W912WJ17Q0156.pdf

STAMFORD HURRICANE BARRIER

PO BOX 396 DYKE LANE

STAMFORD CT 06904-0394

TEL: FAX:

W13G8671887876

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912WJ17Q0156 28-Aug-2017 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

08-Sep-2017(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

978/318-8720KIMBERLY B PUMYEA

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912WJ17Q0156

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Install Solar Photovoltaic Array - SHB

FFP

Contractor shall provide design and installation a complete and functional premium ground fixed solar photovoltaic array at Stamford Hurricane Barrier, Stamford, CT in accordance with the Statement of Work.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

MILSTRIP: W13G8671887876

PURCHASE REQUEST NUMBER: W13G8671887876

NET AMT

Section C - Descriptions and Specifications

DEFINITIVE RESPONSIBILITY CRITERION

In addition to examining the criteria in FAR 9.104-1, the Contracting Officer will also examine whether the low bidder can meet the requirements of the following definitive responsibility criterion. The apparent low bidder will be required to meet the following experience requirements: Ten (10) projects, completed within the last five years, that included installation of PV systems ranging in system size from 5kW to 60kW to carport roofs, building roofs, or ground-mounted systems, to include associated components, monitoring systems and all necessary conductors and conduit that resulted in fully operational systems, free of deficiencies.

The contractor crew shall have included at least one North American Board of Certified Energy Practitioners certified installer.

The Contracting Officer will verify that the submitted project(s) meet the definitive responsibility criterion as part of the responsibility determination. Bidders are not required to submit documentation that demonstrates they have met this criterion at the time of bid. The Government will request such supporting documentation from the bidder anticipated to receive the award.

Photovoltaic Solar Array System

U.S. Army Corps of Engineers Stamford Hurricane Barrier

Stamford, CT

The U.S. Army Corps of Engineers, New England District, Concord, MA, is soliciting proposals from qualified contractors to design and install a solar photovoltaic electric generating system. Contractor must demonstrate the ability to perform the work described in the Scope of Services set forth in this solicitation and have significant experience successfully performing comparable work.

1. SCOPE OF SERVICES

1.1. Objective

The objective of this Request for Proposal (RFP) is to identify and select the most qualified, best value, turnkey photovoltaic (PV) system Contractor for the design and installation of a complete solar photovoltaic array at the Stamford Hurricane Barrier, Stamford, CT. The contractor shall coordinate with the local electrical service provider the tie back connection to the local grid for buyback of the energy produced by the new PV system. The Contractor shall prepare a system summary detailing location, size, equipment, and sample cash flow analysis detailing expected savings (both kWh and

USD).

1.2. Location

Stamford Hurricane Barrier, Stamford, CT

1.3. Scope of Services

The Scope of Services by the contractor shall include all tasks required to design and install a complete and functional premium ground fixed solar photovoltaic array at previously indicated location. The scope shall include, but not be limited to securing all permits and approvals from government agencies and local electric service provider, all labor, taxes, services, permit fees, and equipment necessary to produce a fully operational solar PV array at the site. The proposal is for a Photovoltaic array to be located on U.S.

Government owned property. The proposal shall include a detailed explanation of the complete project and delineation of all work tasks to be performed by the awarded contractor. Proposal is to determine feasibility and costs

1.4. Description

The array, located at the Stamford Hurricane Barrier, shall be capable of producing approximately 48,000 kWh annually.

The PV array shall be ground as shown on page 21.

1.5. Design & Engineering

Design/engineer the solar PV system to maximize the solar energy resources, taking into consideration the customer’s electrical demand and load patterns, proposed installation site (See Annex 1), available solar resources, existing site conditions, proposed future site improvements, and other relevant factors. All array designs must be completed by an engineer licensed in the state in which the project is being built. The Contractor shall provide design documents that provide the following minimum information:

Timeline/Project Schedule System description Equipment details and description Layout of installation Layout of equipment Selection of key equipment Specifications for equipment procurement and installation All engineering associated with structural and mounting details Performance of equipment components, and subsystems Integration of solar PV system with other power sources Electrical grid interconnection requirements Controls, monitors, and instrumentation System performance monitoring

Identify an appropriate location for the solar PV inverter equipment and its related components and environmental control systems that will meet the following criteria:

Ease of maintenance and monitoring Efficient operation

Low operating losses Secured location and hardware Compatibility with existing facilities Avoidance of flood-prone areas Visual harmony

1.6. Professional Licenses

All engineering services shall be performed by design professionals licensed in the state in which the project is being built, with responsible control for each respective design discipline.

