Am1_Spec_W912PL-14-B-0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc. ) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

0001 Aug 27, 2014

W912PL

USACE-LOS ANGELES DISTRICT

CONTRACTING DIVISION, WEST REGION BRANCH

915 Wilshire Blvd., Suite 1400

LOS ANGELES, CA 90053-2325

W912PL-14-B-0003

Aug 5, 2014

PHASE II, PRADO DAM, CALIFORNIA INSTITUTION FOR WOMEN (CIW) DIKE, SANTA ANA RIVER MAINSTEM, CHINO, SAN BERNARDINO COUNTY, CALIFORNIA.

Amendment issued to extend the date for receipt of bids to September 5, 2014, 1:00PM, and to incorporate the following changes. (See continuation page)

Phase II, Prado Dam W912PL-14-B-0003 California Institution for Women (CIW) Dike Chino, San Bernardino County, CA

SF-30 Continuation page Amendment 1

SF-30 Continuation Sheet – Block 14

a. Replace the:

Cover sheet, Table of Contents, SF-1442 - Solicitation, Offer and Award

b. Specification: REPLACE the following Specification Sections :

00 10 00 Price Schedule and Certificate of Offeror’s Principle 00 73 00 Supplementary Conditions (changes to paragraphs Security Requirements and Required Insurance) 00 73 46 Wage Rates

01 11 00 Summary of Work 01 22 00 Measurement and Payment 31 00 00 Earthwork

c. REPLACE the following Plans/Drawings:

File No. Sheet No. Drawing Title

373/482 T2 INDEX T 0 CONTRACT DRAWINGS

373/492 C01 PLAN & PROFILE, STATION 6+00 TO 15+00

373/493 C02 PLAN & PROFILE, STATION 15+00 TO 24+00

373/510 C19 S0UTH GRADING PLAN

373/511 C20 CULVERT AT DIKE STA 26+00

373/514 M2 MISCELLANEOUS DETAILS 2

373/515 M3 MISCELLANEOUS DETAILS 3

373/530 L5 S 0UTH DIKE LANDSCAPE PLAN

373/531 L6 B 0RROW AREA LANDSCAPE PLAN

373/605 OP3 PARK GRADING PLAN WEST

373/606 OP4 OVERFLOW PARKING LOT ACCESS ROAD, TEMPORARY

ACCESS ROAD, PARK CULVERT

373/608 OP6 CULVERT AT PARK ROAD PLAN AND PROFILE

373/609 OP7 OVERFLOW PARKING LOT CROSS-SECTIONS

373/612 OP10 SCE EASEMENT CR0SS - SECTI0N S

373/613 OP11 MISCELLANEOUS DETAILS

d. ADD the following Plans/Drawings:

373/618 OP12 MISCELLANEOUS DETAILS

373/619 OP13 OVERFLOW PARKING LOT ELECTRICAL GROUNDING PLAN AND

DETAILS

California Institution for Women (CIW) Dike, Santa Ana River Mainstem, Table of Contents - 1 Amendment 1

PROJECT TABLE OF CONTENTS

DIVISION 00 - BIDDING REQUIREMENTS, CONTRACT FORMS AND CONTRACT CONDITIONS

SF-1442 Solicitation, Offer and Award Am1 00 10 00 Certificate of Offeror’s Principle and Price Schedule Am1

00 21 00 Instructions 00 21 13 Instructions to Bidders 00 45 00 Representations and Certifications

00 70 00 Conditions of the Contract 00 73 00 Supplementary Conditions Am1 00 73 46 Wage Rates Am1

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK Am1 01 22 00 MEASUREMENT AND PAYMENT Am1

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 01 USACE QUALITY CONTROL

01 45 01.10 USACE QUALITY CONTROL SYSTEM (QCS)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 20 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 02 - EXISTING CONDITIONS

02 13 00 DIVERSION AND CONTROL OF WATER

02 41 00 DEMOLITION

DIVISION 03 – CONCRETE

03 30 07 CONCRETE FOR MINOR STRUCTURES

03 36 00 GROUTING STONE PROTECTION

DIVISION 05 – METALS

05 50 15 CIVIL WORKS FABRICATIONS

DIVISION 31 – EARTHWORK

31 00 00 EARTHWORK Am1

31 05 22 GEOTEXTLE USED AS FILTERS

31 10 00 CLEARING FOR CIVIL WORKS

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 11 23 AGGREGATE AND/OR GRADED-CRUSHED AGGREGATE BASE COURSE

32 12 12 BITUMINOUS PAVING

32 31 13 CHAIN LINK FENCES AND GATES

32 92 19 HYDROSEEDING

32 93 00 EXTERIOR PLANTS

Table of Contents - 2 Amendment 1

DIVISION 33 – UTILITIES

33 21 00 MONUMENTATION AND INSTRUMENTATION

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 31 19 STONE PROTECTION

-- End of Project Table of Contents --

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by the offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION CALL

