W912PP22R0006 ERCIP Install MicroGrid_Amendment 0001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

W912PP

ERCIP Install Micro-Grid at White Sands Missile Range, New Mexico.

1.This is Amendment No. 0001 to Solicitation No. W912PP22R0006 The following revisions shall be incorporated into the specifications. All other provisions shall remain unchanged.

U.S. ARMY ENGINEER DISTRICT, ALBUQUERQUE

CORPS OF ENGINEERS

4101 JEFFERSON PLAZA, N.E.

ALBUQUERQUE, NEW MEXICO 87109-3435

See Item 6

J

W912PP22R0006

1 2

03/15/2022

03/14/2022

W912PP22R0006

AMENDMENT No. 0001

2. SPECIFICATIONS: Delete the following listed pages and substitute the pages attached hereto. On the revised pages, for convenience, changes are emphasized by STRIKETHROUGH for deletions and UNDERLINE for additions from the previous issue. All portions of the revised (or new) pages shall apply whether or not changes have been indicated.

Delete Page Insert Page

00 21 00 – INSTRUCTIONS, PAGE 14 OF

00 21 00 – INSTRUCTIONS, PAGE 14 OF

01 00 00.00 44 - CONSTRUCTION

SCHEDULE, ENTIRETY

01 00 00.00 44 - CONSTRUCTION

SCHEDULE, ENTIRETY

3. DRAWING CHANGES: The following drawings have been revised and the sequence number changed to indicate such revision:

Delete Page Insert Page

NA

////////LAST ITEM////////

W912PP22R0006

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- Date: 29 March 2022 Time: 9:00am - 11:00am (MST)

(c) Offerors and subcontractors shall register for the site visit AT LEAST THREE (3) BUSINESS DAYS BEFORE the date of the site visit.

(d) Personnel are required to wear masks during site visits if a distance of six (6) feet cannot be maintained between individuals. Contractors must provide their own masks.

(e) Offerors and subcontractors wishing to participate will provide the following information to the Site Visit Registration POCs listed below:

--Visitor Name --Company Name --Driver's License number

(f) Site Visit Registration POCs:

POC #1: Phil Lovato POC#2: Roy Bonhorst Email: phillip.j.lovato@usace.army.mil Email: roy.n.bonhorst@usace.army.mil Phone: 575-678-2591 Phone: 575-678-5644 Mobile: 505-379-0471 Mobile: 915-892-2706

(g) Participants will meet at Building 102, located at the southwest corner of the intersection of Springfield Street and Headquarters Ave., in the main cantonment area of White Sands Missile Range, NM. Participants will proceed to the ERCIP Micro-Grid project site together after signing in and receiving a site visit briefing from the Government representatives at Building 102 located at the intersection of Springfield St. and Headquarters Ave.

(End of provision)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far

(End of provision)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

31 March 2022 l4ct9fmt Cross-Out

WSMR ERCIP Install Micro-Grid W912PP22R0006 WSMR, NM Amendment 0001

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

10/2015

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 73 00 CONTRACT CLAUSES COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK and LIQUIDATED

DAMAGES:

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work for WSMR ERCIP Install Micro-Grid.

See NTP. 540 $ 557.70

NOTE: All work on this project shall be completed within the number of calendar days stated in Item of Work (1) above, inclusive of all review periods and Government phasing requirements specified. If the Government accepts a proposal for a completion period of lesser duration, and such proposal alters the time periods for review and phasing, the Contract shall be read to include the original periods for review and phasing. If a completion period of lesser duration is proposed and accepted by the Government, the accepted completion period will replace the original construction schedule listed above in the Schedule. If an alternate completion period is proposed, the Bid Schedule must reflect pricing information for the alternate proposed completion period. The liquidated damages stated above will be applied for each calendar day the Contractor exceeds the Contract scheduled duration.

a. Liquidated damages for individual items of work will not be combined. Only the rate of the affected item of work will be assessed.

b. Liquidated damages are not accumulative for multiple phases of work.

SECTION 01 00 00.00 44 Page 1

** Operation and Maintenance Manuals: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph OPERATION AND MAINTENANCE MANUALS for requirements and withholding amount to ensure completion of O&M Manuals.

*** Record Drawings: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph titled RECORD DRAWINGS for requirements and withholding amount to ensure completion of record drawings.

