Amendment_0002_W912UM-18-R-0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04 EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

a. This amendment is issued to include revised specification as attached.

b. Changes are indicated by asterisks before and after a revision and annotation "(Am-0002)” is shown at the bottom of each page.

c. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 1

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA 15C. DATE SIGNED 15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer) (Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912UM-18-R-0002

X 9B. DATED (SEE ITEM 11)

08-Mar-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN TH

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

15-Mar-2018

CODE

CONTRACTING DIVISION

U.S. ARMY CORPS OF ENGINEERS

FAR EAST DISTRICT

UNIT #15546

APO AP 96205-5546

W912UM 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODE CODE

EMAIL:TEL:

X

W912UM-18-R-0002

252.245-7001 Tagging, Labeling, and Marking of Government-Furnished Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012 252.245-7004 Reporting, Reutilization, and Disposal SEP 2016 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for

Military Operations

OCT 2010

252.247-7023 Transportation of Supplies by Sea APR 2014 5152.232-9000 Payment for Materials Delivered Off-Site. NOV 2014

CLAUSES INCORPORATED BY FULL TEXT

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed (NTP), (b) prosecute the work diligently, and (c) complete the entire work ready for use in accordance with the schedule set forth below. The time stated for completion shall include final cleanup of the premises.

YRP PN A09Y617 (C4I090) BCTC Secure Facility, USAG Humphreys, Korea

Phase Description Contract Completion Date 0 Administrative, Procurement, and

Mobilization Work Approximately 90 calendar days after a partial NTP

1 C4I090, BCTC Secure Facility, Construction to include Commissioning and Turnover

630 Calendar days after Phase 1 NTP

Note: An NTP for Phase 0 will be issued on or about 30 Jun 2018 for administrative, procurement, and mobilization work. A separate Construction Security contractor will construct the temporary security facilities and must be in place prior to NTP for Phase 1. An NTP for phase 1, the contract commencement for C4I090, BCTC Secure Facility, will be issued on or about 30 Sep 2018.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

a. If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount shown below for each calendar day of delay until the work is completed or accepted.

YRP PN A09Y617 (C4I090) BCTC Secure Facility (Building Phase/US) and

Phase 1 ------------------------------------------ *$10,398.00*

b. If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(Am-0002)