W912HP18R1001_81st_RD_FIS_Region_C_SF1449_2018.02.26.pdf

SEE ADDENDUM

(No Collect Calls)

W912HP18R1001 26-Feb-2018

b. TELEPHONE NUMBER

843-329-8060

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 27 Mar 2018

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912HP9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

ANGELA KELLY

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

U.S. ARMY CORPS OF ENGINEERS, CHARLESTON

DISTRICT, CONTRACTING DIVISION

69-A HAGOOD AVENUE

CHARLESTON SC 29403

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

843-329-2322FAX:

TEL: 843-329-8060 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$38,500,000

NAICS:

561210

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF68

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W912HP18R1001

Section B - Supplies or Services and Prices

NOTES TO THE PROPOSAL SCHEDULE

PREVENTATIVE MAINTENANCE

PROPOSAL SCHEDULE NOTES

1. See also Section J, Attachment J-020000-07, Exhibit Line Item Numbers (ELINS). Offerors shall complete and submit Attachment J-020000-07 in MS Excel Format. The total price for each CLIN submitted in the proposal schedule above shall equal the total price displayed on the "CLIN Summary" tab of Attachment J-020000-07. All subCLIN and ELIN prices shall be complete in Attachment J-020000- 07. All subCLINs will be incorporated into the award resulting from this solicitation. Failure to bid on all the items in the proposal schedule and/or Attachment J-020000-07 may cause the bid to be considered nonresponsive and therefore ineligible for contract award.

2. Firm Fixed Price (FFP) Items. Prices for all FFP items shall cover all work, complete and in accordance with the PWS and shall be considered full compensation for all work in connection therewith, to include all labor, supervision, management, tools, material, equipment, facilities, incidental engineering, vehicles, transportation, costs related to quality control, and other items necessary to perform the work, except as otherwise specified to be furnished by the Government. Payments for FFP items at the contract price shall constitute full and final compensation. Full performance for all FFP items shall begin on the dates specified in the PWS. The Contractor will have a minimum of 10 calendar days prior to full performance to implement any necessary phase-in / transition efforts. The Government will not pay for phase-in / transition efforts.

3. Indefinite Delivery / Indefinite Quantity (IDIQ) Items. See also paragraph 2.14 of the PWS Section C 0200000. Prices for IDIQ CLINs refer to a “Not to Exceed” (NTE) capacity amount, and will be derived from the estimated quantity for the unit priced labor after applying the Contractor’s proposed coefficient. The total ordering value of all task orders issued under IDIQ CLINs of the contract resulting from this solicitation shall not exceed the capacities proposed and/or negotiated during the formation of the base contract. NOTE: See the IQ tabs within Attachment J-020000-07 for the estimated quantity for proposal purposes.

4. Minimum Guarantee. The minimum guaranteed amount to be ordered under this contract, in accordance with FAR 52.216-22, is $10,000. Normally, the minimum order will be accomplished via the issuance of a task order for performance of the base year FFP items (see paragraph 2 above), concurrent with the base contract award. In the event such a task order is not issued, a task order will be issued in the amount of the minimum guaranteed amount.

Section C - Descriptions and Specifications

PERFORMANCE WORK STATEMENT

The Performance Work Statement (PWS) is PROVIDED IN THE PWS. These documents can be downloaded at the following website: http://www.FBO.gov OFFERORS ARE RESPONSIBLE FOR ENSURING THEY HAVE THE MOST RECENT VERSION OF THESE DOCUMENTS. Any struck Through items (SAMPLE) in these documents is included to indicate that those items are NOT to be included in the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items.

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY REFERENCE

52.246-15 Certificate of Conformance APR 1984 52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.246-4 INSPECTION OF SERVICES--FIXED-PRICE (AUG 1996)

(a) Definitions. "Services," as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Government may (1) require the Contractor to take necessary action to ensure that future performance conforms to contract requirements and (2) reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may (1) by contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service or (2) terminate the contract for default.

(End of clause)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

Section F - Deliveries or Performance

DELIVERABLES AND SUBMITTALS

The Performance Work Statement (PWS) is PROVIDED IN THE PWS. These documents can be downloaded at the following website: http://www.FBO.gov OFFERORS ARE RESPONSIBLE FOR ENSURING THEY HAVE THE MOST RECENT VERSION OF THESE DOCUMENTS. Any struck Through items (SAMPLE) in these documents is included to indicate that those items are NOT to be included in the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items.

Section G - Contract Administration Data

CONTRACT ADMINISTRATION INFORM

G.1. UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

a. The Contractor shall not accept any instructions issued by any person, employed by the Government or otherwise, other than the Contracting Officer or the Contracting Officer’s Representative (COR) acting within the limits of the COR’s Authority. Only a warranted Contracting Officer (either a Procuring Contracting Officer (PCO), or an Administrative Contracting Officer (ACO)), acting within their delegated limits, has the authority to issue modifications, task orders, or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

b. Administration of the actions under this contract will be performed by the Contracting Office, USACE Charleston District.

CONTRACTOR MANPOWER REPORTING

The Contractor Manpower Reporting Application (CMRA) is a business process that has been approved by the Army as a means for collecting information on contracts that provide services to the Department of the Army. Contractors are required to register and report information via the CMRA website located at https://cmra.army.mil/. Additional information such as links to user guides, frequently asked questions and help desk information is available via the CMRA website.

Section H - Special Contract Requirements

SCA WAGE DETERMINATIONS

The Performance Work Statement (PWS) is PROVIDED IN THE PWS. These documents can be downloaded at the following website: http://www.FBO.gov OFFERORS ARE RESPONSIBLE FOR ENSURING THEY HAVE THE MOST RECENT VERSION OF THESE DOCUMENTS. Any struckthrough items (SAMPLE) in these documents is included to indicate that those items are NOT to be included in the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items. This section is PROVIDED IN A SEPARATE FILE made available for download on the following website: http://www.FBO.gov (posted under RFP# W912HP-18-R-1001).

Notice: Applicable Davis Bacon Wage Determinations (DB WD) will be included in Task Orders as applicable.

UNUSUAL WEATHER TIME EXTENSION

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (Ref. FAR 52.249-10) In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORKDAYS BASED ON 5-DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(c) Upon acknowledgment of the Notice to Proceed and continuing through-out the contract, the Contractor will record on the daily Contractor Quality Control report the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a modification in accordance with the contract clause entitled

DEFAULT (FIXED PRICE CONSTRUCTION).

Notice; This clause will be included in Task Orders as applicable.

Section I - Contract Clauses

52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Alt I Restrictions On Subcontractor Sales To The Government

(Sep 2006) -- Alternate I

OCT 1995

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

OCT 2016

52.208-9 Contractor Use of Mandatory Sources of Supply or Services MAY 2014 52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-18 Variation in Estimated Quantity APR 1984 52.216-8 Fixed Fee JUN 2011 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-17 Nondisplacement of Qualified Workers MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-41 Service Contract Labor Standards MAY 2014 52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.227-5 Waiver of Indemnity APR 1984 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-1 Payments APR 1984 52.232-16 Progress Payments APR 2012 52.232-23 Assignment Of Claims MAY 2014 52.232-25 Prompt Payment JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.237-1 Site Visit APR 1984 52.237-3 Continuity Of Services JAN 1991 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.243-1 Changes--Fixed Price AUG 1987 52.246-1 Contractor Inspection Requirements APR 1984 52.249-4 Termination For Convenience Of The Government (Services)

(Short Form)

APR 1984

52.249-8 Default (Fixed-Price Supply & Service) APR 1984 52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.216-7006 Ordering MAY 2011 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7013 Requirement for Competition Opportunity for American Steel

Producers, Fabricators, and Manufacturers

JUN 2013

252.239-7001 Information Assurance Contractor Training and Certification JAN 2008

252.242-7000 POST AWARD CONFERENCE MAY 2007

252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within (Contracting Officer insert number) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than . * The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

Notice: This clause will be inlcuded in Task Orders as applicable.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Notice: This clause will be included in Task Orders as applicable.

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (NOV 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

_X___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

____ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

___ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-

282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

__X_ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div.

C).

___X (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub.

L. 111-117, section 743 of Div. C).

___ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

__X__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (July 2013) (41 U.S.C. 2313).

____ (10) [Reserved]

____ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a).

____ (ii) Alternate I (NOV 2011) of 52.219-3.

____ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (ii) Alternate I (JAN 2011) of 52.219-4.

____ (13) [Reserved]

____ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

____ (ii) Alternate I (NOV 2011).

____ (iii) Alternate II (NOV 2011).

____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

____ (ii) Alternate I (Oct 1995) of 52.219-7.

____ (iii) Alternate II (Mar 2004) of 52.219-7.

____ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

____ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (Nov 2016) of 52.219-9.

____ (iii) Alternate II (Nov 2016) of 52.219-9.

____ (iv) Alternate III (Nov 2016) of 52.219-9.

____ (v) Alternate IV (Nov 2016) of 52.219-9.

____ (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)).

____ (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)).

____ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C.

657f).

____ (22) 52.219-28, Post Award Small Business Program Rerepresentation (July 2013) (15 U.S.C. 632(a)(2)).

____ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

____(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

____ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

__X__(26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

____ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

____ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

____ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

____ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014) (29 U.S.C. 793).

____ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

____ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496).

__X__ (33)(i) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O.

13627).

____ (ii) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

____ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__X__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693).

__X__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693).

____ (38) (i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (39)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-14.

__X__ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

____ (41)(i) 52.223-16, Acquisition of EPEAT[supreg]-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-16.

__X__ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O.

13513).

____ (43) 52.223-20, Aerosols (June, 2016) (E.O. 13693).

____ (44) 52.223-21, Foams (June, 2016) (E.O. 13693).

__X__ (45)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

____ (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

____ (47) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L.

103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I (May 2014) of 52.225-3.

____ (iii) Alternate II (May 2014) of 52.225-3.

____ (iv) Alternate III (May 2014) of 52.225-3.

____ (48) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

____ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

____ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150

____ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C.

5150).

____ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__X__ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

____ (55) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (July 2013) (31 U.S.C. 3332).

____ (56) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (July 2013) (31 U.S.C. 3332).

____ (57) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

____ (59) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)).

____ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.

Appx. 1241(b) and 10 U.S.C. 2631).

____ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

_____(1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495).

_____ (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

_____ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

_____ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

_____ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (MAY 2014) (41 U.S.C. chapter 67).

__X___(8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (E.O. 13658).

_____ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

_____ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792).

_____ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1)in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (MAY 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xii) _____ (A) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O.

13627).

_____ (B) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xvii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xiv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xv)52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658).

(xvi) (A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xvii) 52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xviii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xix) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xx) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price Indefinite Delivery Indefinite Quantity contract resulting from this solicitation.

(End of provision)

52.216-18 ORDERING. (OCT 1995)

(a) Any supplies and services to be furnished under this contract shall be ordered by issuance of delivery orders or task orders by the individuals or activities designated in the Schedule. Such orders may be issued through Date of Contract Award through Date of Contract Expiration.

(b) All delivery orders or task orders are subject to the terms and conditions of this contract. In the event of conflict between a delivery order or task order and this contract, the contract shall control.

(c) If mailed, a delivery order or task order is considered "issued" when the Government deposits the order in the mail. Orders may be issued orally, by facsimile, or by electronic commerce methods only if authorized in the Schedule.

52.216-19 ORDER LIMITATIONS (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $2,500 (insert dollar figure or quantity), the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor -

(1) Any order for a single item in excess of $150,000 insert dollar figure or quantity);

(2) Any order for a combination of items in excess of $150,000 (insert dollar figure or quantity); or

(3) A series of orders from the same ordering office within 30 days that together call for quantities exceeding the limitation in paragraph (b) (1) or (2) of this section.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) of this section.

(d) Notwithstanding paragraphs (b) and (c) of this section, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 7 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons. Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after 30 Days after last task order completion date.

52.216-4003 ORDERING PROCEDURES

The following shall apply: (a) Services for each task order may be requested either verbally or in writing, including facsimile and electronic means. Written requests for proposal shall be issued by the Contracting Officer or Contracting Officer's Representative. Oral or telecommunication request shall be issued only by the Contracting Officer. (See also EMERGENCY ISSUANCE OF TASK ORDERS in this contract clause). Any type of request for proposal shall not be interpreted as a Notice to Proceed with the work. (b) The Government request for proposal will delineate (1) general scope of work, (2) location of work, (3) character and extent of services, (4) technical requirements which supplement or complement those contained in SECTION C of this basic contract, and (5) time period(s) within which the work must be performed. (c) The Architect-Engineer shall prepare an estimate of time and cost(s) to perform the work, and submit its proposal in writing to the Contracting Officer within 10 calendar days. Verbal proposals, when so requested and authorized, shall be directed only to the Contracting Officer.

Itemized cost proposals shall strictly correspond to the units contained in Schedule B of this contract. (d) Each task order shall be discussed by the Architect-Engineer's and the Contracting Officer, as necessary, to develop a mutual understanding of:

(1) Type and scope of work to be accomplished, including accuracy criteria.

(2) End product required by the Contracting Officer.

(3) Commencement and completion dates required by the Contracting Officer.

(4) Existing site conditions, survey control, and other available data.

(5) A fair and reasonable estimated cost to perform the work.

(e) Time periods within which required work must be accomplished shall be defined in each task order placed against the basic contract. Each task order shall contain the agreed to scope of work, type(s) of service(s) to be performed, specific deliverable items, and the negotiated fixed-price cost for performing the work.

(f) Emergency issuance of task orders: For certain restricted types of work requiring expedited and immediate field support, only the Contracting Officer may telephonically convey the scope of work and negotiate time and cost. Only the Contracting Officer may then issue a verbal order to proceed with the work. Verbal requests for proposals and orders to proceed are restricted to projects involving critical construction measurement, payment, or acceptance survey support where delays in fielding such support would adversely impact construction progress, or survey support for emergency operations where delays in obtaining such support could be hazardous to life and property.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within any period of time prior to the expiration of the current ordering period. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within any period of time prior to the expiration of the current ordering period.

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within any period of time prior to the expiration of the current ordering period (insert the period of time within which the Contracting Officer may exercise the option); provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least any period of time prior to the expiration of the current ordering period days (60 days unless a different number of days is inserted) before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed five years and six months after the date of contract completion .

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded…