W912QR25BA018_Specs-0004_Amendment 4.pdf

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of theoffer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

J 1 9

0004 31 JUL 2025 513946

W912QR

W072 ENDIST LOUISVILLE

KO CONTRACTING DIVISION, 600 DR MARTIN LUTHER KING JR PL

LOUISVILLE, KY 40202-2230

UNITED STATES

LADONNA HAUG, EMAIL: LADONNA.J.HAUG@USACE.ARMY.MIL TELEPHONE: 000-

000-0000

SCD: PAS:

W912QR25BA018

01 JUL 2025

SEE SECTION G - CONTRACT ADMINISTRATION DATA

THIS AMENDMENT SERVES TO EXTEND THE DUE DATE OF BIDS FROM 30 JULY 2025 10:00 AM TO 7 AUGUST 2025 10:00 AM, AND REPLACE THE PLANS & SPECS IN

THEIR ENTIRETY.

THE EXTENSION OF THE BID DATE HAS ALREADY BEEN EXTENDED INFORMALLY ON SAM.

UPDATED WAGE DETERMINATIONS IN20250006, DATED 18 JULY 2025 HAVE BEEN INCLUDED.

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS CLAUSE 252.232-7006 HAS BEEN REMOVED.

W912QR25BA018_Specs-0004

513947 CANNELTON L&D INTERLOCKS/DAM ENCODERS UPGRADE

CANNELTON L&D, CANNELTON, INDIANA

SECTION 00 80 00.00 0 6

SPECIAL PROVISIONS

04/21, CHG 1: 06/23

PART 1 GENERAL

Attachments to this specification are as follows:

Project Submittal Register

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2024) Safety -- Safety and Occupational Health (SOH) Requirements

ERDC/ITL TR-12-1 (2015) A/E/C Graphics Standard, Release 2.0

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1926.59 Hazard Communication

1.2 SUBMITTALS

Government approval/acceptance is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

Local Agency Check; G, RO

SF1413 Statement and Acknowledgement; G, RO

SD-02 Shop Drawings

SD-04 Samples

Equipment Warranty Identification Tags; G, RO

SD-05 Design Data

Progress Photographs; G, RO

SD-07 Certificates

Warranty of Construction; G, RO

DOCUMENT 00 80 00.00 06 Page 1 Certified Final Amendment 0004

Amendment 0004

NO ASBESTOS - CONTAINING MATERIAL (ACM) CERTIFICATION; G, RO

Construction Phase:

Certification for each individual product installed and identified to contain mineral fibers that no asbestos-containing materials were installed; G, RO

Documentation to show that the products containing mineral fiber materials have been microscopically examined by an AIHA- or NVLAP-certified laboratory and the lab has determined that the material does not contain asbestos; GG, RO

Insurance; , RO

Sales and Use Tax; G, RO.

SD-11 Closeout Submittals

Preliminary (Working) As-Built Drawings; G, RO

Final As-Built Drawings; G, RO

CAD Working As-Built Drawings; G

Equipment-in-Place List; G, RO

Maintenance and Parts Data; G, RO

Warranty Management Plan; G, RO

1.3 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

a. Refer to clause 52.211-12 "LIQUIDATED DAMAGES" in Section 00 70 00 for the amount of Liquidated Damages for the project.

b. Refer to clause 52.211-10 "Commencement, Prosecution, and Completion of Work" in Section 00 70 00 for a notification of significant contract dates.

c. After approval of the required bonds, the Government will issue an Administrative Notice-to-Proceed (NTP) to allow for preconstruction activities to be initiated in accordance with the contract requirements. The contract period of performance specified in Contract Clause 52.211-10 will begin upon issuance of Administrative NTP. No physical onsite work will be permitted during the Administrative NTP period. All required preconstruction activities and submittals must be submitted and accepted by the Government, where applicable, within the Administrative NTP period of 45 days. The Government will issue a Construction NTP to allow commencement of all other contract work after the Administrative NTP period, or after the contractor's completion of all work specified in the Administrative NTP. Failure to complete all required preconstruction activities may result in the contract being terminated for default in accordance with Contract Clause 52.249-10 Default (Fixed-Price Construction).

DOCUMENT 00 80 00.00 06 Page 2 Certified Final

1.3.1 Additional Requirements/Clarifications of Work Included Within the Contract

a. The time stated in clause 52.211-10 "Commencement, Prosecution, and Completion of Work" in Section 00 70 00 for completion shall include construction efforts, as well as as-built drawings, O&M manuals, operational tests/reports/training/instructions, equipment lists.

