W912QR20R0019Specs-0001.pdf

CIVIL/OPS/ENVIRONMENTAL BR

ATTN: GLENN W MOON

600 DR M L KING JR PL RM 821

LOUISVILLE KY 40202-2236

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Solicitation W912QR20R0019 for the Yakima TEMF and ESC at Yakima Training Center (YTC), Washington is hereby modified as follow s:

See Continuation Page.

1. CONTRACT ID CODE PAGE OF PAGES

1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912QR20R0019

X 9B. DATED (SEE ITEM 11)

18-Feb-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

09-Mar-2020

CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE 964860

FACILITY CODECODE

EMAIL:TEL:

W912QR20R0019SPECS-0001

W912QR20R0019

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The following have been added by full text:

SUMMARY OF CHANGES -AMEND 0001

Modified Tactical Equipment Maintenance Facility (TEMF) for Equipment Concentration Site (ECS) 10 Yakima Training Center (YTC), Washington

W912QR-20-R-0019

Amendment 0001

SUMMARY OF CHANGES

1. Offerors must acknowledge all amendments.

2. The due date and time for proposal submission remains 19 March 2020 at 10:00 AM Eastern Time.

3. The following FAR clauses are now included due to the addition of options in the Price Breakout Schedule:

FAR 52.217-5 and 52.217-7.

4. Wage Rates:

General Decision Number WA20200020, has updated and is hereby replaced with the current version General Decision Number WA20200020, dated 02/14/2020.

General Decision Number WA20200079, has updated and is hereby replaced with the current version General Decision Number WA20200079, dated 02/14/2020.

5. SPECIFICATIONS:

1. Price Breakout Schedule – Added Option 1 and Option 2 to break out schedule.

6. DRAWING SUMMARY OF CHANGES

1. S-001 – Added general note 5.B.3, "Place all slabs and footings on compacted graded-crushed aggregate base course per Section 32 11 23 or native basalt bedrock."

2. S-011, S-012, S-101, S-102, S-421, S-422, S-423 – Revised various notes to change "imported crushed rock" and "fill" to "compacted graded-crushed aggregate base course per Section 32 11 23 or native basalt bedrock."

3. AB-010 – Revised General Note 1.

4. M-504 – Added Detail A1, showing piping schematic for unit heaters with no control valve.

5. M-714 – Updated controls schematic A1 to remove control valve for unit heaters to reflect what was already shown in sequence of operations, points list, and control valve schedule.

7. SPECIFICATIONS SUMMARY OF CHANGES

1. Section 00 10 00 PRICE BREAKOUT SCHEDULE – Added bid options.

2. Project Table of Contents – Added new sections.

3. Section 07 27 10.00 10 BUILDING AIR BARRIER SYSTEM – Added new section.

4. Section 08 71 00 DOOR HARDWARE – Revised many paragraphs throughout the section.

5. Section 08 34 59 VAULT DOORS AND DAY GATES – Added new section.

6. Section 10 11 00 VISUAL DISPLAY UNITS – Added paragraph 2.6 Projection Screen.

7. Section 23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC – Added paragraph

2.6.17 to cover float switches that will be used in the POL system

SECTION 00 10 00 - SOLICITATION

The following have been modified:

PRICE BREAKOUT SCHEDULE

PRICE BREAKOUT SCHEDULE

PROPOSER’S NAME:

Item Description Unit Amount

BASE BID

0001 Primary Facilities – Tactical Equipment Maintenance Facility

(TEMF)

Job $ -

0002 Supporting Facilities – Tactical Equipment Maintenance Facility

(TEMF)

Total Bid

Amendment 0001***************************************************************

OPTIONS

0003 Option 1 – Removal of fence and aggregate surface (TEMF)

0004 Option 2 – Removal of fence (TEMF)

Total All Options

Total Base with All Options $ -

***************************************************************Amendment 0001

NOTES FOR PRICE BREAKOUT SCHEDULE

1. The company name should be indicated on the face of the Price Breakout Schedule to preclude being misplaced.

2. Offerors must insert a price on all numbered items (including options) of the Price Breakout Schedule. Failure to do so may result in the offer being unacceptable.

3. Description of Items - The general outline of the principal features of each item as listed below does not in any way limit the responsibility of the Offeror for making a thorough investigation of the drawings and the specifications to determine the scope of work including each item of the Price Breakout Schedule.

