W912P823B0064 FINAL Solicitation w-o Specs - Plans 8-9-23.pdf

ED 20-003

IFB NO. W912P823B0064

US Army Corps of Engineers New Orleans District

Flood Control, Amite River and Tributaries, LA Comite River Basin, Comite River Diversion Project

Comite River Diversion Channel Reach 1

East Baton Rouge Parish, Louisiana

Construction Solicitation and Specifications

August 2023

SOLICITATION: W912P823B0064 August 2023

FOR: Flood Control, Amite River and Tributaries, LA, Comite River Basin, Comite River Diversion Project, Comite River Diversion Channel Reach 1, East Baton Rouge Parish, Louisiana

TO OPEN:

I. NOTE THE AFFIRMATIVE ACTION PROGRAM REQUIREMENT OF THE EQUAL OPPORTUNITY

CLAUSE WHICH MAY APPLY TO THE CONTRACT RESULTING FROM THIS SOLICITATION.

II. NOTE THE CERTIFICATION OF NONSEGREGATED FACILITIES IN THIS SOLICITATION. Bidders, offerors, and applicants are cautioned to note the "Certification of Non-segregated Facilities" in the solicitation.

Failure of a bidder or offeror to agree to the certification will render his bid or offer non-responsive to the terms of solicitations involving awards of contracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause.

III. Prospective contractors must register in the System for Award Management (SAM). See FAR Clause 52.204-7 for required information. The website for SAM is https://www.sam.gov. You will be required to provide your company’s Dun and Bradstreet (D&B) D-U-N-S number. If you do not already have a D&B D-U-N-S number, one can be requested at http://fedgov.dnb.com/webform.

BIDDERS MUST PROVIDE FULL, ACCURATE AND COMPLETE INFORMATION AS REQUIRED BY THIS

SOLICITATION AND ITS ATTACHMENTS. THE PENALTY FOR MAKING FALSE STATEMENTS IN BIDS IS

PRESCRIBED IN 18 U.S.C. 1001. (FAR 52.214-4 APR 1984)

DESCRIPTION AND MAGNITUDE OF WORK: The work consists of excavation of a segment of the Comite River Diversion channel, stockpiling of excavated earthen materials, placement of bedding material and channel riprap, demolition, clearing and grubbing, furnishing and installing of precast, prestressed concrete girders and prestressed concrete piles, placing cast-in-place structural concrete, placing CMU walls, utility relocation of a 48-inch sewer force main, excavation and backfill for sewer force main relocation, metal work, installing fencing and handrails, painting and coating, installing pipe casing, installing utility vaults, construction of access road, drainage, culverts, flap gates installation, construction unwatering, and traffic control and coordination.

CAUTION TO BIDDERS: In delivery of hand-carried bids, bidders are cautioned to allow sufficient time for delays which may be encountered as a result of frequent trains which are subject to block all access roads to place of bid opening for various lengths of time and for visitor background checks by MVN security when entering the installation at place of bid opening. Such delays DO NOT permit acceptance or consideration of late bids.

NOTE: ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH THE PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS MANUAL", DATED NOVEMBER 2014.

https://www.sam.gov/ http://fedgov.dnb.com/webform

ALL INQUIRIES REGARDING THIS SOLICITATION

SHOULD BE MADE TO THE FOLLOWING:

JASON B. MEYERS

CONTRACT SPECIALIST

AND/OR

CHARLES R. ZAMMIT, JR.

CONTRACT OFFICER

U.S. ARMY CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

E‐MAIL: jason.b.meyers@usace.army.mil

PHONE: (504) 862‐1016

AND/OR

charles.r.zammit@usace.army.mil

PHONE: (504) 862‐1164

COLLECT CALLS NOT ACCEPTED

NOTE: FOR THE MOST PROMPT REPSONSE, PLEASE SEND ALL QUESTIONS VIA

E‐MAIL

mailto:jason.b.meyers@usace.army.mil mailto:charles.r.zammit@usace.army.mil

PROJECT TABLE OF CONTENTS

Division 00 - PROCUREMENT AND CONTRACT REQUIREMENTS

Solicitation, Offer and Award (SF-1442) 00010 Bidding Schedule 00100 Instructions to Bidders 00600 Representations and Certifications 00700 Contract Clauses

