Combined_Synopsis_&_Solicitation.pdf

US Army Corps of Engineers St. Louis District

CLARENCE CANNON POWER

PLANT

REPLACEMENT OF UNIT NO. 1

SHAFT PACKING

SALT RIVER

RALLS COUNTY, MISSOURI

COMBINED SYNOPSIS & SOLICITATION

AND SPECIFICATIONS

SOLICITATION NUMBER: W912P919T0032

MAY 2019

W912P919T0032

SCOPE OF WORK

U.S. ARMY CORPS OF ENGINEERS

CLARENCE CANNON DAM

MONROE CITY, MISSOURI

REPLACEMENT OF UNIT NO. 1 SHAFT PACKING

1. GENERAL

1.1 SCOPE. The Contractor shall furnish all labor, equipment, and supplies necessary for the replacement of

Unit No. 1 Turbine packing, packing gland, and H-ring assembly. The Unit No. 1 turbine is of the Kaplan-type and is rated for 43,500 horsepower at 75 ft. net head. It was built by Allis-Chalmers. This contract shall also include the cleaning and painting of existing packing box. Refer to Appendix A for as-built drawings of the site and components. A summary of major items of work included in this service include:

Disassembly and reassembly of packing, packing gland, and H-ring assembly.

Painting of packing box.

Supply of H-ring assembly and packing gland.

1.2 DEFINITIONS

1.2.1 CONTRACTING OFFICER. The term “Contracting Officer” (KO) means the person executing this contract on behalf of the Government, and any officer or civilian employee who is properly designated Contracting Officer. The term also includes, except as otherwise provided in this contract, the authorized representative of the Contracting Officer (COR) acting within the limits of their authority.

1.3 CODE AND SAFETY COMPLIANCE. All work shall be performed in accordance with the requirements of EM 385-1-1 and any local, state, or federal ordinances.

1.3.1 SAFETY. All work shall be performed in accordance with the safety requirements set forth in the Corps of Engineers Manual, EM 385-1-1, entitled “Safety and Health Requirements Manual”, 30 November, 2014; a copy is available at:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf The Contractor shall be responsible for complying with the current edition and all changes posted on the web. The COR will notify the Contractor of any noncompliance with these provisions. The Contractor shall, after receipt of such notice, immediately take corrective action. Such notice, when delivered to the Contractor, shall be deemed sufficient for the purpose. If the Contractor fails or refuses to comply promptly, the COR may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to any such stop orders shall be made the subject of claim for extension of time or for excess cost or damages by the Contractor. Compliance with the provisions of this clause by subcontractors will be the responsibility of the Contractor.

1.3.2 PROTECTIVE GEAR. Personnel performing arc gouging, plasma cutting, grinding, welding or painting shall be equipped with respiratory protection appropriate for the activity being performed. Personnel performing grinding operations shall wear appropriate hearing and eye protection. The Contractor shall continuously monitor the air in the vicinity of painting and provide barriers for welding operations which insure personnel will not be subjected to flash burns. Personnel in any work areas of the power plant shall at all times wear approved hard hats and safety shoes. Hearing protection may be required in some areas of the power plant.

1.3.3 OPERATION OF GATE OPERATING MECHANISMS. Only Government personnel will be allowed to operate the turbine gate operating mechanism and only after the Contractor has insured the COR, in writing, that no personnel are in the areas of the turbine where they could be injured, and that all of the Contractor’s personnel are aware that they must stay out of the danger areas. After operation of the wicket gate mechanisms, it will be positively locked out of service by Government and Contractor personnel. Following this, the Contractor will be given a written notice signed by the COR indicating that the Contractor’s personnel may begin to resume their work. The Contractor’s personnel shall not begin work, or resume work, without receipt of this written notice.

1.3.4 RUNNER MAINTENANCE PLATFORM ASSEMBLY. If used, the assembly of the runner maintenance platform requires some “high work” over water in the turbine draft tube. The contractor shall furnish safety rope, safety harnesses and safety vests for his/her personnel for this effort. This shall be addressed in the Accident Prevention Plan discussed in Paragraph 1.5.

1.3.5 CONFINED SPACE TRAINING. The turbine spiral case and draft tube areas have been declared confined spaces. As such, no person may enter these areas unless they have received approved confined space training. The Contractor shall submit for information, certificates indicating that all personnel entering these areas have received confined space training. The turbine pit has not been declared a confined space; however, considering the limited access and potential for injury by the gate operating mechanism, it is also required that personnel working in these areas receive confined space training.

1.3.6 SITE SAFETY AND HEALTH OFFICER (SSHO). Site Safety and Health Officer (SSHO) shall be provided at the work site at all times to perform safety and occupational health management, surveillance, inspections and safety enforcement for the Contractor. The Contractor Quality Control (QC) person can be the SSHO on this project. The SSHO shall meet the following requirements and provide proper certification to the Mark Twain Lake Project Office within twenty days after receipt of award:

(1) Work on similar projects

(2) 10 hours OSHA safety class or equivalent within the last three (3) years

(3) Competent person training as needed

1.3.7 PUBLICATION REFERENCE.

EM 285-1-1 USACE Safety and Health Requirements Manual

1.4 ACCIDENT PREVENTION PLAN (APP)

1.4.1 The Contractor shall use a qualified person to prepare the written site-specific APP. Prepare the APP in accordance with the format and requirements of USACE EM 385-1-1 and as supplemented herein. Cover all paragraph and subparagraph elements in USACE EM 385-1-1, Appendix A, "Minimum Basic Outline for Accident Prevention Plan". Specific requirements for some of the APP elements are described below. The APP shall be job specific and shall address any unusual or unique aspects of the project or activity for which it is written. The APP shall interface with the Contractor's overall safety and health program. Any portions of the Contractor's overall safety and health program referenced in the APP shall be included in the applicable APP elements and made site specific. The Government considers the Prime Contractor to be the "controlling authority" for all work site safety and health of the subcontractors. Contractors are responsible for informing their subcontracts of the safety provisions under the terms of the contract and the penalties for noncompliance, coordinating the work to prevent one craft from interfering with or creating hazardous working conditions for other crafts, and inspecting subcontractor operations to ensure that accident prevention responsibilities are being carried out. The APP shall be signed by the person and firm (senior person) preparing the APP, the Contractor, the on-site superintendent, the designated site safety and health officer and any designated Certified Safety Professional (CSP) and /or Certified Industrial Hygienist (CIH).