DESCRIPTION OF BASE BID ITEMS

a) Item No. 0001 – “Primary Facilities – Tactical Equipment Maintenance Facility (TEMF)” includes all construction work for primary facilities as indicated on the Construction Documents.

b) Item No. 0002 – “Supporting Facilities – Tactical Equipment Maintenance Facility (TEMF)” includes all construction work for the supporting facilities as indicated on the Construction Documents.

Amendment 0001***************************************************************

DESCRIPTION OF OPTION BID ITEMS

c) Item No. 0003 – “Option 1 – Removal of fence and aggregate surface (TEMF)” includes all construction work for Option 1 as indicated on the Construction Documents, Sheet CD100. This option may be exercised within 120 calendar days from Notice to Proceed.

d) Item No. 0004 – “Option 2 – Removal of fence (TEMF)” includes all construction work for Option 2 as indicated on the Construction Documents, Sheet CD100. This option may be exercised within 120 calendar days from Notice to Proceed.

***************************************************************Amendment 0001

-END OF PRICE BREAKOUT SCHEDULE—

SECTION 00 21 00 - INSTRUCTIONS

The following have been added by reference:

52.217-5

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been added by full text:

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within timeline specified in the Price Breakout Schedule. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

(End of clause)

(End of Summary of Changes)

General Decision Number: WA20200020 02/14/2020

Superseded General Decision Number: WA20190020

State: Washington

Construction Type: Building

County: Yakima County in Washington.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.80 for calendar year 2020 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.80 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2020. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/03/2020 1 02/14/2020

ASBE0007-002 06/01/2019

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 26.62 16.59

BRWA0001-002 06/01/2017

Rates Fringes

BRICKLAYER.......................$ 39.46 16.15

CARP0059-014 06/01/2019

Rates Fringes

CARPENTER (Excluding Acoustical Ceiling Installation)

EAST OF 120TH MERIDIAN......$ 30.49 16.88

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - ALL

CLASSIFICATIONS EXCEPT MILLWRIGHTS AND PILEDRIVERS

Hourly Zone Pay shall be paid on jobs located outside of the free zone computed from the city center of the following listed cities:

Seattle Olympia Bellingham Auburn Bremerton Anacortes Renton Shelton Yakima Aberdeen-Hoquiam Tacoma Wenatchee Ellensburg Everett Port Angeles Centralia Mount Vernon Sunnyside Chelan Pt. Townsend

Zone Pay:

0 -25 radius miles Free 26-35 radius miles $1.00/hour 36-45 radius miles $1.15/hour 46-55 radius miles $1.35/hour Over 55 radius miles $1.55/hour

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - MILLWRIGHT

AND PILEDRIVER ONLY)

Hourly Zone Pay shall be computed from Seattle Union Hall, Tacoma City center, and Everett City center

Zone Pay:

0 -25 radius miles Free 26-45 radius miles $ .70/hour Over 45 radius miles $1.50/hour

CARP0770-017 06/01/2019

Rates Fringes

CARPENTER (Excluding Acoustical Ceiling Installation)

WEST OF 120TH MERIDIAN......$ 30.10 14.28

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - ALL

CLASSIFICATIONS EXCEPT MILLWRIGHTS AND PILEDRIVERS

Hourly Zone Pay shall be paid on jobs located outside of the free zone computed from the city center of the following listed cities:

Seattle Olympia Bellingham Auburn Bremerton Anacortes Renton Shelton Yakima Aberdeen-Hoquiam Tacoma Wenatchee Ellensburg Everett Port Angeles Centralia Mount Vernon Sunnyside Chelan Pt. Townsend

Zone Pay:

0 -25 radius miles Free 26-35 radius miles $1.00/hour

36-45 radius miles $1.15/hour 46-55 radius miles $1.35/hour Over 55 radius miles $1.55/hour

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - MILLWRIGHT

AND PILEDRIVER ONLY)

Hourly Zone Pay shall be computed from Seattle Union Hall, Tacoma City center, and Everett City center

Zone Pay:

0 -25 radius miles Free 26-45 radius miles $ .70/hour Over 45 radius miles $1.50/hour

ELEC0112-014 06/01/2019

Rates Fringes

ELECTRICIAN......................$ 46.05 21.06

ENGI0302-017 07/01/2018

West of the 120th Meridian

Rates Fringes

Power equipment operators:

Group 1A...................$ 44.44 19.97 Group 1AA..................$ 45.09 19.97 Group 1AAA.................$ 45.73 19.97 Group 1.....................$ 43.79 19.97 Group 2.....................$ 43.23 19.97 Group 3.....................$ 42.74 19.97 Group 4.....................$ 40.01 19.97

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1AAA - Cranes-over 300 tons, or 300 ft of boom (including jib with attachments)

GROUP 1AA - Cranes 200 to 300 tons, or 250 ft of boom (including jib with attachments); Trackhoe: Over 90 metric tons

GROUP 1A - Cranes, 100 tons thru 199 tons, or 150 ft of boom (including jib with attachments); Loaders-overhead, 8 yards and over; Trackhoe: over 50 metric tons to 90 metric tons

GROUP 1 - Cranes 45 tons thru 99 tons, under 150 ft of boom (including jib with attachments); Trackhoe: over 30 metric tons to 50 metric tons; Loader- overhead 6 yards to, but not including 8 yards; Dozer D-10; Screedman; Scrapers: 45 yards and over; Grader/Blade

GROUP 2 - Cranes, 20 tons thru 44 tons with attachments;

Drilling machine; Trackhoe: 15 to 30 metric tons;

Horizontal/directional drill operator; Loaders-overhead under 6 yards; Crane Oiler-100 Tons and Over; Compactor;

Scraper: under 45 tons

GROUP 3 - Cranes-thru 19 tons with attachments; Dozers-D-9 and under; Motor patrol grader-nonfinishing; Roller-Plant Mix; Crane Oiler under 100 tons; Trackhoe: under 15 metric tons; Forklift: 3000 lbs and over with attachments

GROUP 4 - Roller-other than plant mix; Forklift: under 3000 lbs with attachments

* ENGI0370-018 07/01/2019

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 28.46 17.25

GROUP 2.....................$ 28.78 17.25

GROUP 3.....................$ 29.39 17.25

GROUP 4.....................$ 29.55 17.25

GROUP 5.....................$ 29.71 17.25

GROUP 6.....................$ 29.99 17.25

GROUP 7.....................$ 30.26 17.25

GROUP 8.....................$ 31.36 17.25

ZONE DIFFERENTIAL (Add to Zone 1 rate): Zone 2 - $2.00

Zone 1: Within 45 mile radius of Spokane, Pasco, Washington;

Lewiston, Idaho

Zone 2: Outside 45 mile radius of Spokane, Pasco, Washington; Lewiston, Idaho

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Compactor; Rollers, all types on subgrade, including seal and chip coatings

GROUP 2: Fork Lift

GROUP 3: Bulldozer (up to D-6 or equivalent)

GROUP 4: Drills (churn, core, calyx or diamond); Oiler;

Loaders (overhead & front-end, under 4 yds. R/T); Vacuum Drill (reverse circulation drill under 8 inch bit)

GROUP 5: Trackhoe (hoe Ram) (under 3/4 yd.); Cranes (25 tons & under), Drilling Equipment(8 inch bit & over) (Robbins, reverse circulation & similar)

GROUP 6: Asphalt Roller; Trackhoe (Hoe Ram) (3/4 yd. to 3 yd.); Compactor (self-propelled with blade); Cranes (over 25 tons, to and including 45 tons), Bulldozer, 834 R/T & similar; Loader Operator (front-end & overhead, 4 yds.

incl. 8 yds.); Scrapers, all, rubber-tired

GROUP 7: Trackhoe (Hoe Ram) (3 yds & over); Cranes (over 45 tons to but not including 85 tons); Loaders (overhead & front-end, over 8 yds. to 10 yds.); Rubber-tired Scrapers (multiple engine with three or more scrapers)

GROUP 8: Cranes (85 tons and over, and all climbing, overhead,rail and tower); Loaders (overhead and front-end, 10 yards and over)

BOOM PAY: (All Cranes, Including Tower)

180 ft to 250 ft $ .50 over scale Over 250 ft $ .80 over scale

NOTE:

In computing the length of the boom on Tower Cranes, they shall be measured from the base of the Tower to the point of the boom.

HAZMAT:

Anyone working on HAZMAT jobs, working with supplied air shall receive $1.00 an hour above classification.