Division 01 - GENERAL REQUIREMENTS

01100 General Provisions 01 32 01.00 12 Project Schedule 01 33 00 Submittal Procedures 01 33 29 Sustainability Requirements and Reporting 01 42 00 Sources for Reference Publications 01 45 00.15 10 Resident Management System Contractor Mode (RMS CM) 01 45 04.00 10 Contractor Quality Control 01 50 00 Traffic Control and Coordination 01 57 20.00 12 Environmental Protection 01 57 23.00 12 Storm Water Pollution Prevention Plan 01 57 23.01 12 Truck Wash-Down Racks 01 78 02.00 10 Closeout Submittals

Division 02 - EXISTING CONDITIONS

02 41 00 Demolition

Division 03 - CONCRETE

03 11 14.00 12 Formwork for Concrete 03 21 00.00 12 Reinforcing Steel 03 31 00.00 12 Cast-In-Place Structural Concrete 03 42 13.00 10 Plant-Precast Concrete 03 45 33 Precast Prestressed Structural Concrete

Division 04 - MASONRY

04 20 00 Concrete Masonry Unit Walls

Division 05 - METALS

05 50 03.00 12 Metalwork Fabrication and Miscellaneous Provisions 05 52 01 Aluminum Handrails

Division 06 - WOODS, PLASTICS, AND COMPOSITES

06 82 14 Fiberglass Reinforced Structural Shapes and Panels

Division 08 - OPENINGS

08 34 02 Bullet-Resistant Components

Division 09 - FINISHES

09 90 00 Paints and Coatings

Division 26 - ELECTRICAL

26 20 00 Conduit

Division 31 - EARTHWORK

31 00 00 Earthwork 31 05 19.04 12 Separator Geotextile 31 11 00.00 12 Clearing and Grubbing 31 23 16.16 10 Structural Excavation and Backfill 31 23 16.16 12 Excavation and Backfill for Sanitary Sewers and Related Structures 31 23 20.00 12 Unwatering 31 37 00.01 12 Grouted Riprap 31 62 13.20 Precast/Prestressed Concrete Piles

Division 32 - EXTERIOR IMPROVEMENTS

32 15 00.01 12 Surfacing 32 31 13.53 High-Security Fences Chain Link and Gates 32 31 26 Wire Fences and Gates 32 92 19.04 12 Turf Establishment and Maintenance

Division 33 - UTILITIES

33 05 23.00 12 Steel Casing and Spacers 33 11 00 Sanitary Sewer Force Main Bypass Piping 33 31 23.00 10 Sanitary Sewer Force Main Piping 33 40 00 Storm Drainage Utilities

Division 35 - WATERWAY AND MARINE CONSTRUCTION

35 20 18 Flap Gate and Appurtenances 35 31 19.04 12 Riprap and Bedding Construction

APPENDIXICES

Appendix 1 Geotechnical Engineering Report Comite Diversion Canal Sewer Force Main Crossing

Appendix 2 Existing Force Main Test Hole Data Sheets Appendix 3 Parish of East Baton Rouge Department of Environmental Services

(DES) Standard Specifications

FLOOD CONTROL, AMITE RIVER AND TRIBUTARIES, LA COMITE RIVER BASIN

COMITE RIVER DIVERSION CHANNEL REACH 1

EAST BATON ROUGE PARISH, LOUSISANA

THIS IS A 100% TOTAL SMALL BUSINESS SET-ASIDE.

The Rough Order of Magnitude (ROM) is between $25.0 M and $100.0 M.

The work consists of excavation of a segment of the Comite River Diversion channel, stockpiling of excavated earthen materials, placement bedding material and channel riprap, demolition, clearing and grubbing, furnishing and installing precast, prestressed concrete girders and prestressed concrete piles, placing cast-in-place structural concrete, placing CMU walls, utility relocation of a 48-inch sewer force main, excavation and backfill for sewer force main relocation, metal work, installing fencing and handrails, painting and coating, installing pipe casing, installing utility vaults, construction of access road, drainage, culverts, flap gates installation, construction unwatering, and traffic control and coordination.