1.4.2 Submit the APP to the Contracting Officer's Representative (COR) for acceptance following award and prior to the post award conference for acceptance. Work cannot proceed without an accepted APP.

1.4.3 Once accepted by the COR, the APP and attachments will be enforced as part of the contract.

Disregarding the provisions of this contract or the accepted APP will be caused for stopping of work, at the discretion of the COR, until the matter has been rectified.

1.4.4 Once work begins, changes to the accepted APP shall be made with the knowledge and concurrence of the COR, project superintendent, SSHO and quality control manager. Should any hazard become evident, stop work in the area, secure the area, and develop a plan to remove the hazard. Notify the COR within 24 hours of discovery. Eliminate/remove the hazard. In the interim, all necessary action shall be taken to restore and maintain safe working conditions in order to safeguard onsite personnel, visitors, the public and the environment.

1.4.5 Copies of the accepted plan will be maintained at the Mark Twain Lake Project Office. The APP shall be continuously reviewed and amended, as necessary, throughout the life of the contract. Unusual or high hazard activities not identified in the original APP shall be incorporated in the plan as they are discovered.

1.5 ACTIVITY HAZARD ANALYSIS (AHA)

1.5.1 The Activity Hazard Analysis (AHA) format shall be in accordance with USACE EM 385-1-1.

Submit the AHA to the COR for review following award and prior to the post award conference. Format subsequent AHAs as amendments to the APP. The analysis should be used during daily inspections to ensure the implementation and effectiveness of the activities safety and health controls.

1.5.2 The AHA list will be reviewed periodically and updated as necessary when procedures, scheduling or hazards change.

1.5.3 The activity hazard analysis shall be developed for activities being performed. The AHAs will be developed by the contractor, supplier or subcontractor and provided to the prime contractor for submittal to the

COR.

1.5.4 Emergency Medical Treatment. Contractor will arrange for their own emergency medical treatment.

Government has no responsibility to provide emergency medical treatment.

1.6 REPORTS

1.6.1 ACCIDENT REPORTS. For recordable injuries and illnesses, and property damage accidents resulting in at least $2,000 in damages, the Prime Contractor shall conduct an accident investigation to establish the root cause(s) of the accident, complete USACE Accident Report Form 3394 and provide the report to the COR within two (2) calendar days of the accident. The COR will provide copies of any required special forms.

1.6.2 ACCIDENT NOTIFICATION. Notify the COR as soon as practicable, but not later than four (4) hours, after any accident meeting the definition of Recordable Injuries or Illnesses or High Visibility Accidents, or property damage equal to or greater than $2,000. Information shall include contractor name; contract title; type of contract; name of activity, installation or location where accident occurred; date and time of accident; names of personnel injured; extent of property damage, if any; extent of injury, if known, and brief description of accident:

to include type of equipment used, Personnel Protective Equipment (PPE) used, etc. Preserve the conditions and evidence on the accident site until the Government investigation team arrives on-site and Government investigation is conducted.

1.6.3 SECURITY REQUIREMENTS.

1.6.3.1 ACCESS AND GENERAL PROTECTION/SECURITY POLICY AND PROCEDURES. All

Contractors and sub-contractor employees shall comply with installation and facility access guidelines and rules as stated herein. Contractor workforce must comply with all personal identity verification requirements as directed by Department of Defense, Department of the Army, St. Louis District and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in Contractor security matters or processes.

In support of St. Louis District evaluation of personnel authorized for access to federal facilities, the Contractor shall submit background checks, on all employees, that have been conducted by either a bonded third party agency or state police department within the last 6 months prior to the Notice to Proceed date. Background check results will be provided to the St. Louis District Security Office for access 15 calendar days after accessing the project site. The background check will cover, at a minimum, the last five years covering all States the employee has lived in, criminal history and arrest report, and a national sex offender registry check. Uncleared employee must be escorted while on site. This is defined as being in the line of sight of an identified prime contractor employee who has a background check on file with the St. Louis District (as noted on the ACL).

Disqualifying factors include, but are not limited to:

(1) Criminal conduct, in particular violent crime and sex offenders;

(2) Habitual use of intoxicating beverages to excess as evidenced by DUI or public intoxication records; or

(3) Any illegal activity or other disqualification which makes the individual unfit for service (e.g.

drug trafficking or procurement fraud).

IDENTIFICATION BADGES: The Contractor shall be responsible for furnishing a photo identification badge/card to each employee prior to the employee's work on-site, and for requiring each employee engaged on the work to display identification. At a minimum, the badge shall have the following items shown, the employee’s picture, employee’s name, and company name. Any person lacking proper identification credentials or deemed a security threat may be denied access to the project. Such action in no way relieves the Contractor from performance of the contract. The St. Louis District retains the right to deny any Contractor and sub-contractor employee from working on one of its contracts based on final background investigation results. All information received as a result of a background check will be handled according to Privacy Act regulation.

