W912PM21B0009 TA 39-19 1st SWTG HPMTA.pdf

Project Title: 1st SWTG Human Performance Multipurpose Training Area

-----This acquisition is being offered as a Certif ied HUBZone Small Business set-aside.------

SOLICITATION W912PM21B0009

Project Number: TA-39-19 Project Description: Install a new outdoor artif icial turf f ield training area for the 1st Special Warfare Training Group. Other features include a concrete pad w ith pre-engineered metal shade structure and site lighting. Bid options include: a new rope climbing structure, an artif icial turf pullup/sit-up area, a concrete foundation system for future SORINEX equipment and a yard hydrant.

IN ACCORDANCE WITH FAR 36.204(e), THE MAGNITUDE OF CONSTRUCTION FOR THIS PROJECT IS BETWEEN $1,000,000 AND $5,000,000.

FUNDS ARE NOT PRESENTLY AVAILABLE FOR THE ACQUISITION. NO CONTRACT AWARD WILL BE MADE UNTIL APPROPRIATE FUNDS ARE

MADE AVAILABLE.

VERBAL AND WRITTEN REQUESTS FOR INFORMATION MUST BE DIRECTED TO THE PERSON LISTED IN ITEM 9 ABOVE. INQUIRIES AND REQUESTS THAT ARE DIRECTED TO ANY OTHER PERSON MAY NOT BE RELAYED TO THE PROPER PERSON AND THEREFORE, MAY NOT

BE ANSWERED.

X

BOBBY LAW 910-251-4469

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

19-May-2021

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________300 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________00 73 00

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________22 Jun 2021 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U S ARMY CORPS OF ENGINEERS, WILMINGTON

WILMINGTON DISTRICT

ATTN: BOBBY LAW

69 DARLINGTON AVE

WILMINGTON NC 28403-1343

W912PM

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

910-251-4454FAX:TEL: 910-251-4469 TEL: FAX:

W912PM21B0009 47

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912PM21B0009

Section 00 01 10 - Table of Contents

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Contract Specifications 12-APR-2021 Attachment 2 Contact Drawings 12-APR-2021 Attachment 3 SITE VISIT MAP 13-MAY-2021

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

NEW MULTIPURPOSE TRANING FIELDFFP

This project is the construction of a multipurpose training area including synthetic grass area and covered bleacher area, site improvements, demolition of existing shelter and including other site items. See attached specifications and drawings.

FOB: Destination

PSC CD: Y1JZ

NET AMT

0002 1 Each

PAYMENT AND PERFORMANCE BONDSFFP

Cost of Payment and Performance Bond Premiums for all bid items.

0003 1 Job

OPTION BID OPTION - DRINKING FOUNTAINFFP

Optional Bid Item 1 - Construction of public bottle-filling station including plumbing fixture and infrastructure for connection to existing plumbing system at Building 2517. See attached specifications and drawings.

0004 1 Job

OPTION BID OPTION - CLIMBING TOWERFFP

Optional Bid Item 2 - Construction of rope climbing tower including foundations, materials and site improvements. See attached specifications and drawings.

0005 1 Job

OPTION BID OPTION - SIT-UP / PUSH-UP AREAFFP

Optional Bid Item 3 - Construction of site work for new sit-up / push-up area including synthetic grass area and site improvements. See attached specifications and drawings.

0006 1 Job

OPTION BID OPTION - EQUIPMENT FOUNDATIONFFP

Optional Bid Item 4 - Construction of monolithic concrete slab /foundation to support fitness testing equipment. See attached specifications and plans.

NOTICE TO BIDDERS

NOTE 1:

The period of performance of CLIN’s 0001-0006 shall run concurrently with the entire contract duration so that the period of performance shall not exceed 300 calendar days.

NOTE 2:

The exercise of all optional bid items 1 through 6 (CLIN’s 0003-0006) shall be subject to the availability of funds.

NOTE 3:

The government reserves the right to exercise optional bid items 1 through 6 (CLIN’s 0003-0006) by no later than 60 Days after Notice To Proceed.

Section 00 21 00 - Instructions

SUBMISSION OF PROPOSALS

SAFE INSTRUCTIONS

The Offeror’s bid shall be submitted electronically, as described below. The Offeror’s bid shall not contain classified data. The use of hyperlinks in bids is prohibited.

NOTE: The only authorized transmission method for bids in response to this solicitation is electronically via SAFE online submission. NO OTHER TRANSMISSION METHODS (EMAIL, FACSIMILE, REGULAR MAIL, HAND

CARRIED, ETC.) WILL BE ACCEPTED.