A. NAME B. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date):

11. The Contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory, negotiable. (See .)

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12B. CALENDAR DAYS

YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror’s name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212

Designed using Perform Pro, WHS/DIOR, Oct 96

1442-103 STANDARD FORM 1442 (REV. 4-85) (EG)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

W912PL-14-B-0003 x 05 Aug 2014 1 OF 2

USACE, Los Angeles District Contracting Division, West Region Branch 915 Wilshire Blvd, Ste 1400 Los Angeles, CA 90017

See Item 7

Patricia Bonilla 213-452-3255

PHASE II, PRADO DAM, CALIFORNIA INSTITUTION FOR WOMEN (CIW) DIKE, SANTA ANA RIVER MAINSTEM, CHINO, SAN BERNARDINO COUNTY, CALIFORNIA. Construct zoned earthen embankment dikes with total 6,000 ft. long and maximum 32 ft. height. The construction also includes concrete box culverts, a parking lot, access roads, and drainage systems. The principal place of performance is Chino, San Bernardino County, California.

This is a 100% total set-aside for Small Business. The small business standard is $27,500,000.00 in annual receipts for the past 3 years. The proposed period of performance is 390 calendar days from the date of Notice to Proceed. The estimated cost range of this project is over $10,000,000.00 The proposed contract will be awarded using the sealed bidding process in accordance with FAR Part 14. Proposed award to be made to the responsible bidder whose bid is responsive to the terms of the invitation for bids and is most advantageous to the Government, considering only price and the price related factors included in the invitation.

OFFERORS PLEASE NOTE: This solicitation may be delayed, cancelled or revised at any time prior to award.

SPECIAL NOTE: REAL ESTATE CERTIFICATION FOR THIS REQUIREMENT IS NOT COMPLETE AT THIS TIME OF SOLICITATION ISSUANCE* Please see Section 00 21 13, entitled Instructions to Bidders for further information.

10 see 007300

X X *Section 00 73 00

X 10

0 2:00 PM

05 September 2014

X

AMENDMENT 0001

OFFER (Must be fully completed by offeror)

STANDARD FORM 1442 BACK (REV. 4-85)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal or greater than the minimum requirement stated in 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24.SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BYCODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to the issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and

(c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD. (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN

(Type or print)

30B. SIGNATURE 30C. DATE

31A. NAME OF CONTRACTING OFFICER (Type or print)

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

DUNS NO.: TAX ID NO.:

CAGE CODE NO.:

( ) - ; FAX ( ) -

SEE PRICING SCHEDULE

SECTION 00 10 00 Page 1 Amendment 0001

SOLICITATION, CONTRACT LINE ITEMS SCHEDULE

SECTION 00 10 00

(SF-1442 Continuation Page)

CERTIFICATE OF OFFEROR’S PRINCIPAL

(1) IF THE OFFEROR IS PARTNERSHIP OR JOINT VENTURE, LIST FULL NAME OF ALL PARTNERS/ JOINT VENTURERS (Add addendum as necessary):

(Company Name) (Signature) (Title)

(Company Name) (Signature) (Title)

(Company Name) (Signature) (Title)

(2) IF THE OFFEROR IS A CORPORATION, THE FOLLOWING CERTIFICATION SHOULD BE COMPLETED:

CERTIFICATION AS TO CORPORATE PRINCIPAL

I, ______________________________, certify that I am the Secretary of the corporation named as principal on the offer/contract; that ________________________________, who signed the offer/contract on behalf of the principal, was the _________________________________of the corporation; that I know the individual’s signature and that his/her signature is genuine; and that said Offer/Contract was duly signed, sealed and attested for on behalf of said corporation by authority of its governing body.

CORPORATE PRINCIPAL

CORPORATE SEAL ____________________________________

SECRETARY

(3) IF THE OFFEROR IS A LIMITED LIABILITY COMPANY/PARTNERSHIP, LIST FULL NAME OF ALL MANAGERS BELOW (Add addendum as necessary). SIGNATURES BY ALL MANAGERS HERE SIGNIFY THAT THAT THE INDIVIDUAL WHO SIGNED THE OFFER/CONTRACT HAS THE AUTHORITY TO BIND THE LIMITED LIABILITY

COMPANY/PARTNERSHIP.

