A22c_W912EE23B0011-0003 Amt No. 3.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Reference Solicitation No. W912EE-23-B-0011, for Yazoo County, Mississippi, Yazoo City Pump Station Trash Rake, FC/MR&T, Yazoo River Basin, Yazoo River, is amended as follow s:

SEE CONTINUATION PAGE FOR SUMMARY OF CHANGES.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 02-Aug-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EE23B0011

X 9B. DATED (SEE ITEM 11)

06-Jul-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

03-Aug-2023

CODE

VICKSBURG CONTRACTING OFFICE

4155 CLAY ST

VICKSBURG MS 39183-3435

W912EE 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EE23B0011

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0003

SUMMARY OF CHANGES

SPECIFICATIONS: SF1442 and Section 00 80 00.00 09 are revised and replaced.

Specifications revised by this amendment have the notation "Revised by Amendment 0003" at the bottom of the page. Text added by this amendment is shown as underlined. Text deleted by this amendment is shown as overstruck.

(End of Summary of Changes)

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

W912EE23B0011

Vicksburg Contracting Office 4155 Clay ST.

Vicksburg, MS 39183-3435

YAZOO COUNTY, MISSISSIPPI

YAZOO CITY PUMP STATION TRASH RAKE

FC/MR&T, YAZOO BASIN

YAZOO RIVER

DESCRIPTION OF WORK: The work consists of furnishing all plant, labor, materials, and equipment, for constructing of the trash rake machine and access road realignment. Principal features of the work include mobilization and demobilization, installation of the trash rake machine, trash debris dump trailer, earthwork, stone protection, road paving, storm water pollution prevention, and environmental protection.

The estimated value of the proposed work is between $1,000,000 and $5,000,000.

SEE SPECIAL NOTICES TO BIDDERS

5. REQUISITION/PURCHASE REQUEST NUMBER

W807PM31142551

W912EE

LAWREN BOOLOS 601.631.5211

107/06/2023

8/8/2023

14:00 CST

Section 00 80 00.00 09

Revised By Amendment 0003

B4CTTRES

Highlight

B4CTTRES

Highlight

B4CTTRES

Highlight

W912EE-23-B-0011

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 80 00.00 09

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

1.2 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

1.3 LIQUIDATED DAMAGES-CONSTRUCTION

1.4 CONTRACT DRAWINGS AND SPECIFICATIONS

1.5 CORRESPONDENCE AND ELECTRONIC COMMUNICATION

1.6 WORK TO BE PERFORMED BY CONTRACTOR'S OWN ORGANIZATION

1.7 PERFORMANCE OF WORK BY THE CONTRACTOR

1.8 WORK TO BE PERFORMED BY CONTRACTOR'S OWN ORGANIZATION

1.9 PHYSICAL DATA

1.10 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.11 OBSTRUCTION OF NAVIGABLE WATERWAYS

1.12 GENERAL SECURITY REQUIREMENTS AND GUIDANCE

1.13 ANTITERRORISM (AT) LEVEL 1 TRAINING

1.14 PHYSICAL SECURITY AND ACCESS CONTROL REQUIREMENTS

1.15 SUSPICIOUS ACTIVITY REPORTING TRAINING (E.G., IWATCH, CORPSWATCH,

OR SEE SOMETHING, SAY SOMETHING)

1.16 ESCORTING IN CLASSIFIED AND/OR SENSITIVE AREAS

1.17 PRE-SCREEN CANDIDATES USING E-VERIFY PROGRAM

1.18 NON-U.S. CITIZENS WORKING ON GOVERNMENT CONTRACTS

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section Table of Contents --

DOCUMENT 00 80 00.00 09 Page 1 Revised By Amendment 0003

SECTION 00 80 00.00 09

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this section to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EP-1110-1-8 (2009) Construction Equipment Ownership and Operating Expense Schedule

1.2 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 240380 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises. (FAR 52.211-10)

1.3 LIQUIDATED DAMAGES-CONSTRUCTION

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,108.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (FAR 52.211-12)

1.4 CONTRACT DRAWINGS AND SPECIFICATIONS

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall --

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

DOCUMENT 00 80 00.00 09 Page 2

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general --

(1) Large-scale drawings shall govern small scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the INDEX TO DRAWINGS shown on Drawing No.

G-002 entitled PROJECT LOCATION MAP AND INDEX TO DRAWINGS.

(DFARS 252.236-7001)

1.5 CORRESPONDENCE AND ELECTRONIC COMMUNICATION

For ease and speed of communications, both the Government and Contractor shall exchange correspondence and all other documents duplicate in both hard paper copy and electronic format. Inclusion of an electronic copy is in addition to any other parts of the contract that may specify a minimum number of hard copies to be submitted, such as for shop drawing transmittals. Electronic submission can be accomplished by one of the following methods: email, file upload to the following DoD Safe website https://safe.apps.mil/, or through the Resident Management System - Contractor Mode (RMS-CM) software interface with the Resident Management System (RMS). Format for electronic submissions will be in portable document format (.pdf). File naming will be determined by the Contracting Officer and presented at the Preconstruction Conference. Documents include all general correspondence, administrative plans, all material submittals including shop drawings, progress schedules, submittal registers, requests for information (RFIs), Quality Control (QC) test results, pay requests, etc. Paper documents will govern, in the event of discrepancy with the electronic version. Generally, paper documents will also govern where effective receipt dates are required, such as contractor claims submitted under the Disputes clause of the contract and progress payment requests. However in the case of administrative plans, shop drawings and other submittals transmitted for government review, both the electronic and hard copies are required to begin the review process, so the effective date of receipt will be the date when both the electronic and hard copies are received by the government.

1.6 WORK TO BE PERFORMED BY CONTRACTOR'S OWN ORGANIZATION

Within 10 days after award, the successful Bidder/Contractor must furnish the Contracting Officer a description of the items of work which will be performed with its own forces and the estimated cost of those items. (See Contract Clause LIMITATIONS ON SUBCONTRACTING.)

DOCUMENT 00 80 00.00 09 Page 3

1.7 PERFORMANCE OF WORK BY THE CONTRACTOR

The Contractor shall perform on the site and with its own organization, work equivalent to at least twenty (20) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government. (FAR 52.236-1)

1.8 WORK TO BE PERFORMED BY CONTRACTOR'S OWN ORGANIZATION

Within 10 days after award, the successful Bidder/Contractor must furnish the Contracting Officer a description of the items of work which will be performed with its own forces and the estimated cost of those items. (See paragraph PERFORMANCE OF WORK BY THE CONTRACTOR.)

1.9 PHYSICAL DATA

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys.

(b) Weather Conditions. Information with respect to temperatures and precipitation may be obtained from the National Weather Service.

(c) Transportation Facilities.

(1) Roads. Interstate 20 and 55, U.S. Highway No. 61, Mississippi State Highway No. 3, and local roads serve the general area.

(2) Railroads. The Contractor is responsible for determining the availability of railroad service.

(d) Floods. High water stages or events are not to be considered a "flood", and damages resulting therefrom are not compensable under Section 01 00 00.00 09 GENERAL CONTRACT REQUIREMENTS, paragraph DAMAGE TO WORK unless high water stages or events exceed Elevation 90 NGVD at Site Yazoo City Pump Station (Landside).

1.10 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

(a) This special contract requirement does not apply to terminations. See 52.249-500, Basis for Settlement of Proposals and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a Contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the

DOCUMENT 00 80 00.00 09 Page 4

Contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region III.

Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the Contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

(USACE Acquisition Instruction ("UAI") 31.105-101)

NOTE: EP-1110-1-8 , "Construction Equipment Ownership and Operating Expense Schedule" is available on the Internet at http://www.publications.usace.army.mil/USACEPublications/EngineerPamphlets.aspx, then search for EP 1110-1-8, then click on the link and then choose EP_1110-1-8_Vol-03.pdf or may be purchased from the Government Printing Office on CD-ROM by calling (202) 512-1800.

1.11 OBSTRUCTION OF NAVIGABLE WATERWAYS

(a) The Contractor shall-

(1) Promptly recover and remove any material, plant, machinery, or appliance which the Contractor loses, dumps, throws overboard, sinks, or misplaces, and which, in the opinion of the Contracting Officer, may be dangerous to or obstruct navigation;

(2) Give immediate notice, with description and locations of any such obstructions, to the Contracting Officer; and

(3) When required by the Contracting Officer, mark or buoy such obstructions until the same are removed.

(b) The Contracting Officer may--

(1) Remove the obstructions by contract or otherwise should the Contractor refuse, neglect, or delay compliance with paragraph (a) of this clause; and

(2) Deduct the cost of removal from any monies due or to become due to the Contractor; or

DOCUMENT 00 80 00.00 09 Page 5

(3) Recover the cost of removal under the Contractor's bond.

(c) The Contractor's liability for the removal of a vessel wrecked or sunk without fault or negligence is limited to that provided in Sections 15, 19, and 20 of the River and Harbor Act of March 3, 1899 (33 U.S.C. 410 et. seq). (DFARS 52.236-7002)

1.12 GENERAL SECURITY REQUIREMENTS AND GUIDANCE

The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts.

The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations.

Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures.

The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures, to include identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

1.13 ANTITERRORISM (AT) LEVEL 1 TRAINING

All contract personnel requiring routine access to Army installations, facilities, and controlled access areas, or requiring network access shall complete initial and annual refresher AT Level I awareness training.

Online AT Level I awareness training is available at https://jko.jten.mil/ (website subject to change).

1.14 PHYSICAL SECURITY AND ACCESS CONTROL REQUIREMENTS

All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that

DOCUMENT 00 80 00.00 09 Page 6 location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-III") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

1.15 SUSPICIOUS ACTIVITY REPORTING TRAINING (E.G., IWATCH, CORPSWATCH, OR

SEE SOMETHING, SAY SOMETHING)

All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

1.16 ESCORTING IN CLASSIFIED AND/OR SENSITIVE AREAS

In accordance with applicable regulations, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas.

1.17 PRE-SCREEN CANDIDATES USING E-VERIFY PROGRAM

Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at ( https://www.e-verify.gov/ ) (website subject to change) to meet the contract employment eligibility requirements.

Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/ eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

1.18 NON-U.S. CITIZENS WORKING ON GOVERNMENT CONTRACTS

Government Approval MUST be obtained PRIOR to any non-U.S. Citizen being permitted to work on a government contract. The Contractor must submit a letter requesting approval via the Contracting Officer/Contracting Officer Representative to the Vicksburg District Security Officer. The letter must include the contract number, period of performance, location(s) of work performance and attach a copy of the individual's passport and visa/work authorization documents.

DOCUMENT 00 80 00.00 09 Page 7

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section --

DOCUMENT 00 80 00.00 09 Page 8