X

JASON B MEYERS 504-862-1016

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

09-Aug-2023

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______ 7 calendar days and complete it within ________ 524 calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ 0 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________ 07 Sep 2023 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIV- CHIEF

7400 LEAKE AVENUE, ROOM 172

NEW ORLEANS LA 70118-3651

W912P8

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

12:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX: TEL: TEL: FAX:

W912P823B0064 83

20B. SIGNATURE

(REV. 4-85) STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE 27. PAYMENT WILL BE MADE BY: 26. ADMINISTERED BY

(Include ZIP Code) 14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14) 16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this 28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror) OFFER

Section 00 01 10 - Table of Contents

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 SPECS 881 13-JUL-2023 Attachment 2 Drawings 64 13-JUL-2023

SECTION 00010 – BIDDING SCHEDULE

Flood Control, Amite River and Tributaries, LA, Comite River Basin, Comite River Diversion Channel Reach 1, East Baton Rouge Parish, Louisiana

Item DESCRIPTION Estimated Quantity Unit Unit Price Estimated Amount

BASE WORK

0001 Mobilization and Demobilization 1 JOB

0002 Safety Fence 1 JOB

0003 Video and Photographic Documentation 1 JOB

0004 Traffic Control 1 JOB

0005 Silt Fences 6,850 LF

0006 Straw Bales 1,425 LF

0007 Truck Wash-Down Rack 1 JOB

0008 Demolition – 48” Sewer Main 1 JOB

0009 Concrete Utility Bridge 1 JOB

0010 Concrete Transition Structures 2 EA

0011 Precast Prestressed Concrete Girders 615 LF

0012 CMU Walls 3,946 SF

0013 ARV Protector 2 EA

0014 Bridge Handrails 452 LF

0015 Stair Handrails 132 LF

0016 Bullet-Resistant Doors 4 PR

0017 Conduit 1 JOB

0018 Channel Excavation 1,261,000 CY

0019 Drainage Ditch Excavation 7,250 CY

0020 Compacted Fill 47,000 CY

0021 Separator Geotextile 184,250 SY

0022 Clearing Areas 1 JOB

0023 Clearing and Grubbing Areas 1 JOB

0024 Construction Unwatering 1 JOB

0025 Grouted Riprap 6,200 SY

0026 Hollow Precast Prestressed Concrete Piles 30"x30” 796 LF

0027 Precast Prestressed Concrete Piles 14"x14” 1,126 LF

0028 Temporary Access Roads/ Staging Areas 1 JOB

0029 Permanent Access Roads/Parking Areas #57 Limestone 84 CY

0030 Permanent Access Roads/ Parking Areas #610 Limestone 290 CY

0031 Access Deterrent Fencing 568 LF

0032 Bypass Vaults Security Fencing/Gates 222 LF

0033 Barnett Road Security Fencing/Gates 1 JOB

0034 Turf Establishment and Maintenance 60 AC

0035 36-inch Force Sewer Main Bypass Piping 1 JOB

0036 48-inch Force Sewer Main Piping 1,410 LF

0037 Sewer Force Main Valves 1 JOB

0038 60" Reinforced Concrete Pipes 462 LF

0039 15" Arch Reinforced Concrete Pipes 128 LF

0040 60" RCP Concrete Headwall 1 EA

0041 60" Aluminum Flap Gate 3 EA

0042 Bedding Material 39,900 TON

0043 Channel Riprap R-90 85,900 TON

TOTAL BASE WORK: $

OPTION WORK (OW)

0044 Silt Fences - OW 1,825 LF

0045 Straw Bales - OW 200 LF

0046 Demolition - OW 1 JOB

0047 Channel Excavation - OW 290,000 CY

0048 Separator Geotextile - OW 43,150 SY

0049 Clearing and Grubbing Areas – OW 1 JOB

0050 Construction Unwatering - OW 1 JOB

0051 Turf Establishment and Maintenance

- OW 15 AC

0052 Bedding Material - OW 8,500 TON

0053 Channel Riprap R-90 - OW 18,250 TON

TOTAL OPTION WORK: $

TOTAL BASE + OPTION WORK: $

**The unit "JOB" as used in this Bidding Schedule is synonymous with the term "Lump Sum" used elsewhere within these plans and specifications.