ACCESS CONTROL LIST: The Contractor will provide the Contracting Officer an Access Control List (ACL) which lists all employees to be on site during the duration of contract. Employees not listed on the approved ACL but are on site will be required to leave. As employees are added or deleted from the submitted and approved ACL, this information must be reported immediately to the Contracting Officer. Added employees will not be permitted on-site until requirements of this paragraph are completed, submitted, and approved. In the event that an unexpected change in personnel is required, due to sudden absence of a critical employee or unforeseen change in work site condition, the Contractor shall immediately contact the Contracting Officer to obtain written approval for new/additional personnel to be brought on site prior to background check acceptance. Contractor shall submit Personnel Change Request Letter to the Contracting Officer and will receive written authorization from the Contracting Officer prior to bringing new personnel on site, and will ensure a criminal background check mentioned above is sent to the St. Louis District Security Office no later than 15 days from written notice of approval. Contracting Officer and/or the District Security Office reserves the right to terminate access of the employee upon completion of the Government’s review of the background check and the Contractor shall be notified immediately of any such Government decision.

Contractor and subcontractor personnel not expected to be on the worksite for more than 15 days may be allowed on site with the following conditions:

(1) Employee will be on site a total of 15 days or less, for the duration of the project.

(2) Employee is added to the ACL as a short term employee.

(3) Employee is escorted while on site. This is defined as being in the line of sight of an identified prime contractor employee who has a background check on file with the St. Louis District (as noted on the ACL).

(4) Each prime contractor employee can sponsor only five short term employees at a time.

FOREIGN NATIONAL EMPLOYEES: Due to a difference in background check procedures for long term foreign national employees, all such employees must provide a photocopy of their passport to the St. Louis District Security Office NLT 30 days prior to arrival on site. Additional background check requirements may be required before being allowed access. Short term foreign national employees (e.g. specialists with a two week period of performance) may work on site with the following conditions:

(1) Foreign national employee will be on site a total of 15 days or less, for the duration of the project.

(2) Foreign national employee will comply with E-verify requirements (see E-verify paragraph).

(3) Approved and identified prime contractor employee shall escort the foreign national employee at ALL times while on site.

(4) Each prime contractor employee can sponsor only one short term foreign national at a time.

1.6.3.2 SUSPICIOUS ACTIVITY REPORTING TRAINING. The contractor and all associated sub-contractors shall receive a brief/training (provided by the COR) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

1.6.3.3 CLASSIFIED AND/OR SENSITIVE MATERIALS AND/OR SENSITIVE OR RESTRICTED

AREAS. All contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

1.6.3.4 PRE-SCREEN EMPLOYEES USING E-VERIFY PROGRAM. The Contractor must pre-screen employees using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the employee has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible employee must be provided to the COR no later than 3 business days after the initial contract award.

1.6.4 SUBMITTALS. Within 10 business days of “notice to proceed” the Contractor shall provide to the Contracting Officer submittals required by this specification. Submittals may be requested in addition to those specified when deemed necessary to adequately describe the work covered in the respective sections. Submittals shall include items such as: Contractor’s, manufacturer’s or fabricator’s drawings; descriptive literature including (but not limited to) catalog cuts, diagrams, operating charts or curves; test reports; samples; parts lists;

certificates; warranties; and other such required submittals. Submittals requiring Government approval shall be scheduled and made prior to the acquisition of the material or equipment covered thereby.

1.6.4.1 Government approval is required for submittals with a "G" designation; submittals not having "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted:

SD-01 Preconstruction Submittals Contractor's work plan; G

SD-03 Product Data H-Ring Assembly; G Packing Gland; G

1.6.5 VEHICLE USE. The Contractor shall not drive off the paved access roads without the prior approval of the COR. The repair of any vegetative damage, rutting, or other impairment, to its original condition shall be the responsibility of the Contractor. The Contractor’s vehicles shall be identified with the company name prominently displayed on the outside of both front doors of each vehicle in such a manner as to provide a readily visible means of identification.

1.6.6 FACILITIES.

1.6.6.1 The contractor shall provide and service sanitation facilities, to be utilized by the contractor and his/her personnel. The sanitation facilities shall have the rated capacity for the number of employees that will utilize them. All facilities shall be located outside the power house. The location of all facilities will be subject to COR approval.

1.6.6.2 The following facilities will be available for the convenience of the Contractor and his/her personnel; however, if in the opinion of the COR, the facilities are being abused or excess effort is needed to clean up after the Contractor and his/her personnel, some or all of these facilities will no longer be made available.

(1) DRINKING WATER/LUNCH AREA. Drinking water will be available at the drinking fountains on floor El.538.5, and 555.5. Picnic tables will be supplied as a dining area on floor El. 555.5 for the Contractor and his/her personnel.

(2) PARKING AREA/UNLOADING. Parking and unloading for the Contractor and his/her personnel will be in a location where directed by the COR.

(3) STORAGE AREA. Area(s) for storage of the Contractor’s equipment and materials will be provided in the power plant where directed by the COR. The Government assumes no responsibility for Contractor’s equipment/materials left on the site.

1.6.7 GOVERNMENT DUTIES. Government personnel will perform the following:

(1) Dewater the turbine.

(2) Open the access hatches to the turbine’s spiral case and draft tube.

(3) Operate the turbine’s wicket gate mechanisms. The Contractor shall notify the COR in writing at least one (1) normal working day before this service is needed. This service will, however, be subject to the safety requirements of Paragraph 1.4.3 “Operation of Gate Operating Mechanisms.”

1.6.8 SITE CLEANUP/ENVIRONMENTAL. The Contractor shall maintain work and storage areas in a clean and tidy manner. Any dirt, waste or litter shall be removed from the Contractors’ work and storage areas and shall be properly disposed of off-site. NOTE: Any waste, including, but not limited to paints, oils, cleaning fluids, and welding and grinding dusts, shall be properly disposed of off-site. All local and federal laws and regulations shall be followed in disposing of these wastes. Welding and grinding dusts and materials shall not be allowed to fall or drain into the water in the turbine draft tube.