1.7. Licensed Installers

The installation crew shall include at least one North American Board of Certified Energy Practitioners certified installer.

1.8. Permitting

The contractor shall secure from governing agencies and the utility company all required rights, permits, approvals, and interconnection agreements at no additional cost to the Government. This includes but not limited to, providing all required supporting documentation, data, and information that the permitting and licensing agencies may require. The contractor shall coordinate all such work and be the primary liaison with the permitting and licensing agencies. The contractor shall be solely responsible for all permitting and licensing fees. The contractor shall comply with all requirements of permits and licenses issued for the project. The New England District U.S. Army Corps of Engineers, will become the signatory on applications, permits, and utility agreements only where necessary.

1.9. New Equipment and Materials

The U.S. Army Corps of Engineers, New England District, shall not accept used, reconditioned, after-market, or grey-market products or equipment. Any offeror supplying used, reconditioned, after-market, or grey-market products may be held responsible for damages to the Government. The contractor shall be prohibited from using any new equipment or materials that are manufactured in China, due to variation in quality of products. The Contractor shall follow the Buy American Construction Materials Clauses included in this contract. The Contractor shall coordinate with the Technical Point of Contact regarding locations and appearance of all equipment prior to installation. All new equipment used shall be of corrosion-resistant material, such as stainless steel, aluminum, or hot-dipped galvanized steel. All Equipment and materials shall be of the highest grade and quality. The Module Efficiency shall not be less than 19% (Standard Test Conditions

- STC).

Only products that are listed, tested, identified, or labeled by UL or another nationally recognized testing laboratory shall be used when available. Non-listed products are permitted only when listed products do not exist. Non-listed products must be identified as such in all submittals and must be approved by the Corps of Engineers, prior to use in construction of the system.

1.10. Codes, Standards, Regulations, References

American Society of Testing and Materials International (ASTM) http://www.astm.org/ o ASTM - E1026-08 - Standard Test Methods for Electrical Performance of Non-concentrator Terrestrial Photovoltaic Modules and Arrays o ASTM - E1038-10 - Standard Test Methods for Determining Resistance of Photovoltaic Modules to Hail o ASTM - E1171-09 - Standard Methods for Photovoltaic Modules in Cyclic Temperature and Humidity Environments o E1462-00(2006) - Standard Test Methods for Insulation Integrity and Ground Path Continuity of Photovoltaic Modules o E1799-08 - Standard Practice for Visual Inspection of Photovoltaic Modules o E1830-09 - Standard Test Methods for Mechanical Integrity of Photovoltaic Modules o E2848 - Standard Test Method for Reporting Photovoltaic Non-Concentrator

System Performance o E2939 - Standard Practice for Determining Reporting Conditions and Expected Capacity for Photovoltaic (PV) Non-Concentrator Systems

National Electrical Manufacturers Association (NEMA) o NEMA 250 (2008) Enclosures for Electrical Equipment (1000 Volts Maximum) o NEMA Z535.4 (2011) American National Standard for Product Safety Signs and Labels

Institute Of Electrical And Electronics Engineers (IEEE) o IEEE 81 (2012) - Guide for Measuring Earth Resistivity, Ground Impedance, and Earth Surface Potentials of a Ground System o IEEE 100 (2000; Archived) - The Authoritative Dictionary of IEEE Standards Terms o IEEE C2 NESC - National Electric Safety Code (NESC) as applicable to modifications to the utility system not covered by National Electric Code (NEC) o IEEE P929 - Recommended Practice for Utility Interface of Photovoltaic (PV) Systems o IEEE 1547 - Interconnecting Distributed Resources with Electric Power Systems o IEEE 1547a - Means and methods for inverter low-voltage ride through, low-frequency ride through, and power factor adjustments. Must be used with mutual agreement of Contractor, the Government, and the Utility.

o IEC 61727 (IEEE) - Photovoltaic (PV) systems – Characteristics of the utility interface o IEEE 519 - Recommended Practices and Requirements for Harmonic Control in Electric Power Systems o IEEE 1262 - Recommended Practice for PV Module Qualification, Performance, and Reliability o IEEE 1374 - Guide for Terrestrial PV Power System Safety o IEC 62548 - Installation and Safety Requirements for Photovoltaic (PV) Generators o IEEE 2030 - Guide for Smart Grid Interoperability of Energy Technology and Information Technology Operation with Electric Power Systems and End-use Applications and Loads