Award will be made as a whole to one bidder.

NOTE 1: Bidders shall furnish unit prices for each item listed in the Schedule requiring a unit price. If the bidder fails to insert a unit price in the appropriate blank for required item(s), but does furnish an extended total, or an estimated amount for such item(s), the Government shall deem the unit price to be the quotient obtained by dividing the extended amount for that line item by the quantity. IF A BIDDER OMITS BOTH THE UNIT PRICE AND THE EXTENDED TOTAL

OR ESTIMATED AMOUNT FOR ANY ITEM, ITS BID SHALL BE DECLARED NON-

RESPONSIVE AND THEREFORE INELIGIBLE FOR AWARD.

NOTE 2: Any bid may be rejected if the Contracting Officer determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only total price of bid, but the price for individual line items as well. Any bid may be rejected if the prices for any line items or sub line items are materially unbalanced (See FAR 14.404-2, Rejection of Individual Bids).

NOTE 3: THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442. The NTP will be issued immediately after verification of acceptable performance and payment bonds. Within seven (7) days after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Accident Prevention Plan, Contractor Quality Control Plan, and other submittals which may be required, have been submitted and approved and all preliminary meetings called for under the contract, have been conducted.

NOTE 4: OPTION WORK ITEMS: The Government may require the delivery of, in whole or part, the Option Work Items. The Government may exercise the Option Items by written notice to the Contractor. If the Government activates an Option Items, the activation will occur while the Contractor’s plant is within the limits of work. No additional mobilization/ demobilization will be paid to the Contractor for the Optional work.

NOTE 5: EVALUATION OF OPTIONS (FAR 52.217-5 JUL 1990). Except when it is determined in accordance with FAR 17.206(b) not to be in the Government’s best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for this basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

NOTE 6: TIME ADJUSTMENT IN THE EVENT OF THE EXERCISE OF OPTIONAL WORK. In the event that the OPTIONAL WORK items are exercised under the terms of the contract, the time required for completion of the contract shall be 158 calendar days in addition to the original contract duration of 524 calendar days established for the BASE WORK items specified in Section 00700 CONTRACT CLAUSES paragraph entitled "COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK".

NOTE 7: Should any OPTIONAL WORK be awarded under this contract, the duration(s) allowed for the awarded optional work item(s) will not extend the duration allowed for completion of the BASE work.

NOTE 8: RAPID VENDOR PAYMENT: Web based instructions for the submission of invoices;

http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment.aspx http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment.aspx

BID BOND

(See instructions on reverse)

OMB Control Number: 9000-0045

Expiration Date: 8/31/2025

PRINCIPAL (Legal name and business address) TYPE OF ORGANIZATION ("X" one)

STATE OF INCORPORATION

SURETY(IES) (Name and business address)

PERCENT

OF BID

PRICE

PENAL SUM OF BOND

AMOUNT NOT TO EXCEED

MILLION(S) THOUSAND(S) HUNDRED(S) CENTS

BID IDENTIFICATION

BID DATE INVITATION NUMBER

PRINCIPAL

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1. 2.

2.

3.

3.

(Seal) (Seal) (Seal) Corporate Seal

INDIVIDUAL SURETY(IES)

SIGNATURE(S)

NAME(S)

(Typed)

1.

1.

2.

2.

(Seal) (Seal)

CORPORATE SURETY(IES)

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is NOT usable

STANDARD FORM 24 (REV. 8/2016)

Prescribed by GSA - FAR (48 CFR) 53.228(a)

FOR (Construction, Supplies or Services)

OBLIGATION:

We, the Principal and Surety(ies) are firmly bound to the United States of America (hereinafter called the Government) in the above penal sum. For payment of the penal sum, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally. However, where the Sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum "jointly and severally" as well as "severally" only for the purpose of allowing a joint action or actions against any or all of us. For all other purposes, each Surety binds itself, jointly and severally with the Principal, for the payment of the sum shown opposite the name of the Surety. If no limit of liability is indicated, the limit of liability is the full amount of the penal sum.

CONDITIONS:

The Principal has submitted the bid identified above.

