Amendment_0001-Tampa_Harbor_FY-16.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT, AND 34-FOOT PROJECTS, HILLSBOROUGH BAY HB), CUT-A (HB), CUT C

(HB) AND CUT-D (HB), HILLSBOROUGH COUNTY, FLORIDA

This amendment is being issued to provide:

1) Site visit roster and answ ers to the questions posed during the site visit

2) Revise Section 00010A Line Items and Pricing Schedule.

3) FAR Clauses 52.204-17, 52.209-7 and 999.204-4002 added to Section 00101.

4) Revised Technical Specification Sections 01 57 20 and 35 20 23.

5) Revised Draw ings C-11, C-12, C-13

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EP-16-B-0007

X 9B. DATED (SEE ITEM 11)

01-Jul-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

25-Jul-2016

CODE

USA ENGINEER DISTRICT, JACKSONVILLE

PRUDENTIAL OFFICE BLDG

701 SAN MARCO BLVD

ATTN: CESAJ-CT

JACKSONVILLE FL 32207-8175

W912EP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SF 30 CONTINUATION SHEET

TAMPA HARBOR, MAINTENANCE DREDGING,

43-FOOT, 41-FOOT, AND 34-FOOT

PROJECTS, HILLSBOROUGH BAY (HB), CUT-A

(HB), CUT C (HB) AND CUT-D (HB)

THE PURPOSE OF THIS REVISION IS TO PROVIDE:

1) Site visit roster and answers to the questions posed during the site visit.

2) Revised section 00010A Line Items and Pricing Schedule.

3) FAR Clauses 52.204-17, 52.209-7 and 999.204-4002 in Section 00101.

4) Revised Technical Specification Sections 01 57 20 and 35 20 23.

5) Revised Drawings C-11, C-12, C-13

CONTRACTING DOCUMENTS:

SECTION 00100 - INSTRUCTIONS TO OFFERORS:

Delete FAR Clauses 52.204-17, 52.209-7 and 999.204-4002 in their ENTIRETY.

SECTION 00101 - REPRESENTATIONS AND CERTIFICATIONS:

Add FAR Clauses 52.204-17, 52.209-7 and 999.204-4002 in their ENTIRETY.

TECHNICAL SPECIFICATIONS:

SECTION: 01 57 20 - ENVIRONMENTAL PROTECTION

Delete Section 01 57 20 in its ENTIRETY and replace with the ATTACHED revised Section 01 57 20.

SECTION: 35 20 23 - DREDGING

Delete Section 35 20 23 in its ENTIRETY and replace with the ATTACHED revised Section 35 20 23.

DRAWINGS:

Delete Drawings C-11, C-12 and C-13 in their ENTIRETY, replace with ATTACHED revised Drawings C-11, C-12 and C-13.

W912EP‐16‐B‐0007

Tampa Harbor Maint. Dredging, Cuts A, C and D (HB) Site Visit July 13, 2016 Contractors’ Questions/Comments

1. Is the Contractor permitted to pump additional water to the north end discharge area at 3D to raise the ponding level to discourage bird nesting inside disposal area 3D?

The Contractor is allowed to pump additional water to the DMPF-3D to raise the ponding level to discourage bird nesting. However, please refer to paragraph (2) subparagraph (b) of subheading titled “3.1.5.8 Protection of Migratory Bird Species” in specification SECTION 01 57 20 - ENVIRONMENTAL PROTECTION which informs the Contractor on the need to conduct migratory bird surveys prior to mobilizing equipment to the island.

2. If bird monitoring is needed and required, would the local Audubon personnel perform bird monitoring at their own expense, or would the Contractor need to provide a monitor at his own expense?

The Contractor will need to provide the bird monitor for the duration of the contract. Please refer to specifications SECTION 01 22 00 MEASUREMENT AND PAYMENT.

3. If pumping of ponded water from inside 3D to discharge water outside 3D (to maintain a constant water level inside 3D to protect possible bird nesting inside 3D) is needed, would that then be considered a contract modification, or would that be considered to already be included in the contract and no modification could be provided to compensate for pumping‐out type operations?

Refer to contract amendment 0001 for changes to managing water within DMPF-3D.

4. Is there a preference for order of dredging in the various channel cuts?

Refer to heading titled “1.4.1 Order of Work” under specification SECTION 35 20 23

DREDGING.

5. Is there a basis that could be described and provided for the decision on which areas (Base and Options) might be awarded? Do any of the Options have higher priority and therefore more likely to be awarded if not all Options are awarded?

In accordance with the FAR Clause 52.217-7 the Contracting Officer may execute the Option(s) by written notice to the Contractor at any time before the Contractor starts Demobilization.

6. Since much of the dredging quantity is in the over‐depth, would USACE consider providing a bid schedule allowing for proposal of different unit prices for areas where there is a large majority of over‐depth material versus areas with available required dredging material?

No changes to bid schedule will be provided. However, Plan Sheet G-02 is provided the dredging quantities expected to be between required and allowable overdepth.

W912EP-16-B-0007

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION, OFFER, AND AWARD

The required response date/time has changed from 02-Aug-2106 02:00 PM to 05-Aug-2016 02:00 PM.

The number of offeror copies required has increased by 1 from 0 to 1.