1.4 EXCLUSION OF PERIODS IN COMPUTING COMPLETION SCHEDULES

Project site to remain active during construction. All construction efforts requiring outages to project areas to be coordinated and scheduled with Construction Officer and project lockmaster. All outage requests to be submitted in writing no less than 14 days prior to work. Outages exceeding 4 hours will require USACE coordination with industry (public navigation impact notice) and shall be kept to a minimum. Maximum of 12-hour shutdowns will be permitted during construction. All requested dates are to be approved prior to the outage work. No work will be allowed during the periods of highwater on the river. High water season is typically months between November and April inclusive, and such period has not been considered in computing the time allowed for completion. If upper pool staff gauge is 21' or above, or water is ingressing into filling/emptying valve pits, coordinate with Construction Officer and project lockmaster on construction efforts or potential stoppages. River hydrographs have been provided as an appendix to this specification for contractor reference. The Contractor may, however, perform work during all or any part of this period upon giving prior written notice to and receiving approval from the Contracting Officer.

Project mission is number one priority and impacts to mission due to construction efforts are to be minimized. Lock navigation to remain open, contractor may perform work on single lock at any given time to ensure project mission continuation.

Contractor to complete lock interlock modification work on 600’ auxiliary lock work first prior to performing work on 1200’ main chamber. USACE Operations Division will provide additional downtime allowances for installation/fabrication/testing to allow contractor to streamline construction process. Downtime to 1200’ main lock to be kept to minimum, and contractor to use lessons learned on auxiliary chamber for update to main chamber.

Daily workplans and overall construction focus efforts are to consider project system downtime(s). Considerations are to be taken for routing/preparing/installing equipment prior to taking existing equipment offline for installation (e.g. – routing of wiring, instrument assemblies fully assembled prior to installation, instrument junction box completion prior to impacting existing system, etc.). Additional considerations are to be taken to allow for use of new and old equipment concurrently while rehab is ongoing to allow for operability (e.g. new culvert valve position indication installed while old miter gate equipment is still being utilized).

All situations causing impacts to operability of lock systems are to be relayed to USACE COR and project lockmaster prior systems being taken offline. Project may have to operate in bypass mode to accommodate construction efforts. Multiple outages may be taken with proper coordination, system to be operable after each outage.

Amendment 0004*******************************************************************

*******************************************************************Amendment 0004

DOCUMENT 00 80 00.00 06 Page 3 Certified Final

1.5 CONTRACT DRAWINGS AND SPECIFICATIONS

In addition to DFARS 252.236-7001 "Contract Drawings and Specifications" in Section 00 70 00 the following will apply:

a. After Award or no later than Notice to Proceed (NTP), the Government will furnish the Contractor a compact disk containing all technical contract documents in electronic media only. This disk will include a complete set of drawing files and technical specification files which have all amendments included. The disk will contain drawing files in PDF format along with technical specifications in PDF format. These PDF files are the contract documents that represent the construction requirements of the contract, and are being provided for the Contractor's use in printing paper copies of contract documents.

b. In addition, native CAD files(this includes, but not limited to, all source files, models, custom fonts and linestyles, plot files, and images used to create the contract drawings) are provided in accordance with the "AS-BUILT DOCUMENTS" paragraph for the Contractor's use in maintaining and preparing as-built plans. If another CAD Program is used other than the Using Agency's System, all native CAD files that were generated with that software and all support files will also be included. Only native files are to be used for As-Built preparation and information.

c. Native files are to be used for As-Built preparation only. The PDF files are the contract documents that represent the construction requirements of the contract.

513947 CANNELTON L&D INTERLOCKS/DAM ENCODERS UPGRADE

CANNELTON L&D, CANNELTON, INDIANA

1.6 AS-BUILT DOCUMENTS FOR DESIGN BID BUILD PROJECTS

1.6.1 General

This section covers the completion of final as-built drawings, as a requirement of the contract. The Contractor is responsible for maintaining paper copy working as-built drawings during the construction phase. These paper copy drawings will be used by the Contractor to prepare, maintain and submit the final as-built drawings

1.6.1.1 As-Built Drawings

An as-built drawing is a contract construction drawing revised to reflect the final as-built conditions of the project because of modifications, changes, corrections to the project design required during construction, submittals and extensions of design. The terms "drawings," "contract drawings," "drawing files," "working as-built drawings" and "final as-built drawings" refer to contract drawings that are revised to be used for the "RECORD DRAWING AS-BUILTS".

DOCUMENT 00 80 00.00 06 Page 4 Certified Final

1.6.1.2 Government-Furnished Files

a. The Contractor will be provided electronic files at the beginning of construction for use during the construction phase which are to be maintained during construction for the preparation of as-builts. The Contractor shall be responsible to print two full size paper copies.