1.1.1 Testing of Heating and Air-Conditioning Systems

The times stated for completion of this project includes all required testing specified in appropriate specification sections of heating, air conditioning and ventilation systems including HVAC Commissioning.

Exception: boiler combustion efficiency test, boiler full load tests, cooling tower performance tests, and refrigeration equipment full load tests, when specified in the applicable specifications, shall be performed in the appropriate heating/cooling season as determined by the Contracting Officer.

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. Weather Conditions

(1) Climate is typical of the southwest desert with a wide temperature range between day and night, often as high as 50 degrees F change in 24 hours. The annual range temperature is from a maximum of 108 degrees F in summer to an extreme low of 0 degrees F in winter. The recorded low was -10 degrees F .

(2) Average annual rainfall varies from about 9.5 inches in the southern part of the reservation to over 10 inches in the northern part. During most years, about 60 percent precipitation occurs in July, August, and September.

(3) The prevailing winds are out of the west. A salient feature of these winds is their gusty nature. Wind velocities have reached a maximum of 123 miles per hour . The higher velocities are experienced adjacent to the mountains, and the lower velocities in the valley regions. These winds, chiefly from the west and southwest, vary from small whirlwinds known as "dust-devil," to high winds of more than 24-hour duration. The dust-devil type of whirlwinds throw sand and gravel with sufficient velocity to cause visible pitting of automobile windows and impingement. The high winds with their gusts have removed windows and roofs from houses and buildings in the Post Area. The sand and dust (most prevalent in the spring), cause rapid deterioration of unprotected equipment and instruments. Damaging high winds have also been recorded in November, December, and March.

(4) The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

SECTION 01 00 00.00 44 Page 2

WORK DAYS BASED ON (5) DAY WORK WEEK

WHITE SANDS, NM AREA (WSMR AND RESERVE CTR AT LAS CRUCES)

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

1 1 1 1 2 1 4 4 2 1 1 3

a. Upon receipt of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day.

b. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

1.3 WORK RESTRICTIONS

1.3.1 Working Hours

Normal working hours are Monday through Friday, 0630 to 1700 hours, unless otherwise indicated at the preconstruction conference. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer.

1.3.2 Security Requirements

1.3.2.1 Installation Entrance Requirements

Entrance requirements to the Installation are specified in Section 01 35

20.00 44 SPECIAL PROJECT PROCEDURES FOR WHITE SANDS MISSILE RANGE.

Access to White Sands Missile Range will be delayed between 5 minutes and 30 minutes or longer due to increased security precautions, including the checking of vehicle ID’s, vehicle manifests, and the searching of all vehicles. Any general or specific threat to the safety of those working or living at White Sands Missile Range could result in longer waiting times at the access points to White Sands Missile Range. Individuals shall have one form of picture ID such as a driver's license (issuing state and number). In addition to the picture ID, conference attendees shall also have their company's name and address, a memo on their company's letterhead stating the reason for entry, and the location on White Sands Missile Range where the conference is located.

1.3.3 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification

SECTION 01 00 00.00 44 Page 3 as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.4 UTILITIES

1.4.1 Payment for Utility Services

Utility availability and Payment For Utility Services are specified in Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROL.

1.4.2 Coordination

For Contractor Telephone And Internet Service, the Contractor shall coordinate with ITBC and the local phone company for contractor telephone and internet service during construction.

1.4.3 Outages

The Contractor shall coordinate all requests for utility outages with the Contracting Officer and local utility provider (where applicable) in writing 14 days prior to date of requested outage:

a. Water, gas, steam, and sewer outages shall be held to a maximum duration of 4 hours unless otherwise approved in writing.

b. Electrical outages shall have a maximum duration of 4 hours.

c. All utility outages shall be scheduled only on Saturdays, Sundays, or holidays unless specific approval is otherwise received.

1.5 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. RMS - will be used to the greatest extent practicable. Some items may not be submittable via RMS due to program constraints.

Those items shall use an alternate method. All ENGR 4025’s shall be generated and submitted in RMS.

2. Secure, Password Protected Web-Based System Access must be

SECTION 01 00 00.00 44 Page 4 allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product samples, color boards, and any other item not feasible to submit digitally, shall be submitted hard copy. ENGR 4025 shall be submitted digitally always. The Government reserves the right to request hard copy submission on any item, if deemed necessary.

Contractor shall be prepared to provide requested hard copy at any time.