International Electric Code (IEC) o IEC 62093 - Balance-of-system components for photovoltaic systems - Design qualification natural environments o IEC 62109 - Safety of power converters for use in photovoltaic power systems, Parts 1 and 2 o IEC 61730 - Module safety qualification o IEC 61724 - Photovoltaic systems performance monitoring – guidelines for measurement, data exchange and analysis o IEC 62446 - Grid connected photovoltaic systems – Minimum requirements for systems documentation, commissioning tests and inspection

National Fire Protection Association (NFPA) o NFPA 1 Fire Code - The entirety of the code applies.

o NFPA 70 & NEC - Refer to version of the National Electric Code (NEC), which is adopted by the local jurisdiction having authority. The electrical requirements of the NEC have been adopted by the Government in lieu of the technical electrical requirements of the ICC Electrical Code. All sections are referenced, with particular emphasis on the following articles:

1. NEC Article 300: Wiring Methods and Materials

2. NEC Article 690: Solar Photovoltaic Systems

3. NEC Article 705: Interconnected Electrical Power Production Sources

Underwriters Laboratories (UL) http://ulstandards.ul.com/

Only products that are listed, tested, identified, or labeled by UL or another nationally recognized testing laboratory shall be used when available. Non-listed products are permitted only when listed products do not exist. Non-listed products must be identified as such in all submittals and must be approved by the Government prior to use in construction of the system.

o UL 467 (2007) - Grounding and Bonding Equipment o UL 1699 - Arc-Fault Current Interrupters o UL 1703 - Standard for Safety for Flat Plate Photovoltaic Modules and Panels o UL 1741 - Inverters, Converters, Controllers, and Interconnect System Equipment for Use with Distributed Energy Resources o UL 2703 - Rack Mounting Systems and Clamping Devices for Flat Plate Photovoltaic Modules

National Renewable Energy Laboratory (NREL) www.nrel.gov o PVWATTS calculator

American Concrete Institute (ACI) https://www.concrete.org/ o ACI-318 (latest edition) Requirements for Structural Concrete

1.11. Installation

Supply all equipment, materials, and labor necessary to install the solar PV array and integrate them with other power sources.

1.12. Electrical Interconnections

Supply and install all equipment required to interconnect the solar PV array to National Grid distribution system. The awarded Contractor will fulfill all application, required studies, and testing procedures to complete the interconnection process. All costs associated with utility interconnection shall be borne by the awarded Contractor.

1.13. Expected Service Life

Unless noted otherwise, all materials furnished for the project shall have an expected service life of thirty years (30) or more. Equipment warranties for modules and inverters are listed below.

1.14. Commissioning & Acceptance Testing

During the start-up, the Government, and/or its independent engineer/consultant, shall observe and verify each system performance. Required commissioning and acceptance test services include:

Starting up the solar PV systems until it achieves the performance requirements Conducting the performance testing over a consecutive twenty-four (24) hour period Conducting the successful delivery of power within thirty (30) days following completion of the system, meeting each benchmark.

1.15. Operation and Maintenance Manuals and As-Built Drawings Provide three (3) sets of operation, maintenance, and parts manuals for the solar PV system. The manual shall cover all components, options, and accessories supplied. It shall include maintenance, trouble-shooting, and safety precautions specific to the supplied equipment. Provide three (3) sets of as-built drawings including one (1) on CAD. These requirements shall be delivered prior to acceptance of the solar PV system.

1.16. Testing and Monitoring

Contractor shall perform a complete system test according to manufacturer’s recommendations, to verify system operability and provide a baseline. Acceptance shall be after the PV system has generated electric energy for ten (10) continuous days at energy and power production levels consistent with the proposed PV system’s estimated production with 100% system availability. If any of these requirements are not met, then the Government shall provide Contractor with a detailed notice of such failure (a “Rejection Notice”) within the ten (10) Business Day period, and Contractor shall promptly remedy at Contractor’s cost the relevant, specified failure and conduct new System Acceptance Testing until it indicates that the PV systems meets the requirements.

The Contractor shall notify the Government not less than five (5) Business Days prior to the anticipated date of each PV System Acceptance Testing. The Government shall have the right, but not the obligation, to be present at and observe the System Acceptance Testing, at the Government’s sole cost.

