W912HY19B0022_Amendment_1.pdf

W45VAK90982114 453357

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to change the Pre-Aw ard days to 1 Working Day after Bid Opening.

1. Section 00 21 00 Paragraph 1.5 PPREAWARD INFORMATION DREDGING (FAR 9.105-1) has been changed from five (5) w orking days to one (1) w orking day after Bid Opening.

2. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 12-Aug-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HY19B0022

X 9B. DATED (SEE ITEM 11)

05-Aug-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

12-Aug-2019

CODE

US ARMY CORPS OF ENGINEERS

2000 POINT FORT ROAD

P.O. BOX 1229

GALVESTON TX 77553-1229

W912HY 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HY19B0022

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 21 00 - INSTRUCTIONS

The following have been modified:

LOCAL CLAUSES

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (FAR 36.204)

The estimated price range of the proposed construction is between $1,000,000 and $5,000,000.

1.2 AVAILABILITY OF PLANS AND SPECIFICATIONS ON THE FEDERAL BUSINESS

OPPORTUNITIES WEBSITE ((FBO) (FAR 5.102(a)(1)

After solicitation issuance, contractors may register to be placed on a plan holders list, view and/or download this solicitation and all amendments at the Federal Business Opportunities (FBO) website at http://www.fbo.gov/

Plans and specifications will not be available in paper format or on compact disc. It is the offeror’s responsibility to monitor the FBO website daily (using the above link) for amendments to the solicitation. You must be registered in the System for Award Management (SAM) to receive a government contract award. The website for SAM is https://www.sam.gov/SAM/ .

1.3 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (18 MAR 2013) (UAI 31.105-

100)

In accordance with FAR 31.105(d)(2)(i)(b), equipment ownership and operating cost shall be determined using EP

1110-1-8, Construction Equipment Ownership and Operating Expense Schedule.

1.4 TECHNICAL INFORMATION DREDGING (FAR 14.211)

(a) For technical information regarding the plans and specifications submit questions in PROJNET, see paragraph

1.9 of this section for details.

(b) The Contractor [ ] shall [X] shall not be permitted to use self-propelled hopper dredges to perform the work specified herein.

1.5 PREAWARD INFORMATION DREDGING (FAR 9.105-1)

The apparent low bidder shall submit within ONE (1) WORKING DAY after Bid Opening, the following information:

(a) A statement as to whether he is now or ever has been engaged in performing dredging of [] deep or [ ] shallow draft channels. Mechanical dredging of objects

(b) A list of key personnel available for the current project and their qualifications.

(c) A copy of the bidder's latest financial statement, including the names of banks or other financial institutions with which the bidder conducts business. If the financial statement is more than 60 days old, a certificate should be attached stating that the financial condition is substantially the same, or if not the same, the changes that have taken place. Such statement will be treated as confidential.

(d) A list of present commitments, including the dollar value thereof, name of office under which the work is being performed, the scheduled completion date of each, days ahead or behind schedule and the name of the dredge(s) to be used on the job.

https://www.sam.gov/SAM/

(e) Name and location of the firm's dredging plant to perform the work under this contract, the date this plant will commence work, and the plants capability to perform the work as required by the specifications.

(f) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within (2) working days after Bid Opening.

1.6 DISPOSAL OF EXCAVATED MATERIAL

The following owners in the vicinity of the work to be accomplished under this Invitation for Bids are known to desire fill material:

NAME ADDRESS

If any of the areas owned by the above-listed owners are proposed to be utilized by the Contractor in the performance of the work, the provision for use of alternate areas DREDGING: PLACEMENT OF EXCAVATED

MATERIAL of the specifications will be applicable.

1.7 BIDDER'S QUALIFICATIONS (FAR 9.105-1)

Before a bid is considered for award, the bidder may be requested by the Government to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial resources, and plant available to be used in performing the work.

1.8 NOTICE TO BIDDERS (FAR 52.214-18)

All information required by the terms of the solicitation must be furnished. MISTAKES OR OMISSIONS CAN BE

COSTLY. Important items for you to check are included in but not limited to, those listed below. This checklist is furnished only to assist you in submitting a proper offer. Check as you read.

Have you acknowledged all amendments?

Have you completed Section 00 45 00, Representations & Certifications portion of the solicitation package

Is your offer properly signed

If a bid guarantee is required, is it included with your offer? (A late bid guarantee is treated the same as a late offer).

Is your bid guarantee in the proper amount? Bid guarantee shall be in the amount of 20 percent of the amount of the offer, or $3 million, whichever is less.

If your bid guarantee is in the form of a bid bond, is the bond properly signed by both the bidder and surety and are all required seals affixed?

Is the name in which you submitted the offer the same as your bid bond?

If required have you entered a unit price for each item? (The solicitation will specifically state when this is necessary).

Are decimals in unit prices in the proper places? Are your figures legible?

Are the extensions of your unit prices, and your total offer price correct?

Are all erasures or corrections initialed by the person signing the offer?

I have not restricted my offer by altering the provisions of the solicitation.

REMINDER TO BIDDERS

1. Acknowledge all Amendments on the reverse side of SF 1442, Item 19, Solicitation, Offer, and Award.

2. The Contracting Officer signing this contract is the Primary Contracting Officer. However, any Contracting

Officer assigned to the Galveston District may take formal action. See Section entitled "Specific Project

Requirements".

1.9 SPECIAL INSTRUCTIONS PERTAINING TO ELECTRONIC BID SUBMISSION: (FAR 14.302 and

14.304)

Bids and a copy of the SF24 Bid Bond must be submitted through the Federal Business Opportunities bid package submission via https://www.fbo.gov/ , not later than the response date and time indicated in the solicitation.

Original copies of the Bid Bond shall be submitted to USACE, Galveston District, ATTN: Debora Wells, 2000 Fort

Point Road, Galveston, Texas 77553, on or before the response date and time.

SENDING FILES:

The Federal Business Opportunities bid package submission application can be accessed via https://www.fbo.gov/ under the Solicitation Number W912HY19B0022.

A note will be visible within the "Notice Details" sub-tab. The “Electronic Response” sub-tab indicates that the opportunity allows for electronic responses. Note, a vendor must login to the system to be able to submit electronic responses for opportunities.

There are two types of electronic response submissions possible:

1. Line Item Builder form (CLIN) - This can serve as a template for the items that vendors are sometimes requested to quote.

2. Document upload. Multiple documents with attachments can be loaded here

a. Choose “Document Upload”

b. The Documents section allows the user to submit files as part of their electronic response to the opportunity.

3. The user can enter a description for every file to be uploaded, note this is optional.

a. To select a file for upload, the user clicks on the Browse button. (Note for files over 10 Mb, please use the large upload (JAVA) button). This will allow the user to select a file located on their computer for upload

4. After selecting the file, the user can click and Add New button to select additional files for upload

5. The user can delete any file(s) previously selected for upload by clicking on the Delete button.

6. The user has three options at the bottom of the Response page:

a. Submit saves and electronically submits the response to the government point of contact for that opportunity in the system. Note, the system will send an email to the email address on file for the user confirming the electronic submission

b. Save as Draft saves the response created, but does not submit it to the government point of contact for the opportunity in the system; if selected, the system returns to the Notice Details tab and there is a note at the top indicating that the user has saved a draft response for the opportunity. The user can click on the blue Click here link in the note to review/submit a response.

After clicking the link to review/submit, the system opens the Electronic Response tab and displays the draft response for review. There is a note at the top which will advise the user whether or not the response deadline has passed. If not, the user can click on the blue Click here link to make changes to the draft response and submit if ready.

c. Return does not save the response and takes the user back to the Notice Details tab for the opportunity.

1.10 BIDDER INQUIRY – PROJNET (FAR 14.211)

http://www.fbo.gov/

1. Prospective Offerors should submit questions concerning this solicitation via Bidder Inquiry in ProjNet at www.projnet.org/projnet .

A. To submit and review bid inquiry items, bidders will need to be a current registered user or self register into the system. To self-register, go to the aforementioned web page and click on the BID tab. Select

Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your email address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

***Please Note: Offerors shall only submit one question per inquiry. Inquiries containing multiple questions may be rejected.

B. From this page, you may view all bidder inquiries or add inquiry.

C. Offerors will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team.

D. The Solicitation Number is: W912HY19B0022

The Bidder Inquiry Key is: 5CKZXQ-VFR42F

2. The Bidder Inquiry System will be unavailable for new inquires fifteen (15) calendar days prior to offer submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary.

3. Offerors are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

4. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

1.11 CONSTRUCTION WAGE RATE REQUIREMENTS (FAR 52.222-6)

Paragraph entitled CONSTRUCTION WAGE RATE REQUIREMENTS of (CONTRACT CLAUSES - Section 00

72 00, FAR 52.222-6) is applicable to this solicitation. Wage Rates will be incorporated by amendment, if they are not included in this solicitation.

(End of Summary of Changes) http://www.projnet.org/projnet