1.6.9 ENVIRONMENTAL LITIGATION.

1.6.9.1 If the performance of all or any part of the work is ordered by a court of competent jurisdiction to be suspended, delayed, or interrupted as a result of environmental litigation, as defined below, the Contracting Officer, at the request of the Contractor, shall determine whether the order is due in any part to the acts or omissions of the Contractor or a Subcontractor at any tier not required by the terms of this contract. If it is determined that the order is not due in any part to acts or omissions of the Contractor or a Subcontractor at any tier other than as required by the terms of this contract, such suspension, delay, or interruption shall be considered as if ordered by the Contracting Officer in the administration of this contract under the terms of the Contract Clause entitled "Suspension of Work".

1.6.9.2 The term "environmental litigation", as used herein, means a lawsuit alleging that the work will have an adverse effect on the environment or that the Government has not duly considered, either substantively or procedurally, the effect of the work on the environment.

1.6.10 PROTECTION OF MATERIAL AND WORK. The Contractor shall at all times protect and preserve all materials, supplies, and equipment of every description (including property which may be Government-furnished or owned) and all work performed. All reasonable requests of the Contracting Officer to enclose or specially protect such property shall be complied with. If, as determined by the Contracting Officer, material, equipment, supplies, and work performed are not adequately protected by the Contractor, such property may be protected by the Government and the cost thereof may be charged to the Contractor or deducted from any payments due to the Contractor.

1.6.11 DEMOBILIZATION. Upon completion of the contract work, the Contractor shall disassemble the runner maintenance platform, if used, and return it to storage. The Contractor shall also remove any of his/her tools and equipment and perform a final site cleanup to insure the work and storage areas are restored to the same condition “as found” at the commencement of the contract. The contract will not be considered complete until this effort is accomplished.

1.6.12 KEYS. If Government keys are issued to the Contractor, work will not be considered completed and accepted until the keys are returned to the government’s key control officer.

1.7 CAUTION. All bidders are encouraged to inspect the work area prior to bidding. WARNING: IN NO

EVENT WILL A FAILURE TO INSPECT THE SITE CONSTITUTE GROUNDS FOR PRICE

ADJUSTMENTS AFTER BID OPENING.

1.8 DELIVERY AND STORAGE. Items specified in this section shall be scheduled for shipment to arrive on the job site no more than seven (7) days prior to its scheduled installation date. Upon delivery at the work site, the Contractor shall unload, store, and protect all items in accordance with the manufacturer’s written recommendations indoors in the power plant as coordinated with the project staff. All deliveries shall be directed to the below address. Deliveries should be scheduled M-F 0700-1500hrs. No deliveries will be accepted on weekends or federal holidays. A 48 hour notification is required for all deliveries. The Government will not be liable for any additional delivery fees due to not following the listed delivery times and requirements.

Shipping Address:

U.S. Army Corps of Engineers Clarence Cannon Dam & Mark Twain Lake 20642 Hwy J Monroe City, MO 63456

1.9 BIDDING SCHEDULE. This solicitation contains multiple bid line items. Contractors are required to quote on all items listed, in addition to inserting the total quote price in the appropriate space provided. Failure to do so will be considered cause to disqualify the quote.

2. BASE WORK TO BE PERFORMED BY CONTRACTOR

2.1 MOBILIZATION AND DEMOBILIZATION.

2.1.1 Mobilization and demobilization for the disassembly, installation of parts and equipment, and reassembly shall be bid under line item 0001. The Contractor shall provide tools, labor, material, equipment and any needed temporary scaffolding to allow access to the runner access door. The Government furnished turbine platform will be made available for the Contractor's use below the runner. All work shall be performed according to EM 385-1-1.

2.2 DISASSEMBLY AND REASSEMBLY.

2.2.1 Contractor shall supply all labor, supervision, and equipment necessary for disassembly and reassembly, and shall be bid under line item 0002. This work shall include labor, material, and equipment required to install temporary platforms, remove covers, inspect parts and install repainted packing box, H-ring, gland and shaft sleeve, including leak test of the finished product and if required, corrective work to repair leaks.

2.2.2 INSTALLATION OF PACKING

The Contractor shall submit the proposed Contractor's work plan for this effort, including a detailed description of the tasks and equipment which will be used to accomplish this, for approval.

2.2.3 Removal of Gland, H-ring, and Packing

The Contractor shall remove and properly dispose of, off site, the existing packing. The existing Gland and H-ring shall be turned over to the Government. Note: the existing packing may contain Asbestos and shall be disposed of according to state and federal regulations.

2.2.4 Installing Packing, Packing Gland, and H-ring.

The Contractor shall install the packing, H-ring, and gland. The new Government provided packing material is a 1" square braid made by Chesterton. The Contractor shall install the packing and packing glands with special care so that neither is damaged. See drawing 4585-FR-5 and 4585-HW-5.

2.2.5 Installation of the Shaft Sleeve

The shaft sleeve is a bolt-on style sleeve. The Contractor shall remove the existing sleeve, hand clean area with solvent and scotch-brite, and install Government provided shaft sleeve. The Contractor is responsible for providing new fasteners and liquid metal sealant (Devcon or similar) at the sleeve split, as shown on drawing 5852-FM-1. The new fasteners shall be of the same grade and size of the existing.

2.2.6 Access door resealing

The Contractor shall provide a replacement rubber gasket made from 40 Durometer Neoprene. The gasket shall be dimensionally the same as the existing gasket. Contractor shall provide new fasteners of the same grade and size.

2.3 PAINTING OF PACKING BOX.

2.3.1 The Contractor shall supply all labor, supervision, and equipment necessary for painting the existing packing box, and shall be bid under line item 0003.

2.4 SUPPLY OF PARTS.

2.4.1 The following two (2) items supplied under this contract shall be from the original manufacturer, Allis-Chalmers (now Voith). These parts shall be bid under line item 0004. Components are for the Bearing Assembly – Voith Dwg. No 1123-AQZ-1. Submittal approval of items to be supplied is required before Contractor purchase.