The Contractor shall enter changes and corrections on two sets of paper full size construction plans on a weekly basis in accordance with Paragraph "Maintenance of Working As-Built Drawings" in this section.

b. The Contractor is required to prepare final as-built drawings utilizing the native files provided by the Government. If translation is required, the original design models (BIM or CAD) shall be updated to As-Built conditions and then appropriately translated. Updating translated drawings will not be accepted. The contractor shall update the CAD working as-built drawings, in accordance with paragraph "Maintenance of Working As-Built Drawings", on a quarterly basis and submit them to the COR for independent Government review. Both paper and electronic documents shall be available at all times and shall be provided promptly to the Contracting Officer's Representatives when requested. The Contractor shall be responsible for backup of electronic files during construction and for controlling release of information.

1.6.2 Withholding

Maintenance of working as-builts is considered part of the value of the facilities being constructed and will not be paid for as a separate line item. All costs in conjunction with periodic as-built maintenance and final preparation shall be considered a subsidiary obligation of the Contractor.

1.6.2.1 Failure to Maintain

If the Contractor fails to maintain the working as-built drawings as specified herein, the Contracting Officer will deduct from the monthly progress payment an amount up to 10% or which, in the Contracting

Officer's judgment, represents the estimated cost of bringing the as-built documents up to date. This monthly deduction will continue until an agreement can be reached between the Contracting Officer and the Contractor regarding the accuracy and completeness of working as-built documents. This includes conversion of submittals and other miscellaneous documents.

DOCUMENT 00 80 00.00 06 Page 5 Certified Final

1.6.2.2 As-Builts Prepared by Contractor

The Contractor is required to prepare and provide final as-built drawings. The Contractor shall include an activity in the cost-loaded schedule for the final As-Built drawing submittal in the amount defined in the following paragraph. See Section 01 32 01.00 06, PROJECT SCHEDULE, para "Basis for Payment and Cost Loading". This amount shall be withheld and not paid until the final As-Built drawing submittal has been accepted by the Government.

Withholding for the final as-built drawing submittal shall be in the amount of: 1% for contract awards less than $5,000,000; $50,000 for contracts awarded from $5,000,000 to $10,000,000; or $100,000 for contracts awarded greater than $10,000,000. Withholding shall be withheld until the final as-built drawing submittal has been approved and accepted by the Government.

1.6.3 Maintenance of Working As-Built Drawings

The Contractor shall revise two (2) sets of paper drawings by red-line process to show the as-built conditions during the prosecution of the project. These as-built marked drawings shall be kept current on a weekly basis and available on the jobsite at all times. Changes in the work from the contract or additional information which is uncovered in the course of construction shall be accurately and neatly recorded as they occur by means of details and notes. Changes must be reflected on all sheets that the change affects . The working as-built marked drawings will be jointly reviewed for accuracy and completeness by the Contracting Officer and the Contractor before submission of each monthly pay estimate. The working as-built drawings shall show the following information if applicable to the project, but not be limited thereto:

a. The actual location, kinds and sizes of all sub-surface utility lines. In order that the location of these lines and appurtenances may be determined in the event the surface openings or indicators become covered over or obscured, the as-built drawings shall show, by offset dimensions to two permanently fixed surface features, the end of each run including each change in direction. Valves, splice boxes and similar appurtenances shall be located by dimensioning along the utility run from a reference point. The average depth below the surface of each run shall also be recorded.

b. The location and dimensions of any changes within the building structure.

c. The correct alignments, grade elevations, typical cross section, earthwork, structures or utilities if any changes were made from contract plans.

d. Additional as-built information that exceeds the detail shown on the Contract Drawings. These as-built conditions include those that

DOCUMENT 00 80 00.00 06 Page 6 Certified Final reflect structural details, fabrication, erection, installation plans and placing details, pipe sizes, insulation material, dimensions of equipment foundations and layouts, equipment, sizes, mechanical and electrical room layouts and other extensions of design, that were not shown in the original contract documents because the exact details were not known until after the time of approved shop drawings. It is recognized that the shop drawing submittals (revised showing as-built conditions) will serve as the as-built record without actual incorporation into the contract drawings. The final as-built construction drawing shall reference the shop drawing file that includes the as-built information. In turn, the shop drawing shall reference the applicable construction as-built drawing. All such shop drawing submittals must include the paper copy and PDF of the drawings.

e. The invert elevations and grades of any drainage structures or ditches installed or affected as part of the project construction.

f. Changes or modifications which result from the final inspection.

g. Not used.

h. Where contract drawings present options, only the option selected for construction shall be shown on the final as-built drawings.

i. Systems designed or enhanced by the Contractor, such as HVAC controls, fire alarms, fire sprinklers, fire protection, fire detection and irrigation systems and other related systems in this project, shall be incorporated into the as-built drawings to include detailed information for all aspects of the systems including wiring, piping, and equipment drawings.

j. Room numbers shown on the contract drawings are selected for design convenience and may not represent the actual numbers intended for use by the end user. Final as-built drawings shall reflect actual room numbers adopted by the end user.

k. Contract modification (change order price) shall include the Contractor's cost to change working and final as-built drawings to reflect modifications and compliance with the following procedures (See "Markings and Indicators"):

(1) Directions in the modification for posting descriptive changes shall be followed.