IRON0086-009 07/01/2019

Rates Fringes

IRONWORKER (Reinforcing, Structural, and Ornamental)......$ 33.59 29.26

LABO0348-006 06/01/2019

Rates Fringes

LABORER

GROUP 2....................$ 26.51 11.94

GROUP 3....................$ 29.01 11.94

GROUP 4....................$ 29.71 11.94

GROUP 5....................$ 30.22 11.94

BASE POINTS: CHELAN, SUNNYSIDE, WENATCHEE, AND YAKIMA

ZONE 1 - Projects within 25 radius miles of the respective city hall ZONE 2 - More than 25 radius miles from the respective city hall

ZONE DIFFERENTIAL (ADD TO ZONE 1 RATES):

ZONE 2 - $2.25

LABORERS CLASSIFICATIONS

GROUP 2: Flagman

GROUP 3: Chipping Gun (under 30 lbs.); Form Stripping

GROUP 4: Chipping Gun (over 30 lbs.); Concrete Saw Operator;

Gunite; Vibrating Plate

GROUP 5: Mason Tender-Brick; Mason Tender-Cement/Concrete;

Grade CheckeR

PAIN0005-026 07/01/2019

Rates Fringes

Painters: (Parking Lot and highway Striping)................$ 31.61 16.07

PAIN0005-027 04/15/2013

Rates Fringes

Painters:

BRUSH, ROLLER AND SPRAY.....$ 15.58 10.23

PAIN0054-001 06/01/2008

Rates Fringes

DRYWALL FINISHER/TAPER...........$ 22.78 8.88

PAIN0054-004 10/01/2005

Rates Fringes

FLOOR LAYER: Carpet and Vinyl....$ 15.50 4.22

PLAS0072-009 06/01/2019

Rates Fringes

PLASTERER........................$ 30.21 14.93

Zone Differential (Add to Zone 1 rate): Zone 2 - $2.00

BASE POINTS: Spokane, Pasco, Lewiston, Wenatchee

Zone 1: 0-45 radius miles from the main post office

Zone 2: Over 45 radius miles from the main post office

* PLUM0598-017 06/01/2019

Rates Fringes

PLUMBER (including HVAC Pipe Installation)....................$ 50.47 32.17

ROOF0189-014 07/01/2019

Rates Fringes

ROOFER (Includes Roof Tear Off, Waterproofing, and Installation of Metal Roofs).....$ 28.25 12.81

* SFWA0699-005 04/01/2019

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 34.45 24.13

SHEE0066-021 06/01/2017

Rates Fringes

Sheet metal worker...............$ 34.75 20.68

SUWA2009-033 05/22/2009

Rates Fringes

LABORER: Common or General......$ 14.50 0.00

LABORER: Handheld Drill.........$ 17.17 5.36

LABORER: Irrigation.............$ 11.58 0.00

LABORER: Landscape..............$ 11.08 0.00

LABORER: Pipelayer..............$ 17.25 4.40

OPERATOR: Backhoe...............$ 19.59 0.00

OPERATOR: Bobcat/Skid Steer/Skid Loader................$ 22.05 7.35

OPERATOR: Concrete Pumper.......$ 22.30 5.27

OPERATOR: Excavator.............$ 25.02 5.43

OPERATOR: Mechanic..............$ 24.33 4.33

OPERATOR: Oiler.................$ 23.76 8.71

OPERATOR: Roller................$ 19.08 0.00

OPERATOR: Screed................$ 19.08 0.00

PIPEFITTER.......................$ 23.88 6.62

TILE SETTER......................$ 25.51 0.00

TRUCK DRIVER: Dump Truck........$ 11.87 0.00

TRUCK DRIVER: Semi-Trailer Truck............................$ 20.59 5.56

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses

(29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

General Decision Number: WA20200079 02/14/2020

Superseded General Decision Number: WA20190079

State: Washington

Construction Type: Heavy including water and sewer line construction

County: Yakima County in Washington.

HEAVY CONSTRUCTION PROJECTS (including sewer/water construction).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.80 for calendar year 2020 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.80 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2020. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/03/2020 1 02/14/2020

BRWA0001-002 06/01/2017

Rates Fringes

BRICKLAYER.......................$ 39.46 16.15

CARP0059-016 06/01/2018

Rates Fringes

MILLWRIGHT

EAST OF 120TH MERIDIAN......$ 45.42 18.83

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - MILLWRIGHT

AND PILEDRIVER ONLY)

Hourly Zone Pay shall be computed from Seattle Union Hall, Tacoma City center, and Everett City center

Zone Pay:

0 -25 radius miles Free 26-45 radius miles $ .70/hour Over 45 radius miles $1.50/hour