(1) One (1) bronze H-Ring assembly (in quarters) per Voith drawing numbers 4585-FR-5 and 4585- HW-5. Original Master No. 360, Item 051. This assembly includes clamp plates, stop plates, and flat head screws.

(2) One (1) aluminum Packing Gland (in halves) per Voith drawing number 3821-OM-5 (this drawing is not provided with solicitation; reference this number when you contact Voith for quote).

Original Master No. 360, Item No. 001. Hardware (dowel bolts and hex nuts) shall be included.

2.5 ORDER AND COORDINATION OF WORK.

2.5.1 WORK SCHEDULE. The services listed herein shall be performed during the contract period of performance; however, the Contractor will have a 14 calendar day window of time to be on site at the power plant. The period of performance incorporates the long lead times associated with the supply of the required parts.

Issuance of a Award will allow the Contractor to start all work listed within this solicitation. All work shall be completed no later than the end date of the Period of Performance. Work shall be performed Monday through Saturday, between the hours of 0600 to 1630CST. No work shall be allowed on Sundays or federal holidays unless approved in advance in writing by the COR. Any variation to the above defined work schedule shall be given, in writing to the COR for approval.

2.5.2 Once the contract has been awarded, the Contractor shall contact and schedule a meeting within 7 business days with the COR, prior to any work being performed to discuss insurance, license, schedule, and issuance of “notice to proceed”.

3. INSPECTION AND ACCEPTANCE

3.1 INSPECTION. All supplies shall be inspected upon delivery. No inspector is authorized to change any requirements of the contract.

3.2 INSPECTION OF COMPONENTS. The Contractor shall inspect the area around the packing box, the packing box, piping, gland, H-ring, and lower head cover for damage. Any damage shall be reported to the Government COR immediately. The existing packing box shall be repainted with Carboline 890 or approved equal. Paint application shall be according to Carboline application instructions and performed off-site.

3.3 FINAL INSPECTION

3.3.1 Adjustment

After inspection of new packing, the unit will be watered up and the packing gland adjusted to allow for a small amount of leakage around the packing.

3.3.2 Leak Test

The area around the turbine access door shall be inspected for leakage with the unit full watered up. Zero leakage is allowed. Any leaks shall be repaired by the Contractor.

3.4 CONTRACT ADMINISTRATION DATA. Payment may be made by way of Government Visa for the work actually completed if in the Government’s best interest. Invoices shall contain the following information:

Contractor’s name and address; contract number; contract description of supplies or services as specified in Section 4; quantities and extended totals, and upon submission to the Contracting Officer a complete accounting of all man-hours used to accomplish the job.

4. INSURANCE

4.1 REQUIRED INSURANCE. As required by the Contract Clause entitled “Insurance – Work on a

Government Installation”, the Contractor shall furnish to the Contracting Officer, prior to the commencement of work, a certificate or written statement as evidence of the minimum insurance listed below. The Contractor shall procure and maintain such types and amounts of insurance during the entire period of performance under this contract. The Contractor shall assure that the certificate or written statement is in accordance with required wording indicated in paragraph b of the aforementioned Contract Clause.

Workmen’s Compensation – Amounts required by applicable jurisdiction statutes.

Employer’s Liability Insurance - $100,000.00 Comprehensive General Liability Insurance – (No property damage liability insurance is required.)

Bodily Injury - $500,000 per occurrence Comprehensive Automobile Insurance –

Bodily Injury - $200,000.00 each person $500,000.00 each accident

Certificates of Insurance should be submitted to the following address:

U.S. Army Corps of Engineers Clarence Cannon Dam & Mark Twain Lake 20642 Hwy J Monroe City, MO

SITE VISIT INFORMATION

SITE VISIT. A pre-bid site visit is scheduled for Wednesday, 29 May 2019 at 10:00 AM to see the location of the proposed project. Participants will meet at the U.S. Army Corps of Engineers, Clarence Cannon Dam, 43691 Power Plant, Monroe City, Missouri 63456. POC for this site visit is Mr. Travis Arch. Mr. Arch can be reached at (573) 735-4843 for additional information.

Section SF 1449 - CONTINUATION SHEET

WAGE RATE DETERMINATION

WD 15-5097 (Rev.-9) was first posted on www.wdol.gov on 01/01/2019

REGISTER OF WAGE DETERMINATIONS UNDER | U.S. DEPARTMENT OF LABOR

THE SERVICE CONTRACT ACT | EMPLOYMENT STANDARDS ADMINISTRATION

By direction of the Secretary of Labor | WAGE AND HOUR DIVISION

| WASHINGTON D.C. 20210

| Wage Determination No.: 2015-5097

Daniel W. Simms Division of | Revision No.: 9 Director Wage Determinations| Date Of Revision: 12/26/2018 Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Service Contract Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. The EO minimum wage rate will be adjusted annually.

Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

State: Missouri

Area: Missouri Counties of Audrain, Clark, Knox, Lewis, Marion, Monroe, Montgomery, Pike, Ralls, Randolph, Scotland, Shelby

**Fringe Benefits Required Follow the Occupational Listing**

OCCUPATION CODE - TITLE FOOTNOTE RATE

01000 - Administrative Support And Clerical Occupations 01011 - Accounting Clerk I 14.10 01012 - Accounting Clerk II 15.83 01013 - Accounting Clerk III 18.57 01020 - Administrative Assistant 24.14 01035 - Court Reporter 19.05 01041 - Customer Service Representative I 11.12 01042 - Customer Service Representative II 12.50 01043 - Customer Service Representative III 13.64 01051 - Data Entry Operator I 12.22 01052 - Data Entry Operator II 14.40 01060 - Dispatcher, Motor Vehicle 19.05 01070 - Document Preparation Clerk 13.51 01090 - Duplicating Machine Operator 13.51 01111 - General Clerk I 12.33 01112 - General Clerk II 15.00 01113 - General Clerk III 17.07 01120 - Housing Referral Assistant 20.96 01141 - Messenger Courier 11.61 01191 - Order Clerk I 12.99 01192 - Order Clerk II 14.18 01261 - Personnel Assistant (Employment) I 16.33 01262 - Personnel Assistant (Employment) II 19.05 01263 - Personnel Assistant (Employment) III 20.73 01270 - Production Control Clerk 20.73 01290 - Rental Clerk 16.06 01300 - Scheduler, Maintenance 15.96 01311 - Secretary I 15.96 01312 - Secretary II 17.85 01313 - Secretary III 20.96 01320 - Service Order Dispatcher 18.12 01410 - Supply Technician 24.14 01420 - Survey Worker 19.05 01460 - Switchboard Operator/Receptionist 15.10 01531 - Travel Clerk I 11.94

