W912DS26BA008_Solicitation.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section 00 00 00 - Procurement and Contracting Requirements Instrument Name: Maintenance Dredging, Hudson River Federal Navigation Project, Reach N04, Troy, NY

W912DS26BA008

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price

Amount

0001 Mobilization & Demobilization Product Service Code: Y1KF Pricing Arrangement: Firm Fixed Price

1 Job

0002 Dredging Work: (12' MLLW + 1' OD).

Dredging of material except ledge rock to -14 feet mean lower low water (MLLW) + 1-foot allowable overdepth from the Hudson River Channel at Reach N04, Troy, NY, with Transportation and Placement of the dredged material at a licensed commercial disposal site of chosen by the Contractor. Estimated Quantities.

Product Service Code: Y1KF Pricing Arrangement: Firm Fixed Price

9,035 Cubic Yard

0003 Site Restoration Product Service Code: Y1KF Pricing Arrangement: Firm Fixed Price

1 Job

Section 00 20 00 - Instructions for Procurements

TOTAL BID (CLINs 0001 THRU 0003)..........................$ ___________________

NOTES TO BIDDERS:

1. Bidders must bid on all items. Failure to bid on all work will be cause for rejection of the bid as nonresponsive

2. Award of contract will be based on the responsible and responsive bidder with the lowest total price for the total of the CLINs 0001 through 0003.

3. The unit price for CLIN 0002 represents the cost per cubic yard for the removal, handling, transportation and placement of the estimated quantities of dredged material plus the respective allowable over-depth of 1 foot.

4. All bidders are hereby advised that the estimated dredge quantities for placement in the price schedule are estimated and based on the survey data collected from March 2025.

5. The Government may reject a bid as non-responsive if the prices bid are materially unbalanced between line items and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low bid.

6. Bidders are reminded that they must bid on the issued plans and specifications as amended.

Any deviations, conditions or attachments made by the bidder himself may render the proposal non-responsive and may be cause for its rejection.

*** END OF NARRATIVE ***

Section 00 21 00 - Instructions

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.204-7 System for Award Management- Registration. (Deviation 2026- O0038)

2026-02

52.214-3 Amendments to Invitations for Bids. (Deviation 2026-O0038)

2026-02

52.214-4 False Statements in Bids. 1984-04

52.214-5 Submission of Bids. (Deviation 2026-O0038)

2026-02

52.214-6 Explanation to Prospective Bidders.

1984-04

52.214-7 Late Submissions, Modifications, and Withdrawals of Bids.

(Deviation 2026-O0038)

2026-02

52.214-12 Preparation of Bids. 1984-04

52.214-34 Submission of Offers in the English Language.

1991-04

52.214-35 Submission of Offers in U.S.

Currency.

1991-04

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (Deviation 2026- O0038)

2026-02

52.225-12 Notice of Buy American Requirement-Construction Materials Under Trade Agreements.

2014-05

DFARS Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements.

2023-11

252.204-7024 Notice on the Use of the Supplier Performance Risk System.

2023-03

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors.

2023-01

FAR Provisions Incorporated by Full Text

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.216-1 Type of Contract. (Deviation 2026-O0038)

2026-02

Type of Contract (Feb 2026) (Deviation 2026-O0038)

The Government contemplates award of a contract resulting from this FIRM FIXED PRICE solicitation.

(End of provision)

52.228-1 Bid Guarantee. 1996-09

Bid Guarantee (Sept 1996)

Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening(a) of bids, may be cause for rejection of the bid.

The bidder shall furnish a bid guarantee in the form of a firm commitment, bid bond(b) e.g., supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

To unsuccessful bidders as soon as practicable after the opening of bids; and(1)

To the successful bidder upon execution of contractual documents and bonds (including any(2) necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

The amount of the bid guarantee shall be percent of the bid price or ,(c) 20% $3,000,000.00 whichever is less.

If the successful bidder, upon acceptance of its bid by the Government within the period(d) specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

In the event the contract is terminated for default, the bidder is liable for any cost of(e) acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

52.252-1 Solicitation Provisions Incorporated by Reference.

1998-02

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far

(End of provision)

52.252-3 Alterations in Solicitation. 1984-04

Alterations in Solicitation (Apr 1984)

Portions of this solicitation are altered as follows:

N/A

(End of clause)

52.252-5 Authorized Deviations in Provisions.

2020-11

Authorized Deviations in Provisions (Nov 2020)

The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1)(a) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

The use in this solicitation of any (b) Defense Acquisition Regulation (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

DFARS Provisions Incorporated by Full Text

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.215-7008 Only One Offer. 2022-12

ONLY ONE OFFER (DEC 2022)

(a) Cost or pricing data requirements. After initial submission of offers, if the Contracting Officer notifies the Offeror that only one offer was received, the Offeror agrees to-

(1) Submit any additional cost or pricing data that is required in order to determine whether the price is fair and reasonable (10 U.S.C. 3705) or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 3702 and FAR 15.403-3); and

(2) Except as provided in paragraph (b) of this provision, if the acquisition exceeds the certified cost or pricing data threshold and an exception to the requirement for certified cost or pricing data at FAR 15.403-1(b)(2) through (5) does not apply, certify all cost or pricing data in accordance with paragraph (c) of DFARS provision 252.215-7010, Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data, of this solicitation.

(b) Canadian Commercial Corporation. If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with DFARS 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.

S. Contracting Officer that the proposed price is fair and reasonable ____[U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(c) Subcontracts. Unless the Offeror is the Canadian Commercial Corporation, the Offeror shall insert the substance of this provision, including this paragraph (c), in all subcontracts exceeding the simplified acquisition threshold defined in FAR part 2.

(End of provision)

Section 00 21 13 - Instructions to Bidders

CPARS - The Federal Acquisition Regulation (FAR) requires that Past Performance Information (PPI)be collected on DoD contracts. The Contractor Performance Assessment Reporting System (CPARS) is a web enabled application the supports the completion, distribution and retrieval of all contract performance evaluations. Contractor Representative are responsible for reviewing and commenting on evaluations submitted on the Contractor Performance Assessment Reporting System (CPARS)website at https://www.cpars.gov/index.htm.

BONDS - The Standard Forms (SF24, SF25, and SF25A) for these bonds have been revised as of October 2023, when including your bid/offer, contractors/sureties shall use the revised versions.

No other version will be valid and thus may render your bid/offer nonresponsive.

E VERIFY - "The Contractor must pre-screen Candidates using the E-Verify Program(http://www.

uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-Verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3business days after the initial contract award." *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

BID SUBMISSION INSTRUCTIONS - Contractors are required to deliver Bids to 26 Federal Plaza room 16-300 the designated recipient of bids is Nicholas Emanuel (917) 790-8069. Bids are due no later than 02 July 2026 at 2:00 P.M. Bid opening will happen on 01 July 2026 at 2:00 P.M.EST

NOTE: If dropping bids off in person, please advise via email to orlando.nieves@usace.army.mil and nicholas.p.emanuel@usace.army.mil

The government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive proposals. Offerors are responsible for ensuring that Bids are submitted so as to reach the designated recipient and designated location. Offerors are responsible for allowing sufficient time for the bids to be received in accordance with the instructions provided. Bidders are encouraged to call into the following teleconference line:

Dial in by phone

+1-601-262-2433, United States

Phone conference ID: 936 152 298#

Bidder must keep their phone on mute as to not disrupt the reader. Please limit the amount of company employees calling into the line so that the line does not disconnect. The abstract of bids will be posted to the Sam.Gov website.

ADDITIONAL INSTRUCTIONS

Potential Bidders are reminded that only the minimum documents are required for bid submission:

1. Signed 1442.

2. Acknowledged amendments.

3. Filled out bid schedule and totals.

4. Bid Guarantee.

5. Bidders must check off box (d)in 52.204-8 Annual Representations and Certifications (JAN 2025) for being on SAM.gov.

*** END OF NARRATIVE ***

Section 00 22 13 - Supplementary Instructions to Bidders

Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of condition)

*** END OF NARRATIVE ***

Section 00 45 00 - Representations and Certifications

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.

2024-09

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements- Representation.

2017-01

52.229-12 Tax on Certain Foreign Procurements.

2021-02

DFARS Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials.

2022-09

252.204-7008 Compliance with Safeguarding Covered Defense Information Controls.

2016-10

252.225-7055 Representation Regarding Business Operations with the Maduro Regime.

2022-05

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region- Representation.

2023-06

252.232-7016 Notice of Progress Payments or Performance-Based Payments.

2020-04

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.209-7 Information Regarding Responsibility Matters.

(Deviation 2026-O0038)

2026-02

Information Regarding Responsibility Matters (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this provision-

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

252.204-7007 Alternate A, Annual Representations and Certifications.

2025-10 Alternate A

2025-10

ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2025)

Substitute the following paragraphs (b), (d), and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (e) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (e) applies.

[ ] (ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.204-7016, Covered Defense Telecommunications Equipment or Services- Representation. Applies to all solicitations.

(ii) 252.216-7008, Economic Price Adjustment-Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $200,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)-Representation. Applies to solicitations and contracts when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)-Representation. Applies to solicitations and contracts when contract performance will be in Spain.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

[ ](i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

[ ](ii) 252.225-7000, Buy American-Balance of Payments Program Certificate.

[ ](iii) 252.225-7020, Trade Agreements Certificate.

[ ] Use with Alternate I.

[ ](iv) 252.225-7031, Secondary Arab Boycott of Israel.

[ ](v) 252.225-7035, Buy American-Free Trade Agreements-Balance of Payments Program Certificate.

[ ] Use with Alternate I.

[ ] Use with Alternate II.

[ ] Use with Alternate III.

[ ] Use with Alternate IV.

[ ] Use with Alternate V.

[ ](vi) 252.226-7002, Representation for Demonstration Project for Contractors Employing Persons with Disabilities.

[ ](vii) 252.232-7015, Performance-Based Payments-Representation.

(e) The Offeror has completed the annual representations and certifications electronically via the SAM website at https://www.sam.gov. After reviewing the SAM database information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [Offeror to insert changes, identifying change by provision number, title, date].

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Provision # Title Date Change

Any changes provided by the Offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

252.204-7016 Covered Defense Telecommunications Equipment or Services-Representation.

2019-12

COVERED DEFENSE TELECOMMUNICATIONS EQUIPMENT OR SERVICES-

REPRESENTATION (DEC 2019)

(a) Definitions. As used in this provision, "covered defense telecommunications equipment or services" has the meaning provided in the clause 252.204-7018, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered defense telecommunications equipment or services".

(c) Representation. The Offeror represents that it [ ] does, [ ] does not provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

252.204-7017 Prohibition on the Acquisition of Covered Defense

2021-05

Telecommunications Equipment or Services-Representation.

PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS

EQUIPMENT OR SERVICES-REPRESENTATION (MAY 2021)

The Offeror is not required to complete the representation in this provision if the Offeror has represented in the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation, that it "does not provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument."

(a) Definitions. "Covered defense telecommunications equipment or services," "covered mission," "critical technology," and "substantial or essential component," as used in this provision, have the meanings given in the 252.204-7018 clause, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services, of this solicitation.

(b) Prohibition. Section 1656 of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits agencies from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) at https://www.sam.gov for entities that are excluded when providing any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless a waiver is granted.

(d) Representation. If in its annual representations and certifications in SAM the Offeror has represented in paragraph (c) of the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation, that it "does" provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument, then the Offeror shall complete the following additional representation:

The Offeror represents that it [ ] will [ ] will not provide covered defense telecommunications equipment or services as a part of its offered products or services to DoD in the performance of any award resulting from this solicitation.

(e) Disclosures. If the Offeror has represented in paragraph (d) of this provision that it "will provide covered defense telecommunications equipment or services," the Offeror shall provide the following information as part of the offer:

(1) A description of all covered defense telecommunications equipment and services offered (include brand or manufacturer; product, such as model number, original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable).

(2) An explanation of the proposed use of covered defense telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition referenced in paragraph (b) of this provision.

(3) For services, the entity providing the covered defense telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known).

(4) For equipment, the entity that produced or provided the covered defense telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

Section 00 70 00 - Conditions of the Contract

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.219-9 Small Business Subcontracting Plan. (Deviation 2026-O0038) (Alternate I)

2026-02 Alternate I 2026-02

52.222-3 Convict Labor. (Deviation 2026- O0038)

2026-02

52.222-7 Withholding of Funds. (Deviation 2026-O0038)

2026-02

52.228-11 Pledges of Assets (DEVIATION 2020-O0016)

2021-02 Deviation 2020- O0016

2020-04

52.240-90 Security Prohibitions and Exclusions Representations and Certifications. (Deviation 2026- O0038)

2026-02

52.240-91 Security Prohibitions and Exclusions. (Deviation 2026- O0038)

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.247-7023 Transportation of Supplies by 2024-10 Alternate I 2024-10

Sea. (Alternate I)

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.228-15 Performance and Payment Bonds-Construction (Deviation 2020-O0016)

2020-06 Deviation 2020- O0016

2020-04

PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (APR 2020) (DEVIATION 2020-

O0016)

(a) Definitions. As used in this clause-

Original contract price means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) Amount of required bonds. Unless the resulting contract price is $150,000 or less, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance bonds (Standard Form 25, except that no seal is required). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment bonds (Standard Form 25A, except that no seal is required). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection.

(i) The Government may require additional performance and payment bond protection if the contract price is increased. The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.

(e) Notice of subcontractor waiver of protection (40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right is waived, and executed after such person has first furnished labor or material for use in the performance of the contract.

(End of clause)

Section 00 72 00 - General Conditions

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than . The time stated for 90 calendar days completion shall include final cleanup of the premises.

(End of clause)

*** END OF NARRATIVE ***

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.202-1 Definitions. 2020-06

52.203-3 Gratuities. 1984-04

52.203-5 Covenant Against Contingent Fees.

2014-05

52.203-6 Restrictions on Subcontractor Sales to the Government.

2020-06

52.203-7 Anti-Kickback Procedures. 2020-06

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

2014-05

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity.

2014-05

52.203-12 Limitation on Payments to Influence Certain Federal Transactions.

2020-06

52.203-13 Contractor Code of Business Ethics and Conduct.

2021-11

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-9 Personal Identity Verification of Contractor Personnel.

2011-01

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (Deviation 2026-O0038)

2026-02

52.204-13 System for Award Management- Maintenance. (Deviation 2026- O0038)

2026-02

52.204-14 Service Contract Reporting Requirements. (Deviation 2026- O0038)

2026-02

52.204-19 Incorporation by Reference of Representations and Certifications.

2014-12

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Deviation 2026- O0038)

2026-02

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters.

(Deviation 2026-O0038)

2026-02

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations.

(Deviation 2026-O0038)

2026-02

52.210-1 Market Research. (Deviation 2026-O0038)

2026-02

52.211-13 Time Extensions. 2000-09

52.214-18 Preparation of Bids-Construction. 1984-04

52.214-19 Contract Award-Sealed Bidding- Construction.

1996-08

52.214-26 Audit and Records-Sealed Bidding. (Deviation 2026-O0038)

2026-02

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data- Modifications-Sealed Bidding.

2020-06

52.214-28 Subcontractor Certified Cost or Pricing Data-Modifications- Sealed Bidding. (Deviation 2026- O0038)

2026-02

52.214-29 Order of Precedence-Sealed Bidding.

1986-01

52.219-8 Utilization of Small Business Concerns. (Deviation 2026- O0038)

2026-02

52.219-9 Small Business Subcontracting Plan. (Deviation 2026-O0038)

2026-02

52.219-16 Liquidated Damages- Subcontracting Plan. (Deviation 2026-O0038)

2026-02

52.222-4 Contract Work Hours and Safety Standards-Overtime Compensation. (Deviation 2026- O0038)

2026-02

52.222-6 Construction Wage Rate Requirements. (Deviation 2026- O0038)

2026-02

52.222-8 Payrolls and Basic Records.

(Deviation 2026-O0038)

2026-02

52.222-9 Apprentices and Trainees.

(Deviation 2026-O0038)

2026-02

52.222-10 Compliance with Copeland Act Requirements. (Deviation 2026- O0038)

2026-02

52.222-11 Subcontracts (Labor Standards).

(Deviation 2026-O0038)

2026-02

52.222-12 Contract Termination-Debarment. 2014-05

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. (Deviation 2026- O0038)

2026-02

52.222-15 Certification of Eligibility. 2014-05

52.222-19 Child Labor-Cooperation with Authorities and Remedies.

(Deviation 2026-O0038)

2026-03

52.222-30 Construction Wage Rate Requirements-Price Adjustment

2018-08

(None or Separately Specified Method).

52.222-35 Equal Opportunity for Veterans.

(Deviation 2026-O0038)

2026-02

52.222-36 Equal Opportunity for Workers with Disabilities. (Deviation 2026- O0038)

2026-02

52.222-37 Employment Reports on Veterans. (Deviation 2026- O0038)

2026-02

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (Deviation 2026- O0038)

2026-02

52.222-50 Combating Trafficking in Persons. (Deviation 2026-O0038)

2026-02

52.222-54 Employment Eligibility Verification. (Deviation 2026- O0038)

2026-02

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (Deviation 2026-O0038)

2026-02

52.222-62 Paid Sick Leave Under Executive Order 13706. (Deviation 2026- O0038)

2026-02

52.223-23 Sustainable Products. (Deviation 2026-O0038)

2026-02

52.226-7 Drug-Free Workplace. 2024-05

52.226-8 Encouraging Contractor Policies 2024-05 to Ban Text Messaging While Driving.

52.227-4 Patent Indemnity-Construction Contracts.

2007-12

52.228-2 Additional Bond Security. 1997-10

52.228-11 Individual Surety-Pledge of Assets.

2021-02

52.228-12 Prospective Subcontractor Requests for Bonds.

2022-12

52.228-14 Irrevocable Letter of Credit. 2014-11

52.228-17 Individual Surety-Pledge of Assets (Bid Guarantee).

2021-02

52.229-3 Federal, State, and Local Taxes. 2013-02

52.232-8 Discounts for Prompt Payment. 2002-02

52.232-17 Interest. 2014-05

52.232-23 Assignment of Claims. 2014-05

52.232-27 Prompt Payment for Construction Contracts.

2017-01

52.232-33 Payment by Electronic Funds Transfer-System for Award Management.

2018-10

52.232-39 Unenforceability of Unauthorized Obligations.

2013-06

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.233-1 Disputes. (Deviation 2026-

2026-02

52.233-3 Protest after Award. (Deviation 2026-O0038)

2026-02

52.233-4 Applicable Law for Breach of Contract Claim. (Deviation 2026- O0038)

2026-02

52.236-2 Differing Site Conditions.

(Deviation 2026-O0038)

2026-02

52.236-3 Site Investigation and Conditions Affecting the Work. (Deviation 2026-O0038)

2026-02

52.236-5 Material and Workmanship.

(Deviation 2026-O0038)

2026-02

52.236-6 Superintendence by the Contractor. (Deviation 2026- O0038)

2026-02

52.236-7 Permits and Responsibilities.

(Deviation 2026-O0038)

2026-02

52.236-8 Other Contracts. (Deviation 2026- O0038)

2026-02

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (Deviation 2026-O0038)

2026-02

52.236-10 Operations and Storage Areas.

(Deviation 2026-O0038)

2026-02

52.236-11 Use and Possession Prior to Completion. (Deviation 2026-

2026-02

52.236-12 Cleaning Up. (Deviation 2026- O0038)

2026-02

52.236-13 Accident Prevention. (Deviation 2026-O0038)

2026-02

52.236-14 Availability and Use of Utility Services. (Deviation 2026-O0038)

2026-02

52.236-15 Schedules for Construction Contracts. (Deviation 2026- O0038)

2026-02

52.236-16 Quantity Surveys. (Deviation 2026-O0038)

2026-02

52.236-17 Layout of Work. (Deviation 2026- O0038)

2026-02

52.242-5 Payments to Small Business Subcontractors.

2017-01

52.242-13 Bankruptcy. 1995-07

52.242-14 Suspension of Work. 1984-04

52.243-4 Changes. (Deviation 2026- O0038)

2026-02

52.244-6 Subcontracts for Commercial Products and Commercial Services. (Deviation 2026-O0038)

2026-04

52.246-12 Inspection of Construction. 1996-08

52.247-64 Preference for Privately Owned U.S.-Flag Commercial Vessels.

(Deviation 2026-O0038)

2026-02

52.249-2 Termination for Convenience of the Government (Fixed-Price).

2012-04

52.249-2 Termination for Convenience of the Government (Fixed-Price).

(Alternate I)

2012-04 Alternate I 1996-09

52.249-10 Default (Fixed-Price Construction).

1984-04

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative.

1991-12

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense- Contract-Related Felonies.

2023-01

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.203-7003 Agency Office of the Inspector General.

2019-08

252.203-7004 Display of Hotline Posters. 2023-01

252.204-7000 Disclosure of Information. 2016-10

252.204-7003 Control of Government Personnel Work Product.

1992-04

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting.

2024-05

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2023-01

252.204-7020 NIST SP 800-171 DoD Assessment Requirements.

2023-11

252.205-7000 Provision of Information to Cooperative Agreement Holders.

2024-10

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements.

2023-01

252.223-7008 Prohibition of Hexavalent Chromium.

2023-01

252.225-7001 Buy American and Balance of Payments Program.

2024-02

252.225-7012 Preference for Certain Domestic Commodities.

2022-04

252.225-7048 Export-Controlled Items. 2013-06

252.225-7056 Prohibition Regarding Business Operations with the Maduro

2023-01

Regime.

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

2023-01

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports.

2018-12

252.232-7004 DoD Progress Payment Rates. 2014-10

252.232-7010 Levies on Contract Payments. 2006-12

252.236-7000 Modification Proposals--Price Breakdown.

1991-12

252.236-7002 Obstruction of Navigable Waterways.

1991-12

252.236-7008 Contract Prices--Bidding Schedules.

1991-12

252.242-7004 Material Management and Accounting System.

2025-01

252.243-7001 Pricing of Contract Modifications. 1991-12

252.243-7002 Requests for Equitable Adjustment.

2022-12

252.244-7000 Subcontracts for Commercial Products or Commercial Services.

2023-11

252.247-7023 Transportation of Supplies by Sea.

2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.211-12 Liquidated Damages- Construction.

2000-09

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of for $2,015.00 each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns. (Deviation 2026-O0038)

Notice of Price Evaluation preference for HUBZone Small Business Concerns (Feb 2026)

(a) Evaluation preference.

(1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except-

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(b) Waiver of evaluation preference. A HUBZone small business concern may choose to waive the evaluation preference. If the concern waives the preference, the factor will be added to its offer for evaluation purposes.

[ ] Offeror chooses to waive the evaluation preference.

(c) Joint venture. A HUBZone joint venture agrees that, in the performance of the contract, at least 40 percent of the aggregate work performed by the joint venture shall be completed by the HUBZone small business parties to the joint venture. Work performed by the HUBZone small business parties to the joint venture must be more than administrative functions.

52.219-28 Postaward Small Business Program Rerepresentation.

Postaward Small Business Program Rerepresentation (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term…