(2) A Revision Triangle shall be placed at the location of each deletion.

(3) For new details or sections which are added to a drawing, a Revision Triangle shall be placed by the detail or section title.

(4) For minor changes, a Revision Triangle shall be placed by the area changed on the drawing (each location).

(5) For major changes to a drawing, a Revision Triangle shall be placed by the title of the affected plan, section, or detail at each location.

(6) For changes to schedules or drawings, a Revision Triangle shall be placed either by the schedule heading or by the change in the

DOCUMENT 00 80 00.00 06 Page 7 Certified Final schedule.

1.6.4 Preliminary (Working) As-Built Drawings

Six (6) weeks before Contract Completion Date, the Contractor shall submit one (1) set of the original paper working as-built drawings to the Contracting Officer for review and approval. These working as-built marked drawings shall be neat, legible and accurate. The review by Government personnel will be expedited to the maximum extent possible. If upon review, the working as-built drawings are found to contain errors and/or omissions, they will be returned to the Contractor for corrections. The Contractor shall complete the corrections and return the working as-built marked drawings to the Contracting Officer within fourteen (14) calendar days. Upon approval, the working as-built drawings will be returned to the Contractor for use in preparation of final as-built drawings.

1.6.5 Preparation of Final As-Built Drawings

The contract drawings shall be modified as may be necessary to correctly show the features of the project as it has been constructed by bringing the contract drawings into agreement with approved working as-built drawings, adding such additional drawings as may be necessary.

These final as-built drawings are part of the permanent records of the project and the Contractor shall be responsible for the protection and safety thereof until returned to the Contracting Officer. Any drawings damaged or lost by the Contractor shall be satisfactorily replaced by the Contractor at no expense to the Government.

When electronic CAD files are a part of the as-built process, a set of files shall be provided to the Government as a part of the Final As-Built submittal for a review to verify the correctness of the as-built markups and that all changes have been incorporated into the electronic files.

Should errors be determined, the Contractor shall update the files and provide a corrected set of files within fourteen (14) calendar days of receipt of comments. An independent Government review, by the Louisville district As-Built Coordinator (CELRL-CDM-Q), will be made on the accepted files to determine compliance with the As-Built requirements of this section, National CAD Standards, and the AEC CAD Standards; and to verify graphic changes were done properly in preparing the electronic files. This review will require submission of electronic files, containing all the files needed to reproduce the contract drawings, a full size set of contract drawings in PDF format, all shop drawings in PDF format, a scanned set of the paper markups and the paper markups. Upon receipt of any comments from this independent review, the contractor shall update the electronic files and provide a corrected set of files within fourteen (14) calendar days of receipt of the comments.

In the event the Contractor accomplishes additional work which changes the as-built conditions of the facility, after submission and approval of the working as-built drawings, the Contractor shall be responsible for the addition of these changes to the working as-built drawings and also to the final as-built documents .

1.6.6 Markings and Indicators

Changes shall be annotated in accordance with ERDC/ITL TR-12-1 "A/E/C Graphics Standard_Release 2.0" at the following locations:

DOCUMENT 00 80 00.00 06 Page 8 Certified Final

a. Bottom of the revised detail.

b. Right hand and bottom border aligned with the revised detail.

c. The revision block of the title block.

Separate markings shall be made for each modification negotiated into the contract.

1.6.7 Construction Contract Specifications

Submit final PDF file record construction contract specifications, including revisions thereto, with submission of final as-built drawings.

1.6.8 Preparation of Other As-Built Documents

All other non-electronic documents which may include, for example, design analysis, catalog cuts, or certification documents that are not available in native electronic format shall be scanned and provided in an organized manner in Adobe PDF format.

1.6.9 Submittal of Final As-Built Documents

Within fourteen (14) calendar days of Final Acceptance meeting of the project, Final As-Built documents shall be provided to the Contracting Officer in the formats described in paragraph "Electronic File Use". The final as-built document submittal shall also include the approved preliminary paper working as-built drawings.

1.6.10 Partial Occupancy

For projects where portions of construction are to be occupied or activated before overall project completion, including portions of utility systems, as-built drawings for those portions of the facility being occupied or activated shall be supplied at the time the facility is occupied or activated. This same as-built information previously furnished must also be shown on the final set of as-built drawings at project completion.