SECTION 00100 - INSTRUCTIONS TO OFFERORS

The following have been deleted:

52.204-17 Ownership or Control of Offeror NOV 2014 52.209-7 Information Regarding Responsibility Matters JUL 2013

999.204-4002 ESTABLISHING AUTHORITY OF PERSON(S) WHO

SIGN(S) THE OFFER

DEC 1999

SECTION 00101 - REPRESENTATIONS & CERTIFICATIONS

The following have been added by full text:

52.204-17 OWNERSHIP OF CONTROL OF OFFEROR (NOV 2014)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Contractor and Government Entity (CAGE) Branch to identify a commercial or government entity, or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Contractor and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as an NCAGE code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

ESTABLISHING AUTHORITY OF PERSON(S) WHO SIGN(S) THE OFFER

The Offeror shall check the paragraph below that corresponds with the Offeror’s status and shall submit appropriate documentation with the offer to confirm authority of person(s) who sign the offer.

___(a) Individual. A contract with an individual shall be signed by that individual. A contract with an individual doing business as a firm shall be signed by that individual, and the signature shall be followed by the individual’s typed, stamped, or printed name and the words, “an individual doing business as _________” [insert name of firm].

___(b) Partnership. A contract with a partnership shall be signed in the partnership name. Before signing for the Government, the contracting officer shall obtain a list of all partners and ensure that the individual(s) signing for the partnership have authority to bind the partnership.

___(c) Corporation. A contract with a corporation shall be signed in the corporate name, followed by the word “by” and the signature and title of the person authorized to sign. The contracting officer shall ensure that the person signing for the corporation has authority to bind the corporation.

___(d) Joint venture. A contract with a joint venture may involve any combination of individuals, partnerships, or corporations. The contract shall be signed by each participant in the joint venture in the manner prescribed in paragraphs (a) through (c) above for each type of participant. When a corporation is participating, the contracting officer shall verify that the corporation is authorized to participate in the joint venture.

___(e) Agent. When an agent is to sign the contract, other than as stated in paragraphs (a) through (d) above, the agent’s authorization to bind the principal must be established by evidence satisfactory to the contracting officer.

(End of paragraph number 999.204-4002)

(End of Summary of Changes)

SECTION 00010A

LINE ITEMS AND PRICING SCHEDULE

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT,

AND 34- FOOT PROJECTS, HILLSBOROUGH BAY (HB),

CUT-A (HB), CUT-C (HB), AND CUT-D (HB)

HILLSBOROUGH COUNTY, FLORIDA

W912EP-16-B-0007 00010A-1 AMENDMENT 0001

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

BASE

CUT-A(HB) BETWEEN STA 0+00 TO 60+44.9 AND

CUT-C(HB) BETWEEN STA. 0+00 TO STA. 120+00

0001 MOBILIZATION AND DEMOBILIZATION 1 LUMP SUM $_______________

0002 EXCAVATION, UNCLASSIFIED

(ESTIMATED QUANTITY - SEE NOTE 3) 230,000 CUBIC YARD $___________ $_______________

0003 TURBIDITY MONITORING 1 LUMP SUM $_______________

0004 ENDANGERED SPECIES OBSERVER 1 LUMP SUM $_______________

0005 MOBILIZATION AND DEMOBILIZATION FOR 1 LUMP SUM $_______________

SEA TURTLE TRAWLING AND RELOCATION

(HOPPER DREDGES ONLY) (SEE NOTE 5)

0006 SEA TURTLE TRAWLING AND RELOCATION 1 DAY $______________ $_______________

* (HOPPER DREDGES ONLY) (SEE NOTES 5 & 7) *

0007 STANDBY TIME (SEE NOTE 6) 24 HOUR $______________ $_______________

0008 BIRD MONITORING 45 DAY $______________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 7)

TOTAL BASE (LINE ITEMS 0001 THROUGH 0008) $_______________

(CONTINUED ON NEXT PAGE)

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT,

AND 34- FOOT PROJECTS, HILLSBOROUGH BAY (HB),

CUT-A (HB), CUT-C (HB), AND CUT-D (HB)

HILLSBOROUGH COUNTY, FLORIDA

W912EP-16-B-0007 00010A-2 AMENDMENT 0001

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

OPTION A

CUT -C (HB) BETWEEN

STA. 120+00 to STA. 210+00

0009 ADDITIONAL PIPELINE MOBILIZATION AND 1 LUMP SUM $_______________

RELOCATION

0010 EXCAVATION, UNCLASSIFIED

(ESTIMATED QUANTITY - SEE NOTE 3) 117,000 CUBIC YARD $___________ $_______________

0011 TURBIDITY MONITORING 1 LUMP SUM $_______________

0012 ENDANGERED SPECIES OBSERVER 1 LUMP SUM $_______________

0013 MOBILIZATION AND DEMOBILIZATION FOR 1 LUMP SUM $_______________

SEA TURTLE TRAWLING AND RELOCATION

(HOPPER DREDGES ONLY) (SEE NOTE 5)