THEREFORE:

The above obligation is void if the Principal - (a) upon acceptance by the Government of the bid identified above, within the period specified therein for acceptance (sixty (60) days if no period is specified), executes the further contractual documents and gives the bond(s) required by the terms of the bid as accepted within the time specified (ten (10) days if no period is specified) after receipt of the forms by the principal; or (b) in the event of failure to execute such further contractual documents and give such bonds, pays the Government for any cost of procuring the work which exceeds the amount of the bid.

Each Surety executing this instrument agrees that its obligation is not impaired by any extension(s) of the time for acceptance of the bid that the Principal may grant to the Government.

Notice to the surety(ies) of extension(s) is waived. However, waiver of the notice applies only to extensions aggregating not more than sixty (60) calendar days in addition to the period originally allowed for acceptance of the bid.

WITNESS:

The Principal and Surety(ies) executed this bid bond and affixed their seals on the above date.

DATE BOND EXECUTED (Must not be later than bid opening date)

Paperwork Reduction Act Statement - This information collection meets the requirements of 44 USC § 3507, as amended by section 2 of the Paperwork Reduction Act of 1995. You do not need to answer these questions unless we display a valid Office of Management and Budget (OMB) control number. The OMB control number for this collection is 9000-0045. We estimate that it will take 1 hour to read the instructions, gather the facts, and answer the questions. Send only comments relating to our time estimate, including suggestions for reducing this burden, or any other aspects of this collection of information to: General Services Administration, Regulatory Secretariat Division (M1V1CB), 1800 F Street, NW, Washington, DC 20405.

JOINT VENTURE

OTHER (Specify)

PARTNERSHIPINDIVIDUAL

CORPORATION

INSTRUCTIONS

1. This form is authorized for use when a bid guaranty is required. Any deviation from this form will require the written approval of the Administrator of General Services.

2. Insert the full legal name and business address of the Principal in the space designated "Principal" on the face of the form. An authorized person shall sign the bond. Any person signing in a representative capacity (e.g., an attorney-in-fact) must furnish evidence of authority if that representative is not a member of the firm, partnership, or joint venture, or an officer of the corporation involved.

3. The bond may express penal sum as a percentage of the bid price. In these cases, the bond may state a maximum dollar limitation (e.g., 20% of the bid price but the amount not to exceed dollars).

4. (a) Corporations executing the bond as sureties must appear on the Department of the Treasury's list of approved sureties and must act within the limitations listed therein. The value put into the LIABILITY LIMIT block is the penal sum (i.e., the face value) of the bond, unless a co-surety arrangement is proposed.

(b) When multiple corporate sureties are involved, their names and addresses shall appear in the spaces (Surety A, Surety B, etc.) headed "CORPORATE SURETY(IES)." In the space designated "SURETY(IES)" on the face of the form, insert only the letter identifier corresponding to each of the sureties. Moreover, when co-surety arrangements exist, the parties may allocate their respective limitations of liability under the bond, provided that the sum total of their liability equals 100% of the bond penal sum.

(c) When individual sureties are involved, a completed Affidavit of Individual Surety (Standard Form 28) for each individual surety, shall accompany the bond.

The Government may require the surety to furnish additional substantiating information concerning its financial capability.

5. Corporations executing the bond shall affix their corporate seals. Individuals shall execute the bond opposite the word "Corporate Seal"; and shall affix an adhesive seal if executed in Maine, New Hampshire, or any other jurisdiction requiring adhesive seals.

6. Type the name and title of each person signing this bond in the space provided.

7. In its application to negotiated contracts, the terms "bid" and "bidder" shall include "proposal" and "offeror."

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

Corporate Seal

LIABILITY LIMIT ($)STATE OF INCORPORATION

2.

2.

1.

1.NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

STANDARD FORM 24 (REV. 8/2016) BACK

INSTRUCTIONS TO BIDDERS

BID SUBMISSION INSTRUCTIONS

NOTE: BIDDERS MAY SUBMIT BIDS BY ONLY ONE METHOD: A) ELECTRONIC COMMERCE (EMAIL) OR BY

2) PHYSICAL SUBMISSION. BIDDERS SHALL LIMIT THE BID SUBMITTAL TO ONE OPTION OR THE OTHER, NOT

BOTH.