1.6.11 Electronic File Use

Only personnel proficient in the preparation of CAD drawings shall be employed to modify the electronic contract drawings or prepare additional new electronic drawings. Additions and corrections to the contract drawings shall be equal in quality to that of the originals. Line work, line weights, lettering, layering conventions, and symbols shall be the same as the original line work, line weights, lettering, layering conventions, and symbols. If additional drawings are required, they shall be prepared using the specified electronic file format applying the same guidance specified for original drawings. Three dimensional (3D) elements shall be placed in files in their proper locations when using 3D files with spatially correct elements. If the Designer of Record used a different software than that requested by the Using Agency, the Designer of Record's files will be used for as-built purposes and then translated and/or exported, by the Contractor, to the Using Agency's system. The title block and drawing border to be used for any new final as-built drawings shall be identical to that used on the contract drawings.

Additions and corrections to the contract drawings shall be accomplished using CAD media files supplied by the Government. All work by the Contractor shall be done on files in the format in which they are provided. Translation of files to a different format, for the purpose of

DOCUMENT 00 80 00.00 06 Page 9 Certified Final

As-Built production, and then retranslating back to the format originally provided, will not be acceptable. The original electronic files provided by the Government will be provided in the format compatible with the Using Agency. The Using Agency uses Autodesk AutoCAD Release 2022 CAD software system. The Contractor shall be responsible for providing all program files and hardware necessary to prepare final as-built drawings. The Contracting Officer will review final as-built drawings for accuracy and the Contractor shall make all required corrections, changes, additions, and deletions.

a. When final revisions have been completed, the cover sheet drawing shall show the wording "RECORD DRAWING AS-BUILT" followed by the name of the Contractor in letters at least 5 mm 3/16 inch high. All other contract drawings shall be marked in the bottom right-hand corner of each drawing either "AS-BUILT" drawing denoting no revisions on the sheet, or "REVISED AS-BUILT" denoting one or more revisions. As-Built drawings shall be dated with the Contract Completion Date in the revision block.

b. After receipt by the Contractor of the approved working as-built drawings and the original contract drawings files the Contractor shall, within sixty (60) calendar days, make the final as-built submittal. This submittal shall consist of 2 sets of completed final as-built drawings on separate media consisting of both CAD files (compatible with the Using Agency's system on electronic storage media identical to that supplied by the Government) and a full size set in PDF format and the return of the approved marked up working as-built drawings. They shall be complete in all details and identical in form and function to the contract drawing files supplied by the Government.

Any translations or adjustments necessary to accomplish this are the responsibility of the Contractor. The Government reserves the right to reject any drawing files it deems incompatible with its CAD system.

All paper drawings, drawing files and storage media submitted will become the property of the Government upon final approval. Failure to submit final as-built drawing files and marked drawings as specified shall be cause for withholding any payment due the Contractor under this contract. Approval and acceptance of final as-built drawings shall be accomplished before final payment is made to the Contractor.

1.7 NOT USED

1.8 EQUIPMENT DATA, O&M, & REPAIR MANUALS WITH FIELD TRAINING REQUIREMENTS

1.8.1 Real Property Equipment

OPTION #2 Equipment-in-Place Data

Contractor shall be required to make an Equipment-in-Place list of all installed equipment furnished under this contract. This list shall include all information usually listed on manufacturer's name plate. The Form is part of SPECIAL PROVISIONS and is included following the SPECIAL PROVISIONS, so to positively identify the piece of property. The list shall also include the cost of each piece of installed property F.O.B.

construction site. For each of the items which are specified herein to be guaranteed for a specified period from the date of acceptance thereof, the following information shall be given: The name, serial and model number address of equipment supplier, or manufacturer originating the guaranteed item. The information shall also be provided in excel spreadsheet format with columns for above information in addition to floor, space id as

DOCUMENT 00 80 00.00 06 Page 10 Certified Final listed in the drawings, system, and submittal register id number for the item. The Contractor's guarantee to the Government of these items will not be limited by the terms of any manufacturer's guarantee to the Contractor. Furnish the list as one (1) reproducible and three (3) copies, and in electronic format on CD to the Contracting Officer thirty

(30) calendar days before completion of any segment of the contract work which has an incremental completion date.

Maintenance and Parts Data The Contractor will be required to furnish a brochure, catalog cut, parts list, manufacturer's data sheet or other publication which will show detailed parts data on all other equipment subject to repair and maintenance procedures not otherwise required in Operations and Maintenance Manuals specified elsewhere in this contract. This information shall be provided electronically in PDF format with bookmarks for each piece of equipment with file name included in a separate column or linked worksheet in the equipment data excel spreadsheet as described in the paragraph above. Distribution of directives shall follow the same requirements as listed in paragraph above.