0014 SEA TURTLE TRAWLING AND RELOCATION 1 DAY $______________ $_______________

* (HOPPER DREDGES ONLY) (SEE NOTES 5 & 7) *

0015 STANDBY TIME (SEE NOTE 6) 24 HOUR $______________ $_______________

0016 BIRD MONITORING 45 DAY $______________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 7)

TOTAL OPTION A (LINE ITEMS 0009 THROUGH 0016) $_______________

TOTAL BASE AND OPTION A (LINE ITEMS 0001 THROUGH 0016) $_______________

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT,

AND 34- FOOT PROJECTS, HILLSBOROUGH BAY (HB),

CUT-A (HB), CUT-C (HB), AND CUT-D (HB)

HILLSBOROUGH COUNTY, FLORIDA

W912EP-16-B-0007 00010A-3 AMENDMENT 0001

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

OPTION B

CUT- C (HB) BETWEEN

STA. 210+00 to STA. 265+00

0017 ADDITIONAL PIPELINE MOBILIZATION AND 1 LUMP SUM $_______________

RELOCATION

0018 EXCAVATION, UNCLASSIFIED 115,000 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 3)

0019 TURBIDITY MONITORING 1 LUMP SUM $_______________

0020 ENDANGERED SPECIES OBSERVER 1 LUMP SUM $_______________

0021 MOBILIZATION AND DEMOBILIZATION FOR 1 LUMP SUM $_______________

SEA TURTLE TRAWLING AND RELOCATION

(HOPPER DREDGES ONLY) (SEE NOTE 5)

0022 SEA TURTLE TRAWLING AND RELOCATION 1 DAY $______________ $_______________

* (HOPPER DREDGES ONLY) (SEE NOTES 5 & 7) *

0023 STANDBY TIME (SEE NOTE 6) 24 HOUR $______________ $_______________

0024 BIRD MONITORING 35 DAY $______________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 7)

TOTAL OPTION B (LINE ITEMS 0017 THROUGH 0024) $_______________

TOTAL BASE PLUS OPTIONS A AND B (LINE ITEMS 0001 THROUGH 0024) $_______________

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT,

AND 34- FOOT PROJECTS, HILLSBOROUGH BAY (HB),

CUT-A (HB), CUT-C (HB), AND CUT-D (HB)

HILLSBOROUGH COUNTY, FLORIDA

W912EP-16-B-0007 00010A-4 AMENDMENT 0001

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

OPTION C

CUT-C (HB) BETWEEN STA. 265+00 to STA. 341+77.7 AND

CUT-D(HB) BETWEEN STA. 2+62.20 TO STA. 10+00

0025 ADDITIONAL PIPELINE MOBILIZATION AND 1 LUMP SUM $_______________

RELOCATION

0026 EXCAVATION, UNCLASSIFIED 136,000 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 3)

0027 TURBIDITY MONITORING 1 LUMP SUM $_______________

0028 ENDANGERED SPECIES OBSERVER 1 LUMP SUM $_______________

0029 MOBILIZATION AND DEMOBILIZATION FOR 1 LUMP SUM $_______________

SEA TURTLE TRAWLING AND RELOCATION

(HOPPER DREDGES ONLY) (SEE NOTE 5)

0030 SEA TURTLE TRAWLING AND RELOCATION 1 DAY $______________ $_______________

* (HOPPER DREDGES ONLY) (SEE NOTES 5 & 7) *

0031 STANDBY TIME (SEE NOTE 6) 24 HOUR $______________ $_______________

0032 BIRD MONITORING 45 DAY $______________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 7)

TOTAL OPTION C (LINE ITEMS 0025 THROUGH 0032) $_______________

TOTAL BASE PLUS OPTIONS A, B AND C (LINE ITEMS 0001 THROUGH 0032) $_______________

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT,

AND 34- FOOT PROJECTS, HILLSBOROUGH BAY (HB),

CUT-A (HB), CUT-C (HB), AND CUT-D (HB)

HILLSBOROUGH COUNTY, FLORIDA

W912EP-16-B-0007 00010A-5 AMENDMENT 0001

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

OPTION D

CUT-D (HB) BETWEEN

STA. 10+00 to STA. 72+88.28

0033 ADDITIONAL PIPELINE MOBILIZATION AND 1 LUMP SUM $_______________

RELOCATION

0034 EXCAVATION, UNCLASSIFIED 29,000 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 3)

0035 TURBIDITY MONITORING 1 LUMP SUM $_______________

0036 ENDANGERED SPECIES OBSERVER 1 LUMP SUM $_______________

0037 MOBILIZATION AND DEMOBILIZATION FOR 1 LUMP SUM $_______________

SEA TURTLE TRAWLING AND RELOCATION

(HOPPER DREDGES ONLY) (SEE NOTE 5)

0038 SEA TURTLE TRAWLING AND RELOCATION 1 DAY $______________ $_______________

* (HOPPER DREDGES ONLY) (SEE NOTES 5 & 7) *

0039 STANDBY TIME (SEE NOTE 6) 24 HOUR $______________ $_______________

0040 BIRD MONITORING 15 DAY $______________ $_______________

(ESTIMATED QUANTITY - SEE NOTE 7)

TOTAL OPTION D (LINE ITEMS 0033 THROUGH 0040) $_______________

TOTAL BASE PLUS OPTIONS A, B, C AND D (LINE ITEMS 0001 THROUGH 0040) $_______________

TAMPA HARBOR, MAINTENANCE DREDGING, 43-FOOT, 41-FOOT,

AND 34- FOOT PROJECTS, HILLSBOROUGH BAY (HB),

CUT-A (HB), CUT-C (HB), AND CUT-D (HB)

HILLSBOROUGH COUNTY, FLORIDA

W912EP-16-B-0007 00010A-6 AMENDMENT 0001

NOTES:

(1) SEE SECTION 00100: "INSTRUCTIONS TO OFFERORS".

