W912EP19B0022_Amendment_0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 3

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

05-Aug-2019

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO.(Ifapplicable)

6. ISSUED BY CODE W912EP 7. ADMINISTERED BY (Ifother than item 6) CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

See Item 6

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

W912EP19B0022

X 9B. DATED (SEE ITEM 11)

15-Jul-2019

10A. MOD. OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACT S/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

A. SEE CONTINUATION SHEET FOR AMENDMENT DETAILS.

B. THE BID OPENING DATE REMAINS UNCHANGED @ AUGUST 15, 2019 @ 2:00 P.M. LOCAL TIME.

ALL OTHER TERMS AND CONDITIONS REMAIN UNCHANGED

Except as provided herein, all terms and conditions ofthe document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

TEL: EMAIL:

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

BY

(Signature of Contracting Officer)

16C. DATE SIGNED

EXCEPTION TO SF 30 30-105-04

STANDARD FORM 30 (Rev. 10-83) APPROVED BY OIRM 11-84 Prescribed by GSA

FAR (48 CFR) 53.243

SF 30 CONTINUATION SHEET

Naval Submarine Base Kings Bay – Entrance Channel, Maintenance Dredging – Cut-1N Through Range-E, 49, 45, and 44-Foot Project, Camden County, Georgia & Nassau County, Florida

W912EP19B0022 2 Amendment 0002

SUMMARY OF CHANGES

1. SPECIFICATIONS:

VOLUME I

DELETE Clause 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) Section 00700 and REPLACE with the attached Clause 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)- ALTERNATE I (APR 1984) Section 00700.

VOLUME II

None

2. DRAWINGS:

None

(End of Summary of Changes)

W912EP19B0022 00700-1A Amendment 0002

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 45 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 175 calendar days after the Contractor receives the notice to proceed. Total includes 170 calendar days for the Base and 5 calendar days for Option A.

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 45 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than April 15, 2020. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 1 Nov 2019. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

NOTE: All hopper dredging activity shall be accomplished between December 15, 2019 and March 31, 2020 (See Specification Section 35 20 23).