Amendment-0001-W912HY20B0006.pdf

W45VAK93369110 007140

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Gulf Intracoastal Waterw ay, Texas, Channel to Victoria Middle and Low er Reach in Calhoun and Victoria Counties, Texas, Maintenance Pipeline Dredging w ith a response date of 28 May 2020 @ 2:00 PM is hereby amended as follow s:

Continued on Page 2.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HY20B0006

X 9B. DATED (SEE ITEM 11)

28-Apr-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

13-May-2020

CODE

US ARMY CORPS OF ENGINEERS

2000 FORT POINT ROAD

P.O. BOX 1229

GALVESTON TX 77553-1229

W912HY 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HY20B0006

A0001-2

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

1. The specifications for Solicitation No. W912HY20B0006, Channel to Victoria, Texas, Middle and Lower Reach Maintenance in Calhoun and Victoria Counties, Texas, are hereby amended as follows:

THE BID OPENING IS HEREBY SCHEDULED FOR May 28, 2020 AT 2:00 P.M. LOCAL TIME

VIA TELECONFERENCE.

THE TELECONFERENCE INFORMATION IS AS FOLLOWS:

PHONE NUMBER – (888) 557-8511

ACCESS CODE – 6218268

SECURITY CODE – 1234

a) Specifications.

(1) SECTION 00 73 00.01 45, SPECIAL CONTRACT REQUIREMENTS, STANDARD – The enclosed SECTION 00 73 00.01 45 entitled SPECIAL CONTRACT REQUIREMENTS, STANDARD supersedes that issued with this Solicitation.

b) Drawings.

2. This amendment shall be attached to and become a part of the solicitation.

01 Encls:

1. SECTION 00 73 00.01 45, SPECIAL CONTRACT REQUIREMENTS,

SWG FILE NO.: IWW 1150-1142 SOLICITATION NO.: W912HY20B0006

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

DOCUMENT 00 73 00.01 45

SPECIAL CONTRACT REQUIREMENTS, STANDARD AMENDMENT NO. 001

PART 1 GENERAL

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10) AM#1

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000) (FAR 52.211-12)

1.3 PHYSICAL DATA (APR 1984) (FAR 52.236-4)

1.4 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE(MAR 1995)

1.5 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984) (52.236-1)

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Section Table of Contents --

DOCUMENT 00 73 00.01 45 Page 1

TO ACCOMPANY AMENDMENT NO. 001 OF SOLICITATION W912HY20B0006

THIS PAGE INTENTIONALLY LEFT BLANK

DOCUMENT 00 73 00.01 45 Page 2

DOCUMENT 00 73 00.01 45

SPECIAL CONTRACT REQUIREMENTS, STANDARD

AMENDMENT NO. 001

PART 1 GENERAL

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10) AM#1

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed;

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use not later than 8995 calendar days after the date the Contractor receives the Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000) (FAR 52.211-12)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $3,426.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

1.3 PHYSICAL DATA (APR 1984) (FAR 52.236-4)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by hydrographic survey.

(b) Weather Conditions. Under ordinary conditions, the mean tidal range is about 1.0 foot. The height of tide is largely dependent on the force, direction, and duration of the wind. Strong northerly winds may depress the water surface as much as, and in some instances more than 1.0 foot below Mean Lower Low Water (MLLW), while southerly winds may raise the water surface as much as, and in some instances more than 2.0 feet above MLLW.

(c) Transportation Facilities. The immediate vicinity is served by railroad, highway, and shallow draft channels. The proposed site is accessible by water via the Gulf Intracoastal Waterway. Highway

DOCUMENT 00 73 00.01 45 Page 3 connections are available at the Channel to Victoria Turning Basin and at the Channel to Seadrift Turning Basin.

(d) Other Information. Channel traffic consists of small boats of various sizes, fishing vessels, tugs, tows consisting of a tug and one or more barges. Traffic will interfere with dredging operations to some extent.

The general shape of the existing section of channel to be dredged is shown by cross sections on the Contract drawings.

1.4 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE(MAR 1995)

(a) This special contract requirement does not apply to terminations.

See 52.249-5000, Basis for Settlement of Proposals, and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the con-tractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region VI. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

NOTE: A copy of EP 1110-1-8, "CONSTRUCTION EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE," is available at the following website:

http://www.publications.usace.army.mil/USACEPublications/EngineerPamphlets.aspx.

DOCUMENT 00 73 00.01 45 Page 4

1.5 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984) (52.236-1)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 65 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Document --

DOCUMENT 00 73 00.01 45 Page 5

THIS PAGE INTENTIONALLY LEFT BLANK

DOCUMENT 00 73 00.01 45 Page 6