Contractor shall train staff to operate the complete system, including:

Normal Operational Mode Test Mode Emergency Mode Maintenance Mode Standard faults and errors Metering/software for monitoring of production and usage

Monitoring of system performance and providing public education and outreach is a required element of the RFP.

Provide the equipment and services to monitor, analyze, and display historical and live solar electricity generation data. The regularly collected data should reflect, but not be limited to, the following:

System performance System availability Average and accumulated output Capacity factor Degradation Cost avoidance

The data acquisition system shall be designed for turnkey, remote operation. Data shall be transmitted via Internet from the site to a remote site that can be accessed by the Government at any time.

Provide a long term cost for electricity (kWh) for the term of the awarded contract and any assumptions used in these calculations.

1.17. Warranties and Guarantees

Identify all warranties on system components

1.18. Special Provisions

Special provisions will be based on the specific Government owned facility

1.19. Benefits

Some of the benefits the government wishes to realize from this project include, but are not limited to, the following:

Annual solar PV production to be at least 95% of site annual consumption (kWh), as averaged over the previous three years.

Overall reduction in building operating costs.

Exceed federal and internal agency sustainability mandates and goals.

2. PROJECT REQUIREMENTS

2.1. Operation & Maintenance Requirements

All respondents must offer a comprehensive on-site operation and maintenance service program for the PV system operations, safety and maintenance activities.

The Contractor's operation and maintenance service program should provide the following minimum requirements:

1. Annual on-site system inspection, including:

a. System testing (operating current of each electrical string)

b. Routine preventive maintenance

2. Repair and/or replacement of defective parts (including equipment and labor)

3. System performance monitoring and historical data access for customer via secure website. Data should include:

a. System energy and power production

b. Ambient temperature

c. Wind speed

d. Insolation

4. Daily system monitoring by vendor, including:

a. Reporting of problems to customer

b. Dispatch of resources for expeditious resolution of problems

3. CONTRACTOR QUALIFICATION

3.1. Certification

Contractor shall provide proof of current NABCEP certification.

3.2. Information to be Provided

Status (private/publicly-held) Number of employees Target customers (residential, commercial, industrial, government, etc.

3.3. Project Team Information

Resumes of personnel to be directly involved with the development of the proposed systems

Team leader identification for the entire Proposal, including full contact information Identification of each entity, sub-contractor, person or firm involved in the Proposal and their role/responsibility, e.g. design, installation, permitting, equipment supply by component, operations and maintenance

Identification of the lead person responsible for each of the entities or firms described in above

Resume of Professional Engineer designing project

3.4. Contractor experience

Provide overview of the firm’s commercial grid-connected PV experience (do not include residential PV experience)

Breakdown by application (roof mounted, vs. ground mounted) installed by your company

Average commercial grid-connected PV system size installed by your company during the last five years

Experience with local government projects

3.5. Contractor References

Contractor shall provide five (5) or more commercial grid-connected PV projects installed in New England area over the last five years. Information to be provided for teach of the projects is as follows:

a. Exact role(s) your organization performed for the project (e.g. material supplier, lead contractor, electrical subcontractor, design, consulting, etc.)

b. Location

c. Application description

d. Product name/type

e. Customer name and contact information

f. Date installed

g. Project cost

h. PV module used

i. kWh rating

j. Cumulative kWh produced since system installation

k. Current operational status of system

Provide actual system data for five (5) of the grid-connected projects that demonstrates 90% or better availability of the PV projects used as customer references

4. PROPOSAL, SCHEDULE, & PRICING

4.1. Proposal Information

Proposals shall demonstrate a proven, robust data acquisition system that includes tracking of site-specific actual kWh production and actual meteorological data including tracking of solar irradiance, ambient temperature, and module temperature, with data available remotely.

Proposals shall provide evidence that the proposed technology and equipment would meet or exceed all currently applicable and proposed safety and interconnection standards. All equipment components must be UL certified, and meet existing facility structural and fire safety requirements.

Proposals shall provide evidence that the proposed technology and equipment would meet or exceed all currently applicable and proposed environmental standards.

4.2. Schedule

Contractor shall provide a proposed schedule for completion of the project. It is the intention of the Government to complete the project fall 2017

4.3. Pricing

Proposals shall demonstrate a proven, robust data acquisition system that includes tracking of site-specific actual kWh production and actual meteorological data including tracking of solar irradiance, ambient temperature, and module temperature, with data available remotely.

