W912HP-16-B-0003_Am-01_Reduce_Prod_Rates__71516.pdf

W81D4A61169707

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

W912HP-16-B-0003 FY16 Murrells Inlet Maintenance Dredging, Georgetow n County, SC - Amendment 01

The purpose of this Amendment 01 is to reduce Production Rates detailed in the Supplemental Instructions found in FAR 52.211-10 (See follow ing page(s)).

All other Solicitation terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 15-Jul-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HP-16-B-0003

X 9B. DATED (SEE ITEM 11)

05-Jul-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

15-Jul-2016

CODE

U.S. ARMY CORPS OF ENGINEERS, CHARLESTON

DISTRICT, CONTRACTING DIVISION

69-A HAGOOD AVENUE

CHARLESTON SC 29403

W912HP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HP-16-B-0003

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [SEE SUPPLEMENTAL INSTRUCTIONS] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than [SEE SUPPLEMENTAL INSTRUCTIONS] * The time stated for completion shall include final cleanup of the premises.

*SUPPLEMENTAL INSTRUCTIONS

(a) Prosecution of Work

The Contractor will be required to commence dredging work under this contract within 30 calendar days after the date of receipt by him of Notice to Proceed. The Contractor will be required to prosecute the dredging work in Murrells Inlet at an average rate of not less than 200,000 cubic yards per month and to complete it within the number of days after the limiting date fixed for commencement; provided that the quantity of material actually removed in any one month shall in no case be less than 150,000 cubic yards.

(b) Continuously Working

The Contractor shall maintain adequate plant on site to have an average production rate of 200,000 cubic yards per month and shall work continuously for every consecutive calendar month until the project is completed.

The number of days allowed for completion after the limiting date fixed for commencement shall be determined by applying the average monthly rate above stipulated to the total quantity of material actually removed and to be paid for under the contract; provided, further that no waiver by the Contracting Officer of any failure of the Contractor to make in any month or series of months the rate of progress required by this paragraph shall be construed as relieving the Contractor from the obligation to make up the deficiency in future months and to complete the entire work within the time allowed by the contract. The time thus determined for completion shall include final clean-up of the premises.

(d) Performing Dredging Work for Others Outside the Requirements of this Contract:

In the event the Contractor elects to perform dredging work contiguous to the project area but outside the requirements of this contract, (i.e. for Federal, state or local activities - “third party”) the Contractor shall

W912HP-16-B-0003

have approval of the Contracting Officer prior to moving off construction site to perform third party work. Reasonable adjustments in time may be granted the Contractor to perform this work at the discretion of the Contracting Officer. Time allotted may include time to relocate pipelines, dredge plant, and to perform the third party work; however, it shall not include time for plant maintenance or similar delays that postpone resumption of work under this contract. The Contractor shall also be responsible for the cost of any additional surveys required due to delays caused by this interruption of work.

(End of supplemental instructions)

(End of clause)

(End of Summary of Changes)