CARP0770-033 06/01/2019

Rates Fringes

MILLWRIGHT

WEST OF 120TH MERIDIAN......$ 47.42 16.52

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - MILLWRIGHT

AND PILEDRIVER ONLY)

Hourly Zone Pay shall be computed from Seattle Union Hall, Tacoma City center, and Everett City center

Zone Pay:

0 -25 radius miles Free 26-45 radius miles $ .70/hour Over 45 radius miles $1.50/hour

ELEC0112-014 06/01/2019

Rates Fringes

ELECTRICIAN......................$ 46.05 21.06

ENGI0302-032 07/01/2018

West of the 120th Meridian

Rates Fringes

Power equipment operators:

Group 1A...................$ 44.44 19.97 Group 1AA..................$ 45.09 19.97 Group 1.....................$ 43.79 19.97 Group 2.....................$ 43.23 19.97 Group 3.....................$ 42.74 19.97 Group 4.....................$ 40.01 19.97

Zone Differential (Add to Zone 1 rates):

Zone 2 (26-45 radius miles) - $1.00 Zone 3 (Over 45 radius miles) - $1.30

BASEPOINTS: Aberdeen, Bellingham, Bremerton, Everett, Kent, Mount Vernon, Port Angeles, Port Townsend, Seattle, Shelton, Wenatchee, Yakima

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1AA - Excavator/Trackhoe: Over 90 metric tons

GROUP 1A - Excavator/Trackhoe: over 50 metric tons to 90 metric tons;

GROUP 1 - Excavator/Trackhoe: over 30 metric tons to 50 metric tons; Screedman; Scrapers: 45 yards and over; Paver

GROUP 2 - Drilling machine; Excavator/Trackhoe: 15 to 30 metric tons; Horizontal/directional drill operator;

Scraper: under 45 tons; Piledriver; Boring Machine

GROUP 3 - Roller-Plant Mix; Excavator/Trackhoe: under 15 metric tons; Service Oiler; Boom Truck over 10 tons

GROUP 4 - Roller-other than plant mix; Drill Assistant; Boom Truck 10 tons and under

* ENGI0370-026 07/01/2019

East of the 120th Meridian

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 28.46 17.25

GROUP 3.....................$ 29.39 17.25

GROUP 4.....................$ 29.55 17.25

GROUP 5.....................$ 29.71 17.25

GROUP 6.....................$ 29.99 17.25

GROUP 7.....................$ 30.26 17.25

ZONE DIFFERENTIAL (Add to Zone 1 rate): Zone 2 - $2.00

Zone 1: Within 45 mile radius of Spokane, Pasco, Washington;

Lewiston, Idaho

Zone 2: Outside 45 mile radius of Spokane, Pasco, Washington; Lewiston, Idaho

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Drill Assistant; Rollers, all types on subgrade, including seal and chip coating

GROUP 3: Boring Machine

GROUP 4: Oiler; Drill (churn, core, calyx or diamond);

GROUP 5: Trackhoe/Excavator (under 3/4 yd.); Drilling equipment (8 unch bit and over) (robbins, reverse circulation and similar); Piledriver; Boom Truck (Under 25 tons)

GROUP 6: Trackhoe/Excavator (3/4 yd. to 3 yd.), Paver;

Scraper; Screed: Asphalt Roller

GROUP 7: Trackhoe/Excavator (3 yds & over)

BOOM PAY: (All Cranes, Including Tower) 180 ft to 250 ft $ .50 over scale Over 250 ft $ .80 over scale

NOTE:

In computing the length of the boom on Tower Cranes, they shall be measured from the base of the Tower to the point of the boom.

HAZMAT:

Anyone working on HAZMAT jobs, working with supplied air shall receive $1.00 an hour above classification.

IRON0086-009 07/01/2019

Rates Fringes

IRONWORKER (Reinforcing, Structural, and Ornamental)......$ 33.59 29.26

LABO0348-002 06/01/2019

Rates Fringes

LABORER

GROUP 2

YAKIMA COUNTY..............$ 26.51 11.94

GROUP 3

YAKIMA COUNTY..............$ 29.01 11.94

GROUP 4

YAKIMA COUNTY..............$ 29.71 11.94

GROUP 5

YAKIMA COUNTY..............$ 30.22 11.94

ZONE DIFFERENTIAL (ADD TO ZONE 1 RATES):

ZONE 2 - $1.00

ZONE 3 - $1.30

BASE POINTS: BELLINGHAM, MT. VERNON, EVERETT, SEATTLE, KENT,

TACOMA, OLYMPIA, CENTRALIA, ABERDEEN, SHELTON, PT.

