W912HV25B0003 RTA Specifications.pdf

Solicitation No. W912HV-25-B-0003

US Army Corps of Engineers Japan District

FY24 REPLACE AMERICAN FORCES

NETWORK (AFN) RADIO TRANSMISSION

TOWER,

CAMP KINSER, OKINAWA, JAPAN

SPECIFICATIONS

READY TO ADVERTISE SUBMITTAL

January 2025

FY24 REPLACE AMERICAN FORCES NETWORK (AFN) RADIO TRANSMISSION 24MC0004

TOWER, CAMP KINSER, OKINAWA, JAPAN

W912HV-25-B-0003 PROJECT TABLE OF CONTENTS Page 1 RTA

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 10 GENERAL CONTRACT REQUIREMENTS

01 20 00 PRICE AND PAYMENT PROCEDURES

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 33 00-A (USACE) – ENG FORM 4025, MAY 2017

01 33 00-B SUBMITTAL REGISTER

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 35 26-A USACE ACCIDENT PREVENTION PLAN CHECKLIST

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 42 15 METRIC MEASUREMENTS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR

MODE (RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 45 35-A STATEMENT OF SPECIAL INSPECTIONS

01 45 35-B SCHEDULE OF SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 50 00-A PROJECT SIGNAGE

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 00-A DD FORM 1354

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 82 00 ASBESTOS REMEDIATION

02 82 00-A HAZARDOUS MATERIAL INSPECTION REPORT

02 83 00 LEAD REMEDIATION (tailored for Japan)

02 84 33 REMOVAL AND DISPOSAL OF POLYCHLORINATED BIPHENYLS

PCBs)

02 84 33-A EMS STANDARD OPERATING PROCEDURE

DIVISION 03 – CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

DIVISION 05 – METALS

05 05 20 POST-INSTALLED CONCRETE AND MASONRY ANCHORS

05 05 23.16 STRUCTURAL WELDING

05 12 00 STRUCTURAL STEEL

05 51 33 METAL LADDERS

05 52 00 METAL RAILINGS

W912HV-25-B-0003 PROJECT TABLE OF CONTENTS Page 2 RTA

DIVISION 09 - FINISHES

09 97 13.25 MAINTENANCE, REPAIR, AND COATING OF TALL ANTENNA

TOWERS

DIVISION 13 – SPECIAL CONSTRUCTION

13 48 73 SEISMIC CONTROL FOR MISCELLANEOUS EQUIPMENT

DIVISION 26 - ELECTRICAL

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 56 00 EXTERIOR LIGHTING

DIVISION 31 – EARTHWORK

31 00 00 EARTHWORK

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 31 13 CHAIN LINK FENCES AND GATES

32 92 23 SODDING

DIVISION 33 - UTILITIES

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

-- End of Project Table of Contents --http://www.wbdg.org/ffc/dod/unified-facilities-guide-specifications-ufgs/ufgs-32-11-16-16 http://www.wbdg.org/ffc/dod/unified-facilities-guide-specifications-ufgs/ufgs-32-11-23 http://www.wbdg.org/ffc/dod/unified-facilities-guide-specifications-ufgs/ufgs-33-71-02

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 10

GENERAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DEFINITIONS

1.2 REFERENCES

1.3 SUBMITTALS

1.4 ACCEPTABLE ALTERNATIVE JAPANESE STANDARDS

1.5 KEY PERSONNEL QUALIFICATIONS

1.5.1 Project Manager

1.5.2 Project Superintendent (Supervisor)

1.5.3 English Speaking Representative (Interpreter)

1.5.4 Contractor Quality Control

1.5.4.1 Contractor Quality Control System Manager (CQCSM)

1.5.4.2 Contractor Quality Control Personnel

1.5.5 Site Safety and Health Officer (SSHO)

1.5.6 Pass Coordinator

1.6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.7 PERMITS AND RESPONSIBILITIES

1.8 SPECIAL CONTRACT REQUIREMENTS

1.8.1 Meetings

1.9 PROGRESS AND COMPLETION PHOTOGRAPHS

1.10 BASE REGULATIONS

1.10.1 Request for Contractor's Employee Passes and Vehicle Passes

1.10.2 No Smoking Policy

1.10.3 Munitions and Explosives of Concern (MEC)

1.11 ORDER OF WORK

1.11.1 Schedule

1.11.2 Working Hours

1.11.3 Noise and Vibration

1.11.4 Work Outside of Regular Hours

1.12 FIRE PREVENTION DURING CONSTRUCTION

1.12.1 General

1.12.2 Supply

1.12.3 Fire Extinguishers

1.12.4 Housekeeping

1.12.5 Handling of Gasoline

1.12.6 Notification of Fire

1.13 CONTRACTOR FURNISHED MATERIAL AND WORKMANSHIP

1.14 CORRESPONDENCE

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 1 RTA

THIS PAGE INTENTIONALLY LEFT BLANK

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 2 RTA

SECTION 01 11 00.00 10

GENERAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DEFINITIONS

The term "Government" refers to "United States Government" whenever the term "Government" appears in this Contract, unless otherwise indicated within the Contract.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 10 (2022) Standard for Portable Fire Extinguishers

NFPA 241 (2022) Standard for Safeguarding Construction, Alteration, and Demolition Operations

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2024) Safety and Health Requirements Manual

U.S. NAVAL FACILITIES ENGINEERING COMMAND (NAVFAC)

NAVFAC P-307 (2016) Weight Handling Program Management

CFAS Instruction 5532.2D Base Access Control

U.S. ARMY GARRISON JAPAN (USAG-J)

Regulation 190-13 (2013) Installation Access and Control Procedures

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control or Designer of Record approval . Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Initial Site Conditions Photos Key Personnel Qualifications; G

SD-07 Certificates

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 3 RTA

Monthly Progress Photos

1.4 ACCEPTABLE ALTERNATIVE JAPANESE STANDARDS

Where indicated in the technical specifications REFERENCES paragraphs, acceptable Japanese standards are listed which are considered acceptable alternatives to the US Standards within the Contract Specifications.