The Offeror’s bid must be received by the Government by the date/time specified in the solicitation. Offerors shall electronically submit their bids using the following link:

https://safe.apps.mil/

Within SAFE, please send bids to both Contract Specialist Robert Law at robert.n.law@usace.army.mil and to Contracting Officer Michael Mullen at Michael.M.Mullen@usace.army.mil.

Failure to properly submit a bid by the time due (12:00 PM EDT) will render it late, and late bids will not be read.

As this is an electronic submission subject to internet connectivity and other potential network traffic issues, offerors are cautioned to plan accordingly.

INSTRUCTIONS FOR SUBMITTING ELECTRONIC BIDS:

In effort to reduce paperwork and cost, all bids shall be submitted electronically through the SAFE site. Submission shall be in Adobe PDF format. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB).

If you have a large number of files, recommend that you combine or ZIP your files before uploading to the SAFE site. Offerors may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

REQUEST FOR UPLOAD CODE: In order to electronically submit a bid through DoD SAFE, offerors must email Contract Specialist Robert Law at robert.n.law@usace.army.mil and to Contracting Officer Michael Mullen at Michael.M.Mullen@usace.army.mil no later than five (5) working days (15 June 2021) prior to the bid due date to receive a request code which will allow for file uploads via the SAFE site. Offerors that fail to email for request a code five (5) working days before bid submission date may not be able to receive a request code in time to upload their submission.

FILE DESCRIPTION: Include a “File Description” for each file(s) you upload. The “File Description” will be included in the email notice to each of the recipients you choose to have access your file(s).

NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.)

Submission shall be in Adobe PDF format.

INSTRUCTIONS TO FOLLOW ON THE SAFE WEBSITE:

Once at the SAFE website select the “Drop-off” icon. This allows users without a CAC or users whose computer is not configured to read a Common Access Card (CAC) the option to access the SAFE site as a guest.

After selecting the “Click Here” link you will be prompted to add your personal information, file information, recipient (Government representative) information and email settings.

When completing your file information for transmittal via the SAFE website, you will be required to enter the email address for all recipients. For this solicitation, the recipients are the Contract Specialist and the Contracting Officer.

The email address for the Contract Specialist for this solicitation is robert.n.law@usace.army.mil AND the Contracting Officer is Michael.M.Mullen@usace.army.mil

The E-Mail address of the Government Employee who initiated the request code will be automatically entered. The Offeror must enter the E-Mail address for both the Contracting Officer and Specialist. The Offeror can enter an additional E-Mail address if desired. After entering the email address, click the ADD button to add the person(s) email to the “Recipients List” of your response. When your bid is submitted, a notification will be sent to the recipients you added.

NOTE: Do NOT send the SAFE site packages to group email accounts.

Even if you successfully upload your bid to the SAFE site, notification will not be sent to the government recipients until you verify your email address. Entering an incorrect email may result in the rejection of your submission for lateness. An Offeror can confirm proper submission by the ‘Drop-Off Completed” screen which generates based on proper file submission.

NOTE: It has been reported that documents are more quickly uploaded into the SAFE website when using a Firefox web browser. The Government cannot verify that this is true and offers no guarantee that Offerors will have more success utilizing any particular browser.

RECEIPT OF SUBMISSIONS:

For the purposes of establishing whether a bid submission is considered timely, the government considers the date and time the submission is completely uploaded into the SAFE website. For bids larger than the 2GB capacity of the SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive bids. Offerors are responsible for ensuring that bids are submitted so as to reach the designated recipient. Offerors are responsible for allowing sufficient time for the bid to be received in accordance with the instructions provided.

Because uploaded documents expire in DoD SAFE, the submission of bids should only occur during a limited window of time from 1400 on 20 June 2021 to the due date, in order to ensure that the submitted bids don’t expire before the bid opening officer has time to download the bids and conduct the bid opening.

Offerors are responsible for ensuring that they submit the submitted bid does not expire prior to bid opening.

Bid Due Date and Time: 22 June 2021 no later than 12:00PM (Noon)

Bid Opening Date and Time: 22 June 2021 at 14:00 EST

Audio Conference Line instructions:

USA TOLL-FREE: 844-800-2712

ACCESS CODE: 43391920

INFORMATION TO BIDDERS

System for Award Management (SAM) and Electronic Funds Transfer (EFT)

1. All contractors must register in the System for Award Management (SAM) database before they can be awarded a contract. You may register at http://www.sam.gov. SAM information or help is also available by calling 866- 606-8220.

2. Public Law 104-134 requires the use of Electronic Funds Transfer (EFT) for all Federal payments. For contractor payments, EFT information will be pulled from your SAM by:

USACE FINANCE CENTER

5720 INTEGRITY DRIVE,

MILLINGTON, TN 38054-5005

(End of information)

PRE-AWARD INFORMATION

1. Contracts shall be awarded to responsible prospective contractors only. Before award, to be determined responsible, a prospective contractor must:

a. Have adequate financial resources to perform the contract, or the ability to obtain them;

b. Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and government business commitments;

c. Have a satisfactory performance record;

d. Have a satisfactory record of integrity and business ethics;

e. Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them;

f. Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

g. Be otherwise qualified and eligible to receive an award under applicable laws and regulations.

2. Each Bidder shall, upon request of the Contracting Officer, furnish information on any or all of the above areas so that the Contracting Officer can make an affirmative determination of responsibility or nonresponsibility.

(End of information)

SOLICITATION/TECHNICAL INQUIRY

1. Solicitation/Technical Inquiries.

a. Inquiries are to be submitted via Bidder Inquiry at the ProjNet website at https://www.projnet.org <https://www.projnet.org> .

b. If you have technical problems accessing the Bidder Inquiry via the ProjNet website, contact the ProjNet Help Desk at 1-800-428-4357 (HELP). This number is for technical issues accessing the website ONLY.

2. Read this paragraph in conjunction with contract provision FAR 52.214-6, “Explanation to Prospective Bidders”.

3. Any prospective bidder/offeror desiring an explanation or interpretation of the solicitation, drawings specifications, etc., must request it in writing via Bidder Inquiry in ProjNet within no less than ten (10) calendar days prior to the date of bid opening or receipt of proposals. The Government reserves the right to decline addressing questions received less than ten (10) calendar days prior to receipt of bid opening or receipt of proposals.

4. No Inquiries will be accepted by the Bidder Inquiry system within ten (10) calendar days prior to the date of bid opening. However, you may still access the Bidder Inquiry system to view answers/replies to previous inquiries until the bid opening.

5. ProjNet - Bidder Inquiry module.

a. To submit and review bid inquiry items, bidders/offerors will need to be a current registered user or selfregister into system. To access Bidder Inquiry, go to the ProjNet web page at http://www.projnet.org <http://www.projnet.org> and click the “Quick Add” link. Once at the Quick Add screen, select agency USACE, enter Bidder Inquiry Key for this solicitation listed below, and bidder’s/offeror’s e-mail address, then click login. If this is bidder’s/offeror’s first time logging in they will be taken to the Bidder Inquiry Create Account screen to self-register. Fill in all required information and click create user. Verify that information on next screen is correct and click continue. Please remember your Secret Question Answer and email address used for future access to this website.

b. From this page you may view all bidder/offeror inquiries under Reports or post a new inquiry under Submit.

c. Bidders/Offerors will receive an acknowledgement of their question via email, followed by another email notification that an answer to their question has been posted after it has been reviewed by our technical team and responded to by a Contracting Officer. It is the responsibility of the Bidder/Offeror to check their junk email and email delivery options to ensure delivery of these acknowledgement emails.

d. Bidders/Offerors are responsible for checking bid inquiry items.

e. Bidders/Offerors are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry. The name of the submitter or firm is not published for the public on the report of all Bidder Inquiries. Bidders/ Offerors are on notice of, and assumed to be aware of, all inquiries, responses, and information posted in the Bidder Inquiry System up to the date of bid submission, whether the inquiry was generated by the Bidder themselves or another potential Bidder/ Offeror. Bidders are responsible for incorporating all such information into their bid, or for requesting further clarification."

6. Solicitation Information:

IFB No: W912PM21B0009 Bidder Inquiry Key: Z6MJMK‐YT3RN2

(end of section)

CLAUSES INCORPORATED BY REFERENCE

252.204-7017 Prohibition on the Acquisition of Covered Defense

Telecommunications Equipment or Services -- Representation

DEC 2019

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

CLAUSES INCORPORATED BY FULL TEXT

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00 whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

Section 00 21 13 - Instructions to Bidders

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

26.2% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from

Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Fort Bragg, Cumberland County, North Carolina.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

U.S. Army Corps of Engineers Wilmington District Contracting Division ATTN: Michael Mullen, Contracting Officer 69 Darlington Avenue Wilmington, NC 28403

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visit information:

A Site Visit shall be conducted on 27 May 2021 from 0900 - 1100 for this project. It is incumbent on the contractor to contact the POC for this project within 5 days of receipt of this solicitation.

The Point of Contact for this project is:

Nathaniel J. Hermann, P.E.