Electronic Submission of Bids (Email):

The New Orleans District utilizes electronic commerce (Email) for receipt of electronic bids under this IFB solicitation. To submit an electronic commerce (Email) bid please follow these steps:

1. Send an email containing your name, email address and bid/proposal to the following emails associated with the IFB (MUST include all emails):

jason.b.meyers@usace.army.mil charles.r.zammit@usace.army.mil

2. ALL BIDS SUBMITTED BY EMAIL MUST CONTAIN THE SOLICITATION NUMBER IN THE

SUBJECT LINE.

3. Once the agency receives your bid at the above email addresses, you will then receive a confirmation email stating your bid was received. If a bidder does not receive a reply acknowledging receipt electronically from the New Orleans District, it is incumbent upon the bidder to seek confirmation from the issuing Contracting office by phone.

Note: The size limit for incoming emails is 35MB. Any bid over this size may not be accepted by the server and will constitute the bid not being received timely. Please note that embedded links, URLs, and other html language included may interfere with the USACE server security, which may cause emails to be removed prior to being received by the contracting office. Bidders are advised to refrain from including external links, embedded links, URLs, and other html language not germane to the bid. Please note it is a bidder’s responsibility, when transmitting its bid electronically, to ensure the receipt of its bid to the proper designee at the proper time. See FAR 14.304(b)(1)(i) regarding untimely electronic bids. Please note, MVN’s computer system firewall may cause a delay in receipt of emails, so be sure to allow ample time for possible delay. If your email would exceed 35MB you can use one of the following methods as a work-around:

• Use .zip files as attachments. Combine multiple files into a .zip file to compress file size prior to adding as an email attachment.

• Send multiple emails. Label each email with same subject line and indicate number of emails. For example: Smith Construction W912P823B0064 (1 of 2) Smith Construction W912P823B0064 (2 of 2).

Physical Submission of Bids:

Bidders may submit their bids by hand carrying or express mail to the New Orleans District Contracting Office in Room

172. Bidders are advised to allow adequate time to ensure timely submission of its bid. Traffic onto the New Orleans District campus may be delayed by trains blocking the entrance or security either at the gate and/or inside of the building.

Express delivery may be utilized but it is incumbent upon the bidder to ensure bid delivery time and date is before the receipt of bid cutoff time. See FAR 14.304(b)(1)(ii) and (c).

In accordance with current Security procedures at the District, any bidder hand carrying bids must notify the contract specialist and contracting officer no later than the day before the bid opening via email that they intend to submit their bid in person. Security will be notified of the expected time of the visit. For this bid opening, please notify:

jason.b.meyers@usace.army.mil charles.r.zammit@usace.army.mil

Bid Opening:

The Bid Opening is currently scheduled for Thursday, 7 September, 2023, at 1:00 PM CT. The Contracting Officer and Contract Specialist will begin downloading bids at 12:00 PM CT, which is the bid submission receipt cutoff time. All bids received after 12:00 PM CT on Thursday, 7 September 2023, will be considered late.

Audio Teleconference Bid Opening Information:

The audio teleconference number for the bid opening at 1:00 PM CT is:

1-844-800-2712

Attendee Code:1992251879 https://usace1.webex.com/meet/christopher.nuccio

Following the conclusion of the bid opening, in accordance with FAR 14.403(b), abstracts of offers for unclassified acquisitions shall be available for public inspection via SAM.GOV.

REPRESENTATIONS & CERTIFICATIONS

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2023)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $45,000,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(C) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran— Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

W912P823B0064

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Mobilization & Demobilization