Contract specifications authorize the use of specified acceptable alternative Japanese standards. A limited set of modified UFGS incorporating previously identified and accepted Japanese standards and methods (also known as Japan Edited Specifications, or JES) can be found at https://www.poj.usace.army.mil/Business-With-Us/References/. Other portions of the specifications also authorize the use of specified acceptable alternative Japanese standards. The use of products not meeting the applicable US standards of the Contract or alternative Japanese standards specifically authorized by the Contract is prohibited unless authorized by the Contracting Officer. Japanese standards not identified in these specifications as being acceptable alternatives to US standards may be submitted to the Contracting Officer for consideration as acceptable alternatives after award using the variation request process set forth in Section 01 33 00 SUBMITTAL PROCEDURES. Prior to the use of such proposed additional alternative Japanese standards, written approval by the Contracting Officer is required. Incorporation of methods, materials, and equipment that will promote cost-effective and timely maintenance, and that are otherwise authorized by the contract, is highly encouraged.

1.5 KEY PERSONNEL QUALIFICATIONS

The Contractor's Project Key personnel shall not be assigned duties to any other Contracts (excluding the project manager) without approval from the Contracting Officer. The Project Superintendent, CQC System Manager, and Site Safety Health Officer shall all be separate persons, and shall not have other duties assigned. Within five (5) working days after receipt of the Notice to Proceed, the Contractor shall submit in writing to the Contracting Officer an organizational chart, the qualifications and background history of the proposed Key Personnel for approval. The Contracting Officer shall have the explicit right to determine acceptability (or rejection) of the proposed individuals. In addition, the Contractor shall be responsible to replace said individuals upon notification by the Government should performance become inadequate during the Contract period. Key Personnel shall attend the Preconstruction conference.

1.5.1 Project Manager

The Project Manager shall have a minimum of five (5) years experience as a Project Manager on construction projects containing structural engineering with Professional Engineer or Japanese Equivalent Registration components similar in size and scope to this Contract. The Project Manager shall maintain oversight of Contract proposals prepared by the Contractor staff and be authorized to negotiate Contract terms and sign Contract documents on behalf of the Contractor. The project manager does not need to be present on the site daily, but shall attend weekly progress meetings and be available on site within 24 hours upon request. Project Manager shall not have other duties assigned.

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 4 RTA

1.5.2 Project Superintendent (Supervisor)

The Project Superintendent shall be on the work site when on-site work is being performed and shall be available to the Contracting Officer or his representatives upon request. The Project Superintendent shall have overall responsibility for all operations at the job site and be authorized to make decisions, negotiate Contract terms and sign Contract documents on behalf of the Contractor. The Project Superintendent shall have a minimum of five (5) years experience as a superintendent on construction projects containing Crane operations with registration, highrise construction, civil engineering with Professional Engineer or Japanese Equivalent Registration components similar in size and scope to this Contract, and have at least one the following qualifications:

a. U.S. Registered Structural Engineer or U.S. Registered Architect or 1 Kyu Kenchikushi (1st Class Qualified Architect).

b. U.S. Registered Civil Engineer or 1 Kyu Doboku Sekou Kanrigishi (1st Class Civil Engineering Works Management Engineer).

c. U.S. Bachelors Degree in Construction Management or 1 Kyu Kenchiku Sekou Kanrigishi (1st Class Building Construction Management Engineer)

1.5.3 English Speaking Representative (Interpreter)

At all times during the Contract period the Contractor shall have an employee capable of fluent bilingual speech in the Japanese and English languages at the job site. The bilingual interpreter shall have the capability to receive and issue concise and technical explanation and instructions between the Government representative(s) and Contractor supervisory personnel concerning all aspects of Contract administration and construction. Within fifteen (15) days after receipt of the Notice to Proceed, the Contractor shall submit in writing to the Contracting Officer the qualifications and background history of the proposed interpreter for approval. The Contracting Officer shall have the explicit right to determine acceptability or rejection of the proposed individual. In addition, the Contractor shall be responsible to replace said individual upon notification by the Government should performance become inadequate during the Contract period. The interpreter shall attend the preconstruction conference.

1.5.4 Contractor Quality Control

1.5.4.1 Contractor Quality Control System Manager (CQCSM)

The CQC System Manager is required to be a graduate of an accredited college with an engineering, architecture, or construction management degree, with a minimum of 3 years construction experience on construction of similar size and scope to this Contract. Refer to Section 01 45 00.00 10 QUALITY CONTROL, Paragraph "CQC System Manager" for additional requirements.

1.5.4.2 Contractor Quality Control Personnel

The following Contractor Quality Control (CQC) Personnel are required:

Structural, Architectural, Concrete, Pavements, Soils and Cranes. All other specialties in section 01 45 00.00 10 not identified in this paragraph does not apply to this project.

