SOLC_18-8-5004_MOD_2.pdf

F8D3CE8106AW01

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is to adjust Bid Opening Date, add slides for site visit, and add Liquated Damages Clause/amounts. PLEASE

NOTE BID OPENING WILL BE 16 AUG 2018, 2:00 P.M.CST AT ADDRESS LISTED.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 30-Jul-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912L718B5004

X 9B. DATED (SEE ITEM 11)

15-Jun-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

30-Jul-2018

CODE

118 CONTRACT OFFICE (FA6421)

118 CONTRACT & ADMINISTRATION 240 KNAPP BLV

NASHVILLE TN 37217-2538

W912L7 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912L718B5004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00100 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

The following have been modified:

INSTRUCTIONS TO OFFERS

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

Description of the Project: Provide all plant, labor, transportation, materials, tools, equipment, appliances and supervision necessary to construct physical fitness track and reroute existing road.

1. Instructions to Bidders:

1.1. You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled) W912L7-18-B-5004 titled Construct Physical Fitness Track, Project Number BKTZ162008, at Berry Field ANG Base, Nashville, TN.

1.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price.

1.3. This solicitation is set-aside 100% for Small Business. The North American Industry Classification

(NAICS) Code is 236220, with a size standard of $36,500,000.00. The magnitude is between $500,000 and $1,000,000.

2. EVALUATION FOR AWARD. Reference DFARS 252.236-7007.

As prescribed in 236.570(b)(5), use the following provision:

ADDITIVE OR DEDUCTIVE ITEMS (DEC 1991)

(a) The low offeror and the items to be awarded shall be determined as follows—

(1) Prior to the opening of bids, the Government will determine the amount of funds available for the project.

(2) The low offeror shall be the Offeror that—

(i) Is otherwise eligible for award; and

(ii) Offers the lowest aggregate amount for the first or base bid item, plus or minus (in the order stated in the list of priorities in the bid schedule) those additive or deductive items that provide the most features within the funds determined available.

(3) The Contracting Officer shall evaluate all bids on the basis of the same additive or deductive items.

(i) If adding another item from the bid schedule list of priorities would make the award exceed the available funds for all offerors, the Contracting Officer will skip that item and go to the next item from the bid schedule of priorities;

and

(ii) Add that next item if an award may be made that includes that item and is within the available funds.

(b) The Contracting Officer will use the list of priorities in the bid schedule only to determine the low offeror.

After determining the low offeror, an award may be made on any combination of items if—

(1) It is in the best interest of the Government;

(2) Funds are available at the time of award; and

(3) The low offeror's price for the combination to be awarded is less than the price offered by any other responsive, responsible offeror.

(c) Example. The amount available is $100,000. Offeror A's base bid and four additives (in the order stated in the list of priorities in the bid Schedule) are $85,000, $10,000, $8,000, $6,000, and $4,000. Offeror B's base bid and four additives are $80,000, $16,000, $9,000, $7,000, and $4,000. Offeror A is the low offeror. The aggregate amount of offeror A's bid for purposes of award would be $99,000, which includes a base bid plus the first and fourth additives. The second and third additives were skipped because each of them would cause the aggregate bid to exceed $100,000.

(End of provision)

3. RESERVED

4. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

4.1. A pre-bid conference will be conducted on 19 JULY 2018 at 9:00 A.M. Central Standard Time for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at 118th Civil Engineering, Building 810, 240 Knapp Blvd located on Berry Field ANG Base, Nashville, TN 37217. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

4.2. Due to security conditions, all offerors must register to attend this conference and site visit. Email the following information for all attendees to SMSgt Bryan White at the following addresses:

bryan.k.white10.mil@mail.mil

Firm Name and Telephone Number Visitor’s Name and Drivers License and State of Issue

4.3. This information must be provided in advance no later than 3 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating.

The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

4.4. Visitors must arrive at the Installations Main Gate fourty-five (45) minutes prior to scheduled site visit in order to process. You will be required to present the following information upon arrival: (1) Vehicle Registration,

(2) Valid Drivers License, (3) Proof of Insurance for Vehicle, (4) Safety Inspection and Car Rental agreement if applicable. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

4.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

4.1. A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.fbo.gov. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

5. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

5.1. Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W912L7-18-B-5004 Email: bryan.k.white10.mil@mail.mil

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

5.2. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

5.3. All questions and requests for information (RFI) must be received NOT LATER THAN the fifth working day prior to bid opening. OFFERORS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS

EARLY IN THIS PROCESS.

5.4. Any changes to the drawings, specifications, etc. will be issued in the form of an amendment.

However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on FBO at http://www.fbo.gov

5.5. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

5.6. For security reasons, all technical and engineering data related to this solicitation will be distributed using the Federal Business Opportunities (FedBizOpps.gov or fbo.gov) system. Plans and specifications are locked on FBO and require Contractors to request explicit access from the Contracting Officer OR export controlled access through DLA. See complete instructions on FBO. FedBizOpps is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with FedBizOpps before accessing the system.

5.6.1. Amendments, if/when issued will be posted to https://www.fbo.gov/ for electronic downloading.

This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible due to various reasons.

6. BID REPOSITORY AND BID OPENING:

6.1. A bid repository is provided for hand carried bids and is located at 118 Wing Contracting, Room 256, Building 801, Berry Field ANG Base, Nashville, TN 37217. Hand carried bids must be deposited in the repository prior to the time established for opening of bids. Bidders are cautioned that they will be required to sign-in and obtain a visitor’s pass to enter the facility and should allow time to accomplish this. See instructions for obtain access to the base in the Site Visit instruction. Follow the same instruction for obtaining entry to hand carry bid.

Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304. BIDS MAY BE EMAILED TO bryan.k.white10.mil@mail.mil on or before July 19, 2018 to allow bid to to be read at public opening. Please note orginal bonds have to be recieved prior to bid opening or will be considered none responsive.

6.2. The bid opening will occur at the time and date specified in Block 13 of the SF1442 16 AUG, 2018 at 2:00 P.M. Central Standard Time at Berry Field ANG Base, Buliding 801, room 258 Nashville, TN 37217. All interested offerors and their major subcontractors are encouraged to attend the bid opening.

7. WAGE DETERMINATION:

7.1. Construction Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are. General Decision Number TN 180084 Building, dated 01/05/2018 Mod 0.

Applicable wage rates can be found at http://www.wdol.gov/wdol/scafiles/davisbacon/TN.html

8. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS: This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

9. CLAUSES:

9.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

10. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids including the bid bond.

11. OFFERORS QUALIFICATIONS:

To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

SECTION 00700 - CONTRACT CLAUSES

The following have been added by full text:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $363.84 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)