FFP

FOB: Destination

PSC CD: Y1PZ

NET AMT

0002 1 Job Safety Fence

FFP

0003 1 Job Video & Photographic Documentation

FFP

0004 1 Job Traffic Control

FFP

0005 6,850 Linear

Foot

Silt Fences

FFP

0006 1,425 Linear

Straw Bales

0007 1 Job Truck Wash-Down Rack

FFP

0008 1 Job Demolition – 48” Sewer Main

FFP

0009 1 Job Concrete Utility Bridge

FFP

0010 2 Each Concrete Transition Structures

FFP

0011 615 Linear

Precast Prestressed Concrete Girders

0012 3,946 Square

CMU Walls

0013 2 Each ARV Protector

FFP

0014 452 Linear

Bridge Handrails

0015 132 Linear

Stair Handrails

0016 4 Pair Bullet-Resistant Doors

FFP

0017 1 Job Conduit

FFP

0018 1,261,000 Cubic

Yard

Channel Excavation

0019 7,250 Cubic

Drainage Ditch Excavation

0020 47,000 Cubic

Compacted Fill

0021 184,250 Square

Separator Geotextile

0022 1 Job Clearing Areas

FFP

0023 1 Job Clearing & Grubbing Areas

FFP

0024 1 Job Construction Unwatering

FFP

0025 6,200 Square

Grouted Riprap

0026 796 Linear

Hollow Precast Prestressed Concrete

Piles 30"x30”

0027 1,126 Linear

Precast Prestressed Concrete

Piles 14"x14”