(2) OFFERORS MUST PROVIDE PRICING FOR ALL ITEMS.

(3) QUANTITY INCLUDES REQUIRED DEPTH, ALLOWABLE OVERDEPTH, AND SHOALING ESTIMATED TO OCCUR BETWEEN DATES OF SURVEYS SHOWN ON DRAWINGS AND COMMENCEMENT OF DREDGING. ACTUAL QUANTITIES MAY DIFFER

FROM ESTIMATED QUANTITIES.

(4) THE GOVERNMENT RESERVES THE RIGHT TO EXERCISE OPTION ITEMS ANY TIME PRIOR TO DEMOBILIZATION OF EQUIPMENT. SEE CLAUSE 52.217-7 of SECTION 00700. THE CONTRACTOR SHALL NOTIFY THE CONTRACTING OFFICER, IN WRITING, A MINIMUM OF 7 DAYS PRIOR TO THE ANTICIPATED DATE OF THE DEMOBILIZATION OF A DREDGE PLANT.

(5) SEA TURTLE TRAWLING AND RELOCATION WILL ONLY BE PAID FOR IF THE CONTRACTOR IS REQUIRED TO PERFORM THE WORK UNDER THE PROVISIONS OF THIS CONTRACT. SEE SECTION 01 57 20: ENVIRONMENTAL PROTECTION FOR

PROVISIONS TO INITIATE SEA TURTLE TRAWLING AND RELOCATION.

(6) STANDBY TIME MAY BE EXERCISED WHEN THE DREDGE PLANT IS NOT IN OPERATION AT THE DIRECTION OF THE CONTRACTING OFFICER. THIS LINE ITEM IS NOT SUBJECT TO THE VARIATION IN ESTIMATED QUANTITY CLAUSE, AND PAYMENT WILL ONLY BE MADE FOR ACTUAL STANDBY TIME REQUIRED BY THE CONTRACTING OFFICER.

(7) THIS LINE ITEM IS FOR BIDDING PURPOSES ONLY. ACTUAL QUANTITIES MAY DIFFER FROM ESTIMATED QUANTITIES. THIS LINE ITEM IS NOT SUBJECT TO THE VARIATION IN ESTIMATED QUANTITIES CLAUSE, AND PAYMENT WILL ONLY BE MADE FOR

* ACTUAL DAYS PERFORMED. *

Tampa Harbor, Maintenance Dredging, 43-Ft, 41-Ft, & 34-Ft Projects Hillsborough Bay (HB), Cut-A (HB), Cut-C (HB), & Cut D (HB)

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 20

ENVIRONMENTAL PROTECTION

PART 1 GENERAL

1.1 SCOPE

1.2 ENVIRONMENTAL LAWS, REGULATIONS AND DOCUMENTS

1.2.1 Miscellaneous Environmental Laws And Regulations

1.2.2 NEPA Reference

1.3 REFERENCES

1.4 QUALITY CONTROL

1.5 PERMITS AND AUTHORIZATIONS

1.6 SUBMITTALS

1.7 SUBCONTRACTORS

1.8 NOTIFICATION

1.9 CONTRACTOR PERSONNEL QUALIFICATIONS IN POLLUTION CONTROL

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 PROTECTION OF ENVIRONMENTAL RESOURCES

3.1.1 General Project Environmental Design and Installation Criteria

3.1.1.1 Sewage-Based Systems Environmental Design and Installation

Criteria

3.1.2 Protection of Land Resources

3.1.2.1 Work Area Limits

3.1.2.2 Contractor Facilities and Other Work Areas

3.1.2.3 Solid Wastes

3.1.2.4 Fuel, Oil, and Lubricants

3.1.2.5 Hazardous Waste

3.1.2.6 Hazardous Materials

3.1.2.7 Disposal of Other Materials

3.1.3 Preservation and Recovery of Historic, Archeological, and

Cultural Resources

3.1.3.1 Applicable Law

3.1.3.2 Known Resources

3.1.3.3 Inadvertent Discoveries

3.1.3.4 Claims for Downtime due to Inadvertent Discoveries

3.1.4 Protection of Water Resources

3.1.4.1 Washing and Curing Water

3.1.4.2 Monitoring of Water Areas

3.1.4.3 Turbidity

3.1.4.4 Oil, Fuel, and Hazardous Substance Spill Prevention and

Mitigation

3.1.5 Protection of Fish and Wildlife Resources

3.1.5.1 Endangered Species Protection

3.1.5.2 Endangered Species Observers

W912EP-116-B-0007- SECTION 01 57 20 Page 1 Amendment 0001

3.1.5.3 Manatee, Sea Turtle, and Whale Sighting Reports

3.1.5.4 Disposition of Turtles or Turtle Parts

3.1.5.5 Report Submission

3.1.5.6 Hopper Dredge Equipment

3.1.5.7 Trawling and Relocation (For Hopper Dredges Only)

3.1.5.8 Protection of Migratory Bird Species

3.1.6 Seagrass Protection Measures

3.1.7 Protection of Air Resources

3.1.7.1 Particulates

3.1.7.2 Burning

3.1.7.3 Odors

3.1.8 Protection of Sound Intrusions

3.2 POSTCONSTRUCTION CLEANUP

3.3 PRESERVATION AND RESTORATION OF LANDSCAPE AND MARINE VEGETATION

DAMAGES

3.4 INVASIVE AND NUISANCE SPECIES

3.4.1 Prevention of Invasive and Nuisance Species Transfer

3.4.2 Invasive and Nuisance Species Reporting

3.5 MAINTENANCE OF POLLUTION CONTROL FACILITIES

3.6 CONSTRUCTION FORMS AND DETAILS

-- End of Section Table of Contents --

W912EP-116-B-0007- SECTION 01 57 20 Page 2 Amendment 0001

SECTION 01 57 20

ENVIRONMENTAL PROTECTION

PART 1 GENERAL

1.1 SCOPE

This Section covers prevention of environmental damage as the result of construction operations under this contract and for those measures set forth in other Technical Requirements of these specifications. For the purpose of this specification, environmental damage is defined as the presence of hazardous, physical, chemical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances; affect other species, biological communities, or ecosystems; or degrade the quality of the environment for aesthetic, cultural, and/or historical purposes. The control of environmental damage requires consideration of land, water, and air, and includes management of visual aesthetics, noise, solid waste, radiant energy and radioactive materials, as well as other pollutants.

1.2 ENVIRONMENTAL LAWS, REGULATIONS AND DOCUMENTS

1.2.1 Miscellaneous Environmental Laws And Regulations

There are numerous environmental laws and regulations. At the Federal level, the applicable laws and regulations include compliance with the Clean Water Act (CWA); Clean Air Act (CAA); Coastal Zone Management Act (CZMA); Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA); Endangered Species Act (ESA); Fish and Wildlife Coordination Act (FWCA); Marine Protection, Research, and Sanctuaries Act (MPRSA);

Magnuson-Stevens Fishery Conservation and Management Act (MSFCMA); National Environmental Policy Act (NEPA); National Historic Preservation Act (NHPA);

National Pollution Discharge Elimination System (NPDES); Research and Sanctuaries Act; Native American Graves Protection and Repatriation Act (NAGPRA); Resource Conservation and Recovery Act (RCRA); Rivers and Harbors Act (R&H); Safe Drinking Water Act (SDWA); Toxic Substance Control Act (TSCA); Wild and Scenic Rivers Act (WSRA); Federal Insecticide, Fungicide, and Rodenticide Act (FIFRA); Marine Mammal Protection Act (MMPA); Migratory Bird Treaty Act; Code of Federal Regulations (CFRs); Executive Orders; and, Environmental Protection Agency (EPA) requirements.

1.2.2 NEPA Reference

Commitments made in the NEPA document have been incorporated into these specifications. The NEPA document can be found at the following website:

http://www.saj.usace.army.mil/About/DivisionsOffices/Planning/ EnvironmentalBranch/EnvironmentalDocuments.aspx

1.3 REFERENCES

Any publication listed below forms a part of this specification to the extent referenced. Publications are referred to in the text by basic designation only.

W912EP-116-B-0007- SECTION 01 57 20 Page 3 Amendment 0001

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 1110-1-1003 (1996) NAVSTAR Global Positioning System Surveying

1.4 QUALITY CONTROL

The Contractor shall establish and maintain quality control for environmental protection of all items set forth herein. The Contractor shall record on daily quality control reports or attachments thereto, any problems in complying with laws, regulations and ordinances, and corrective action taken.

1.5 PERMITS AND AUTHORIZATIONS

a. Florida Department of Environmental Protection Permit No.

0157891-011-EM; Effective Date: 9/12/2006; Expiration Date: 4/07/2021.

The above permits indicate issuing agency approval of work required by this contract. Permits and environmental compliance documents, including Environmental Compliance Matrix (ECM) defining roles and responsibilities, are available at the following web address:

http://www.saj.usace.army.mil/About/DivisionsOffices/Planning/ EnvironmentalBranch/EnvironmentalCompliance.aspx

The Contractor shall obtain and comply with the requirements of all other permits or licenses required for construction of this project in accordance with the Clause PERMITS AND RESPONSIBILITIES of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Submit the following preconstruction submittal items no later than 20 calendar days after award or 5 calendar days after Notice to Proceed, whichever is later:

SD-01 Preconstruction Submittals

Environmental Protection Plan; G, DO

No later than 20 calendar days after award or 5 calendar days after Notice to Proceed, whichever is later, the Contractor shall submit an Environmental Protection Plan for review and acceptance by the Contracting Officer. The Government will consider an interim plan for the first 30 days of operations. However, the Contractor shall furnish an acceptable final plan no later than 30 calendar days after receipt of Notice to Proceed. Acceptance of the Contractor's plan shall not relieve the Contractor of his responsibility for adequate and continuing control of pollutants and other environmental protection measures. Acceptance of the plan is conditional and predicated on satisfactory performance during construction. The Government reserves the right to require the Contractor to make changes to the Environmental Protection

W912EP-116-B-0007- SECTION 01 57 20 Page 4 Amendment 0001

Plan or operations if the Contracting Officer determines that environmental protection requirements are not being met. No physical work at the site shall begin prior to acceptance of the Contractor's plan or an interim plan covering the work to be performed. The Environmental Protection Plan shall include but not be limited to the following:

a. A list of Federal, State, and local laws, regulations, and permits concerning environmental protection, pollution control, and abatement that are applicable to the Contractor's proposed operations and the requirements imposed by those laws, regulations, and permits.

b. Methods for protection of features to be preserved within authorized work areas. The Contractor shall prepare a listing of methods to protect resources needing protection, i.e., trees, shrubs, vines, grasses and ground cover, landscape features, air and water quality, fish and wildlife, soil, historical, archeological, and cultural resources.

c. Procedures to be implemented to provide the required environmental protection and to comply with the applicable laws and regulations. The Contractor shall provide written assurance that immediate corrective action will be taken to correct pollution of the environment due to accident, natural causes, or failure to follow the procedures set out in accordance with the environmental protection plan.

d. A permit or license for and the location of the solid waste disposal area.

e. Drawings showing locations of any proposed temporary excavations or embankments for haul roads, stream crossing, material storage areas, structures, sanitary facilities, and stockpiles of excess or spoil materials.

f. Environmental monitoring plans for the job site, including land, water, air, and noise monitoring.

g. Traffic control plan.

h. Methods of protecting surface and ground water during construction activities.

i. Spill prevention. The Contractor shall specify all potentially hazardous substances to be used on the job site and intended actions to prevent accidental or intentional introduction of such materials into the air, ground, water, wetlands, or drainage areas. The plan shall specify the Contractor's provisions to be taken to meet Federal, State, and local laws and regulations regarding labeling, storage, removal, transport, and disposal of potentially hazardous substances.

j. Spill contingency plan for hazardous, toxic, or petroleum material.

k. Work area plan showing the proposed activity in each portion of the area and identifying the areas of limited use or nonuse. Plan should include measures for marking the limits of

W912EP-116-B-0007- SECTION 01 57 20 Page 5 Amendment 0001 use areas.

l. A statement as to the person who shall be responsible for implementation of the Environmental Protection Plan. The Contractor personnel responsible shall report directly to the Contractor's top management and shall have the authority to act for the Contractor in all environmental protection matters.

m. Recycling and Waste Management Plan. Executive Order 12873 of 20 October 1993 requires a number of considerations in planning a project. Fallen trees should not be burned or buried.

Mulching, composting, and other uses for trees should be considered. Also, recovery of metals at the job site, including aluminum cans, should be considered with proceeds to be retained by the Contractor. Non-Federal recycling and waste minimization efforts shall also be incorporated into this plan.

n. Turbidity Monitoring Plan. A statement as to the person who shall be responsible for turbidity monitoring and reporting to be performed. Method of turbidity monitoring and reporting that will be performed. The turbidity monitoring requirements of any special areas such as outstanding Florida waters.

o. Operational plan to achieve protection of sea turtles during hopper dredge(s) operation.

p. Construction activities shall be conducted in a manner as not to impact migratory birds or induce their nesting.

q. Migratory Bird Protection Plan. The Contractor shall include in the Environmental Protection Plan a detailed plan for protecting migratory birds in the project area. The project site is important migratory bird nesting habitat, and experiences high densities of both common and rare bird species. All species utilizing this site for nesting are protected under the MBTA. The nesting season is generally between March 1 and September 15 in this region; however, migratory birds and their eggs are protected at all times of the year pursuant to the MBTA. Since construction may occur during the nesting season, the Contractor will be responsible for ensuring that migratory birds are not impacted during construction. As mentioned in subparagraph "Protection of Fish and Wildlife Resources" below, delays in work due to the presence of migratory birds or their nests shall not be compensable. The Migratory Bird Protection Plan shall include the following components:

1) Proposal for managing project activities to prevent the creation of suitable nesting habitat in the active conservation area prior to and during the nesting season;

(2) Measures to be implemented by the Contractor prior to nesting season to deter birds from nesting in areas where construction is anticipated to occur during nesting season;

(3) Monitoring protocol during construction, including names and qualifications of the proposed bird monitors;

(4) Steps that will be followed to address any unintentional take of migratory birds, should that occur. Construction

W912EP-116-B-0007- SECTION 01 57 20 Page 6 Amendment 0001 activities shall be conducted in a manner so as not to impact migratory birds or their eggs.

r. Invasive and Nuisance Species Transfer Prevention Plan.

SD-02 Shop Drawings

Daily Logs/Summary of Bird Nesting Monitoring; G, DO

Contractor shall submit as specified, daily logs of bird monitoring activities detailing the current bird activity on the island, ongoing nesting, and nesting success during the nesting season.

Weekly Logs/Summary of Bird Nesting Monitoring; G, DO

Contractor shall submit minimum weekly uploads of seabird and shorebird nesting count data using specific procedures outlined in the Florida Fish and Wildlife Conservation Commission Breeding Bird Protocol (BBP). Data collected using this protocol will be required to be uploaded to the Florida Shorebird Database (FSD) using the online website www.FL.ShorebirdDatabase.org, and to be submitted to the Contracting Officer's Representative in electronic pdf file format on a weekly basis.