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 5 RTA

See Section 01 45 00.00 10 QUALITY CONTROL for qualification requirements for CQC personnel. These individuals or specialized technical companies must be directly employed by the prime Contractor and can not be employed by a supplier or subcontractor on this project. These individuals shall have no other duties other than quality control. A single person can cover more than one area provided that the single person is qualified to perform quality control activities in each designated and that workload allows.

1.5.5 Site Safety and Health Officer (SSHO)

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS.

1.5.6 Pass Coordinator

A person on the contractor's staff who is familiar with the requirements of USAG-J Regulation 190-13 , Individual and Vehicle Access Pass Procedures, and USAG-J vehicle security inspection procedures. The Pass Coordinator must be able to obtain a DBIDS access pass with escort privileges and may be required to escort other contract personnel.

Although a TOEIC score is not required, the Pass Coordinator must be able to understand pass requirements and complete pass application forms in the English language.

1.6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This paragraph specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract clause entitled "DEFAULT (FIXED-PRICE CONSTRUCTION)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the Contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The listing below defines the monthly anticipated adverse weather days for the Contract period and is based upon 20th Weather Squadron (MAC), U.S. Air Force; Iwakuni U.S. Marine Corps Air Station, Weather Service; Sasebo Naval Pacific Meteorology and Oceanography Detachment;

JASDF (Japan Air Self Defense Force), or similar data for the geographic location of the project. (More specific information may be obtained as specified under Special Contract Requirements Clause entitled "Physical Data.")

MONTHLY ANTICIPATED ADVERSE WEATHER DELAYS

WORK DAYS BASED ON (5) DAY WORK WEEK

Misawa-area Kanto Plain Iwakuni Okinawa Sasebo Osaka

JAN 8 1 2 5 7 4

FEB 9 3 4 7 6 4

MAR 6 6 7 8 7 5

APR 3 6 6 6 7 4

MAY 4 4 6 6 6 4

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 6 RTA

JUN 5 9 8 6 12 5

JUL 6 6 6 6 9 4

AUG 6 6 5 9 9 3

SEP 6 7 6 7 9 4

OCT 4 5 4 4 8 4

NOV 6 4 4 4 5 3

DEC 7 1 3 5 5 3

The above schedule of anticipated adverse weather days shall constitute the base line for monthly (or portion thereof) weather time evaluations.

c. Upon acknowledgment of the Notice-to-Proceed (NTP) and continuing throughout the Contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b), above, the Contracting Officer shall convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the Contract clause entitled "DEFAULT

(FIXED PRICE CONSTRUCTION)".

e. For all work under this Contract, adverse weather is defined as:

(1) Rainfall - Number of occurrences of precipitation greater than or equal to 0.10 inches (2.54mm).

(2) Snowfall - Number of occurrences of precipitation greater than or equal to 1.00 inches (25.4mm). (Not applicable to Okinawa Area)

(3) Cold Temperature - Number of occurrences when daily maximum temperature does not exceed the monthly mean low temperature or 32 degrees Fahrenheit (0 degrees Celsius), whichever is lower. (Not applicable to Okinawa Area)

(4) Concurrence between snowfall and cold temperature is 80 percent, i.e. 80 percent of the time snow falls, the temperature is "cold".

(5) Wind - Number of occurrences when the wind is gusting 30 knots (56 kilometers/hour) or greater.

f. The Contractor's schedule must reflect the above anticipated adverse weather delays on all weather-dependent activities.

1.7 PERMITS AND RESPONSIBILITIES

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any laws, codes, and regulations (including the requirements of material, prefectural, and local Government of Japan, and associated military installation) applicable to the performance of work.

The Contractor shall also be responsible for all damages to persons or

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 7 RTA property that occur as a result of the Contractor's fault or negligence.

These damages shall be repaired or replaced by the Contractor at no cost to the Government. The Contractor shall take proper safety and health precautions to protect all work and workers.

Submit a schedule of planned road closures to the Contracting Officer with the initial project schedule. Notification of specific road closures shall be in writing to the Contracting Officer not less than thirty (30) calendar days in advance of the intended closure. The road closure request shall include the planned traffic control measures as well as the general information about the closure. All road closures shall be coordinated with base officials and are subject to base requirements. No road closure shall be permitted until the Contractor receives written approval from the Contracting Officer. Full road closures is generally not permitted (at least one way traffic shall always be provided).

1.8 SPECIAL CONTRACT REQUIREMENTS

1.8.1 Meetings

a. Preconstruction Conference. A Preconstruction Conference per FAR

42.503 shall be held. The chairperson shall be the Contracting Officer or his/her designee. The chairperson shall be responsible for providing minutes of the meeting.

b. Weekly Progress Meetings. A weekly progress meeting shall be conducted, with the day, time, and location to be determined at the Preconstruction Conference. The Contractor's Project Manager, Superintendent, Interpreter, and Quality Control Manager shall attend. Representatives from the Government may include, but are not limited to, Director of Public Works/Facilities Engineering personnel, Project's Resident Office personnel, and Project Manager. The Contractor shall be prepared to discuss work completed during the previous week, work currently in progress, and work forecasted for the following week, as well as the status of any construction issues and open action items. Provide the meeting agenda for review 24 hours prior to the meeting, take notes during the meeting, and provide electronic copies of the meeting minutes in English within 24 hours of the progress meeting for review.