(Officer’s Name) (Signature) (Title)

SECTION 00 10 00 Page 2 Amendment 0001

PRICE SCHEDULE

Base Bid Items for STATION 13+00 TO STATION 72+20

Item Description Quantity Unit Unit Price

Amount

0001 DIVERSION AND CONTROL OF

WATER

1 Job LS

0002 CLEAR SITE AND REMOVE

OBSTRUCTIONS

1 Job LS

0003 ENVIRONMENTAL PROVISIONS 1 Job LS

0004 REMOVE ABANDONED SEWER LINE

WITH 2 MANHOLES

1 Job LS

0005 REMOVE EXIST. SETTLEMENT PIPE

CASING AND CONCRETE

SETTLEMENT BASE

1 Job LS

0006 REMOVE IRRIGATION PUMP AND

VALVE

2 EA

0007 REMOVE MONITORING WELLS 2 EA

0008 CONSTRUCTION OF OVERFLOW

PARKING LOT

1 Job LS

0009 STORM DRAIN/SEWER

MODIFICATIONS

1 Job LS

0010 SETTLEMENT MONUMENTS 38 EA

0011 SETTLEMENT BASE 4 EA

0012 PIEZOMETER 1 EA

0013 GRADE MONITORING WELLS 2 EA

0014 STRIPPING

a. FIRST 44,000 CUBIC YARDS

b. OVER 38,300 CUBIC YARDS

44,000

38,300

CY

CY

0015 EXCAVATION 201,000 CY

0016 COMPACTED FILL, ZONE 1 72,000 CY

0017 COMPACTED FILL, ZONE 2 253,000 CY

0018 COMPACTED FILL, SELECT ZONE 2 30,000 CY

0019 TOP SOIL (NON COMPACTED FILL) 20,000 CY

0020 NON COMPACTED, ZONE 2 UNDER

RESERVOIR SIDE RIPRAP

3,500 CY

SECTION 00 10 00 Page 3 Amendment 0001

0021 NON COMPACTED FILL,

MISCELLANEOUS FILL

22,500 CY

0022 RIPRAP 26,000 TON

0023 STONE FOR GROUTED STONE 170 TON

0024 GROUTING 30 CY

0025 AGGREGATE BASE COURSE 7,100 TON

0026 GEOTEXTILE FILTER FABRIC 41,540 SY

0027 CONCRETE CULVERT, STA. 26+00 1 Job LS

0028 CONCRETE CULVERT, STA. 51+60 1 Job LS

0029 CONCRETE DITCH 4,430 LF

0030 SWING GATE 2 EA

0031 GUARD CABLE FENCE 5,970 LF

0032 HYDROSEED, DIKE SEED MIX 39 ACRE

0033 HYDROSEED, NATIVE PLANT MIX 32 ACRE

0034 HYDROSEED, BORROW SITE 47 ACRE

0035 24” Box Trees 33 EA

0036 SECURITY GUARD SERVICE 1 Job LS

0037 PRADO OFFICE MAINTENANCE 15 MONTH

0038 AS-BUILT DRAWINGS 1 Job LS

0039 CHAIN LINK FENCE 5,190 LF

0040 TEST SECTION, SUBGRADE

PREPARATION, AND COMPACTION

BETWEEN STATION 13+00 & 37+00

1 Job LS

SUB TOTAL LINE ITEMS 0001 – 0040 (BASE BID): $ ________________

SECTION 00 10 00 Page 4 Amendment 0001

OPTION 1 ITEMS FOR STATION 6+90 TO STATION 13+00

0041 DIVERSION AND CONTROL OF

WATER

1 Job LS

0042 CLEAR SITE AND REMOVE

OBSTRUCTIONS

1 Job LS

0043 REMOVE EXISTING UTILITY

FEATURES @ STA 9+00

1 Job LS

0044 SETTLEMENT MONUMENTS 1 EA

0045 STRIPPING 2,800 CY

0046 EXCAVATION 42,000 CY

0047 COMPACTED FILL, ZONE 1 5,700 CY

0048 COMPACTED FILL, ZONE 2 40,000 CY

0049 COMPACTED FILL, SELECT ZONE 2 2,800 CY

0050 TOP SOIL (NON COMPACTED FILL) 2,200 CY

0051 NON COMPACTED ZONE 2 UNDER

RESERVOIR SIDE RIPRAP

300 CY

0052 RIPRAP 2,500 TON

0053 AGGREGATE BASE COURSE 1,250 TON

0054 GEOTEXTILE FILTER FABRIC 3,600 SY

0055 CONCRETE DITCH 350 LF

0056 SWING GATE 1 EA

0057 GUARD CABLE FENCE 610 LF

0058 CHAIN LINK FENCE 336 LF

0059 HYDROSEED, DIKE SEED MIX 0.5 ACRE

0060 HYDROSEED, NATIVE PLANT MIX 2.5 ACRE

SUB-TOTAL LINE ITEMS 0041 – 0060 (OPTION 1 ITEMS): $ __________

SECTION 00 10 00 Page 5 Amendment 0001

OPTION 2 ITEM

0061 ADDITIONAL ROLLING (2 PASSES) 1 Job LS $

OPTION 3 ITEM FOR STATION 6+90 TO STATION 13+00

0062 ADDITIONAL ROLLING (2 PASSES) 1 Job LS $

OPTION 4 ITEM FOR STATION 6+90 TO STATION 13+00

0063 ADDITIONAL ROLLING (2 PASSES) 1 Job LS $

Total Estimated Amount (Base Bid plus Options 1 through 4): $ ______________

Abbreviations:

LF = Linear Foot CY = Cubic Yard TON = Ton (1 Ton equals to 2000 pounds) EA = Each LS = lump sum SY = Square Yard

MONTH= Months of Services provided

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

SECTION 00 10 00 Page 6 Amendment 0001

ADDITIONAL BIDDER'S NOTES:

1. All extensions of the unit prices shown will be subject to verification by the Government. In case of variation between the unit price and the extension, the unit price will be considered to be the bid.

2. If a modification to a bid based on unit prices is submitted which provides for a lump sum adjustment to the total estimated amount, the application of the lump sum adjustment to each unit price in the Price Schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the Price Schedule.

3. Prices must be submitted on all individual items of the Price Schedule, otherwise the bid will be considered non-responsive and will be rejected.

4. For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of the Price Schedule as submitted by the bidder:

a. Obviously misplaced decimal points will be corrected;

b. In case of discrepancy between the unit price and the extended price, the unit price will govern;

c. Apparent errors in extensions of unit prices will be corrected;

d. Apparent errors in addition of lump sum and extended prices will be corrected.

5. For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends the bid to be evaluated on the basis of unit prices the totals arrived at by the resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

6. The lump sum "LS" line items in the Price Schedule are not "Estimated Quantity" line items and are not subject to the "Variation in Estimated Quantity" contract clause.

7. The Contract Clause 52.232-27, "Prompt Payment for Construction Contracts" requires that the name and address of the contractor official, to whom payment is to be sent, be the same as that in the contract or in a proper Notice of Assignment.

8. Principal Contracting Officer. The Contracting Officer who signs this contract will be the Principal Contracting Officer for this contract.

However, any Contracting Officer assigned to the Los Angeles District, Contracting within his authority, may take formal action on this contract when the Principal Contracting Officer is unavailable and the action needs to be taken.

9. Amounts and prices shall be indicated in either words or figures, NOT

BOTH.

10. The bidder shall distribute his indirect costs (overhead, profit, bond, etc.,) over all items in the Price Schedule. The Government will review all submitted Price Schedules for any unbalancing of the items. Any submitted Price Schedule determined to be unbalanced may be considered nonresponsive and cause the bidder to be ineligible for contract award.

SECTION 00 10 00 Page 7 Amendment 0001

11. The bidder shall furnish all plant, labor, material, equipment, etc., necessary to perform all work in strict accordance with the terms and conditions set forth in the contract in include all attachments thereto.

12. Some quantities are ESTIMATED, the bidders prices MUST BE FIRM.

13. Bidder is cautioned to check his Price Schedule carefully prior to submission. If the Price Schedule contains unit prices, they should be round off to the second decimal point only NOT EXTENDED FURTHER.

15. Contractor is required to fill in Cage code, TIN and DUNS Number in Block No. 14 on Standard Form 1442, the Name and Address Block.