1.6 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201 (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $750,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 60 days. Accessing and using CPARS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.csd.disa.mil/ . If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

1.7 CONTRACTOR PAYROLL RECORD

Contractor shall be required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor shall maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. The ENG 3180's shall be updated weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, the Contractor shall provide the completed ENG 3180’s to the Contracting Officer's Representatives.

SECTION 01 00 00.00 44 Page 5

1.8 CONTRACTOR SUPPLY and USE OF ELECTRONIC SOFTWARE FOR PROCESSING WAGE

RATE REQUIREMENTS CERTIFIED LABOR PAYROLLS

(a) The contractor is required to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

(b) The contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with the Wage Rate Requirements statute. When the contractor uses an electronic payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. The contractor shall obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of this construction contract. The access shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

(c) The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the Federal Acquisition Regulation (FAR);

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export in an Excel spreadsheet;

(5) demonstrated security of data and data entry rights;

(6) ability to produce contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the date/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic payroll processing system shall be provided to the Government during contract closeout.

(d) All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic

SECTION 01 00 00.00 44 Page 6 payroll processing services shall not be a separately bid or reimbursed item under this contract.

1.9 ADDITIONAL CONTRACTOR PAYROLL RECORD

(1) The Albuquerque District requires the contractor and all sub-contractors to use an electronic payroll system meeting the requirements the above referenced requirements and the following.

(a) The Certified Labor Payrolls must be tracked electronically via WEB-based software and all data must be submitted via WEB. Payroll guidelines,"Instructions to Contractors on Contract Labor Requirements, published as "Appendix A, SWFP 1185-1-1" (also known as the Green book), will be provided to advise/inform contractors how these labor provisions will be administered and enforced.

(b) The WEB-based software must be capable of downloading data directly from existing electronic payrolls, track workers to ensure that overtime is being paid when overtime status is reached on Government contracts whether on one or multiple contracts or different sub-contractors. The software must track apprentices and journeyman ratios, create and track SF-1444 "Request for Authorization of Additional Classification and Rate", track workers by name/address/with or without Social Security Numbers, allow automated redaction of information appearing on payroll statements for agency response to Freedom of Information Act (FOIA requests), and provide free online training by the software provider to any user of the software.

(c) The software must allow fringe benefit statement to track fringe benefits "whether cash or into an approved plan, fund, or program. If the fringe benefits are paid into a plan, fund, or program the company's name (receiving benefits), phone number, and address shall be listed on the Statement of Compliance Form (DD Form 879 or WH-347).

(d) Software must provide a method of tracking standard and non-standard deductions such as restitution, alimony, child support, and allow for custom entries. Method of tracking must list the deductions on the statement of compliance or be listed as an attachment.

(e) The Contractor is required to provide the updated 3180's and notify the Contracting Officer's Representatives weekly by email when the current payrolls are complete and ready for inspection/review on the WEB. Before final payment, the Contractor shall provide the completed ENG For 3180's and 3 disks (CD/DVD) which include complete copies of the Contractor and sub-contractor's payrolls/attachments, to the Contracting Officer's Representatives.

(2) Electronic copies of electronically/manually signed forms/memos/letters such as SF 1413 Statement of Acknowledgement (sub-contractor agreement), SF-1444 "Request for Authorization of Additional Classification and Rate", employee deduction authorization, certification of apprentices and trainees shall be provided to the Contracting Officer's Representative as required by FAR.

1.10 STREET CLOSINGS

The Contractor shall coordinate all requests for street closings with the Contracting Officer in writing 21 days prior to date of requested outage:

SECTION 01 00 00.00 44 Page 7

a. One lane traffic shall be maintained at all times (except that a total closing may be allowed for specific 8-hour periods).

b. The final street repair shall be completed within 21 calendar days after the start of any street crossing. Any part of the street returned to service prior to final repair shall be maintained smooth with hot-mix cold-lay surface course.

c. Open cuts across paved roads and streets for utility crossings will not be allowed. Utility crossings will be accomplished by boring or jacking procedures only .

1.11 Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS 222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

U.S. Department of Labor Veterans' Employments and Training Service (VETS):

www.dol.gov.vets

Federal Veteran Employment Information:

https://www.fedshirevets.gov/

Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

U.S> Army Warrior Transition Command Employments Index:

https://wct.army.mil/modules/employers/index.html

Hiring Our Heroes:

https://www.uschamberfoundation.org/hiring-our-heroes

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 00 00.00 44 Page 8