c. Red Zone Meeting. A Red Zone meeting shall be conducted for Contracts with a value in excess of 55,000,000 JPY or those deemed sufficiently complex by the Contracting Officer to warrant one. The purpose of the Red Zone meeting is to discuss closeout requirements for the contract and to establish a timeline to get those items completed (see Section 01 78 00 CLOSEOUT SUBMITTALS for typical closeout requirements). The meeting is a good time for the Contractor to gain approval on format for items such as Operations and Maintenance manuals, the equipment-in-place list, the warranty plan, and any other items. The Initial Red Zone is typically scheduled when project reached 75 percent completion milestone. Provide the meeting agenda for review 24 hours prior to the meeting, take notes during the meeting, and provide electronic copies of the meeting minutes in English within 24 hours of the Red Zone meeting.

d. Safety and Quality Control Meetings. Safety and quality control meetings shall be held as needed and determined by the Contractor.

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and Section 01 45 00.00 10 USACE QUALITY CONTROL for specific requirements.

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 8 RTA

e. Construction Waste Management Meetings. See Section 01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT for requirements.

1.9 PROGRESS AND COMPLETION PHOTOGRAPHS

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600 by 1200 by 24 bit true color 300 DPI minimum resolution in JPEG file format showing the sequence and progress of work. Take a minimum of 10 digital photographs each week throughout the entire project. Submit the Initial Site Conditions Photos and Monthly Progress Photos. Indicate photographs demonstrating environmental procedures. Provide photographs for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Include a date designator in file names. Cross reference submittals in the appropriate daily report. Photographs provided are for unrestricted use by the Government.

1.10 BASE REGULATIONS

The Contractor and Subcontractor(s) shall become familiar with and obey all base regulations, including fire, traffic, safety, and security regulations. All Contractors shall keep within the limits of the work (and avenues of ingress and egress), and shall not enter any restricted areas unless required to do so and are cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification.

1.10.1 Request for Contractor's Employee Passes and Vehicle Passes

No employee or representative of the Contractor shall be admitted to the work site without a Contracting Officer's furnished authorized admittance. Refer to CFAS Instruction 5532.2D Base Access Control. Prior to the start of on-site work, submit applications for base passes to the Contracting Officer for key employees (project manager, site supervisor, interpreter, etc.) for long term DBIDS passes. The Contractor (through the employment of a Pass Coordinator) , with assistance from the Resident Office, is responsible for securing sufficient passes for other workers, including subcontractor's employees and vehicles, required to access the base for the project duration. Additional personnel data shall also be furnished.

Provide all information required for background checks to meet base access requirements to be accomplished by Base Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. The Government reserves the right to make changes to the Contractor security requirements or processes due to a change in the Force Protection Condition (FPCON).

In addition to security requirements, cranes, delivery "unic" trucks, forklifts, backhoes, and other equipment capable of vertical lift operations must comply with NAVFAC rules for access to the base. Refer to NAVFAC P-307 . The operator must submit a P-1 Pass request and submit the equipment, its records, and operator records for inspection by Public Works prior to the initial entry onto base property. Vehicle passes for vertical lift equipment must be renewed monthly with Public Works as long as the equipment remains on base property.

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 9 RTA

Upon completion of this Contract, return all employee and vehicle passes to the base, and obtain a certification of receipt. Final payment shall be withheld until all passes have been returned.

1.10.2 No Smoking Policy

Smoking is prohibited on installations except in designated smoking areas. This applies to existing buildings, buildings under construction, and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer shall identify designated smoking areas.

1.10.3 Munitions and Explosives of Concern (MEC)

Munitions and Explosives of Concern (MEC): Unexploded Ordnance (UXO), Material Presenting a Potential Explosive Hazard (MPPEH), Chemical Agents (CA), or Discarded Military Munitions (DMM) on jobsites shall be treated as extremely dangerous and must be reported immediately. Follow the 3Rs:

RECOGNIZE, RETREAT, and REPORT. In the event MEC are discovered or uncovered, immediately stop work in that area and immediately inform the Contracting Officer's Representative. Contractor shall provide dispatch and Contracting Officer's Representative with specific location of the item. Contractor personnel shall stop work in the immediate vicinity of the discovery and maintain a minimum distance of 300 meters from the item.

Contractor shall maintain flexibility in redirecting personnel and work effort in the event that items possessing an explosive hazard are discovered and construction personnel are excluded from areas during the destruction/removal process.

1.11 ORDER OF WORK

1.11.1 Schedule

Schedule all work to cause the least amount of interference with activity operations. Permission to interrupt any activity or roads shall be requested in writing a minimum of 30 calendar days prior to the desired date of interruption. Interruptions of activities, roads, and utility services shall be allowed only when they will not cause interference with the operations of the activity. The Contractor shall remove and dispose off Government property all Contractor generated debris at the end of each shift, or more frequently if required, to keep the space usable. Upon award of this Contract, the Contractor shall begin and complete all required work; ready for use and including cleanup, within the time period specified on this Contract. All work scheduled in occupied areas shall be accomplished in such a manner as to cause the least possible inconvenience to the occupants.

1.11.2 Working Hours

Normal Working Hours and Days are Monday through Saturday, 0700 hours through 1700 hours. Work during holidays, inspections, and tests on Saturdays are subject to Government approval.