4.4. Incurring Costs

The Government is not liable, and shall not be liable, for any cost incurred by entities prior to executing a contract or purchase order.

5. SELECTION PROCESS

Proposals will be evaluated by the New England District Corps of Engineers based on:

The competence to perform the services as reflected by past experience in providing the services outlined herein

The ability to meet the requirements of this RFP Overall package and financial benefit to the Government

The New England District Corps of Engineers reserves the right to select any Contractor that, in its opinion and at its sole discretion, is deemed to be most advantageous and in the best interests of the Government. The New England District Corps of Engineers also reserves the right to delay or discontinue this selection process at any time during the process. The New England District Corps of Engineers shall not be liable for any cost incurred by any Contractor during the selection process.

6. PRECONSTRUCTION CONFERENCE

Prior to the start of any work, the Technical Point of Contact will schedule and conduct a “Preconstruction Conference”. The Contractor’s Project Manager and Quality Control Personnel will attend this meeting. This conference will be held at the time and location agreeable to the government and contractor. No work may be performed under this contract prior to this conference. The purpose of the conference is to enable the Technical Point of Contact to outline the procedures that will be followed by the Government in its administration of the contract, and to discuss the performance that will be expected from the Contractor. This conference will allow the Contractor an opportunity to ask questions about the Government’s administration and inspection of contract work or obtain other pertinent information that might be required. At the Preconstruction conference the contractor shall provide to the name of the project superintendent with a telephone number for project coordination.

The following is a general list of items for discussion during this Preconstruction Conference:

Safety Authority of the Technical Point of Contact and Quality Assurance

Inspectors Contractor’s Safety Program (including sub-contractors) Activity Hazard Analysis (Submitted & accepted prior to start of work on site site) Weekly Safety Meetings (Documented on NED Form 251) Accident Reporting (ENG Form 3394) Safety Data Sheet (SDS) requirements Correspondence, Communication, Administrative and Security Procedures Invoice and payment

7. COMMENCEMENT & WORK SCHEDULE

Work shall commence within 14 days after the Contractor receives the Notice to Proceed (NTP). The work shall be completed and ready for use no later than 90 days after the NTP.

The Government shall be given 7 days’ notice prior to the start of work. The project area will be open to the contractor Monday through Friday 7:00 AM to 3:30 PM and all work must be done during those hours unless additional hours are approved by the Technical Point of Contact. No work shall be done on weekends or Government holidays.

8. SUBMITTALS:

Although the Government technically reviews submissions required by this scope of work, it is emphasized that the Contractor’s work must be prosecuted using proper internal controls and review procedures. The documents identified below must be prepared in accordance with the applicable standards, submitted to the Technical Point of Contact for review and accepted by the government prior to the commencement of any field activities.

Product Specification Sheets – Prior to ordering system components. Including the following components:

o Photovoltaic Panels (solar array) o Grid-tied Inverter(s) o Solar Cable o Meters & Monitoring Software Interface

Manufacturer Warranty for Photovoltaic panels and associated system components.

Accident Prevention Plan (APP) including fall protection plan – Prior to the Start of

Field Work Activity Hazard Analysis (AHA) – Prior to the Start of Field Work First Aid & CPR Certificates

Security Verification – through E-Verify Site Plan - Showing existing utilities (water, gas, sewer, hydrants, storm drain, telecom), with a Solar Trenching Plan, to be submitted prior to start of work.

Draft Electrical Single Line Drawing Set (showing inter-connections, electrical cabling route and communications lines) Data Sheets for Any Non-UL Listed Products – See code section above.

9. COMPLIANCE

The contractor will comply with all pertinent provisions of the latest edition of the U.S.

Army Corps of Engineers Safety and Health Requirements COE EM 385-1-1. A copy of COE EM 385-1-1 is available for reference at the project office, or the manual may be viewed at the following link:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf

9.1. Excavation

The contractor shall also comply with all OSHA work safety standards. The project staff can and will order the cessation of work at any time should the safety of employees and visitors become jeopardized.

Contractor is responsible for locating all existing underground utilities prior to excavation and for utilizing “Call before You Dig” – http://call811.com hotline. Any damage done to existing underground utility systems are the sole responsibility of the Contractor.

Any site utility drawings provided by the Government are for informational purposes only and are to be considered incomplete and inaccurate. The Contractor is responsible for confirming the exact location and type of underground utilities present.