-- End of Section –

SECTION 00 73 00- 1 Amendment 0001

SECTION 00 73 00

SUPPLEMENTARY CONDITIONS

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

EXERCISE OF OPTION BID ITEM(S)

52.211-13 TIME EXTENSIONS (SEP 2000)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-17 LAYOUT OF WORK (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997) - ALTERNATE I

(APR 1984

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

52.0236-4201 CONTRACTOR PERFORMANCE EVALUATIONS

252.236-7000 MODIFICATION PROPOSALS - PRICE BREAKDOWN. (DEC 1991)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

252.236-7008 CONTRACT PRICES - BIDDING SCHEDULES. (DEC 1991)

252.236-7013 REQUIREMENT FOR COMPETITION OPPORTUNITY FOR AMERICAN STEEL

PRODUCERS, FABRICATORS, AND MANUFACTURERS (JAN 2009)

UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

SAFETY REQUIREMENTS

SECURITY CONTRACT LANGUAGE FOR ALL CORPS OF ENGINEERS' UNCLASSIFIED

CONTRACTS

REQUIRED INSURANCE

ER 415-1-15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 89)

SECTION 00 73 00- 2 Amendment 0001

52.211-10 COMMENCEMENT, PROSECUTION, AND

COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work (including any or all options that may be exercised) ready for use not later than 390 Calendar Days after the contractor receives the Notice to Proceed. * The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP

2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,028.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

EXERCISE OF OPTION BID ITEM(S)

The Government reserves the right to exercise the option(s) by written notice to the Contractor either singularly or in any combination for up to 90 calendar days after the Contractor’s receipt of NTP without an increase in the Offeror’s bid price. No additional time for contract completion will be allowed when an option is exercised. The given contract completion time was formulated to include time necessary to perform all option work.

52.211-13 TIME EXTENSIONS (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

SECTION 00 73 00- 3 Amendment 0001

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting Officer of

(1) subsurface or latent physical conditions at the site which differ materially from those indicated in this contract, or

(2) unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.

(b) The Contracting Officer shall investigate the site conditions promptly after receiving the notice. If the conditions do materially so differ and cause an increase or decrease in the Contractor's cost of, or the time required for, performing any part of the work under this contract, whether or not changed as a result of the conditions, an equitable adjustment shall be made under this clause and the contract modified in writing accordingly.

(c) No request by the Contractor for an equitable adjustment to the contract under this clause shall be allowed, unless the Contractor has given the written notice required; provided, that the time prescribed in

(a) above for giving written notice may be extended by the Contracting Officer.

(d) No request by the Contractor for an equitable adjustment to the contract for differing site conditions shall be allowed if made after final payment under this contract.

52.236-3 SITE INVESTIGATION AND CONDITIONS

AFFECTING THE WORK (APR 1984)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to

(1) conditions bearing upon transportation, disposal, handling, and storage of materials;

(2) the availability of labor, water, electric power, and roads;

(3) uncertainties of weather, river stages, tides, or similar physical conditions at the site;

(4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, SECTION 00 73 00- 4 Amendment 0001 including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys.

(b) Weather conditions: the contractor shall make his own investigations as to weather conditions at the site.

(c) Transportation facilities: the contractor shall make his own investigations as to transportation facilities.

Access ways shall be investigated by the contractor to satisfy himself/herself as to their existence and allowable use.

(d) Other pertinent information: None.

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer's approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor's expense, with all shipping charges prepaid. Machinery, equipment, material, SECTION 00 73 00- 5 Amendment 0001 and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR

1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work which may have been accepted under the contract.

52.236-8 OTHER CONTRACTS (APR 1984)

The Government may undertake or award other contracts for additional work at or near the site of the work under this contract. The Contractor shall fully cooperate with the other contractors and with Government employees and shall carefully adapt scheduling and performing the work under this contract to accommodate the additional work, heeding any direction that may be provided by the Contracting Officer. The Contractor shall not commit or permit any act that will interfere with the performance of work by any other contractor or by Government employees.

SECTION 00 73 00- 6 Amendment 0001

52.236-9 PROTECTION OF EXISTING VEGETATION,

STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

(a) The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

(b) The Contractor shall protect from damage all existing improvements and utilities

(1) at or near the work site, and

(2) on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

(a) The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

(b) Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting Officer, the buildings and utilities may be abandoned and need not be removed.

(c) The Contractor shall, under regulations prescribed by the Contracting Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

SECTION 00 73 00- 7 Amendment 0001

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION

(APR 1984)

(a) The Government shall have the right to take possession of or use any completed or partially completed part of the work. Before taking possession of or using any work, the Contracting Officer shall furnish the Contractor a list of items of work remaining to be performed or corrected on those portions of the work that the Government intends to take possession of or use. However, failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The Government's possession or use shall not be deemed an acceptance of any work under the contract.