E-mail: nathaniel.j.hermann@usace.army.mil 910-580-2398

Assemble at the JSOC Visitor Center. The JSOC Visitors Center is off Butner Road. You will park in the Designated Parking Area as directed by the JSOC Security Officer personnel. All participants will walk from the Visitors Center to Building 3-3139 and back after site visit.

(c) Site Visit Map:

See attached site visit map titled “SC-00001-21_Bldg site map.pdf”.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov

Section 00 45 00 - Representations and Certifications

52.204-8 Annual Representations and Certifications MAR 2020 52.219-3 Notice of HUBZone Set-Aside or Sole Source Award MAR 2020

BIDDER IDENTIFICATION

Offeror is requested to furnish the following information:

Name/Address: ____________________________________________________________

Telephone No. ____________________________________________________________

DUNS: ________________________ CAGE: _______________________

(End of Provision)

CORPORATE CERTIFICATES

The offeror shall execute and affix seal on attached Corporate Certificate if the company is incorporated. Company name on the seal should always be the same as company name on Page A-1 of the solicitation. If a proposal is signed by an officer of the company, the certificate shall be certified by another officer of the company. If the proposal is signed by someone other than an officer of the company, the proposal must be accompanied by: (1) a Corporate Resolution that individual signing the contract has authority to bind the company; or (2) a Corporate Resolution stating that an officer of the company may appoint individuals to sign proposals and bind the company.

NOTE: Contractor, if a corporation, should cause the following certificate to be executed under its corporate seal, provided that the same officer shall not execute both the contract and the certificate.

CERTIFICATE

I, ________________________________________________ , certify that I am ____________________________________________of the corporation named Contractor herein, that _____________________________________________ signed this contract on behalf of the Contractor, was then ______________ of said corporation; that said contract was duly signed for and in of said corporation by authority of its governing body, and is within the scope of its corporate powers.

____________________________________ (CORPORATE SEAL)

(Signature)

TAXPAYER IDENTIFICATION

Taxpayer Identification Number (TIN),” as used in this provision, means the number required by the Internal Revenue Service (IRS) to be used by the offeror in reporting income tax and other returns. The TIN may be either a Social Security Number or an Employer Identification Number.

(a) Taxpayer Identification Number (TIN).

___ TIN:.___________________________

___ TIN has been applied for.

___ TIN is not required because:

___ Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

___ Offeror is an agency or instrumentality of a foreign government;

___ Offeror is an agency or instrumentality of the Federal Government.

(b) Type of organization.

___ Sole proprietorship;

___ Partnership;

___ Corporate entity (not tax-exempt);

___ Corporate entity (tax-exempt);

___ Government entity (Federal, State, or local);

___ Foreign government;

___ International organization per 26 CFR 1.6049-4;

___ Other ______________________________

(c) Common parent.

___ Offeror is not owned or controlled by a common parent ___ Name and TIN of common parent:

Name _________________________________

TIN ___________________________________

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government

52.202-1 Definitions JUN 2020 52.203-2 Certificate Of Independent Price Determination APR 1985 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2018 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

JUN 2016

52.204-22 Alternative Line Item Proposal JAN 2017 52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

OCT 2020

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

JUN 2020

52.209-7 Information Regarding Responsibility Matters OCT 2018 52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-13 Violation of Arms Control Treaties or Agreements -- Certification.

FEB 2021

52.211-13 Time Extensions SEP 2000 52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-14 (Dev) Limitations on Subcontracting (DEVIATION 2020-O0008) MAR 2020 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records AUG 2018 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-16 Approval of Wage Rates MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons OCT 2020 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 NOV 2020 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.224-3 Privacy Training JAN 2017 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.229-2 North Carolina State and Local Sales and Use Tax APR 1984 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-1 Payments APR 1984 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-1 Value Engineering JUN 2020 52.248-3 Value Engineering-Construction OCT 2020 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.215-7008 Only One Offer JUL 2019 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.225-7048 Export-Controlled Items JUN 2013 252.225-7974 (Dev) Representation Regarding Business Operations with the

Maduro Regime (DEVIATION 2020-O0005)

FEB 2020

252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7006 Cost Limitation JAN 1997 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JAN 2021 252.247-7023 Transportation of Supplies by Sea FEB 2019

52.204-20 Predecessor of Offeror (AUG 2020)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365 calendar days after date of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1104.58 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (NOV 2020)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code assigned to contract number .

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the Contractor represented itself as a women-owned small business concern in paragraph (h)(3) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture.

[The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the Contractor represented itself as a women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(5)(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: .] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a…