01532 - Travel Clerk II 12.86 01533 - Travel Clerk III 13.72 01611 - Word Processor I 13.51 01612 - Word Processor II 16.06 01613 - Word Processor III 19.05

05000 - Automotive Service Occupations 05005 - Automobile Body Repairer, Fiberglass 23.12 05010 - Automotive Electrician 20.59 05040 - Automotive Glass Installer 19.74 05070 - Automotive Worker 19.74 05110 - Mobile Equipment Servicer 18.01 05130 - Motor Equipment Metal Mechanic 21.46 05160 - Motor Equipment Metal Worker 19.74 05190 - Motor Vehicle Mechanic 20.40 05220 - Motor Vehicle Mechanic Helper 16.72 05250 - Motor Vehicle Upholstery Worker 18.88 05280 - Motor Vehicle Wrecker 19.74 05310 - Painter, Automotive 20.59 05340 - Radiator Repair Specialist 19.74 05370 - Tire Repairer 15.80 05400 - Transmission Repair Specialist 21.46

07000 - Food Preparation And Service Occupations 07010 - Baker 12.77 07041 - Cook I 11.02 07042 - Cook II 12.07 07070 - Dishwasher 8.91 07130 - Food Service Worker 10.05 07210 - Meat Cutter 16.34 07260 - Waiter/Waitress 9.26

09000 - Furniture Maintenance And Repair Occupations 09010 - Electrostatic Spray Painter 20.56 09040 - Furniture Handler 13.35 09080 - Furniture Refinisher 20.56 09090 - Furniture Refinisher Helper 16.55 09110 - Furniture Repairer, Minor 18.84 09130 - Upholsterer 22.61

11000 - General Services And Support Occupations 11030 - Cleaner, Vehicles 11.74 11060 - Elevator Operator 11.74 11090 - Gardener 16.03 11122 - Housekeeping Aide 11.46 11150 - Janitor 11.46 11210 - Laborer, Grounds Maintenance 12.55 11240 - Maid or Houseman 9.08 11260 - Pruner 11.10 11270 - Tractor Operator 15.03 11330 - Trail Maintenance Worker 12.55 11360 - Window Cleaner 13.02

12000 - Health Occupations 12010 - Ambulance Driver 19.90 12011 - Breath Alcohol Technician 17.32 12012 - Certified Occupational Therapist Assistant 26.25 12015 - Certified Physical Therapist Assistant 26.01 12020 - Dental Assistant 17.19 12025 - Dental Hygienist 32.12 12030 - EKG Technician 26.24 12035 - Electroneurodiagnostic Technologist 26.24 12040 - Emergency Medical Technician 19.90 12071 - Licensed Practical Nurse I 15.48 12072 - Licensed Practical Nurse II 17.32 12073 - Licensed Practical Nurse III 19.31 12100 - Medical Assistant 13.28 12130 - Medical Laboratory Technician 19.29 12160 - Medical Record Clerk 14.89 12190 - Medical Record Technician 15.83 12195 - Medical Transcriptionist 17.62 12210 - Nuclear Medicine Technologist 38.06 12221 - Nursing Assistant I 10.54 12222 - Nursing Assistant II 11.86 12223 - Nursing Assistant III 12.94

12224 - Nursing Assistant IV 14.52 12235 - Optical Dispenser 16.07 12236 - Optical Technician 15.99 12250 - Pharmacy Technician 15.52 12280 - Phlebotomist 14.52 12305 - Radiologic Technologist 25.09 12311 - Registered Nurse I 26.36 12312 - Registered Nurse II 29.18 12313 - Registered Nurse II, Specialist 29.18 12314 - Registered Nurse III 35.30 12315 - Registered Nurse III, Anesthetist 35.30 12316 - Registered Nurse IV 42.33 12317 - Scheduler (Drug and Alcohol Testing) 21.46 12320 - Substance Abuse Treatment Counselor 17.29

13000 - Information And Arts Occupations 13011 - Exhibits Specialist I 18.31 13012 - Exhibits Specialist II 22.69 13013 - Exhibits Specialist III 27.76 13041 - Illustrator I 20.80 13042 - Illustrator II 25.56 13043 - Illustrator III 30.15 13047 - Librarian 26.36 13050 - Library Aide/Clerk 12.34 13054 - Library Information Technology Systems 23.81 Administrator 13058 - Library Technician 14.61 13061 - Media Specialist I 17.18 13062 - Media Specialist II 19.21 13063 - Media Specialist III 21.43 13071 - Photographer I 16.71 13072 - Photographer II 18.69 13073 - Photographer III 23.16 13074 - Photographer IV 27.91 13075 - Photographer V 33.77 13090 - Technical Order Library Clerk 15.49 13110 - Video Teleconference Technician 17.77

14000 - Information Technology Occupations 14041 - Computer Operator I 17.04 14042 - Computer Operator II 19.06 14043 - Computer Operator III 21.26 14044 - Computer Operator IV 23.61 14045 - Computer Operator V 26.16 14071 - Computer Programmer I (see 1) 22.01 14072 - Computer Programmer II (see 1) 26.17 14073 - Computer Programmer III (see 1) 14074 - Computer Programmer IV (see 1) 14101 - Computer Systems Analyst I (see 1) 14102 - Computer Systems Analyst II (see 1) 14103 - Computer Systems Analyst III (see 1) 14150 - Peripheral Equipment Operator 18.26 14160 - Personal Computer Support Technician 25.31 14170 - System Support Specialist 23.98