0028 1 Job Temporary Access Roads/ Staging Areas

FFP

0029 84 Cubic

Permanent Access Roads/Parking Areas

#57 Limestone

0030 290 Cubic

Permanent Access Roads/ Parking Areas

#610 Limestone

0031 568 Linear

Access Deterrent Fencing

0032 222 Linear

Bypass Vaults Security Fencing/Gates

0033 1 Job Barnett Road Security Fencing/Gates

FFP

0034 60 Acre Turf Establishment and Maintenance

FFP

0035 1 Job 36-inch Force Sewer Main Bypass Piping

FFP

0036 1,410 Linear

48-inch Force Sewer Main Piping

0037 1 Job Sewer Force Main Valves

FFP

0038 462 Linear

60" Reinforced Concrete Pipes

0039 128 Linear

15" Arch Reinforced Concrete Pipes

0040 1 Each 60" RCP Concrete Headwall

FFP

0041 3 Each 60" Aluminum Flap Gate

FFP

0042 39,900 Actual

Tons

Bedding Material

0043 85,900 Actual

Channel Riprap R-90

0044 1,825 Linear

OPTION Silt Fences - OW

0045 200 Linear

OPTION Straw Bales - OW

0046 1 Job OPTION Demolition - OW

FFP

0047 290,000 Cubic

OPTION Channel Excavation - OW

0048 43,150 Square

OPTION Separator Geotextile - OW

0049 1 Job OPTION Clearing and Grubbing Areas – OW

FFP

0050 1 Job OPTION Construction Unwatering – OW

FFP

0051 15 Acre OPTION Turf Establishment and Maintenance - OW

FFP

0052 8,500 Actual

OPTION Bedding Material - OW

0053 18,250 Actual

OPTION Channel Riprap R-90 - OW

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0004 N/A N/A N/A N/A

0005 N/A N/A N/A N/A

0006 N/A N/A N/A N/A

0007 N/A N/A N/A N/A

0008 N/A N/A N/A N/A

0009 N/A N/A N/A N/A

0010 N/A N/A N/A N/A

0011 N/A N/A N/A N/A

0012 N/A N/A N/A N/A

0013 N/A N/A N/A N/A

0014 N/A N/A N/A N/A

0015 N/A N/A N/A N/A

0016 N/A N/A N/A N/A

0017 N/A N/A N/A N/A

0018 N/A N/A N/A N/A

0019 N/A N/A N/A N/A

0020 N/A N/A N/A N/A

0021 N/A N/A N/A N/A

0022 N/A N/A N/A N/A

0023 N/A N/A N/A N/A

0024 N/A N/A N/A N/A

0025 N/A N/A N/A N/A

0026 N/A N/A N/A N/A

0027 N/A N/A N/A N/A

0028 N/A N/A N/A N/A

0029 N/A N/A N/A N/A

0030 N/A N/A N/A N/A

0031 N/A N/A N/A N/A

0032 N/A N/A N/A N/A

0033 N/A N/A N/A N/A

0034 N/A N/A N/A N/A

0035 N/A N/A N/A N/A

0036 N/A N/A N/A N/A

0037 N/A N/A N/A N/A

0038 N/A N/A N/A N/A

0039 N/A N/A N/A N/A

0040 N/A N/A N/A N/A

0041 N/A N/A N/A N/A

0042 N/A N/A N/A N/A

0043 N/A N/A N/A N/A

0044 N/A N/A N/A N/A

0045 N/A N/A N/A N/A

0046 N/A N/A N/A N/A

0047 N/A N/A N/A N/A

0048 N/A N/A N/A N/A

0049 N/A N/A N/A N/A

0050 N/A N/A N/A N/A

0051 N/A N/A N/A N/A

0052 N/A N/A N/A N/A

0053 N/A N/A N/A N/A

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government 0005 N/A N/A N/A Government 0006 N/A N/A N/A Government 0007 N/A N/A N/A Government 0008 N/A N/A N/A Government 0009 N/A N/A N/A Government 0010 N/A N/A N/A Government 0011 N/A N/A N/A Government 0012 N/A N/A N/A Government 0013 N/A N/A N/A Government 0014 N/A N/A N/A Government 0015 N/A N/A N/A Government 0016 N/A N/A N/A Government 0017 N/A N/A N/A Government 0018 N/A N/A N/A Government 0019 N/A N/A N/A Government 0020 N/A N/A N/A Government 0021 N/A N/A N/A Government 0022 N/A N/A N/A Government 0023 N/A N/A N/A Government 0024 N/A N/A N/A Government 0025 N/A N/A N/A Government 0026 N/A N/A N/A Government 0027 N/A N/A N/A Government 0028 N/A N/A N/A Government 0029 N/A N/A N/A Government 0030 N/A N/A N/A Government 0031 N/A N/A N/A Government 0032 N/A N/A N/A Government 0033 N/A N/A N/A Government 0034 N/A N/A N/A Government 0035 N/A N/A N/A Government 0036 N/A N/A N/A Government 0037 N/A N/A N/A Government 0038 N/A N/A N/A Government 0039 N/A N/A N/A Government 0040 N/A N/A N/A Government 0041 N/A N/A N/A Government 0042 N/A N/A N/A Government 0043 N/A N/A N/A Government 0044 N/A N/A N/A Government

0045 N/A N/A N/A Government 0046 N/A N/A N/A Government 0047 N/A N/A N/A Government 0048 N/A N/A N/A Government 0049 N/A N/A N/A Government 0050 N/A N/A N/A Government 0051 N/A N/A N/A Government 0052 N/A N/A N/A Government 0053 N/A N/A N/A Government

CLAUSES INCORPORATED BY REFERENCE

52.203-2 Certificate Of Independent Price Determination APR 1985 52.204-7 System for Award Management OCT 2018 52.209-7 Information Regarding Responsibility Matters OCT 2018 52.209-13 Violation of Arms Control Treaties or Agreements --

Certification

NOV 2021

52.211-18 Variation in Estimated Quantity APR 1984 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-10 Contract Award--Sealed Bidding JUL 1990 52.214-12 Preparation Of Bids APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-24 Multiple Technical Proposals APR 1984 52.214-26 Audit and Records--Sealed Bidding JUN 2020 52.217-4 Evaluation Of Options Exercised At The Time Of Contract

Award

JUN 1988

52.217-5 Evaluation Of Options JUL 1990 52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.219-8 Utilization of Small Business Concerns OCT 2022 52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-6 Construction Wage Rate Requirements AUG 2018 52.223-15 Energy Efficiency in Energy-Consuming Products MAY 2020 52.225-12 Notice of Buy American Requirement - Construction

Materials Under Trade Agreements

MAY 2014

52.228-1 Bid Guarantee SEP 1996 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.233-1 Disputes MAY 2014 52.236-2 Differing Site Conditions APR 1984 52.236-12 Cleaning Up APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-28 Preparation of Proposals--Construction OCT 1997 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.243-4 Changes JUN 2007 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-10 Default (Fixed-Price Construction) APR 1984 52.249-14 Excusable Delays APR 1984 252.203-7004 Display of Hotline Posters JAN 2023 252.227-7003 Termination AUG 1984 252.243-7002 Requests for Equitable Adjustment DEC 2022

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 524 calendar days after the date of receipt by the Contractor of the Notice to Proceed.

The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP…