16-B-0012_0001.pdf

W68SBV60848418

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The puspose of this amendment is to revise the follow ing clauses and update the technical specifications.

The due date for Bids remains the same.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 25-Aug-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EF-16-B-0012

X 9B. DATED (SEE ITEM 11)

02-Aug-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

25-Aug-2016

CODE

USAED, WALLA WALLA - CONTRACTING DIV.

CRISTINA VEGA

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

W912EF 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EF-16-B-0012

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The following have been added by full text:

AMENDMENT 0001

Summary of changes for Amend -0001 McNary Washington Shore Fish Ladder Lamprey Modifications

1. Revised the following Specifications (See revised specification for details):

a. SECTION 01 14 00.10 28 PROJECT SITE RESTRICTIONS

Revised Paragraph 1.6.1 General

b. SECTION 01 55 10.00 28 CONTRACTOR WORK, ACCESS AND STORAGE AREAS Revised Paragraph 1.4.1 Government Crane Service

2. Revised the following Clauses (See Yellow Highlights):

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than as detailed below.

ALL US Army Corps of Engineers locks on the Columbia/Snake River system will be out of service for an extended outage between 6:00 A.M. on 12 December 2016 and ends at 6:00 P.M.

on 20 March 2017.

The Contractor will have access to the Washington Fish Ladder, for work on this contract, from 8 December 2016 through 11:59 p.m. 20 January 2017. See Section 01 14 00.10 28 PROJECT SITE RESTRICTIONS, paragraph FISH LADDER WORK RESTRICTIONS for additional information.

The Project will be performing required maintenance on the tilting weirs during this same fish ladder outage (See Section 01 14 00.10 28 PROJECT SITE RESTRICTIONS, paragraph "Government's Work Schedule" for Government work hours). Initial coordination between the Government and Contractor will take place at the Pre-Work Meeting. See Section 01 11 01.00 28 SUPPLEMENTARY REQUIREMENTS, paragraph Pre-Work Meeting. Anticipate that the required coordination will require the Contractor to work sequentially from one end of the fish ladder exit weirs to the other.

(1) The Contractor shall complete all work for the Lamprey Modifications of the Washington shore fishway by not later than 11:59 p.m. 20 January 2017, to allow rewatering of the fish ladder, and additional project work by the Government.

(2) The Contractor shall complete final cleanup and demobilization (for all items and equipment) by not later than 15 calendar days after completion of work in (1) above

(3) The Contractor shall complete final submission of working “as-built” contract drawings and final approved versions of Contractor prepared drawings (see Section 01 78 00.00 28 CLOSEOUT SUBMITTALS) by not later than 30 calendar days after completion of work in (1) above.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,270.00 for each calendar day of delay until the work specified in subparagraph (c)(1) of FAR Clause

52.211-10, COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK(APR

1984), until the Contractor has completed the work as specified or satisfactorily prepared work area in preparation for work to resume in the next in-water work window.

(b) (The Contractor will lose access to the work site beginning 11:59 p.m. 20 January 2017. The Government will resume assessing liquidated damages on 1 January 2018. Liquidated damages will continue to accrue until the Contractor completes all work, including the work referenced in paragraph (c)(1) of FAR Clause 52.211-1, COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK (APR 1984), and work has been accepted by the Government.

(c) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)