TOWNSEND, PT. ANGELES, AND BREMERTON

ZONE 1 - Projects within 25 radius miles of the respective city hall ZONE 2 - More than 25 but less than 45 radius miles from the respective city hall ZONE 3 - More than 45 radius miles from the respective city hall

LABORERS CLASSIFICATIONS

GROUP 2: Flagger

GROUP 3: General or Common Laborer; Form-Stripping

GROUP 4: Pipelayer; Handheld Drill

GROUP 5: Mason Tender-Brick; Mason Tender-Cement/Concrete;

Grade Checker

PAIN0005-010 04/15/2013

Rates Fringes

Painters: (Brush, Roller and Spray)...........................$ 15.58 10.23

SHEE0066-021 06/01/2017

Rates Fringes

Sheet metal worker...............$ 34.75 20.68

SUWA2009-070 08/07/2009

Rates Fringes

CARPENTER, Includes Form Work....$ 27.02 6.70

CEMENT MASON/CONCRETE FINISHER...$ 24.07 0.00

LABORER: High Scaler............$ 21.08 6.61

LABORER: Landscape & Irrigation.......................$ 12.27 2.73

OPERATOR: Asphalt Plant.........$ 34.14 0.68

OPERATOR: Backhoe...............$ 27.29 6.60

OPERATOR: Broom/Sweeper.........$ 27.03 4.67

OPERATOR: Bulldozer.............$ 28.17 5.97

OPERATOR: Crane, All Types......$ 28.83 6.11

OPERATOR: Forklift..............$ 28.17 5.97

OPERATOR: Grader/Blade..........$ 29.43 3.60

OPERATOR: Mechanic..............$ 28.46 6.04

OPERATOR: Power Shovel..........$ 25.12 7.83

OPERATOR: Skid Steer............$ 10.63 0.00

OPERATOR: Loader.................$ 28.46 6.04

PIPEFITTER.......................$ 32.50 6.90

TRUCK DRIVER, Includes Dump Truck............................$ 16.40 3.60

TRUCK DRIVER: Dump (Trailer) Truck............................$ 13.00 1.24

TRUCK DRIVER: Flatbed Truck.....$ 22.74 6.29

TRUCK DRIVER: Lowboy Truck......$ 22.89 5.72

TRUCK DRIVER: Semi-Trailer Truck............................$ 18.32 4.91

TRUCK DRIVER: Water Truck.......$ 23.46 6.06

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

P2# 472443 MODIFIED TACTICAL EQUIPMENT MAINTENANCE FACILITY(TEMF)

YAKIMA TRAINING CENTER (YTC), WA

PROJECT TABLE OF CONTENTS Page 1 Certified Final Submittal

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 80 00.00 06 SPECIAL PROVISIONS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 32 01.00 06 PROJECT SCHEDULE

01 33 00.00 06 SUBMITTAL PROCEDURES

01 33 29.00 06 SUSTAINABILITY REPORTING

01 35 26.00 06 GOVERNMENT SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 04.10 06 CONTRACTOR QUALITY CONTROL

01 45 35 SPECIAL INSPECTIONS

01 46 00.00 06 TOTAL BUILDING COMMISSIONING (CONTRACTOR CxA)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19.00 06 TEMPORARY ENVIRONMENTAL CONTROLS AND PERMITS

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

03 42 13.00 10 PLANT-PRECAST CONCRETE PRODUCTS FOR BELOW GRADE

CONSTRUCTION

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

05 21 00 STEEL JOIST FRAMING

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 51 33 METAL LADDERS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 20 00 FINISH CARPENTRY

06 41 16.00 10 PLASTIC-LAMINATE-CLAD ARCHITECTURAL CABINETS

06 61 16 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 13 BOARD AND BLOCK INSULATION

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 41 13 METAL ROOF PANELS

07 42 13 METAL WALL PANELS

07 60 00 FLASHING AND SHEET METAL

07 61 14.00 20 STEEL STANDING SEAM ROOFING

07 84 00 FIRESTOPPING

PROJECT TABLE OF CONTENTS Page 2

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 33 13 COILING COUNTER DOORS

