means of resolving and/or overcoming such problems.

6. Evaluation and otherwise monitor and critique and provide recommendations pertaining to Consultants’ proposed plan of work, work schedule, procurement schedule, shop drawing submittal schedule, subcontracting schedule, and the anticipated and actual progress related thereto.

7. Evaluation and otherwise monitor and critique work tasks required for LEED certification.

In the event of proposed or actual litigation between the County and Consultants employed on County construction contracts, develop and provide expert witness testimony and related support documentation pertaining to claims for changes in contract time and changes in contract compensation caused thereby.

8. Such other evaluations pertaining to the time periods for construction contracts, work schedules, work progress, work delays, and related issues as the County may request.

C. Legal Support Services or Testimony

The Consultant shall provide advice and assistance to the County Attorneys’ Office or other county divisions/ departments in support of resolving and/or defending claims made by the

Section 2, Scope of Services | Page 18 construction Consultants or others against the County, including expert witness and legal testimony on matters relating to claims for damages and/or changes in construction contract compensation and time.

3. AUTHORIZATION OF SERVICES

As individual projects are generated by the County, the Consultant will be provided with, or shall participate in, the development of a general Scope of Services statement.

This statement shall provide the basis for the Consultant and the County’s Project Manager to mutually develop a more detailed, comprehensive, Scope of Services. On the basis of such a Scope of Services, supplemented with a Consultant’s Service Performance Schedule, the Consultant shall prepare and submit for the County’s consideration a detailed proposal covering the cost of the professional services and any other related costs involved for each assignment.

Upon (1) agreement as to the Scope of Services, (2) the acceptance of the Consultant’s Service Performance Schedule, and (3) the approval by the County of the Consultant’s proposal and fee, whether or not modified by negotiation, the Consultant will be authorized to proceed to provide and/or perform the agreed to services by the County’s issuance of a written Delivery Order.

4. JOB DESCRIPTION:

A. Project Manager responsibilities for this position include, but are not limited to:

1. Coordination and review of all assigned work packages and sub-packages.

2. Develop cost-effective proposals and schedules for completion of task assignments that most effectively use available resources.

3. Oversee performance of all trade estimators and reviews construction documentation to ensure estimates are…