15000 - Instructional Occupations 15010 - Aircrew Training Devices Instructor (Non-Rated) 34.92 15020 - Aircrew Training Devices Instructor (Rated) 42.25 15030 - Air Crew Training Devices Instructor (Pilot) 50.64 15050 - Computer Based Training Specialist / Instructor 34.92 15060 - Educational Technologist 28.74 15070 - Flight Instructor (Pilot) 50.64 15080 - Graphic Artist 21.87 15085 - Maintenance Test Pilot, Fixed, Jet/Prop 40.84 15086 - Maintenance Test Pilot, Rotary Wing 40.84 15088 - Non-Maintenance Test/Co-Pilot 40.84 15090 - Technical Instructor 20.66 15095 - Technical Instructor/Course Developer 25.27 15110 - Test Proctor 16.67 15120 - Tutor 16.67

16000 - Laundry, Dry-Cleaning, Pressing And Related Occupations 16010 - Assembler 9.71 16030 - Counter Attendant 9.71

16040 - Dry Cleaner 12.51 16070 - Finisher, Flatwork, Machine 9.71 16090 - Presser, Hand 9.71 16110 - Presser, Machine, Drycleaning 9.71 16130 - Presser, Machine, Shirts 9.71 16160 - Presser, Machine, Wearing Apparel, Laundry 9.71 16190 - Sewing Machine Operator 13.44 16220 - Tailor 14.37 16250 - Washer, Machine 10.69

19000 - Machine Tool Operation And Repair Occupations 19010 - Machine-Tool Operator (Tool Room) 22.05

19040 - Tool And Die Maker 25.72 21000 - Materials Handling And Packing Occupations 21020 - Forklift Operator 19.14 21030 - Material Coordinator 20.64 21040 - Material Expediter 20.64 21050 - Material Handling Laborer 19.18 21071 - Order Filler 12.91 21080 - Production Line Worker (Food Processing) 19.14 21110 - Shipping Packer 14.89 21130 - Shipping/Receiving Clerk 14.89 21140 - Store Worker I 13.28 21150 - Stock Clerk 18.93 21210 - Tools And Parts Attendant 19.14 21410 - Warehouse Specialist 19.14

23000 - Mechanics And Maintenance And Repair Occupations 23010 - Aerospace Structural Welder 26.30 23019 - Aircraft Logs and Records Technician 21.72 23021 - Aircraft Mechanic I 25.34 23022 - Aircraft Mechanic II 26.30 23023 - Aircraft Mechanic III 27.31 23040 - Aircraft Mechanic Helper 19.24 23050 - Aircraft, Painter 24.07 23060 - Aircraft Servicer 21.72 23070 - Aircraft Survival Flight Equipment Technician 24.07 23080 - Aircraft Worker 22.71 23091 - Aircrew Life Support Equipment (ALSE) Mechanic 22.71 I 23092 - Aircrew Life Support Equipment (ALSE) Mechanic 25.34

II

23110 - Appliance Mechanic 22.59 23120 - Bicycle Repairer 18.08 23125 - Cable Splicer 31.98 23130 - Carpenter, Maintenance 26.52 23140 - Carpet Layer 22.39 23160 - Electrician, Maintenance 30.95 23181 - Electronics Technician Maintenance I 24.99 23182 - Electronics Technician Maintenance II 26.36 23183 - Electronics Technician Maintenance III 27.52 23260 - Fabric Worker 20.13 23290 - Fire Alarm System Mechanic 23.21 23310 - Fire Extinguisher Repairer 18.57 23311 - Fuel Distribution System Mechanic 23.01 23312 - Fuel Distribution System Operator 18.08 23370 - General Maintenance Worker 20.67 23380 - Ground Support Equipment Mechanic 25.34 23381 - Ground Support Equipment Servicer 21.72 23382 - Ground Support Equipment Worker 22.71 23391 - Gunsmith I 18.57 23392 - Gunsmith II 21.52 23393 - Gunsmith III 23.58 23410 - Heating, Ventilation And Air-Conditioning 22.39 Mechanic 23411 - Heating, Ventilation And Air Contidioning 23.24 Mechanic (Research Facility) 23430 - Heavy Equipment Mechanic 23.21 23440 - Heavy Equipment Operator 25.39 23460 - Instrument Mechanic 23.01 23465 - Laboratory/Shelter Mechanic 22.59 23470 - Laborer 17.17

23510 - Locksmith 22.23 23530 - Machinery Maintenance Mechanic 27.80 23550 - Machinist, Maintenance 24.17 23580 - Maintenance Trades Helper 18.37 23591 - Metrology Technician I 23.01 23592 - Metrology Technician II 23.91 23593 - Metrology Technician III 24.82 23640 - Millwright 27.07 23710 - Office Appliance Repairer 22.23 23760 - Painter, Maintenance 23.03 23790 - Pipefitter, Maintenance 30.12 23810 - Plumber, Maintenance 28.85 23820 - Pneudraulic Systems Mechanic 23.58 23850 - Rigger 23.58 23870 - Scale Mechanic 21.52 23890 - Sheet-Metal Worker, Maintenance 26.55 23910 - Small Engine Mechanic 21.36 23931 - Telecommunications Mechanic I 25.58 23932 - Telecommunications Mechanic II 26.58 23950 - Telephone Lineman 25.91 23960 - Welder, Combination, Maintenance 23.21 23965 - Well Driller 23.21 23970 - Woodcraft Worker 23.58 23980 - Woodworker 18.57