1.11.3 Noise and Vibration

Noise greater than 70 decibels and vibration producing work in occupied buildings shall be conducted outside core school/business hours (0700 - 1430) unless written permission is given by the Contracting Officer.

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 10 RTA

1.11.4 Work Outside of Regular Hours

If the Contractor desires to carry on work outside the regular hours, on Sundays, or holidays, a written application shall be submitted to the Contracting Officer or his representative for approval. The Contractor shall allow three working days notice to enable satisfactory arrangements to be made by the Government for inspecting the work in progress. If work is to be accomplished after daylight hours, the Contractor shall illuminate the area in a manner approved by the Contracting Officer or their representative and in accordance with EM 385-1-1 . Unless directed by a Contracting Officer, work accomplished outside regular working hours shall be at no additional cost to the Government.

1.12 FIRE PREVENTION DURING CONSTRUCTION

1.12.1 General

Comply with all pertinent fire prevention provisions of the US Army Corps of Engineers Manual EM 385-1-1 , NFPA 241 and shall follow the Installation fire regulations. Prior to commencement of welding or other hot work operations, obtain approval from the Installation Fire Chief.

1.12.2 Supply

No more than one day's supply of paint, paint materials, or compounds shall be allowed within the area of the building, and shall be removed from the job site after each working day. No gasoline or similar low flash point flammable liquid shall be allowed within the building area.

After proper coordination with the Facility's Emergency Services (to confirm the maximum allowable quantities and location of storage), storage of additional product may be authorized.

1.12.3 Fire Extinguishers

Provide, as a minimum, the number, size, and type of fire extinguishers in accordance with the latest NFPA 10 . The Contractor shall comply with the Installation Fire Chief's policies if they are more stringent than NFPA 10 .

Fire extinguishers shall remain the property of the Contractor and shall be removed upon completion of the project.

1.12.4 Housekeeping

Accumulations of combustible material shall be removed from the building area on a daily basis.

1.12.5 Handling of Gasoline

Gasoline shall be stored in industry standard approved safety containers.

Adequate ventilation shall be provided to safely dispose of flammable vapors where flammable liquids are utilized. Gasoline powered equipment shall be refueled a minimum 6 meters away from the building area.

1.12.6 Notification of Fire

Be familiar with methods for notifying the Installation Fire Department.

The Installation's fire poster shall be posted in conspicuous locations and at telephones in construction shacks.

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 11 RTA

1.13 CONTRACTOR FURNISHED MATERIAL AND WORKMANSHIP

The Contractor shall furnish all materials necessary for performance of the work of this contract unless otherwise specified. Materials procured shall be new and shall meet any specifications and standards listed in these specifications. If no specification for a material needed to perform this contract are stated, the material shall be new, of acceptable industrial grade and quality, equal to or better than the manufacturer's original equipment for equipment being repaired or replaced, and will be compatible with existing materials and systems. All materials provided under this contract shall be free of asbestos, lead in paint, and PCB.

The Contracting Officer reserves the right to request submittal of any material being provided under this contract. The Contracting Officer shall make the final determination of the acceptability of any material used on this contract.

1.14 CORRESPONDENCE

All correspondence addressed to the Government shall be made through serialized letters furnished with one original and two copies. Serialized letters shall begin with the number S-0001 and shall be continuous without a break in numbering. Serialized letters shall include the contract title and number, date, subject, and shall be signed by an authorized representative of the Contractor.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

W912HV-25-B-0003 SECTION 01 11 00.00 10 Page 12 RTA

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 GENERAL

1.2 Submittals

1.3 LINE ITEMS

1.3.1 CLIN 0001, Remove the Existing AFN Radio Transmission Tower and Install a New Radio Transmission Tower

1.3.1.1 Payment

1.3.1.2 Unit of Measure

1.3.2 CLIN 0002, Demolish Existing Antenna Foundation, Fencing and

Associated Fencing Foundation, Power, and Signal Cabling

1.3.2.1 Payment

1.3.2.2 Unit of Measure

1.3.3 CLIN 0003, Demolish Building 951, including Removal of

Associated Materials and Debris

1.3.3.1 Payment

1.3.3.2 Unit of Measure

1.3.4 CLIN 0004, Construct New Antenna Foundation, Fencing

Foundation, and Provide New Fencing, Power, and Signal Cabling

1.3.4.1 Payment

1.3.4.2 Unit of Measure

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION

3.1 PROGRESS PAYMENT INVOICE

3.2 TRANSPORTATION OF SUPPLIES BY SEA, BILL OF LADING

3.3 CONTRACT COST BREAKDOWN

3.4 CONTRACT ADMINISTRATION

3.4.1 Contracting Officer (KO)

3.4.2 Administrative Contracting Officer (ACO)

3.4.3 Contracting Officer's Representative (COR)

3.5 DESIGNATED BILLING OFFICE

W912HV-25-B-0003 SECTION 01 20 00 Page 1 RTA

THIS PAGE INTENTIONALLY LEFT BLANK

W912HV-25-B-0003 SECTION 01 20 00 Page 2 RTA

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 GENERAL

Payment items for the work of this Contract for which payments shall be made are listed in the CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, topographic surveys, cost of bond premiums, and for performing all work required by drawings and specifications for which separate payment is not otherwise provided. Work paid for under one item shall not be paid for under any other item. No separate payment shall be made for the work, services, or operations required by the Contractor, as specified in DIVISION 01, GENERAL REQUIREMENTS, to complete the project in accordance with these specifications; all costs thereof shall be considered as incidental to the work.

1.2 Submittals

Government approval is required for submittals with a "G" designation;

DESIGN-BID-BUILD:submittals not haveing a "G" designation are for information only. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-07 Certificates

Bill Of Lading; G

1.3 LINE ITEMS

1.3.1 CLIN 0001, Remove the Existing AFN Radio Transmission Tower and Install a New Radio Transmission Tower

1.3.1.1 Payment

Payment shall be made at the Contract job price for CLIN 0001 "Remove the existing AFN Radio transmission tower and install a new radio transmission tower" for work completed. Payment for work completed shall constitute full compensation of CLIN 0001, complete.

1.3.1.2 Unit of Measure

Unit of measure: job.

W912HV-25-B-0003 SECTION 01 20 00 Page 3 RTA

1.3.2 CLIN 0002, Demolish Existing Antenna Foundation, Fencing and Associated Fencing Foundation, Power, and Signal Cabling

1.3.2.1 Payment

Payment shall be made at the Contract job price for CLIN 0002 "Demolish existing antenna foundation, fencing and associated fencing foundation, power, and signal cabling" for work completed. Payment for work completed shall constitute full compensation of CLIN 0002, complete.

1.3.2.2 Unit of Measure

Unit of measure: job.

1.3.3 CLIN 0003, Demolish Building 951, including Removal of Associated Materials and Debris

1.3.3.1 Payment

Payment shall be made at the Contract job price for CLIN 0003 "Demolish Building 951, including removal of associated materials and debris" for work completed. Payment for work completed shall constitute full compensation of CLIN 0003, complete.

1.3.3.2 Unit of Measure

Unit of measure: job.

1.3.4 CLIN 0004, Construct New Antenna Foundation, Fencing Foundation, and Provide New Fencing, Power, and Signal Cabling

1.3.4.1 Payment

Payment shall be made at the Contract job price for CLIN 0004 "Construct new antenna foundation, fencing foundation, and provide new fencing, power, and signal cabling" for work completed. Payment for work completed shall constitute full compensation of CLIN 0004, complete.

1.3.4.2 Unit of Measure

Unit of measure: job.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION

3.1 PROGRESS PAYMENT INVOICE

Requests for payment shall be submitted in accordance with Federal Acquisition Regulations (FAR) Subpart 32.9, entitled "PROMPT PAYMENT", and Paragraphs 52.232-5 and 52.232-27, entitled "Payments Under Fixed-Price Construction Contracts", and "Prompt Payment for Construction Contracts", respectively. In addition each request shall be submitted in the number of copies and to the designated billing office as shown in the Contract.

When submitting payment requests, the Contractor shall complete Blocks 1 through 12 of the "PROGRESS PAYMENT INVOICE" Form as directed by the Contracting Officer (provided in RMS CM). The completed form shall then become the cover document to which all other support data shall be

W912HV-25-B-0003 SECTION 01 20 00 Page 4 RTA attached.

One additional copy of the entire request for payment, to include the "PROGRESS PAYMENT INVOICE" cover document, shall be forwarded to a separate address as designated by the Contracting Officer.

The Contractor shall submit with each pay request, a list of subcontractors that have worked during that pay period. The listing shall be broken down into weeks, identifying each subcontractor that has worked during a particular week, and indicate the total number of employees that have worked on site for each subcontractor for each week. The prime Contractor shall also indicate the total number of employees for its on site staff for each week.

Formal invoices shall be submitted every month between the first and the tenth of the month. Any invoice received after the tenth will be considered as not meeting the contract requirements and rejected. It may be resubmitted on the first of the following month.

3.2 TRANSPORTATION OF SUPPLIES BY SEA, BILL OF LADING

The Contractor shall, within 30 days after each shipment covered by Defense Federal Acquisition Regulation (DFAR) Subpart 252.247-7023, provide the Contracting Officer and the Maritime Administration (MARAD) one copy of the rated on board vessel operating carrier's ocean Bill of Lading. See DFAR 252.247-7023 for information required in the bill of lading. MARAD contact information: usarmy.scott.sddc.mbx.g3-ffw-team@mail.mil and msc.n101.ffw@navy.mil.

The Contractor shall use U.S.-flag vessels when transporting any supplies by sea under this contract. If U.S.-flag vessels are not available, the Contractor may submit a request for use of foreign-flag vessels in writing to the Contracting Officer at least 45 days prior to the sailing date necessary to meet its delivery schedules. Refer to DFAR 252.247-7023 for required documentation when making this request. The Contracting Officer will process requests submitted as expeditiously as possible, but the Contracting Officer's failure to grant approvals to meet the shipper's sailing date will not of itself constitute a compensable delay. Failure to get approval prior to the use of foreign-flag vessels may result in monetary penalty.

3.3 CONTRACT COST BREAKDOWN

The Contractor must furnish within 30 days after the date of Notice to Proceed, and prior to the submission of its first partial payment estimate, a breakdown of its single job pay item or items which will be reviewed by the Contracting Officer as to propriety of distribution of the total cost to the various accounts. Any unbalanced items as between early and late payment items or other discrepancies will be revised by the Contracting Officer to agree with a reasonable cost of the work included in the various items. This contract cost breakdown will then be utilized as the basis for progress payments to the Contractor.

3.4 CONTRACT ADMINISTRATION

3.4.1 Contracting Officer (KO)

This Contract shall be administered by a Contracting Officer (KO) assigned to the U.S. Army Corps of Engineers, Japan Engineer District, APO AP

W912HV-25-B-0003 SECTION 01 20 00 Page 5 RTA

96338-5010.

3.4.2 Administrative Contracting Officer (ACO)

In accordance with the USACE Acquisition Instruction (UAI) 5101.603-3-100, Appointment, Administrative Contracting Officer(s) (ACO's) may be delegated a part of the Contracting Officer's authority to modify this Contract and perform Contract administration functions under Federal Acquisition Regulation (FAR) Section 42.302, subject to the authority and limitations set forth in the appointment and delegation letter.

3.4.3 Contracting Officer's Representative (COR)

The Contracting Officer may designate one or more individuals as his/her authorized representatives in administering this Contract. Refer to the clause in Section 00 70 00 CONDITIONS OF THE CONTRACT entitled CONTRACTING OFFICER'S REPRESENTATIVE (DFARS 252.201-7000) for the definition and limited authority of CORs.

3.5 DESIGNATED BILLING OFFICE

The designated billing office for this Contract is:

Resident Engineer, Kadena Resident Office U.S. Army Corps of Engineers, Japan Engineer District Unit 35132

APO AP 96376-5132

W912HV-25-B-0003 SECTION 01 20 00 Page 6 RTA

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01.00 10

PROJECT SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PROJECT SCHEDULER QUALIFICATIONS

PART 2 PRODUCTS

2.1 SOFTWARE

2.1.1 Government Default Software

2.1.2 Contractor Software

2.1.2.1 Primavera

2.1.2.2 Other Than Primavera

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.2 BASIS FOR PAYMENT AND COST LOADING

3.2.1 Activity Cost Loading

3.2.2 Withholdings / Payment Rejection

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Level of Detail Required

3.3.2 Activity Durations

3.3.3 Procurement Activities

3.3.4 Mandatory Tasks

3.3.5 Government Activities

3.3.6 Standard Activity Coding Dictionary

3.3.6.1 Workers Per Day (WRKP)

3.3.6.2 Responsible Party Coding (RESP)

3.3.6.3 Area of Work Coding (AREA)

3.3.6.4 Modification Number (MODF)

3.3.6.5 Bid Item Coding (BIDI)

3.3.6.6 Phase of Work Coding (PHAS)

3.3.6.7 Category of Work Coding (CATW)

3.3.6.8 Feature of Work Coding (FOW)

3.3.7 Contract Milestones and Constraints

3.3.7.1 Project Start Date Milestone and Constraint

3.3.7.2 End Project Finish Milestone and Constraint

3.3.7.3 Interim Completion Dates and Constraints

3.3.7.3.1 Start Phase

3.3.7.3.2 End Phase

3.3.8 Calendars

3.3.9 Open Ended Logic

3.3.10 Default Progress Data Disallowed

3.3.11 Out-of-Sequence Progress

3.3.12 Added and Deleted Activities

W912HV-25-B-0003 SECTION 01 32 01.00 10 Page 1 RTA

3.3.13 Original Durations

3.3.14 Leads, Lags, and Start to Finish Relationships

3.3.15 Retained Logic

3.3.16 Percent Complete

3.3.17 Remaining Duration

3.3.18 Cost Loading of Closeout Activities

3.3.18.1 As-Built Drawings

3.3.18.2 O & M Manuals

3.3.19 Early Completion Schedule and the Right to Finish Early

3.4 PROJECT SCHEDULE SUBMISSIONS

3.4.1 Preliminary Project Schedule Submission

3.4.2 Initial Project Schedule Submission

3.4.3 Periodic Schedule Updates

3.5 SUBMISSION REQUIREMENTS

3.5.1 Data in Electronic Format

3.5.2 Narrative Report

3.5.3 Schedule Reports

3.5.3.1 Activity Report

3.5.3.2 Logic Report

3.5.3.3 Total Float Report

3.5.3.4 Earnings Report by CLIN

3.5.3.5 Schedule Log

3.5.4 Network Diagram

3.5.4.1 Continuous Flow

3.5.4.2 Project Milestone Dates

3.5.4.3 Critical Path

3.5.4.4 Banding

3.5.4.5 Cash Flow / Schedule Variance Control (SVC) Diagram

3.6 PERIODIC SCHEDULE UPDATE

3.6.1 Periodic Schedule Update Meetings

3.6.2 Update Submission Following Progress Meeting

3.7 WEEKLY PROGRESS MEETINGS

3.8 REQUESTS FOR TIME EXTENSIONS

3.8.1 Justification of Delay

3.8.2 Time Impact Analysis (Prospective Analysis)

3.8.3 Forensic Schedule Analysis (Retrospective Analysis)

3.8.4 Fragmentary Network (Fragnet)

3.8.5 Time Extension

3.8.6 Impact to Early Completion Schedule

3.9 FAILURE TO ACHIEVE PROGRESS

3.9.1 Artificially Improving Progress

3.9.2 Failure to Perform

3.9.3 Recovery Schedule

3.10 OWNERSHIP OF FLOAT

3.11 TRANSFER OF SCHEDULE DATA INTO RMS CM

3.12 PRIMAVERA P6 MANDATORY REQUIREMENTS

W912HV-25-B-0003 SECTION 01 32 01.00 10 Page 2 RTA

SECTION 01 32 01.00 10

PROJECT SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AACE INTERNATIONAL (AACE)