Underground utilities that may be found traversing proposed array areas might include, but are not limited to: telecommunications trunks, cable TV lines, electrical distribution conductors, water mains, oil and natural gas lines, access and security camera systems, waste water and/or storm water drain pipes, traffic and/or street light power, and communications cabling.

An arc-fault detection system which is listed by OSHA’s Nationally Recognized Testing Laboratory (NRTL) and compliant to the 2014 National Electrical Code must be installed with this system.

Lockout Requirements: Provide disconnecting means capable of being locked out for machines and other equipment to prevent unexpected startup or release of stored energy in accordance with 29 CFR 1910.147.

10. FEDERAL COMMUNICATIONS COMMISSION

Per Federal Communications Commission Part 15B, the PV system shall not emit electromagnetic interference (EMI) that interferes with other communications, and incoming EMI shall not cause problems with the control or performance of the PV system.

If the PV system emits EMI, the Contractor shall turn off the system and take measures (e.g., cancellation, shielding, ferrite choke), to eliminate the emission of EMI prior to restarting the system.

10.1. Permits

The contractor shall be responsible for preparing all permitting and licensing applications for the project. This includes and is not limited to, providing all required supporting documentation, data, and information that the permitting and licensing agencies may require. The contractor shall coordinate all such work and be the primary liaison with the permitting and licensing agencies. The contractor shall be solely responsible for all permitting and licensing fees. The contractor shall comply with all requirements of permits and licenses issued for the project.

10.2. Professional Licenses

All engineering services shall be performed by design professionals licensed in the state in which the project is being built, with responsible control for each respective design discipline.

All electrical work shall be performed by a licensed electrician and in accordance with the IBC, the National Electrical Code, as well as other applicable codes, standards, and regulations. Contractor shall install all products to manufacturer’s recommendations in conformance with state and local building/wiring codes and the following requirements:

10.3. Modifications and Alterations of Government Property

Modifications, alterations, and/or additions to existing facilities shall be designed and certified to satisfy applicable requirements of this Statement of Work (SOW) document and the governing codes and standards referenced in this SOW document.

10.4. Security

The contractor will comply with all established security policies on government property.

Due to periods of heightened security that may affect the access to the areas covered under this contract, areas may be subject to periodic closures, which in turn may reduce or inhibit the Contractor’s ability to access certain areas. During periods of heightened security, the Government reserves the right, at any time, to close any property or portion of property and reschedule and/or cancel any subsequent service in an area. The Contractor shall be given at least 24 hour notice of any such closure.

10.5. Contractor Conduct

Alcohol and firearms are prohibited on project grounds. Contractor and employees must comply with CFR 36 Rules and Regulations.

10.6. Payment

Payment shall be made on a per job basis. After final inspection and acceptance by the Government, the Contractor must submit an invoice to the Technical Point of Contact. The invoice shall include the invoice date, contract number, dates of service, description of work, quantities, process, and total amount due per line item. For jobs greater than 30 days the contractor may request progress payment.

All invoices may be mailed to:

U.S. Army Corps of Engineers 100 Allerton Farms Road Middlebury, CT 06762

Or Emailed to: Marissa.L.Wright@usace.army.mil

11. GENERAL INFORMATION

ENVIRONMENTAL PROTECTION

Containers for excess and/or waste materials, rubbish, etc. shall be provided by the contractor at the site and the site will be inspected/cleaned on a daily basis. No burning is permissible. Water, air and land resources shall not be adversely impacted during the course of the work. Contractor will take necessary steps to ensure all federal, state, and local environmental regulatory requirements are met.

SUSTAINABLE PRODUCTS

All products provided by the contractor must meet the recycled content requirements set forth by the EPA. Products that fall under these requirements are things such as insulation, restroom dividers, roofing materials, etc. The list of approved products is periodically updated, please check the EPA website for the most current list:

https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program#products.

All products must be covered by the Energy Efficiency Program set forth by the Department of Energy. Products that fall under this category will be water and energy efficient, and include light fixtures, gas water heaters, central air conditioners, windows/doors, etc. The list of products is periodically updated, please check the

Department of Energy’s website for current accepted products:

https://energy.gov/eere/femp/find-product-categories-covered-efficiency-programs.

GOVERNMENT RESOURCES

The contractor is responsible for providing all materials to complete the project. Unless specified in the contract, the Government will not provide any equipment, telephone services or other resources. The contractor may use the restroom at the Project Office, but must proceed directly to and from the restroom.