08 34 59 VAULT DOORS AND DAY GATES

08 36 13 SECTIONAL OVERHEAD DOORS

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

DIVISION 09 - FINISHES

09 06 00 SCHEDULES FOR FINISHES

09 29 00 GYPSUM BOARD

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 62 38 STATIC-CONTROL FLOORING

09 65 00 RESILIENT FLOORING

09 67 23.13 STANDARD RESINOUS FLOORING

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 11 00 VISUAL DISPLAY UNITS

10 14 00.20 INTERIOR SIGNAGE

10 21 13 TOILET COMPARTMENTS

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 51 13 METAL LOCKERS

10 56 13 STEEL SHELVING

DIVISION 12 - FURNISHINGS

12 24 13 ROLLER WINDOW SHADES

12 48 13 ENTRANCE FLOOR MATS AND FRAMES

DIVISION 13 - SPECIAL CONSTRUCTION

13 34 19 METAL BUILDING SYSTEMS

13 48 00 BRACING FOR MISCELLANEOUS EQUIPMENT

DIVISION 21 - FIRE SUPPRESSION

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

21 30 00 FIRE PUMPS

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 15 14.00 40 GENERAL SERVICE COMPRESSED-AIR SYSTEMS, LOW PRESSURE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 05 48.19 BRACING FOR HVAC

23 05 93.00 06 TESTING, ADJUSTING, AND BALANCING (TAB) OF HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

PROJECT TABLE OF CONTENTS Page 3

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.01 LONWORKS DIRECT DIGITAL CONTROL FOR HVAC AND OTHER

BUILDING CONTROL SYSTEMS

23 11 25 FACILITY GAS PIPING

23 23 00 REFRIGERANT PIPING

23 35 00.00 10 OVERHEAD VEHICLE TAILPIPE EXHAUST REMOVAL SYSTEM(S)

23 52 00 HEATING BOILERS

23 54 16.00 10 HEATING SYSTEM; GAS-FIRED HEATERS

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

23 82 00.00 20 TERMINAL HEATING UNITS

DIVISION 26 - ELECTRICAL

26 05 48.00 10 BRACING FOR ELECTRICAL EQUIPMENT

26 08 00 APPARATUS INSPECTION AND TESTING

26 12 19.10 THREE-PHASE PAD-MOUNTED TRANSFORMERS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 27 13.10 30 ELECTRIC METERS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 29 23 VARIABLE FREQUENCY DRIVE SYSTEMS UNDER 600 VOLTS

26 32 14.00 10 NATURAL GAS-GENERATOR SET, STATIONARY 15-300 KW, STANDBY

APPLICATIONS

26 36 00.00 10 AUTOMATIC TRANSFER SWITCH AND BY-PASS/ISOLATION SWITCH

26 41 00 LIGHTNING PROTECTION SYSTEM

26 42 14.00 10 CATHODIC PROTECTION SYSTEM (SACRIFICIAL ANODE)

26 51 00 INTERIOR LIGHTING

26 56 00 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 05 28 CABLE TRAYS FOR COMMUNICATIONS SYSTEMS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 13 00.00 48 PHYSICAL ACCESS CONTROL SYSTEM

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00.00 06 EARTHWORK

31 05 19 GEOTEXTILE

31 11 00 CLEARING AND GRUBBING

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 11 23 AGGREGATE BASE COURSES

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 13.06 PORTLAND CEMENT CONCRETE PAVEMENT FOR ROADS AND SITE

FACILITIES

32 16 19 CONCRETE CURBS, GUTTERS AND SIDEWALKS

32 17 23 PAVEMENT MARKINGS

32 31 13.53 HIGH-SECURITY CHAIN LINK FENCES AND GATES

32 32 23 SEGMENTAL CONCRETE BLOCK RETAINING WALL

32 92 19 SEEDING

DIVISION 33 - UTILITIES

PROJECT TABLE OF CONTENTS Page 4

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 16 15 WATER STORAGE STEEL TANKS