Turtle Deflector Device; G, DO

If the Contractor proposes to use a hopper dredge for this work, detail drawings shall be submitted showing the proposed device and its attachment to the Contractor's equipment no later than 20 calendar days after award or 5 calendar days after Notice to Proceed, whichever is later. Contractor's drawings to be submitted shall include the approach angle for any and all depths to be dredged during this contract. A copy of the approved drawings and calculations shall be available on the vessel during the life of this contract. No dredging work shall be allowed to commence until approval of the installed turtle deflector device.

SD-07 Certificates

Bird Monitoring Qualifications; G, DO

Prior to the Preconstruction Conference, the Contractor shall furnish the qualifications of the bird monitor(s) to the Contracting Officer for approval. The Contractor shall furnish an approved plan prior to the issuance of NTP. These qualifications shall also be included as part of the Migratory Bird Protection Plan in the Environmental Protection Plan. Appropriate qualifications for bird monitors shall be a demonstrated ability to find and identify bird species, nesting behavior, nests, and eggs. Monitors shall have extensive knowledge of species' nesting habitat requirements (specifically beach-nesting bird species, including all nesting sea and shorebird species found in Florida,) general and nesting behavior characteristics, nests and eggs, and a knowledge of habitat requirements and experience implementing a variety of methods to deter birds from nesting, and experience working as a migratory bird monitor for construction projects. In addition, references shall be provided to verify non-educational experience. The qualifications shall be submitted on the Bird

W912EP-116-B-0007- SECTION 01 57 20 Page 7 Amendment 0001

Monitoring Qualification Sheet (See web site address http://www.saj.usace.army.mil/Divisions/Engineering/FormsDetails.htm.)

The Contracting Officer shall consult with and coordinate all monitoring plans and activities with the USACE designated biologist.

Manatee Observer Qualifications (Clamshell Only); G, DO

No later than 20 calendar days after award or 5 calendar days after Notice to Proceed, whichever is later, the Contractor shall furnish to the Contracting Officer for approval, the qualifications of the manatee observer. Appropriate qualifications for manatee observer shall be demonstrated experience monitoring manatees and their behaviors in association with in-water construction projects.

SD-11 Closeout Submittals

Logs/Final Summary Report

Contractor shall submit as specified, logs and final summary report of sightings and incidents with endangered species.

Project Environmental Summary Sheet

Contractor shall submit within 30 calendar days following completion of the project, a written report of the absence or occurrence of environmental incidents. In addition, for construction activities whose anticipated duration is more than one calendar year, the Contractor shall complete a sheet each May 31st (plus/minus 14 days).

Closeout Logs/Summary of Bird Nesting Monitoring

Contractor shall submit as specified, a summary of nesting activities that occurred during the nesting season, at the end of the project.

Sea Turtle/Post-Hopper Dredging Project Checklist

Contractor shall submit within 30 calendar days following completion of the project the Sea Turtle/Post-Hopper Dredging Project Checklist.

1.7 SUBCONTRACTORS

Assurance of compliance with this section by subcontractors shall be the responsibility of the Contractor.

1.8 NOTIFICATION

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with the aforementioned Federal, State, or local laws or regulations, permits and other elements of the Contractor's environmental protection plan. The Contractor shall, after receipt of such notice, inform the Contracting Officer of proposed corrective action and take such action as may be approved. If the Contractor fails to comply promptly, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No time

W912EP-116-B-0007- SECTION 01 57 20 Page 8 Amendment 0001 extensions shall be granted or costs or damages allowed to the Contractor for any such suspension.

Additionally, the Contractor shall notify the Contracting Officer, in writing, of the absence or occurrence of environmental incidents, as required on the Project Environmental Summary Sheet, copy on the first web site indicated in paragraph CONSTRUCTION FORMS AND DETAILS below. Refer to paragraph SUBMITTALS above.

1.9 CONTRACTOR PERSONNEL QUALIFICATIONS IN POLLUTION CONTROL

The Contractor's personnel shall be qualified to perform all phases of environmental protection, including methods of detecting and avoiding pollution, familiarization with pollution standards, both statutory and contractual, and careful installation and monitoring of the project to ensure adequate and continuous environmental pollution control. Quality Control and supervisory personnel shall be thoroughly knowledgeable of Federal, State, and local laws, regulations, and permits as listed in the Environmental Protection Plan submitted by the Contractor. Quality Control personnel will be identified in the Quality Control Plan submitted in accordance with Section 01 45 05 DREDGING/BEACH FILL PLACEMENT - CONTRACTOR

QUALITY CONTROL.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION

3.1 PROTECTION OF ENVIRONMENTAL RESOURCES

For contract work, the Contractor shall comply with all applicable Federal, State, or local laws and regulations. The environmental resources within the project boundaries and those affected outside the limits of permanent work under this contract shall be protected at least during the entire period of this contract. The Contractor shall confine activities to areas defined by the drawings and specifications. Environmental protection shall be as stated in the following subparagraphs.