QUALITY ASSURANCE

The contractor is responsible for the quality control of the contract work. The government has the right to inspect and test all items called for by the contract, to the extent practicable at all times and at all places during the term of the contract.

OMISSIONS

This contract may not cover all specified activities, steps, and procedures required to supply the contract product. In case of omission, the normal industry, state, or federal standards, practices, specifications and/or guides shall prevail. In no instance shall an omission be reason to produce less than an acceptable product.

RECEIVING AND STORING MATERIALS

The contractor is responsible for protecting any stored material until it is placed in service. The contractor is responsible for receiving and unloading of delivered goods.

Government employees will not receive material or supplies for the contractor and will not be responsible for damage to contractor equipment or material

SITE SERVICE CONDITIONS

Materials shall be designed to withstand the year-round temperatures and conditions to which they are exposed (sunlight, heat, rain, cold, wind, seismic, salt air, fog, marine corrosiveness, etc.).

SAME MANUFACTURER AND PRODUCT LINE

All modules, inverters, and electrical switchgear are to be of same manufacturer and product line for each array.

IDENTIFYING EQUIPMENT AND APPEARANCE

Major electrical components, including the inverter, isolation transformer, and metering, shall be installed in code-compliant enclosures. Components shall be located indoors whenever feasible. Space is available in the metal building, office building and garage building where the solar systems will be placed. When inverters and major electrical components are located outdoors, they shall be protected from direct exposure to weather (sun, rain, snow, and sleet).

The Contractor shall coordinate with the Technical Point of Contact regarding locations and appearance of all equipment, including PV modules, conduit, and inverters, disconnect switches, wire ways, control and monitoring equipment, prior to installation.

SYSTEM MARKING AND LABELING

Strict conformance to system marking (labeling) requirements of PV systems and their components are crucial for the safety of operators, service personnel and emergency responders. General PV system labeling requirements, as per NEC 2014 690 Ch. VI, and specific requirements from Articles 690 and 705, shall be followed.

Electrical equipment and components used in PV systems shall have markings that identify the manufacturer, size, type, ratings, hazard warnings, and other specifications. Equipment markings should not be removed and all equipment markings must be durable for the environment in which the equipment is installed. Markings must be visible or easily accessible during and after installation.

All markings, whether applied in the factory or the field, shall be designed to withstand the environment in which they are installed (e.g., “UV rated” for outdoor labels) and permanently affixed to the respective equipment in a manner appropriate for the environment and compatible with the substrate materials. Field-applied markings are required on many types of equipment and components, including (but not limited to) conductors, connectors, conduits, disconnecting means, and point-of-utility connections, as are special markings for bi-polar arrays, ungrounded arrays, battery storage systems, stand-alone inverters providing a single 120-volt supply, and other marking as required by local codes.

OTHER CONTRACTS

The Government may undertake or award other contracts for additional work not related to this contract, and the Contractor shall fully cooperate with other Contractors and Government employees. The contractor shall not commit or permit any act, which will interfere with the performance of work by another contractor, or by Government employees.

CLEAN UP

The contractor shall practice good housekeeping to maintain a safe job site. The contractor shall keep the work area, including any storage areas, free from the accumulation of waste materials. Upon completing work in an area the contractor shall remove any tools, equipment, and materials that are not the property of the government. Upon completion of work, the Contractor shall clean up the job site to the satisfaction of the Government.

INFORMATION REQUEST

Requests concerning the work of this project should be directed to the Technical Point of Contact at the Naugatuck River Basin Office at 978-318-8374 or Marissa.L.Wright@usace.army.mil.

SHEDULE

Period of performance is 90 days after contract award.

NOTICE TO OFFERORS

*SITE VISITS ARE HIGHLY RECOMMENDED PRIOR TO PROVIDING A QUOTE.

SEE CLAUSE 52.236-27 FOR ADDITIONAL INFORMATION. Offerors are notified that the basis for award is price alone.

*PLEASE DIRECT QUESTIONS TO KIM PUMYEA AT (978) 318-8720 or kimberly.b.pumyea@usace.army.mil. ANY INFORMATION RECEIVED AT THE SITE

VISIT WHICH CONFLICTS WITH THIS SOLICITAION SHOULD BE BROUGHT TO

THE ATTENTION OF MS. PUMYEA. THE SOLICITATION AND RESULTING

CONTRACT SHALL BE THE GOVERNING DOCUMENT IN ALL CASES.