1.8.2 O&M and Repair Manuals

OPTION #1 Withholding & Copies

The Contractor shall provide 6 complete copies of the Equipment Operating, Maintenance, and Repair Manuals unless the Technical Specification indicates otherwise. The manuals shall be prepared electronically in PDF format containing bookmarks for each table of contents item. The PDF file shall be referenced in a separate column or linked worksheet in the equipment data excel spreadsheet. Separate manuals shall be provided for each utility system as defined per the Technical Specification.

Operations and Maintenance manuals shall be accepted/approved before field training or ninety (90) calendar days before substantial completion (whichever occurs earlier). An amount of $20,000 shall be withheld until submittal and acceptance/ approval of O&M manuals is complete. A draft outline and table of contents shall be submitted for acceptance/ approval at 50% contract completion See paragraph "EQUIPMENT DATA, O&M, & REPAIR MANUALS WITH FIELD TRAINING REQUIREMENTS" for detail O&M and Repair Manual format.

1.8.3 Field Training

1.8.3.1 Training Course

Contractor shall conduct a training course for the operating staff for each particular component and system. Where the training period is not identified by the technical specification, a minimum of 8 hours of training shall be provided for that component or system. Training shall only occur after the Manuals have been approved/ accepted by the Government and during normal working time, and shall start after the system or component is functionally completed. The field instructions shall cover all of the items contained in the Equipment Operating, Maintenance and Repair Manuals as identified per individual Technical Specifications. The training will include both classroom and "hands-on" training. The Contractor shall submit a lesson plan outlining the information to be discussed during training periods. This lesson plan will be submitted ninety (90) calendar days before contract completion and accepted/approved before the field training occurs. Training shall be documented by the Contractor and a list of attendees shall be furnished to

DOCUMENT 00 80 00.00 06 Page 11 Certified Final the Government. Training audio/ video shall be digitally recorded on CDs or DVDs and shall be furnished to the Government within ten (10) calendar days following training.

1.8.3.2 Training Recording

The Contractor shall provide all equipment, materials, and trained personnel required to visually and audibly record all site operations and maintenance (O&M) training sessions. The video technician/trainer shall be employed by a video production company that has been in business for a minimum of 2 years. The Contractor shall submit for acceptance by the Government, the resume of the technician/trainer and the video production company, and the proposed video format. The video format shall be one in wide use, and any software necessary to view the video shall be provided to the Government. Video shall be provided to the Government on DVD.

Audio shall be adjusted, filtered or otherwise controlled to ensure the presenter can be understood at all times. Each system or piece of equipment shall be covered on a single DVD or set of DVDs, which shall be identified with a type written label showing the name of the project, equipment or system, and contract number. This same information shall be provided as an introduction on each DVD. When two or more DVDs are provided for a single system or piece of equipment, they shall be packaged as a set in an appropriate storage case. Provide three copies of each DVD(s) for each training session. Training DVDs shall be furnished to the Government within ten (10) working days following training.

1.9 AVAILABILITY OF UTILITIES

a. Availability and Use of Utility Services

Electric Power for Small Tools not exceeding 20 amperes and 115 volts will be furnished from existing outlets, as specified in the contract at no cost to the Contractor. If contractors trailer requires power, contractor to coordinate power procurement (temporary service) with local utility for trailer. Portable generators shall not be allowed to power trailer.

b. Additional Requirements

(1) Drinking Water may not be obtained from existing outlets by Contractor personnel.

(2) Existing Washing Facilities in the building may not be used by Contractor employees.

1.9.1 Alterations to Utilities

Where changes and relocations of utility lines are noted to be performed by others, the Contractor shall give the Contracting Officer at least thirty (30) calendar days written notice in advance of the time that the change or relocation is required. In the event that, after the expiration of thirty (30) calendar days after the receipt of such notice by the Contracting Officer, such utility lines have not been changed or relocated and delay is occasioned to the completion of the work under contract, the Contractor may be entitled to a time extension equal to the period of time lost by the Contractor after the expiration of said thirty (30) calendar day period.

DOCUMENT 00 80 00.00 06 Page 12 Certified Final

1.9.2 Interruptions of Utilities

a. No utility services shall be interrupted by the Contractor to make connections, to relocate, or for any purpose without approval of the Contracting Officer.

b. Request for Permission to shut down services shall be submitted in writing to the Contracting Officer not less than seventeen (17) working days before date of proposed interruption. The request shall give the following information:

(1) Nature of Utility. (Gas, L.P. or H.P., Water, etc.)

(2) Size of line and location of shutoff.

(3) Buildings and services affected .

(4) Hours and date of shutoff.

(5) Estimated length of time services will be interrupted.

c. Services shall not be shut off until receipt of approval of the proposed hours and date from the Contracting Officer.

d. Shutoffs which will cause interruption of Government work operations as determined by the Contracting Officer shall be accomplished during regular non-work hours or on non-work days of the Using Agency without any additional cost to the Government.

e. Operation of valves on water mains will be by persons of that utility. Where shutoff of water lines interrupts service to fire hydrants or fire sprinkler systems, the Contractor shall arrange his operations and have sufficient material and personnel available to complete the work without undue delay or to restore service without delay in event of emergency.

f. Flow in gas mains which have been shut off shall not be restored until the Government inspector has determined that all items serviced by the gas line have been shut off.

1.10 NOT USED

1.11 PERFORMANCE OF WORK BY THE CONTRACTOR

a. Not used.

b. Not used.

c. Within seven calendar days after the award of any subcontract at any tier, either by himself or a subcontractor, the Contractor shall submit to the Contracting Officer a completed Standard Form SF1413 Statement and Acknowledgement (available at the GSA Forms Library, https://www.gsa.gov/reference/forms#). The form shall include the subcontractor's acknowledgement of the inclusion in his subcontract of the clauses in Section 00 70 00 of this contract entitled 52.222-4 "Contract Work Hours and Safety Standards - Overtime Compensation"; 52.222-8 "Payrolls and Basic Records"; 52.222-7 "Withholding of Funds"; 52.222-14 "Disputes Concerning Labor Standards"; 52.222-13 "Compliance with Construction Wage Rate Requirements and Related Regulations"; 52.222-6 "Construction Wage Rate Requirements" (formerly named "Davis-Bacon Act");

52.222-9 "Apprentices and Trainees"; 52.222-10 "Compliance with Copeland Act Requirements"; 52.222-11 "Subcontracts (Labor Standards); 52.222-12 "Contract Termination - Debarment"; 52.222-15 "Certification of

DOCUMENT 00 80 00.00 06 Page 13 Certified Final

Eligibility". Nothing contained in this contract shall create any contractual relation between any subcontractor and the Government.

d. Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in Subpart 22.13, provision 52.222-38, clause 52.222-35, clause 52.222-37, DFARS Subpart

222.13 and United States Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

(1) U.S. Department of Labor Veterans' Employment and Training Service (VETS): https://www.dol.gov/vets/

(2) Federal veteran employment information:

https://www.fedshirevets.gov/

(3) Veterans Opportunity to Work (VOW) Program:

https://benefits.va.gov/vow/

(4) U.S. Army Warrior Transition Command Employment Index:

http://wct.army.mil/modules/employers/index.html

(5) Hiring Our Heroes:

https://www.uschamberfoundation.org/hiring-our-heroes

1.12 SUPERINTENDENCE OF SUBCONTRACTORS

a. The Contractor shall be required to furnish the following, in addition to the superintendence required by clause 52.236-6 - "Superintendence By The Contractor" in Section 00 70 00.

(1) If more than 50 percent and less than 70 percent of the value of the contract work is subcontracted, one superintendent shall be provided at the site and on the Contractor's payroll to be responsible for coordinating, directing, inspecting and expediting the subcontract work.

b. If the Contracting Officer, at any time after 50 percent of the subcontracted work has been completed, finds that satisfactory progress is being made, he may waive all or part of the above requirements for additional superintendence subject to the right of the Contracting Officer to reinstate such requirement if at any time during the progress of the remaining work he finds that satisfactory progress is not being made.

1.13 IDENTIFICATION OF EMPLOYEES .

a. The Contractor shall be responsible for furnishing an identification badge/card to each employee prior to the employees work on-site, and for requiring each employee engaged on the work to display identification as may be approved and directed by the Contracting Officer. All prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of the employee.

DOCUMENT 00 80 00.00 06 Page 14 Certified Final

b. The Contractor is required to provide a Local Agency Check for each individual that will be working on this contract.

1.14 NO ASBESTOS - CONTAINING MATERIAL (ACM) CERTIFICATION

1.14.1 Not Used

1.14.2 Construction Phase

Before final payment to the contractor, the contractor's project engineer/manager will sign and submit to the Government, on the contracting firm's letterhead, a dated copy of the following statement:

I hereby certify that to the best of my knowledge no asbestos-containing material (ACM) was used as a building material during this project. Furthermore, I understand that the building owner presumes that all materials marked "May Contain mineral fibers" are considered asbestos unless I either:

(1) Submit a certification for each individual product installed and identified to contain mineral fibers that no asbestos-containing materials were installed.

(2) Submit documentation to show that the products containing mineral fiber materials have been microscopically examined by an AIHA- or NVLAP-certified laboratory and the lab has determined that the material does not contain asbestos.

1.15 WARRANTY OF CONSTRUCTION

a. In addition to the requirements found in clause 52.246-21 "WARRANTY OF CONSTRUCTION" in Section 00 70 00 the following shall be included:

(1) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(2) Provide names, addresses, and telephone numbers of all subcontractors, equipment suppliers, or manufacturers with specific designation of their area of responsibilities if they are to be contacted directly on warranty corrections.

b. Warranty Management

(1) Warranty Management Plan

The Contractor shall develop a warranty management plan which shall contain information relevant to the clause "Warranty of Construction" in clause 52.246-21 in Section 00 70 00. At least thirty (30) calendar days before the planned pre-warranty conference, the Contractor shall submit the warranty management plan for Government approval. The warranty management plan shall include all required actions and documents to assure that the Government receives all warranties to which it is entitled. The plan shall be in narrative form and contain sufficient detail to render it suitable for use by future maintenance and repair personnel, whether tradesmen, or of

DOCUMENT 00 80 00.00 06 Page 15 Certified Final engineering background, not necessarily familiar with this contract.

The term "status" as indicated below shall include due date and whether item has been submitted or was accomplished. Warranty information made available during the construction phase shall be submitted to the Contracting Officer for approval prior to each monthly pay estimate. Approved information shall be assembled in a binder and shall be turned over to the Government upon acceptance of the work. The construction warranty period shall begin on the date of project acceptance and shall continue for the full product warranty period. A joint 4 month and 9 month warranty inspection shall be conducted, measured from time of acceptance, by the Contractor, Contracting Officer and the Customer Representative. Information contained in the warranty management plan shall include, but shall not be limited to, the following:

(a) Roles and responsibilities of all personnel associated with the warranty process, including points of contact and telephone numbers within the organizations of the Contractors, subcontractors, manufacturers or suppliers involved.

(b) Listing and status of delivery of all Certificates of Warranty for extended warranty items, to include roofs, HVAC balancing, pumps, motors, transformers, and for all commissioned systems such as fire protection and alarm systems, sprinkler systems, lightning protection systems, etc.

(c) A list for each warranted equipment, item, and feature of construction or system indicating:

1. Name of item.

2. Model and serial numbers.

3. Location where installed.

4. Name and phone numbers of manufacturers or suppliers.

5. Names, addresses and telephone numbers of sources of spare parts.

6. Warranties and terms of warranty. This shall include one-year overall warranty of construction. Items which have extended warranties shall be indicated with separate warranty expiration dates.

7. Cross-reference to warranty certificates as applicable.

8. Starting point and duration of warranty period.

9. Summary of maintenance procedures required to continue the warranty in force.

10. Cross-reference to specific pertinent Operation and Maintenance manuals.

11. Organization, names and phone numbers of persons to call for warranty service.

12. Typical response time and repair time expected for various

DOCUMENT 00 80 00.00 06 Page 16 Certified Final warranted equipment.

(d) The Contractor's plans for attendance at the 4 and 9 month post-construction warranty inspections conducted by the Government.

(e) Procedure and status of tagging of all equipment covered by extended warranties.

(f) Copies of instructions to be posted near selected pieces of equipment where operation is critical for warranty and/or safety reasons.

c. Performance Bond

(1) The Contractor's Performance Bond will remain effective throughout the construction warranty period and warranty extensions.

(2) In the event the Contractor or his designated representative(s) fails to commence and diligently pursue any work required, and in a manner pursuant to the requirements thereof, the Contracting Officer shall have a right to demand that said work be performed under the Performance Bond by making written notice on the surety. If the surety fails or refuses to perform the obligation it assumed under the Performance Bond, the Contracting Officer shall have the work performed by others, and after completion of the work, may make demand for reimbursement of any or all expenses incurred by the Government while performing the work, including, but not limited to administrative expenses.

(3) In the event sufficient funds are not available to cover the construction warranty work performed by the Government at the Contractor's expense, the Contracting Officer will have the right to recoup expenses from the bonding company.

(4) Following oral or written notification of required warranty repair work, the Contractor will respond as dictated by para. 1.16e "Contractor's Response to Warranty Service Requirements". Written verification will follow oral instructions. Failure of the Contractor to respond will be cause for the Contracting Officer to proceed against the Contractor as outlined in the paragraph 1.16c(2) and/or (3)"Performance Bond" .(2)and/or (3) above.

d. Pre-Warranty Conference

Prior to contract completion and at a time designated by the Contracting Officer, the Contractor shall meet with the Contracting Officer to develop a mutual understanding with respect to the requirements of this clause.

Communication procedures for Contractor notification of warranty defects, priorities with respect to the type of defect, reasonable time required for Contractor response, and other details deemed necessary by the Contracting Officer for the execution of the construction warranty shall be established/reviewed at this meeting.