A22_Amendment_0003_W912EE-16-B-0005-0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Reference Solicitation No. W912EE-16-B-0005, for Lease of One Cutterhead, Hydraulic Pipeline Dredge (Not Less Than 22-Inch Diameter), Fully Operated w ith Attendant Plant and Personnel, w ith a Draft not to Exceed 9 Feet, for Construction and Maintenance Dredging w ithin the Vicksburg District, Other Districts w ithin the Mississippi Valley Division, or Districts Adjacent to the Vicksburg District, is amended as follow s:

SEE CONTINUATION PAGE FOR SUMMARY OF CHANGES.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 19-Oct-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EE-16-B-0005

X 9B. DATED (SEE ITEM 11)

11-May-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

19-Oct-2016

CODE

VICKSBURG CONTRACTING OFFICE

4155 CLAY ST

VICKSBURG MS 39183-3435

W912EE 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EE-16-B-0005

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SPECIFICATIONS: Section 00 80 00.00 09 is revised and replaced.

Specifications revised by this amendment have the notation "Revised by Amendment 0003" at the bottom of the page. Text added by this amendment is shown as underlined. Text deleted by this amendment is shown as overstruck.

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 80 00.00 09

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DELIVERY, PROSECUTION, TERMINATION, AND SUBSTITUTION OF PLANT

1.1.1 Delivery

1.1.2 Prosecution

1.1.3 Termination

1.1.4 Substitution of Plant

1.2 WORK TO BE PERFORMED BY CONTRACTOR'S OWN ORGANIZATION

1.3 PERFORMANCE OF WORK BY THE CONTRACTOR

1.4 PHYSICAL DATA (APR 1984)

1.5 MISPLACED MATERIALS

1.6 FUEL TRANSFER

1.7 ENVIRONMENTAL PROTECTION

1.7.1 Scope

1.7.2 Quality Control

1.7.3 Submittals

1.7.4 Notification

1.7.5 Protection of the Environmental Resources

1.7.6 Maintenance of Pollution Control Facilities

1.7.7 Training of Contractor Personnel in Pollution Control

1.7.8 Payment

1.8 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.9 ENVIRONMENTAL LITIGATION

1.10 VARIATION IN ESTIMATED QUANTITIES - SUBDIVIDED ITEMS (MAR 1995)

1.11 ACCESS AND GENERAL PROTECTION/SECURITY POLICY AND PROCEDURES

1.12 PRE-SCREEN CANDIDATES USING E-VERIFY PROGRAM

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section Table of Contents --

DOCUMENT 00 80 00.00 09 Page 1 Revised By Amendment 0003

SECTION 00 80 00.00 09

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DELIVERY, PROSECUTION, TERMINATION, AND SUBSTITUTION OF PLANT

1.1.1 Delivery

a. The Contractor shall deliver the dredge and attendant plant ready for operation to the first work location as described in Section 35 20 23.00 09 DREDGING, paragraph, FIRST WORK LOCATION, or to any alternate work site nearer to the point of origin as may be directed, within 30 calendar days after date of receipt by the Contractor of notice to proceed. The plant will undergo a government inspection within 7-10 days after the bid opening, and the contractor notified of acceptance or rejection.

b. A prework conference will be held prior to commencement of work.

The time and place of the conference will be determined by mutual agreement between the Contracting Officer or his designated representative and the Contractor.

1.1.2 Prosecution

The Contractor shall prosecute the work assigned him to meet the schedule of dredging operations as determined by the Contracting Officer. The work schedule will normally be 24 hours per day, 7 days per week .

1.1.3 Termination

Upon termination or completion of the contract, the dredge and attendant plant will be released to the Contractor at the site of the final work location.

1.1.4 Substitution of Plant

Substitution of dredge or dredges will be allowed in rare cases provided the Contractor furnishes written justification and the following conditions are met:

a. The substitute dredge meets all requirements of the contract specifications, and the Contractor submits clear evidence that the proposed substitute dredge can, and has performed at the rate set forth in Section 35 20 23.00 09 DREDGING, paragraph DREDGING EQUIPMENT.

b. The substitute dredge will be made available for inspection by Government personnel prior to beginning work and prior to the release of the working dredge.

c. The Government is reimbursed all costs in connection with inspection of the substitute dredge.

d. The substitute dredge is delivered to the worksite before the original dredge is shutdown and moved off the jobsite. This

DOCUMENT 00 80 00.00 09 Page 2 requirement does not apply to substitutions made during suspension and release periods as per Section 01 00 00.00 09 GENERAL CONTRACT REQUIREMENTS, paragraph DURATION OF CONTRACT, subparagraph "c".

e. The submitted rate for the substitute dredge has been determined by the Contracting Officer to be in the best interest of the Government.

f. Substitution of plant will not be allowed prior to award of contract.

g. If the substitute dredge does not meet the specifications for the bid item of the original dredge, the hourly rate of the substitute dredge shall be computed by the following formula:

Substitute Dredge Hourly Rate = ((Original Hourly Rate)X(Estimated Hours in Original Bid Item))/(Estimated Hours in Bid Item Applicable to Substitute Dredge)

1.2 WORK TO BE PERFORMED BY CONTRACTOR'S OWN ORGANIZATION

Within 10 days after award, the successful Bidder/Contractor must furnish the Contracting Officer a description of the items of work which will be performed with its own forces and the estimated cost of those items. (See paragraph PERFORMANCE OF WORK BY THE CONTRACTOR.)

1.3 PERFORMANCE OF WORK BY THE CONTRACTOR

The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifty (50) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government. (FAR 52.236-1)

1.4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) Weather Conditions. Data on weather conditions may be obtained from the National Weather Service.

(b) Transportation Facilities. Floating plant may reach the sites of work via the Mississippi, Red, and Ouachita/Black Rivers. Obtaining access through private lands to landings near the sites of work for land transportation is the responsibility of the Contractor.

c. Channel Traffic. Traffic on the rivers consists of commercial towboats and tows, passenger vessels, and small boats. Traffic in the river and harbors may interfere to some extent with dredging operations.

d. The material to be dredged will consist of sand, gravel, loose rock, silt, mud and clay; and in certain localities stumps, roots, logs, riprap, driftwood, sunken objects, and miscellaneous debris may be encountered. The dredge must be equipped with suitable pump impellers and cutters to efficiently handle these varying materials on pipeline lengths up to 6,500 feet.

DOCUMENT 00 80 00.00 09 Page 3

e. The work required consists of making or enlarging dredge cuts, construction of fills, and dredging in various channels and harbors.

The currents may vary from 0 to 7 feet per second. The bank to be cut may extend as much as 45 feet above the water surface.

f. The dredging operations contemplated are not all in or near cities. Camps or floating plant may be necessary for the housing or boarding of the labor employed by the Contractor.

g. Obstruction of Channel. The Government will not keep the channel free from vessels or other obstructions, except to the extent of such regulations, if any, as may be prescribed by the Secretary of the Army in accordance with provisions of Section 7 of the River and Harbor Act, approved 8 August 1917. The Contractor is required to conduct the work in such a manner as to obstruct navigation as little as possible, and if the Contractor's plant obstructs the channel as to make difficult or endanger the passage of vessels, said plant shall be promptly moved on the approach of any vessel to such an extent as may be necessary to afford a safe passage. Upon completion of the work, the Contractor shall promptly remove his plant, including ranges, buoys, piles, and other markers placed by him under the contract in navigable water or on shore.

h. During the contract period, there is a possibility that the Contractor will receive requests from private interests and local governments to dredge outside the channel limits alongside privately owned wharfs or docks. Provided the work can be accomplished without detriment to the work assigned by the Government, and subject to the prior approval of the Contracting Officer in each instance, the Contractor may utilize during the contract period, equipment being furnished to the Government under this contract for accomplishing work requested by said private interests and local governments. It is understood and agreed that in temporarily releasing the Contractor's equipment for performing work outside of channel limits for private interests and local governments, the Government does not assume any responsibility whatsoever for the said work, or for the collection from said private interests and local governments of any amounts earned for work performed.

i. Condition of Channel. Data on current channel conditions may be obtained from the U.S. Coast Guard.

1.5 MISPLACED MATERIALS

Should the Contractor during the progress of the work lose, dump, throw overboard, sink, or misplace any material, plant, machinery, or appliance, which in the opinion of the Contracting Officer may be dangerous to or obstruct navigation, the Contractor shall immediately recover and remove the object. The Contractor shall give immediate notice, with description and location of such obstructions, to the Contracting Officer or inspector, and when required, mark or buoy such obstructions until removed. Should the Contractor refuse, neglect, or delay compliance with the above requirements, the obstruction may be removed by the Contracting Officer, and the cost of such removal may be deducted from any money due or to become due the Contractor, or may be recovered under his bond. The liability of the Contractor of the removal of a vessel wrecked or sunk without fault or negligence shall be limited to that provided in Sections 15, 19, and 20 of the River and Harbor Act of 3 March 1899 (33 U.S.C. 410, DOCUMENT 00 80 00.00 09 Page 4 et seq.)

1.6 FUEL TRANSFER

When marine plant and equipment are in use under this contract, a safe means of fuel transfer will be used. This fuel transfer will meet the Coast Guard Regulations 33 CFR 156.120 regarding fuel/oil transfer operations and 33 CFR 155.320 fuel/oil discharge containment. The marine plant will be checked for compliance before the plant is allowed to be used on the contract.

1.7 ENVIRONMENTAL PROTECTION

1.7.1 Scope

This section covers prevention of environmental pollution and damage as the result of construction operations under this contract and for those measures set forth in this specification, environmental pollution and damage is defined as the presence of chemical, physical, or biological elements or agents which adversely affect human health or welfare;

unfavorably alter ecological balances of importance to human life; affect other species of importance to man; or degrade the utility of the environment for aesthetic, cultural and/or historical purposes. The control of environmental pollution and damage requires consideration of air, water, and land, and includes management of visual aesthetics, noises, solid waste, radiant energy, and radioactive materials, as well as other pollutants.

1.7.2 Quality Control

The Contractor shall establish and maintain quality control for environmental protection of all items set forth herein. The Contractor shall record on daily reports any problems complying with laws, regulations and ordinances and corrective action taken.

1.7.3 Submittals

a. General. Within 15 days after Award of the contract, an Environmental Protection Plan shall be submitted to the Contracting Officer for review and acceptance. The Contractor shall submit an environmental protection plan in accordance with provisions as herein specified. The plan shall include but not be limited to the following:

(1) A list of Federal, State, and local laws, regulations, and permits concerning environmental protection, pollution control, and abatement that are applicable to the Contractor's proposed operations, and the requirements imposed by those laws, regulations, and permits.

(2) Methods for protection of features to be preserved within authorized work areas. The Contractor shall prepare a listing of the methods to protect resources needing protection, including but not limited to trees, shrubs, vines, grasses and ground cover, landscape features, air and water quality, fish and wildlife, soil, historical, archaeological, and cultural resources.

(3) Procedures to be implemented to provide the required environmental protection and to comply with the applicable laws and regulations. The Contractor shall set out the procedures to

DOCUMENT 00 80 00.00 09 Page 5 be followed to correct pollution of the environment due to accident, natural causes, or failure to follow the procedures set out in accordance with the Environmental Protection Plan.

(4) Permit or license and the location of the solid waste disposal area.

(5) Environmental monitoring plans for the job site, including land, water, air, and noise monitoring.

b. Implementation. Prior to commencement of the work, the Contractor shall submit in writing the above Environmental Protection Plan.

Approval of the Contractor's plan will not relieve the Contractor of his responsibility for adequate and continuing control of pollutants and other environmental protection measures. The Contractor shall not commence physical work at the site until the plan has been accepted by the Contracting Officer, or his authorized representative.

1.7.4 Notification

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with the aforementioned Federal, State, or local laws or regulations, permits, and other elements of the Contractor's environmental protection plan. The Contractor shall, after receipt of such notice, inform the Contracting Officer of proposed corrective action and take such action as may be approved. If the Contractor fails to comply, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No time extension shall be granted, or costs or damages allowed to the Contractor for any such suspension.

1.7.5 Protection of the Environmental Resources

a. General. The environmental resources within the project boundaries and those affected outside the limits of permanent work under this contract shall be protected during the entire period of this contract.

The Contractor shall confine his activities to areas defined by the drawings and specifications. Environmental protection shall be as stated in the following paragraphs.

b. Protection of Land Resources

(1) Disposal of Solid Wastes, General. Solid wastes (excluding material resulting from clearing and grubbing) shall be placed in containers which are emptied on a regular schedule. All handling and disposal shall be conducted to prevent contamination.

(2) Disposal of Solid Waste by Removal From Site. The Contractor shall transport all solid waste off of the work site and dispose of it in compliance with federal, state, and local requirements for solid waste disposal.

(3) Disposal of Chemical Waste. Chemical waste shall be stored in corrosion resistant containers, removed from the work area, and disposed of in accordance with federal, state, and local regulations.

(4) Disposal of Discarded Materials. Discarded materials other than those which can be included in the solid waste category will

DOCUMENT 00 80 00.00 09 Page 6 be disposed of as directed by the Contracting Officer.

c. Preservation and Recovery of Historical Archaeological and Cultural Resources. Known historical, archaeological, and cultural resources within the Contractor's work area will be designated by the Contracting Officer, and the Contractor shall take precautions to preserve all such resources as they existed at the time they were pointed out to the Contractor. The Contractor shall install all protection for these resources and shall be responsible for their preservation during this contract. All items having any historical or archaeological interest which are discovered in the course of any construction activities shall be carefully preserved. The Contractor shall leave the archaeological find undisturbed and shall immediately report the find to the Contracting Officer so that the proper authorities may be notified.

d. Protection of Air Resources

(1) General. The Contractor shall keep construction activities under surveillance, management, and control to minimize pollution of air resources. All activities, equipment, processes, and work operated or performed by the Contractor in accomplishing the specified construction activities shall be in strict accordance with the applicable state air pollution regulations and all Federal emission and performance laws and standards. Ambient Air Quality Standards set by the Environmental Protection Agency shall be maintained for those construction operations and activities specified in this section. Special management techniques as set out below shall be implemented to control air pollution by the construction activities which are included in the contract.

(2) Hydrocarbons and Carbon Monoxide. Hydrocarbons and carbon monoxide emissions from equipment shall be controlled to Federal and State allowed limits at all times.

(3) Odors. Odors shall be controlled at all times for all construction activities, processing, and preparation of materials.

(4) Monitoring of Air Quality. Monitoring of air quality shall be the responsibility of the Contractor. All air areas affected by the construction activities shall be monitored by the Contractor.

1.7.6 Maintenance of Pollution Control Facilities

The Contractor shall maintain all constructed facilities and portable pollution control devices for the duration of the contract, or for that length of time construction activities create the particular pollutant.

1.7.7 Training of Contractor Personnel in Pollution Control

The Contractor shall train his personnel in all phases of environmental protection. The training shall include methods of detecting and avoiding pollution, familiarization with pollution standards, both statutory and contractual, and installation and care of facilities (vegetative covers, and instruments required for monitoring purposes) to ensure: adequate and continuous environmental pollution control.

DOCUMENT 00 80 00.00 09 Page 7

1.7.8 Payment

No separate payment or direct payment will be made for the cost of the work covered under this section, and such work will be considered as a subsidiary obligation of the Contractor.

1.8 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

(a) This special contract requirement does not apply to terminations.

See 52.249-5000, Basis for Settlement of Proposals and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a Contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the Contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the Contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region III. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the Contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

(UAI 31.105-101)

NOTE: EP-1110-1-8, "Construction Equipment Ownership and Operating Expense Schedule" is available on the Internet at http://www.usace.army.mil/inet/usace-docs/eng-pamphlets/ep.htm or may be purchased from the Government Printing Office on CD-ROM by calling (202) 512-1800.

1.9 ENVIRONMENTAL LITIGATION

a. If the performance of all or any part of the work is suspended, delayed, or interrupted due to an order of a court of competent jurisdiction as a result of environmental litigation, as defined below, the Contracting Officer, at the request of the Contractor, shall

DOCUMENT 00 80 00.00 09 Page 8 determine whether the order is due in any part to the acts or omissions of the Contractor, or a Subcontractor at any tier, not required by the terms of the contract. If it is determined that the order is not due in any part to acts or omissions of the Contractor, or a Subcontractor at any tier, other than as required by the terms of this contract, such suspension, delay, or interruption shall be considered as if ordered by the Contracting Officer in the administration of this contract under the terms of the Contract Clause SUSPENSION OF WORK in this contract.

The period of such suspension, delay, or interruption shall be considered unreasonable, and an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) as provided in that clause, subject to all the provisions thereof.

b. The term "Environmental Litigation", as used herein, means a lawsuit alleging that the work will have an adverse effect on the environment, or that the Government has not duly considered, either substantively or procedurally, the effect of the work on the environment.

1.10 VARIATION IN ESTIMATED QUANTITIES - SUBDIVIDED ITEMS (MAR 1995)

This variation in estimated quantities clause is applicable only to Item Nos. 0001, 0002, 0003, 0004, 0005, 0006, 0007, 0008, 0015, 0016, 0017, 0018, 0019, 0020, 0021, and 0022, 0023, 0024, 0025, 0026, 0027, 0028, 0029, and 0030.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent sub-item or elimination of all work under such a second or subsequent sub-item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for Item Nos. 0001, 0002, 0003, 0004, 0005, 0006, 0007, 0008, 0015, 0016, 0017, 0018, 0019, 0020, 0021, and 0022, 0023, 0024, 0025, 0026, 0027, 0028, 0029, and 0030 is less than 85 percent of the quantity of the first sub-item listed under such item, the Contractor will be paid at the contract unit price for that sub-item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause FAR 52.211-18, Variation in Estimated Quantity.

(c) If the actual quantity of work performed under Item Nos. 0001, 0002, 0003, 0004, 0005, 0006, 0007, 0008, 0015, 0016, 0017, 0018, 0019, 0020, 0021, and 0022, 0023, 0024, 0025, 0026, 0027, 0028, 0029, and 0030 exceeds 115 percent or is less than 85 percent of the total estimated quantity of the sub-item under that item, and/or if the quantity of the work performed under the second sub-item or any subsequent sub-item under Item Nos. 0001, 0002, 0003, 0004, 0005, 0006, 0007, 0008, 0015, 0016, 0017, 0018, 0019, 0020, 0021, and 0022, 0023, 0024, 0025, 0026, 0027, 0028, 0029, and 0030 exceeds 115 percent or is less than 85 percent of the estimated quantity of any such sub-item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantity. (UAI 52.211-5001)

1.11 ACCESS AND GENERAL PROTECTION/SECURITY POLICY AND PROCEDURES

All Contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander

DOCUMENT 00 80 00.00 09 Page 9 installation/facility access and local security policies and procedures (provided by government representative). The Contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

All contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

1.12 PRE-SCREEN CANDIDATES USING E-VERIFY PROGRAM

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section --

DOCUMENT 00 80 00.00 09 Page 10