** QUOTES CAN BE FAXED OR E-MAILED TO KIMBERLY B. PUMYEA AT (978) 318-

8207 or kimberly.b.pumyea@usace.army.mil. E-mail is the preferred method.

NOTE 1: In accordance with FAR Part 28.102-1(b)(1), the Contractor will be required to provide one of the following payment protections for all construction contracts greater than $35,000.00 but not greater than $150,000.00.

(i) Payment bond

(ii) Irrevocable letter of credit

A Payment Bond or Irrevocable Letter of Credit is the SELECTED payment protection for the Government. The penal amount of bond shall be 100% of the original contract price. If the contract price increases, the Government will require an increase in the penal sum of the existing bond. This bond shall be submitted to the Contracting Officer within 10 days after receipt of award.

NOTE 2:

QUOTATION INSTRUCTIONS:

1. If subcontractor will be used for this work, please provide company name and credentials/qualifications:

2. Contractors must be registered in the System for Awards Management (SAM) database (www.SAM.gov) to receive an award. (Formerly the Central Contractor Registration (CCR) database and the On-Line Representations and Certifications (ORCA).) Any reference to CCR or ORCA in any clause or provision is referring to the www.sam.gov website. Please note that Google and Google Chrome are not supported browsers for SAM registration. Mozilla FireFox, Safari, and Internet Explorer are supported browsers.

IMPORTANT NOTICE: SAM registration may take up to three (3) weeks.

SAM.gov registration takes approximately 3 weeks (DUNS registration 1-2 business days; CAGE code validation up to 10 business days; IRS validation and overall submission 7-10 business days). It is the contractor’s responsibility to track SAM.gov registration and follow-up with required tasks. SAM.gov registration does not have to be “active” to be able to submit a quote. However, contractors must have an active record before a contract award can be made. If SAM.gov registration is not completed in a timely fashion in accordance with the SAM.gov timelines, the Government reserves the right to disqualify the quote in accordance with FAR 52.204-7(d).

NOTE: SAM registration may take up to three (3) weeks. All contractors must have an active SAM.gov registration to be eligible for award.

Contractors should note that 30 September is the end of the Government fiscal year.

As that date approaches, the Government will be unable to delay year-end contract awards and will have to disqualify contractors without an active SAM.gov registration. If you have any questions, please contact the aforementioned point of contact.

NOTE: CONTRACTORS MUST BE REGISTERED IN SAM.GOV BY SEPT. 22, 2017

TO BE ELIGIBLE FOR AWARD.

3. Provide business DUNS number: _______________________________ (phone 800-333-0505 for DUNS).

4. Provide business CAGE code: __________________________________

5. Tax Identification Number: ___________________________________

6. Contractors shall provide completed FAR clause 52.204-8 (Annual Representations and Certifications) found in Section K of this solicitation with their quote, if the Contractors have not completed their annual representations and certifications electronically via the SAM website at www.sam.gov. (See Paragraph 2 above)

7. Contractors are not required to submit an Accident Prevention Plan (APP) with their quote. The successful offeror will be required to submit this document upon award. The APP must be accepted by the Government Designated Authority prior to the preconstruction conference.

8. POTENTIAL OFFERORS ARE NOTIFIED THAT THE BASIS FOR AWARD IS

LOWEST PRICE.

SECURITY REQUIREMENTS

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the Technical Point of Contact not later than 5 calendar days after the completion of the training.

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the Technical Point of Contact no later than 3 business days after the initial award.

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 90 dys. ADC 1 STAMFORD HURRICANE BARRIER

PO BOX 396 DYKE LANE

STAMFORD CT 06904-0394

FOB: Destination

E6R0660

Section G - Contract Administration Data

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-13 System for Award Management Maintenance OCT 2016 52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.219-3 Notice of HUBZone Set-Aside or Sole Source Award NOV 2011 52.219-4 Alt I Notice of Price Evaluation preference for HUBZone Small

Business Concerns (JAN 2011) Alternate I

JAN 2011

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-4 Recovered Material Certification MAY 2008 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-16 Quantity Surveys APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995

52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.227-7033 Rights in Shop Drawings APR 1966 252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 Days from Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2017).

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are ncorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(iii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(iv) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(v) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(vi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(vii) 52.233-4, Applicable Law…