33 30 00 SANITARY SEWERAGE

33 32 13.13 PACKAGED SEWAGE LIFT STATIONS, WET WELL TYPE

33 40 00 STORM DRAINAGE UTILITIES

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

DIVISION 41 - MATERIAL PROCESSING AND HANDLING EQUIPMENT

41 22 13.13 BRIDGE CRANES

DIVISION 46 - WATER AND WASTEWATER EQUIPMENT

46 25 14 COALESCING OIL-WATER SEPARATORS

-- End of Project Table of Contents --

P2# 472443 MODIFIED TACTICAL EQUIPMENT MAINTENANCE FACILITY(TEMF) Amendment 0001

Amdt. #0001

SECTION 07 27 10.00 10

BUILDING AIR BARRIER SYSTEM

08/19

PART 1 GENERAL

1.1 SUMMARY

This Section specifies the construction and quality control of the installation of an air barrier system. Construct the air barrier system indicated, taking responsibility for the means, methods, and workmanship of the installation of the air barrier system. The air barrier must be contiguous and connected across all surfaces of the enclosed air barrier envelope indicated. The maximum leakage requirements of individual air barrier components and materials are specified in the other specification sections covering these items.

This section also defines the maximum allowable leakage of the final air barrier system. The workmanship must be adequate to meet the maximum allowable leakage requirements of this specification.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referenced within the text by the basic designation only.

ASTM INTERNATIONAL (ASTM)

ASTM D4541 (2017) Standard Test Method for Pull-Off Strength of Coatings Using Portable Adhesion Testers

ASTM E96/E96M (2016) Standard Test Methods for Water Vapor Transmission of Materials

ASTM E2178 (2013) Standard Test Method for Air Permeance of Building Materials

ASTM E2357 (2017) Standard Test Method for Determining Air Leakage of Air Barrier Assemblies

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 285 (2012) Standard Fire Test Method for Evaluation of Fire Propagation Characteristics of Exterior Non-Load-Bearing Wall Assemblies Containing Combustible Components

1.3 DEFINITIONS

The following terms as they apply to this section:

SECTION 07 27 10.00 10 Page 1

1.3.1 Air Barrier Accessory

Products designated to maintain air tightness between air barrier materials, air barrier assemblies and air barrier components, to fasten them to the structure of the building, or both (e.g., sealants, tapes, backer rods, transition membranes, fasteners, strapping, primers).

1.3.2 Air Barrier Assembly

The combination of air barrier materials and air barrier accessories that are designated and designed within the environmental separator to act as a continuous barrier to the movement of air through the environmental separator.

1.3.3 Air Barrier Component

Pre-manufactured elements such as windows, doors, dampers and service elements that are installed in the environmental separator.

1.3.4 Air Barrier Envelope

The combination of air barrier assemblies and air barrier components, connected by air barrier accessories that are designed to provide a continuous barrier to the movement of air through an environmental separator. There may be more than one air barrier envelope in a single building. Also known as Air Barrier System.

1.3.5 Air Barrier Material

A building material that is designed, tested and/or produced to provide the primary resistance to airflow through an air barrier assembly of a wall system.

1.3.6 Air Barrier System

Same as AIR BARRIER ENVELOPE.

1.3.7 Air Leakage Rate

The rate of airflow (CFM) driven through a unit surface area (sq.ft.) of an assembly or system by a unit static pressure difference (Pa) across the assembly. (example: 0.25 CFM/sq.ft. @ 75 Pa)

1.3.8 Air Leakage

The total airflow (CFM) driven through the air barrier system by a unit static pressure difference (Pa) across the air barrier envelope. (example:

6500 CFM @ 75 Pa)

1.3.9 Air Permeance

The tested rate of airflow (CFM) through a unit area (sq.ft.) of a material driven by unit static pressure difference (Pa) across the material (example: 0.004 CFM/sq.ft. @ 75 Pa) as established by ASTM E2178.

1.3.10 Environmental Separator

The parts of a building that separate the controlled interior environment from the uncontrolled exterior environment, or that separate spaces within

SECTION 07 27 10.00 10 Page 2 a building that have dissimilar environments. Also known as the Control Layer.

1.3.11 Vapor Permeance

Vapor permeance is separated into three classes based on the water vapor permeance of a material as tested via ASTM E96/E96M

Class I Vapor Barrier/Retarder 0.1 perm or less

Class II Vapor Barrier/Retarder 0.1 perm to 1.0 perm

Class III Vapor Barrier/Retarder 1.0 perm to 10 perm

1.4 PREPARATORY PHASE OR PRECONSTRUCTION CONFERENCE

Organize pre-construction conferences between the air barrier inspector and the sub-contractors involved in the construction of or penetration of the air barrier system to discuss where the work of each sub-contractor begins and ends, the sequence of installation, and each sub-contractor's responsibility to ensure airtight joints, junctures, penetrations and transitions between materials.