24000 - Personal Needs Occupations 24550 - Case Manager 13.20 24570 - Child Care Attendant 9.61 24580 - Child Care Center Clerk 13.39 24610 - Chore Aide 10.44 24620 - Family Readiness And Support Services 13.20 Coordinator 24630 - Homemaker 13.20

25000 - Plant And System Operations Occupations 25010 - Boiler Tender 25.70 25040 - Sewage Plant Operator 23.34 25070 - Stationary Engineer 25.70 25190 - Ventilation Equipment Tender 18.44 25210 - Water Treatment Plant Operator 23.34

27000 - Protective Service Occupations 27004 - Alarm Monitor 17.23 27007 - Baggage Inspector 13.88 27008 - Corrections Officer 18.82 27010 - Court Security Officer 22.13 27030 - Detection Dog Handler 16.66 27040 - Detention Officer 18.82 27070 - Firefighter 25.67 27101 - Guard I 13.88 27102 - Guard II 16.66 27131 - Police Officer I 22.39 27132 - Police Officer II 24.88

28000 - Recreation Occupations 28041 - Carnival Equipment Operator 12.57 28042 - Carnival Equipment Repairer 13.41 28043 - Carnival Worker 8.89 28210 - Gate Attendant/Gate Tender 14.44 28310 - Lifeguard 11.59 28350 - Park Attendant (Aide) 16.15 28510 - Recreation Aide/Health Facility Attendant 11.78 28515 - Recreation Specialist 20.00 28630 - Sports Official 12.86 28690 - Swimming Pool Operator 16.53

29000 - Stevedoring/Longshoremen Occupational Services 29010 - Blocker And Bracer 23.72 29020 - Hatch Tender 23.72 29030 - Line Handler 23.72 29041 - Stevedore I 22.09 29042 - Stevedore II 24.90

30000 - Technical Occupations 30010 - Air Traffic Control Specialist, Center (HFO) (see 2) 38.15 30011 - Air Traffic Control Specialist, Station (HFO) (see 2) 26.30

30012 - Air Traffic Control Specialist, Terminal (HFO) (see 2) 28.97 30021 - Archeological Technician I 19.36 30022 - Archeological Technician II 21.56 30023 - Archeological Technician III 25.04 30030 - Cartographic Technician 27.52 30040 - Civil Engineering Technician 22.72 30051 - Cryogenic Technician I 23.90 30052 - Cryogenic Technician II 26.40 30061 - Drafter/CAD Operator I 19.36 30062 - Drafter/CAD Operator II 21.56 30063 - Drafter/CAD Operator III 24.15 30064 - Drafter/CAD Operator IV 29.71 30081 - Engineering Technician I 17.67 30082 - Engineering Technician II 19.83 30083 - Engineering Technician III 22.18 30084 - Engineering Technician IV 27.48 30085 - Engineering Technician V 33.62 30086 - Engineering Technician VI 40.68 30090 - Environmental Technician 22.06 30095 - Evidence Control Specialist 21.58 30210 - Laboratory Technician 20.55 30221 - Latent Fingerprint Technician I 23.90 30222 - Latent Fingerprint Technician II 26.40 30240 - Mathematical Technician 26.82 30361 - Paralegal/Legal Assistant I 20.04 30362 - Paralegal/Legal Assistant II 24.86 30363 - Paralegal/Legal Assistant III 30.37 30364 - Paralegal/Legal Assistant IV 36.75 30375 - Petroleum Supply Specialist 26.40 30390 - Photo-Optics Technician 26.82 30395 - Radiation Control Technician 26.40 30461 - Technical Writer I 23.51 30462 - Technical Writer II 28.76 30463 - Technical Writer III 34.79 30491 - Unexploded Ordnance (UXO) Technician I 24.24 30492 - Unexploded Ordnance (UXO) Technician II 29.33 30493 - Unexploded Ordnance (UXO) Technician III 35.16 30494 - Unexploded (UXO) Safety Escort 24.24 30495 - Unexploded (UXO) Sweep Personnel 24.24 30501 - Weather Forecaster I 29.71 30502 - Weather Forecaster II 36.14 30620 - Weather Observer, Combined Upper Air Or (see 2) 24.15 Surface Programs 30621 - Weather Observer, Senior (see 2) 26.82

31000 - Transportation/Mobile Equipment Operation Occupations 31010 - Airplane Pilot 29.33 31020 - Bus Aide 12.28 31030 - Bus Driver 16.52 31043 - Driver Courier 15.43 31260 - Parking and Lot Attendant 10.12 31290 - Shuttle Bus Driver 16.94 31310 - Taxi Driver 11.23 31361 - Truckdriver, Light 16.94 31362 - Truckdriver, Medium 17.97 31363 - Truckdriver, Heavy 20.79 31364 - Truckdriver, Tractor-Trailer 20.79

99000 - Miscellaneous Occupations 99020 - Cabin Safety Specialist 14.30 99030 - Cashier 8.96 99050 - Desk Clerk 9.86 99095 - Embalmer 30.54 99130 - Flight Follower 24.24 99251 - Laboratory Animal Caretaker I 10.84 99252 - Laboratory Animal Caretaker II 11.89 99260 - Marketing Analyst 21.67 99310 - Mortician 30.54 99410 - Pest Controller 16.54 99510 - Photofinishing Worker 13.06 99710 - Recycling Laborer 18.45 99711 - Recycling Specialist 22.00

99730 - Refuse Collector 16.24 99810 - Sales Clerk 12.95 99820 - School Crossing Guard 13.18 99830 - Survey Party Chief 20.39 99831 - Surveying Aide 13.53 99832 - Surveying Technician 18.54 99840 - Vending Machine Attendant 17.25 99841 - Vending Machine Repairer 20.15 99842 - Vending Machine Repairer Helper 17.25

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors, applies to all contracts subject to the Service Contract Act for which the contract is awarded (and any solicitation was issued) on or…