3.1.1 General Project Environmental Design and Installation Criteria

Some project sites have features that shall not be impacted in any way, including cultural, historic, or archeological features. At all sites, the Contractor shall minimize disturbance to existing features at the site to the extent possible, including vegetative, topographic, and drainage pattern features. Wetland, seagrass or hardbottoms impacts (temporary access, detours, staging areas, and other work area impacts) to project sites should be avoided and may require separate permitting action. Any wetlands temporarily impacted shall have its soil restored upon project completion. Expansion of previously permitted project footprints may likewise require separate permitting action.

In all cases, the installation of temporary systems to aid construction shall provide for protection of the environment during handling, installing, storing, utilizing, transporting, servicing, testing, refilling, transferring, pumping, processing, removing waste products, repairing and maintaining systems and their components. Necessary protection shall also be considered that would prevent contamination of the environment from impacts to the systems caused by storm water runoff and flooding. Retrofit of temporary systems on project sites to modern environmental protection design standards shall also be considered.

W912EP-116-B-0007- SECTION 01 57 20 Page 9 Amendment 0001

In the event environmental protection measures fail, the Contractor shall implement procedures to control and correct environmental damage. The Contractor shall coordinate with the Contracting Officer if environmental protection measures fail.

3.1.1.1 Sewage-Based Systems Environmental Design and Installation Criteria

In general, there shall be no waste or debris discharges of any kind for a project unless authorized by the Contracting Officer. This shall include the Contractor's providing sufficient temporary sanitary equipment and facilities for the project. The design and/or installation of temporary or permanent sewage systems shall ensure that waters will be free of effects of sewage discharges. Applicable Federal, State, or local codes and requirements regarding sewage shall be strictly adhered to in the design, such as those of the EPA and, in the case of the State, Chapter 62-620 (Wastewater Facilities) of the FAC. Best Management Practices from the applicable agencies shall also be adhered to in the design.

3.1.2 Protection of Land Resources

Prior to the beginning of any construction, the Contractor shall identify all land resources to be preserved or avoided within the Contractor's work area. Materials displaced into uncleared areas shall be removed. The Contractor shall not remove, cut, deface, injure, or destroy land resources including trees, shrubs, vines, grasses, topsoil, and land forms without special permission from the Contracting Officer. The Contractor shall engage a qualified tree surgeon to perform all tree surgery. The Contractor shall be responsible to repair injuries to bark, trunk, branches, and roots of protected trees by dressing, cutting, and painting as specified for Class I Fine Pruning, of the National Arborist Association Pruning Standards for Shade Tree or as per State's Agricultural Extension Agency Guidelines, immediately as occurrences arise. No ropes, cables, or guys shall be fastened to or attached to any trees for anchorage unless specifically authorized. Where such special emergency use is permitted, the Contractor shall provide effective protection for land and vegetation resources at all times as defined in the following subparagraphs.

3.1.2.1 Work Area Limits

Prior to any construction, the Contractor shall mark the areas that are not required to accomplish all work to be performed under this contract.

Isolated areas within the general work area which are to be saved and protected shall also be marked or fenced. The Contractor shall protect from damage all existing trees designated to remain. Protection of tree roots shall be provided against noxious materials in solution caused by run-off or spillage. Fires shall be located outside the canopy of protected trees. No materials, trailers, or equipment shall be stored within the drip line of any protected tree. Monuments and markers shall be protected before construction operations commence. Where construction operations are to be conducted during darkness, the markers shall be visible. The Contractor shall convey to his personnel the purpose of marking and/or protection of all necessary objects.

3.1.2.2 Contractor Facilities and Other Work Areas

Locate facilities, staging and other work areas as indicated in Section 01 50 02 TEMPORARY CONSTRUCTION FACILITIES, and in compliance with permits listed in the paragraph PERMITS AND AUTHORIZATIONS above and obtained for

W912EP-116-B-0007- SECTION 01 57 20 Page 10 Amendment 0001 performance of work. Borrow or Dredge Material Placement Facility (DMPF) shall be managed to minimize erosion and to prevent sediment from entering nearby watercourses, wetlands, or lakes. Spoil areas shall be managed and controlled to limit spoil intrusion into areas designated on the drawings and to prevent erosion of soil or sediment from entering nearby watercourses, wetlands, or lakes. Spoil areas shall be developed in accordance with the grading plan indicated on the drawings. Temporary excavation and embankments for plant and/or work areas shall be controlled to protect adjacent areas from despoilment. If there is suspicion that sediment may be unsuitable for disposal at a specified location, the Contractor shall immediately take measures to contain the suspect sediment and notify the Contracting Officer.

3.1.2.3 Solid Wastes

Solid wastes (excluding clearing debris) shall be placed in containers which are emptied on a regular schedule. All handling and disposal shall be conducted to prevent contamination. Solid waste materials shall be hauled to a solid waste disposal site approved by the Contracting Officer.

The Contractor shall comply with Federal, State and local regulations pertaining to the use of the solid waste disposal site.

3.1.2.4 Fuel, Oil, and Lubricants

Fuel, oil, and lubricants shall be managed so as to prevent spills and evaporation. To prevent spills, fuel dispensers shall have a 4-foot square, 16-gauge metal pan with borders banded up and welded at corners right below the bibb. Edges of the pans shall be 8-inch minimum in depth to ascertain that no contamination of the ground takes place.