W912ES21Q0004 Amendment 00002.pdf

W81G6702794526

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to extend the closing date from 22 Dec 2020 at 10AM CDT to 29 January 2021at 3:00pm CDT and extend the completetion date from 30 Apr 2021 to 31 March 2022.

Amendment 00001 w as used for internal administration, and does not require submittal.

This is amendment 00002, and DOES NEED to accompany your quote.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 16-Dec-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912ES21Q0004

X 9B. DATED (SEE ITEM 11)

04-Dec-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

16-Dec-2020

CODE

CONTRACTING DIVISION

USACE - ST PAUL

180 FIFTH STREET EAST

SUITE 700

SAINT PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES21Q0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 22-Dec-2020 10:00 AM to 29-Jan-2021 03:00 PM.

The following Delivery Schedule item for CLIN 0002 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

30-APR-2021 20,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862 FOB: Destination

966323

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

31-MAR-2022 20,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

The following Delivery Schedule item for CLIN 1001 has been changed from:

CAGE

30-APR-2021 10,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

CAGE

31-MAR-2022 10,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

The following Delivery Schedule item for CLIN 2001 has been changed from:

CAGE

30-APR-2021 10,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

CAGE

31-MAR-2022 10,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

The following Delivery Schedule item for CLIN 3001 has been changed from:

CAGE

30-APR-2021 10,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

CAGE

31-MAR-2022 10,000 EASTERN AREA ENGINEER

THOMAS JOHNSON

902 E 2ND ST STE 302

WINONA MN 55987-6510

651-290-5862

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within Ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than .

All construction work (CLINs 0002 through 3001) shall be completed not later than 03/31/2022*.* *The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 02/22/21. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,250.00 per calendar day for all construction work (CLINs 0002 through 3001) not completed by 03/31/2022

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)