(b) While the Government has such possession or use, the Contractor shall be relieved of the responsibility for the loss of or damage to the work resulting from the Government's possession or use, notwithstanding the terms of the clause in this contract entitled "Permits and Responsibilities." If prior possession or use by the Government delays the progress of the work or causes additional expense to the Contractor, an equitable adjustment shall be made in the contract price or the time of completion, and the contract shall be modified in writing accordingly.

52.236-12 CLEANING UP (APR 1984)

The Contractor shall at all times keep the work area, including storage areas, free from accumulations of waste materials. Before completing the work, the Contractor shall remove from the work and premises any rubbish, tools, scaffolding, equipment, and materials that are not the property of the Government.

Upon completing the work, the Contractor shall leave the work area in a clean, neat, and orderly condition satisfactory to the Contracting Officer.

52.236-13 ACCIDENT PREVENTION (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will

(1) safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) avoid interruptions of Government operations and delays in project completion dates; and

(3) control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall-

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR Part 1926 and 29 CFR Part

SECTION 00 73 00- 8 Amendment 0001

1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor's representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES

(a) The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. Unless otherwise provided in the contract, the amount of each utility service consumed shall be charged to or paid for by the Contractor at prevailing rates charged to the Government or, where the utility is produced by the Government, at reasonable rates determined by the Contracting Officer. The Contractor shall carefully conserve any utilities furnished without charge.

(b) The Contractor, at its expense and in a workmanlike manner satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of each utility used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia.

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval

SECTION 00 73 00- 9 Amendment 0001 three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer.

If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

52.236-17 LAYOUT OF WORK (APR 1984)

The Contractor shall lay out its work from Government established base lines and bench marks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

52.236-21 SPECIFICATIONS AND DRAWINGS FOR

CONSTRUCTION (FEB 1997) - ALTERNATE I (APR 1984

(a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to the Contracting Officer, who shall promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own

SECTION 00 73 00- 10 Amendment 0001 risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.

(b) Wherever in the specifications or upon the drawings the words "directed", "required", "ordered", "designated", "prescribed", or words of like import are used, it shall be understood that the "direction", "requirement", "order", "designation", or "prescription", of the Contracting Officer is intended and similarly the words "approved", "acceptable", "satisfactory", or words of like import shall mean "approved by," or "acceptable to", or "satisfactory to" the Contracting Officer, unless otherwise expressly stated.

(c) Where "as shown," as indicated", "as detailed", or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word "provided" as used herein shall be understood to mean "provide complete in place," that is "furnished and installed".

(d) Shop drawings means drawings, submitted to the Government by the Contractor, subcontractor, or any lower tier subcontractor pursuant to a construction contract, showing in detail (1) the proposed fabrication and assembly of structural elements, and (2) the installation (i.e., fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials furnished by the contractor to explain in detail specific portions of the work required by the contract. The Government may duplicate, use, and disclose in any manner and for any purpose shop drawings delivered under this contract.

(e) If this contract requires shop drawings, the Contractor shall coordinate all such drawings, and review them for accuracy, completeness, and compliance with contract requirements and shall indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the Contracting Officer without evidence of the Contractor's approval may be returned for resubmission. The Contracting Officer will indicate an approval or disapproval of the shop drawings and if not approved as submitted shall indicate the Government's reasons therefor. Any work done before such approval shall be at the Contractor's risk. Approval by the Contracting Officer shall not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements of this contract, except with respect to variations described and approved in accordance with

(f) below.

(f) If shop drawings show variations from the contract requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Contracting Officer approves any such variation, the Contracting Officer shall issue an appropriate contract modification, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued.

(g) The Contractor shall submit to the Contracting Officer for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. Three sets (unless otherwise indicated) of all shop drawings, will be retained by the Contracting Officer and one set will be returned to the Contractor. Upon completing the work under this contract, the Contractor shall furnish a complete set of all shop drawings as finally approved. These drawings shall show all changes and revisions made up to the time the equipment is completed and accepted.

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

If the Contracting Officer decides to conduct a preconstruction conference, the successful offeror will be notified and will be required to attend. The Contracting Officer's notification will include specific details

SECTION 00 73 00- 11 Amendment 0001 regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed.

52.0236-4201 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201(Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract.