IFB W912HN-10-B-0010 Amend 0003.pdf

WILMINGTON CONSTRUCTION BRANCH

ATTN: JIM MULLINS

69 DARLINGTON AVENUE

WILMINGTON NC 28403

W81LJ893519461

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Solicitation No. W912HN-10-B-0010, entitled Clearing and Spillw ay System Maintenance, Atlantic Intracoastal Waterw ay Northern Disposal Areas 16, 19, and 21, Hyde County and Pamlico County, NC. is amended as follow s:

A. Added Note 4 to the Notice for Bidders section after the bid schedule. See Summary of Changes.

B. The Time and Date for Bid Opening is 23 Mar 2010 02:00 PM and remains unchanged.

C. All other terms and conditions of the solicitiaton remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 17-Mar-2010

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HN-10-B-0010

X 9B. DATED (SEE ITEM 11)

19-Feb-2010

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES T HE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. T HIS CHANGE ORDER IS ISSUED PURSUANT T O: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Mar-2010

CODE

USACE CONTRACTING, WILMINGTON DISTRICT

ATTN: BRUCE HELMS

69 DARLINGTON AVE

WILMINGTON NC 28403-1343

W912HN 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE W912HN

FACILITY CODECODE

EMAIL:TEL:

W912HN-10-B-0010

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The following have been modified:

NOTICE TO BIDDERS

DESCRIPTION OF WORK

Clearing and Spillway System Maintenance, Atlantic Intracoastal Waterway Northern Disposal Areas 16, 19, and 21, Hyde County and Pamlico County, NC

The project will include improvements to Disposal Areas 16 and 19 in Hyde County and Disposal Area 21 in Pamlico County. Each of these sites is used for disposal of maintenance dredging material from the AIWW. Improvements are needed at each site to prepare them for disposal of dredged material during the next AIWW dredging cycle for the Alligator Pungo Landcut and the Hobucken Landcut. The existing dikes at each site need to be raised to provide dredged material capacity. Clearing of vegetation from the dikes and from within the diked areas at each site will be required. Grubbing of the new dike embankment footprint areas and borrow areas will be required prior to dike raising. The borrow for dike raising at each site is available within the existing diked area. In addition to clearing, grubbing and dike raising, the existing spillway risers and pipes at each disposal area will be replaced. The existing spillway risers and pipes will be removed and replaced with new 4’x4’ risers and 30” diameter HDPE pipe supported on timber cribbing.

NOTE 1:

OFFERORS MUST BID ON ALL LINE ITEMS PROVIDING ALL UNIT PRICES AND EXTENDED

PRICES FOR EACH LINE ITEM BASED ON UNIT OF MEASURE AND THE TOTAL BID

AMOUNT. SEE PROVISION 52.214-18 (SECTION 00100)

NOTE 2:

FAILURE TO COMPLETE AND RETURN ALL REQUIRED SUBMISSIONS (SF 1442, SECTION

00010, SECTION 00600, AND BID GUARANTEE) COULD RENDER YOUR BID NON-

RESPONSIVE.

NOTE 3:

1. THIS CONTRACT ACTION REQUIRES PRODUCTS AND/OR SERVICES THAT ARE FUNDED

UNDER THE AMERICAN RECOVERY AND REINVESTMENT ACT OF 2009 (ARRA).

2. CONTRACT LINE ITEMS USING ARRA FUNDS WILL BE IDENTIFIED ON THE CONTRACT

AWARD DOCUMENT.

W912HN-10-B-0010

3. SEE ARRA CONTRACT CLAUSES, ARRA REPORTING REQUIREMENTS, AND

WWW.FEDERALREPORTING.GOV FOR MORE INFORMATION.

NOTE 4:

ORDER OF WORK: THE FIRST ORDER OF WORK SHALL BE THE DISPOSAL AREA 21

IMPROVEMENTS IN PAMLICO COUNTY. THE ORDER OF WORK FOR THE DISPOSAL AREA

16 AND 19 IMPROVEMENTS IN HYDE COUNTY SHALL BE AT THE DISCRETION OF THE

CONTRACTOR, UNLESS OTHERWISE DIRECTED BY THE CONTRACTING OFFICER. SEE

SECTION 01 10 00.10 38.

SECTION 01 10 00.10 38 – SUPPLEMENTARY SPECIAL CONTRACT REQUIREMENTS

Delete existing Page 1, Page 16, Page 17 and Page18 in their entirety and replace with revised enclosed like-numbered Pages.

NOTE:

Text that is added or revised by this amendment is replaced in its entirety and underlined and/or printed in bold and/or stamped appropriately.

The text changes may have necessitated reformatting of subsequent text or pages. If this is the case, those pages have also been issued as amended pages but are not underlined or bold text.

-- End of Summary of Changes --

Encls As stated

Disposal Areas 16, 19 and 21 Clearing & Maintenance W912HN-10-B-0010 Hyde County and Pamlico County, North Carolina

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 10 00.10 38

SUPPLEMENTARY SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 AMERICAN RECOVERY AND REINVESTMENT ACT (ARRA) EMBLEM

1.2 PROJECT SIGNS

1.3 REFERENCES

1.4 SUBMITTALS

1.5 DEPARTMENT OF ARMY MANDATED SECURITY REQUIREMENTS

1.6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.7 PERFORMANCE AND PAYMENT BONDS

1.8 WATER CONSERVATION

1.9 BULLETIN BOARD

1.10 SHOP DRAWINGS AND MATERIALS SUBMITTAL

1.11 SAMPLING, CERTIFICATES, AND TESTING

1.12 CERTIFICATES OF COMPLIANCE

1.13 RETAINAGE FOR UNTIMELY SUBMISSION OF SUBCONTRACTING REPORTS

1.14 MINIMUM INSURANCE REQUIREMENTS

1.15 REQUIRED CONSTRUCTION MEETINGS

1.16 "AS-BUILT" RECORD DRAWINGS

1.17 SURVEY DATA

1.18 ADDITIONAL SURVEY AND SURVEY PERSONNEL REQUIREMENTS

1.19 PLANT LOCATION

1.20 WORK IN QUARANTINED AREA

1.21 FINAL AND CONDITIONAL ACCEPTANCE OF GRASSING

1.22 IDENTIFICATION OF EMPLOYEES

1.23 MAINTENANCE DURING CONSTRUCTION

1.24 PARTNERING

1.25 LOAD RESTRICTIONS

1.26 PROTECTION OF EXISTING FACILITIES

1.27 CONTRACT AREA AND TRESPASSING

1.28 CONTRACT DRAWINGS AND SPECIFICATIONS

1.29 ORDER OF WORK

1.30 RATES OF WAGES

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 10 00.10 38 Page 1 (Revised by Amendment No. 0003)

1.29 ORDER OF WORK

The first order of work shall be the Disposal Area 21 improvements. The order of work for the Disposal Area 16 and 19 improvements shall be at the discretion of the Contractor, unless otherwise directed by the Contracting Officer.

1.30 RATES OF WAGES

General Decision Number: NC100009 03/12/2010 NC9

Superseded General Decision Number: NC20080009

State: North Carolina

Construction Type: Heavy

Counties: North Carolina Statewide.

SEWER AND WATER CONSTRUCTION PROJECTS, AND HEAVY CONSTRUCTION

PROJECTS (does not include dam construction projects)

Modification Number Publication Date 0 03/12/2010

SUNC1990-012 02/12/1990

Rates Fringes

Bricklayer.....................$ 7.25

Carpenter......................$ 7.25

Cement mason...................$ 7.25

Electrician....................$ 8.56

Ironworker.....................$ 8.20

Laborers:

_Air drill operator.........$ 7.25 _Asphalt raker..............$ 7.25 _General....................$ 7.25 _Pipelayer..................$ 7.25

Millwright.....................$ 7.25

Painter........................$ 7.25

Plumber/pipefitter .................................$ 7.42

Power equipment operators:

_Asphalt distributor........$ 7.25 _Asphalt finisher...........$ 7.25 _Asphalt paver..............$ 7.25 _Asphalt screed.............$ 7.25 _Backhoe....................$ 7.25

SECTION 01 10 00.10 38 Page 16

_Boring machine.............$ 7.25 _Bulldozer..................$ 7.25 _Crane......................$ 7.60 _Dragline...................$ 7.25 _Drill......................$ 7.25 _Loader.....................$ 7.25 _Mechanic...................$ 7.25 _Motor grader...............$ 7.25 _Roller.....................$ 7.25 _Scraper-pan................$ 7.25 _Tractor....................$ 7.25 _Trenching..................$ 7.25 _Well driller...............$ 7.25

Truck driver...................$ 7.25

Boilermakers:

_All other work.............$ 16.20 4.105 _Storage tank erection/repair..........$ 12.96 4.105

Fence Installers.................$ 7.25

MANHOLE BUILDER..................$ 7.25

TV & Grouting Technicians........$ 9.21

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

In the listing above, the "SU" designation means that rates listed under the identifier do not reflect collectively bargained wage and fringe benefit rates. Other designations indicate unions whose rates have been determined to be prevailing.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests

SECTION 01 10 00.10 38 Page 17 for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 10 00.10 38 Page 18