Solicitation.pdf

W16ROE31904572

a. Burlington Bollards Removal Project, Lake Champlain, Vermont. Contractor w ill be required to complete all w ork w ithin 90 days after receipt of Notice to Proceed.

b. The magnitude of this project is betw een $1,000,000.00 and $5, 000,000.00.

c. This procurement is UNRESTRICTED w ith HubZone Price Evaluation Preference.

d. NAICS Code: 237990, Size Standard: $33,500,000.00.

e. The Contract Specialist f or this procurement is Matthew Guilday, email: matthew .guilday@usace.army.mil f . Due to the ever increasing security at Government installations, all bidders are advised to allow ample time to get through the security checks in order to have their bids delivered before 2pm.

g. Submit bids to the Contracting Off icer at the follow ing address:

U.S. Army Corps of Engineers, New York District Contracting Division, Room 1843 26 Federal Plaza New York, NY 10278

X

MATTHEW GUILDAY 917-790-8081

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

23-Aug-2013

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______5 calendar days and complete it w ithin ________90 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________00 80 00

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________24 Sep 2013 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CORPS OF ENGINEERS, NEW YORK

26 FEDERAL PLAZA, RM 1843

NEW YORK NY 10278-0090

W912DS

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

212 -264-3013FAX:TEL: (917)790-8173 TEL: FAX:

W912DS-13-B-0024 73

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912DS-13-B-0024

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Mobilization and Demobilization

FFP

FOB: Destination

MILSTRIP: W16ROE31904572

PURCHASE REQUEST NUMBER: W16ROE31904572

NET AMT

ITEM NO SUPPLIES/SERVICES ESTIMATED

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

0002 28,000 Pound Bollard 4

FFP

Remove / dispose of steel FOB: Destination

ESTIMATED

UNIT UNIT PRICE ESTIMATED AMOUNT

0003 175 Cubic Yard

Bollard 4

FFP

Remove / dispose of fill

0004 1 Each Bollard 4

FFP

Clean and cap pipelines

UNIT UNIT PRICE ESTIMATED AMOUNT

0005 1 Each Bollard 4

FFP

Cap remains with concrete

UNIT UNIT PRICE ESTIMATED AMOUNT

0006 23,300 Pound Bollard 5

FFP

Remove / dispose of steel

UNIT UNIT PRICE ESTIMATED AMOUNT

0007 145 Cubic

Bollard 5

0008 1 Each Bollard 5

FFP

Clean and cap pipelines

0009 1 Each Bollard 5

FFP

OPTION Bollard 3

FFP

For Informational purposes only. See SubCLINs 0010AA, AB, and AC.

UNIT UNIT PRICE ESTIMATED AMOUNT

0010AA 27,400 Pound OPTION Bollard 3

FFP

Remove/ dispose of steel

UNIT UNIT PRICE ESTIMATED AMOUNT

0010AB 330 Cubic

OPTION Bollard 3

0010AC 1 Each OPTION Bollard 3

FFP

Total Base Bid (CLIN 0001-0009) $ _____

Total Optional Bid Items (CLIN 0010AA-0010AC) $ _____

TOTAL BASE + OPTION (CLIN 0001-0010AC) $ ______

NOTES:

1. Tapering is included in the items and the exact locations are on the plan sheets.

2. Low bidder for the purpose of award will be the conforming bidder offering the lowest amount for the total base bid and all optional items.

3. Any bid which is materially unbalanced as to prices for the Base Bid Items may be rejected. An unbalanced bid is one, which is based on the prices significantly less than cost for some work and prices, which are significantly overstated for other work.

4. Bidders are required to bid on all items or their bids will be rejected.

5. Bidders are reminded that they must bid on the issued plans and specifications as amended. Any deviations, conditions, or attachments made by the bidder himself thereto may render the bid non-responsive and may be caused for its rejection.

6. The Government has 45 days from the date of the receipt by the Contractor of the Notice to

Proceed (Basic Work) to exercise the Optional work.

7. The Basic Work shall be completed in 90 calendar days. The Government is under no obligation to award any Optional items. If the Government elects to exercise Option 1 (CLIN 0010), the duration of the contract will not be extended.

CCASS / CPARS

The Federal Acquisition Regulation (FAR) requires that Past Performance Information (PPI) be collected on DoD contracts. The Construction Contractor Appraisal Support System (CCASS) module is a web-enabled application that supports the completion, distribution, and retrieval of Construction contract performance evaluations (DD Form 2626). Contractor Representatives are responsible for reviewing and commenting on evaluations submitted on Contractor Performance Assessment Reporting System (CPARS) website at http://www.cpars.gov/main/cparsmain.htm.

Section 00100 - Bidding Schedule/Instructions to Bidders

GENERAL INSTRUCTIONS

Electronic Submission: In addition to the hard copies required in block 13 of the Standard Form 1442, all offerors shall submit their bids on a CD-ROM. Written portions of the bid shall be in MS Word or Adobe Acrobat PDF format. The electronic version shall be either a single file tabbed in the same order as the hard copy or multiple files hyperlinked to a single table of contents. The CD-ROM must be clearly labeled by solicitation number, project name, and offeror’s name. The CD-ROM shall be marked with a label stating “Unclassified//Controlled Unclassified Info.” In the event of any conflict between the electronic submission and the hard copy submission, the hard copy submission will govern and will be the material upon which the Government bases its evaluation and ultimately, its decision. Electronic media may be submitted in an un-editable format.

NOTE: Bidders are requested to submit the CD-ROM with their bid but no later than 24 hours after the time and date for receipt of bids. Failure to submit the CD-ROM may impact the timeliness of the award.

CLAUSES INCORPORATED BY REFERENCE

52.204-6 Data Universal Numbering System Number JUL 2013 52.204-7 System for Award Management JUL 2013 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUL 2013

52.214-3 Amendments To Invitations For Bids DEC 1989 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 252.204-7004 Alt A System for Award Management Alternate A MAY 2013

CLAUSES INCORPORATED BY FULL TEXT

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Chief of Contracting U.S. Army Corps of Engineers New York District, Contracting Division 26 Federal Plaza, Room 1843 New York, NY 10278-0090

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/ https://www.acquisition.gov/far/

(End of provision

Section 00600 - Representations & Certifications

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JUNE 2013)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990..

(2) The small business size standard is $33,500,000.00.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business).This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation. This provision applies to solicitations using funds appropriated in fiscal years 2008, 2009, 2010, or 2012.

(vi) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(viii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(ix) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(x) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xi) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xvi) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvii) 52.225-4, Buy American Act--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,494, the provision with its Alternate II applies.

(D) If the acquisition value is $77,494 or more but is less than $100,000, the provision with its Alternate III applies.

(xviii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xix) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xx) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran--Representation and Certifications. This provision applies to all solicitations.

(xxi) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

X (i) 52.219-22, Small Disadvantaged Business Status.

(A) Basic.

(B) Alternate I.

(ii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iii) 52.222-48, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment Certification.

(iv) 52.222-52, Exemption from Application of the Service Contract Act to Contracts for Certain Services–Certification.

(v) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA– Designated Products (Alternate I only).

(vi) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website accessed through https://www.acquisition.gov.

After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

252.209-7999 REPRESENTATION BY CORPORATIONS REGARDING AN UNPAID DELINQUENT TAX

LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (DEVIATION 2012-O0004) (JAN 2012)

(a) In accordance with sections 8124 and 8125 of Division A of the Consolidated Appropriations Act, 2012,(Pub.

L. 112-74) none of the funds made available by that Act may be used to enter into a contract with any corporation that—

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government.

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that—

(1) It is [ ___ ] is not [ ___ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability,

(2) It is [ ___ ] is not [ ___ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

Section 00700 - Contract Clauses

52.202-1 Definitions JAN 2012 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees APR 1984 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures OCT 2010 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct APR 2010 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-13 System for Award Management Maintenance JUL 2013 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

JUL 2013

52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data-- Modifications

AUG 2011

52.215-13 Subcontractor Certified Cost or Pricing Data--Modifications OCT 2010 52.215-19 Notification of Ownership Changes OCT 1997 52.217-4 Evaluation Of Options Exercised At The Time Of Contract

Award

JUN 1988

52.217-5 Evaluation Of Options JUL 1990 52.219-2 Equal Low Bids OCT 1995 52.219-4 Notice of Price Evaluation Preference for HUBZone Small

Business Concerns

JAN 2011

52.219-8 Utilization of Small Business Concerns JUL 2013 52.219-9 Alt I Small Business Subcontracting Plan (JULY 2013) Alternate I OCT 2001 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-5 Davis-Bacon Act--Secondary Site of the Work JUL 2005 52.222-6 Davis Bacon Act JUL 2005 52.222-7 Withholding of Funds FEB 1988 52.222-8 Payrolls and Basic Records JUN 2010 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination-Debarment FEB 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility FEB 1988 52.222-21 Prohibition Of Segregated Facilities FEB 1999 52.222-26 Equal Opportunity MAR 2007 52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-32 Davis-Bacon Act--Price Adjustment (Actual Method) DEC 2001 52.222-35 Equal Opportunity for Veterans SEP 2010 52.222-36 Affirmative Action For Workers With Disabilities OCT 2010 52.222-37 Employment Reports on Veterans SEP 2010 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons FEB 2009 52.222-54 Employment Eligibility Verification JUL 2012 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-4 Recovered Material Certification MAY 2008 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995 52.228-14 Irrevocable Letter of Credit DEC 1999 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002 52.232-17 Interest OCT 2010 52.232-23 Assignment Of Claims JAN 1986 52.232-27 Prompt Payment for Construction Contracts JUL 2013 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.233-1 Disputes JUL 2002 52.233-1 Alt I Disputes (Jul 2002) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.243-6 Change Order Accounting APR 1984 52.244-6 Subcontracts for Commercial Items JUL 2013 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2010 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009 252.203-7004 Display of Fraud Hotline Poster(s) DEC 2012 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7006 Billing Instructions OCT 2005 252.204-7007 Alternate A, Annual Representations and Certifications MAY 2013 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.215-7000 Pricing Adjustments DEC 2012 252.215-7008 Only One Offer JUN 2012 252.219-7003 Small Business Subcontracting Plan (DOD Contracts) AUG 2012 252.223-7004 Drug Free Work Force SEP 1988 252.225-7003 Report of Intended Performance Outside the United States and Canada--Submission with Offer

OCT 2010

252.225-7004 Report of Intended Performance Outside the United States and Canada--Submission after Award

OCT 2010

252.225-7006 Quarterly Reporting of Actual Contract Performance Outside the United States

OCT 2010

252.225-7012 Preference For Certain Domestic Commodities FEB 2013 252.225-7031 Secondary Arab Boycott Of Israel JUN 2005 252.225-7048 Export-Controlled Items JUN 2013 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7023 Drawings and Other Data to become Property of Government MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7004 DOD Progress Payment Rates OCT 2001 252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7022 Representation Of Extent Of Transportation Of Supplies By

Sea

AUG 1992

252.247-7023 Transportation of Supplies by Sea JUN 2013 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of Contracting Officer and shall not be binding until so approved.

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than .90 calendar days after receipt of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,300.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) At a time before the project is physically complete but is functionally complete to the satisfaction of the Government, the Government at its sole discretion may agree to accept transfer of the facility or project provided that the remaining work to be done ("punchlist") is completed no later than 30 days from the date of transfer. In this case the Contractor shall pay liquidated damages for punchlist items not completed in the daily amount of $325.00 per day commencing after 30 days of project transfer or after date required for project completion (including all extensions), whichever occurs later.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237990- assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

2.6% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Burlington County, VT

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to

Chief of Contracting U.S. Army Corps of Engineers

New York, NY 10278

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (SEP 2010)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after…