AACE 29R-03 (2011) Forensic Schedule Analysis

AACE 52R-06 (2006) Time Impact Analysis - As Applied in Construction

U.S. ARMY CORPS OF ENGINEERS (USACE)

ER 1-1-11 (1995) Administration -- Progress, Schedules, and Network Analysis Systems

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control or Designer of Record approval .Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Project Scheduler Qualifications; G

Preliminary Project Schedule; G

Initial Project Schedule; G

Periodic Schedule Update; G

1.3 PROJECT SCHEDULER QUALIFICATIONS

Designate an authorized representative to be responsible for the preparation of the schedule and all required updating and production of reports. The authorized representative must have a minimum of 2-years experience scheduling construction projects similar in size and nature to this project with scheduling software that meets the requirements of this specification. Representative must have a comprehensive knowledge of CPM scheduling principles and application.

W912HV-25-B-0003 SECTION 01 32 01.00 10 Page 3 RTA

PART 2 PRODUCTS

2.1 SOFTWARE

The scheduling software utilized to produce and update the schedules required herein must be capable of meeting all requirements of this specification.

2.1.1 Government Default Software

The Government intends to use Primavera P6.

2.1.2 Contractor Software

Scheduling software used by the contractor must be commercially available from the software vendor for purchase with vendor software support agreements available. The software routine used to create the required sdef file must be created and supported by the software manufacturer.

2.1.2.1 Primavera

If Primavera P6 is selected for use, provide the "xer" export file in a version of P6 importable by the Government system.

2.1.2.2 Other Than Primavera

If the contractor chooses software other than Primavera P6, that is compliant with this specification, provide for the Government's use two licenses, two computers, and training for two Government employees in the use of the software. These computers will be stand-alone and not connected to Government network. Computers and licenses will be returned at project completion.

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

Prepare for approval a Project Schedule, as specified herein, pursuant to FAR Clause 52.236-15 Schedules for Construction Contracts. Show in the schedule the proposed sequence to perform the work and dates contemplated for starting and completing all schedule activities. The scheduling of the entire project is required. The scheduling of construction is the responsibility of the Contractor. Contractor management personnel must actively participate in its development. Subcontractors and suppliers working on the project must also contribute in developing and maintaining an accurate Project Schedule. Provide a schedule that is a forward planning as well as a project monitoring tool. Use the Critical Path Method (CPM) of network calculation to generate all Project Schedules.

Prepare each Project Schedule using the Precedence Diagram Method (PDM).

3.2 BASIS FOR PAYMENT AND COST LOADING

The schedule is the basis for determining contract earnings during each update period and therefore the amount of each progress payment. The aggregate value of all activities coded to a contract CLIN must equal the value of the CLIN.

W912HV-25-B-0003 SECTION 01 32 01.00 10 Page 4 RTA

3.2.1 Activity Cost Loading

Activity cost loading must be reasonable and without front-end loading.

Provide additional documentation to demonstrate reasonableness if requested by the Contracting Officer.

3.2.2 Withholdings / Payment Rejection

Failure to meet the requirements of this specification may result in the disapproval of the preliminary, initial or periodic schedule updates and subsequent rejection of payment requests until compliance is met.

In the event that the Contracting Officer directs schedule revisions and those revisions have not been included in subsequent Project Schedule revisions or updates, the Contracting Officer may withhold 10 percent of pay request amount from each payment period until such revisions to the project schedule have been made.

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Level of Detail Required

Develop the Project Schedule to the appropriate level of detail to address major milestones and to allow for satisfactory project planning and execution. Failure to develop the Project Schedule to an appropriate level of detail will result in its disapproval. The Contracting Officer will consider, but is not limited to, the following characteristics and requirements to determine appropriate level of detail:

3.3.2 Activity Durations

Reasonable activity durations are those that allow the progress of ongoing activities to be accurately determined between update periods.

Less than 2 percent of all non-procurement activities may have Original Durations (OD) greater than 20 work days or 30 calendar days.

3.3.3 Procurement Activities

Include activities associated with the critical submittals and their approvals, procurement, fabrication, and delivery of long lead materials, equipment, fabricated assemblies, and supplies. Long lead procurement activities are those with an anticipated procurement sequence of over 90 calendar days.

3.3.4 Mandatory Tasks

Include the following activities/tasks in the initial project schedule (as applicable to the project) and all updates.

a. Submission, review and acceptance of SD-01 Preconstruction Submittals (individual activity for each).

b. Submission of mechanical/electrical/information systems layout drawings.

c. Long procurement activities

d. Submission and approval of O & M manuals.

W912HV-25-B-0003 SECTION 01 32 01.00 10 Page 5 RTA

e. Submission and approval of as-built drawings.

f. Submission and approval of DD1354 data and installed equipment lists.

g. Submission and approval of testing and air balance (TAB).

h. Submission of TAB specialist design review report.

i. Submission and approval of fire protection specialist.

j. Submission and approval of Building Commissioning Plan, test data, and reports: Develop the schedule logic associated with testing and commissioning of mechanical systems to a level of detail consistent with the contract commissioning requirements. All tasks associated with all building testing and commissioning will be completed prior to submission of building commissioning report and subsequent contract completion.

k. Air and water balancing.

l. Building…