W912QR21B0010-0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Solicitation W912QR21B0010 for the Design/Bid/Build mechanical renovation of buildings 10 and 11 at Defense Supply Center Columbus, OH is hereby modified as follow s:

A. The liquidated damages amount identified in FAR Clause 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000) is hereby changed from $150.00 to $730.00.

B. Incorporate an additional scheduled site visit as identif ied in FAR Clause 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) -

ALTERNATE I (FEB 1995)

C. Revise and incorporate Wage Rate General Decision OH20210078 (Building).

D. Extend the solicitation due date to 29 July 2021 at 2:30 P.M. Eastern Time.

D. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 11

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912QR21B0010

X 9B. DATED (SEE ITEM 11)

17-Jun-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

13-Jul-2021

CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912QR21B0010-0001

W912QR21B0010

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 19-Jul-2021 02:30 PM to 29-Jul-2021 02:30 PM.

SECTION 00 21 00 - INSTRUCTIONS

The following have been modified:

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 30 June, 2021 at 10:00 a.m. Eastern Time.

A second organized site visit has been scheduled for 22 July, 2021 at 1:00 p.m. Eastern Time.

Report to the visitor center located at 401 N Yearling Rd. Enter the gate and move to the right. It is the first building on the right before the security check point with flag poles in front of it. Check in at the visitor center and you will be issued a temp pass good for the day. Once you have the pass you will be directed to the vehicle inspection area. Security will go through the vehicle so please do not bring any prohibited or illegal items with you on the site visit. This process can take up to 30 minutes if its busy. If you miss the turn in to the visitor center tell the police at the security check point and they can show you how to get to the visitor center from the check point.

Parking is any open space around south of building 33

To get into BLDG 330 Building 330 is the US Army Corps of Engineers building, it’s the first building on the right as you enter the base. It located near the Tennis courts.

(c) Participants registration instructions are as follows -

Interested parties must register through both of the below 2 methods in order to participate in this site visit.

Registration must be submitted 5 business days prior to the scheduled site visit date noted above.

1. The first registration must be completed as directed in the VAR Info – DISA Columbus attachment included with the SAM.gov registration.

2. To prepare for the site visit You must pre-register at https://dbids-global-enroll.dmdc.mil/preenrollui/#!/

Once you have pre-registered you will be given a code and that will be sent to Charles Campbell (charles.l.campbell@usace.army.mil).

Sponsor information:

Name Charles Campbell Email: charles.l.campbell@usace.army.mil

Phone # 6146929319 Site Select state of Ohio then select Defense Logistics Agency Columbus

Send the following to Charles (charles.l.campbell@usace.army.mil).

Title:

First Name:

Middle Initial:

Last Name:

Representing:

Arrival Date:

Arrival Time:

Departure Date:

Departure Time:

Destination:

Purpose:

Code from pre register:

We will reply to you stating the visit is approved or not approved.

(End of provision)

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $730.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

WAGE DETERMINATION

"General Decision Number: OH20210078 06/18/2021

Superseded General Decision Number: OH20200078

State: Ohio

Construction Type: Building

County: Franklin County in Ohio.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.95 for calendar year 2021 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.95 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2021. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/01/2021 1 01/15/2021 2 02/12/2021 3 02/26/2021 4 05/21/2021 5 06/18/2021

ASBE0008-010 03/01/2021

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 31.82 19.50

BROH0055-006 06/01/2019

Rates Fringes

BRICKLAYER.......................$ 29.35 18.11

BROH0055-007 06/01/2019

Rates Fringes

TILE FINISHER....................$ 26.66 7.90

TILE SETTER......................$ 27.20 14.69

CARP0200-003 05/01/2017

Rates Fringes

CARPENTER (Soft Floor Layer and Floor Laying - Hardwood Floors Only).....................$ 29.07 16.22

CARP0200-004 05/01/2017

Rates Fringes

CARPENTER (Excludes Acoustical Ceiling Installation)....................$ 29.07 16.22

ELEC0038-004 04/27/2020

Rates Fringes

ELECTRICIAN (HVAC/Temperature Controls Installation Only)......$ 39.88 21.22

FOOTNOTES;

a. 6 Paid Holidays: New Year's Day; Memorial Day; July 4th;

Labor Day; Thanksgiving Day; & Christmas Day

b. 1 week's paid vacation for 1 year's service; 2 weeks' paid vacation for 2 or more years' service

ELEC0683-004 06/01/2020

Rates Fringes

ELECTRICIAN (Low Voltage Wiring Only).....................$ 34.50 21.06

ELEC0683-007 06/01/2020

Rates Fringes

ELECTRICIAN (Excludes Installation of HVAC/Temperature Controls and Low Voltage Wiring)..............$ 34.50 21.06

ELEV0037-003 01/01/2021

Rates Fringes

ELEVATOR MECHANIC................$ 54.83 35.83

PAID HOLIDAYS:

a. New Year's Day, Memorial Day, Independence Day, Labor Day, Vetern's Day, Thanksgiving Day, the Friday after Thanksgiving, and Christmas Day.

b. Employer contributes 8% of regular hourly rate to vacation pay credit for employee who has worked in business more than 5 years; 6% for less than 5 years' service.

ENGI0018-043 05/01/2018

Rates Fringes

POWER EQUIPMENT OPERATOR

Backhoe/Excavator/Trackhoe;

Bobcat/Skid Steer/Skid Loader; Concrete Pump;

Crane.......................$ 35.89 15.09 Bulldozer...................$ 35.77 15.09 Oiler.......................$ 28.09 15.09

ENGI0066-048 06/01/2017

Rates Fringes

POWER EQUIPMENT OPERATOR

Grader/Blade................$ 32.42 19.66 Mechanic....................$ 32.92 19.66

IRON0172-006 06/01/2020

Rates Fringes

IRONWORKER (Reinforcing and Structural)......................$ 30.75 20.80

* IRON0550-009 05/01/2021

Rates Fringes

IRONWORKER, ORNAMENTAL...........$ 30.17 21.08

LABO0423-003 06/01/2020

Rates Fringes

LABORER

Mason Tender - Brick & Cement/Concrete.............$ 28.44 11.20

PAIN1275-001 05/01/2019

Rates Fringes

PAINTER (Spray)..................$ 25.26 14.20

PLUM0189-005 06/01/2019

Rates Fringes

PIPEFITTER.......................$ 38.45 16.98

SFOH0669-009 04/01/2021

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 39.25 25.81

SHEE0024-028 06/01/2017

Rates Fringes

SHEET METAL WORKER (Excludes HVAC Duct and Unit Installation)....................$ 28.32 24.71

SUOH2012-080 08/29/2014

Rates Fringes

ABATEMENT WORKER: ASBESTOS

(Removal from Ceilings, Floors, and Walls)...............$ 22.74 9.25

CARPENTER (Acoustical Ceiling Installation Only)...............$ 24.17 8.61

CEMENT MASON/CONCRETE FINISHER...$ 26.07 12.34

DRYWALL FINISHER/TAPER...........$ 20.81 5.27

DRYWALL HANGER AND METAL STUD

INSTALLER........................$ 21.75 3.11

GLAZIER..........................$ 22.60 11.02

LABORER: Common or General......$ 21.90 8.60

LABORER: Landscape & Irrigation.......................$ 22.18 8.15

LABORER: Pipelayer..............$ 23.98 8.58

OPERATOR: Forklift..............$ 22.79 12.76

OPERATOR: Loader................$ 29.66 12.61

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 30.28 13.29

OPERATOR: Roller................$ 28.83 12.72

PAINTER (Brush and Roller).......$ 23.87 9.42

PLUMBER..........................$ 25.74 6.45

ROOFER...........................$ 25.33 11.37

SHEET METAL WORKER (HVAC Duct and HVAC Unit Installation Only)............................$ 26.26 17.79

TRUCK DRIVER: Dump (All Types)...$ 24.32 11.73

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION"

(End of Summary of Changes)