CG_electric_RFP.pdf

NAME: INSTALLATION OF 50 AMP PEDESTALS AND INSTALATION OF NEW UNDERGROWND POWER LINE, Council Grove Lake, KS

This is a 100% Small Business Set-Aside

The NAICS code for this project is 237130 and size standard is $36.5M

The magnitude of construction is: $100,000.00 - $250,000.00

The Request for Proposal (RFP) date is 09/13/2017 at 1400 (2:00PM CT)

SINA C SULLIVAN

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

20-Aug-2017

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO.

918-669-7279

(Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______10 calendar days and complete it within ________60 calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________ 13 Sep 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIV

USACE, TULSA 1645 S 101 E AVE

TULSA OK 74128-4609

W912BV

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX: TEL: TEL: FAX:

W912BV17R0065 46

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE 27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code) 14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror)OFFER

Section 00 11 00 - SF 1442 and CLIN Schedule

BID SCHEDULE

BID SCHEDULE FOR REWIRING OF ELECTRIC POWER AT GROUP CAMP 2 IN

CANNING CREEK COVE PARK AND INSTALLATION OF 50 AMP ELECTRIC

PEDESTALS IN KIT CARSON COVE AND RICHEY COVE PARKS

COUNCIL GROVE LAKE, KANSAS

Appendix No. Description Quantity Unit Amount

Kit Carson Cove

Option 1 Campsites 1, 3-6 1 LS $__________

Richey Cove Park

Option 2 Campsites 19-24 1 LS $__________

Option 3 Campsites 14-15 & 17 1 LS $__________

Canning Creek Cove

Option 4 Group Camp 2 1 LS $__________

TOTAL $_________

Section 00 21 00 - Instructions, Conditions & Notices to Offerors

INSTRUCTIONS TO OFFERORS

INSTRUCTIONS TO OFFERORS

SECTION 00 21 00

INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

1.0 GENERAL INFORMATION

1.1 COPIES OF SOLICITATION DOCUMENTS AND AMENDMENTS

1.2 OFFEROR’S QUESTIONS AND COMMENTS

1.3 SITE VISIT

1.4 ACCURACY IN PROPOSALS

1.5 PROPOSAL SUBMITTALS

1.6 EVALUATION CRITERIA

1.0 GENERAL INFORMATION

1.1 COPIES OF SOLICITATION DOCUMENTS AND AMENDMENTS

Copies of the solicitation and amendments are available by INTERNET ACCESS ONLY. All solicitation documents will be posted through the Army’s Single Face to Industry (AFSI) to the Federal Business Opportunities (FBO) website at: http://www.fbo.gov

Solicitation number: W912BV17R0065

It shall be the contractor’s responsibility to check the websites for any amendments. The offeror shall submit all requested information specified in this solicitation. There will be no public opening of the proposals received as a result of this solicitation.

1.2 OFFEROR'S QUESTIONS AND COMMENTS

REQUEST FOR INFORMATION (RFIs).

For information regarding this solicitation, the USACE Point of Contact is Ms. Sina Sullivan, 918-669-7279, sina.c.sullivan@usace.army.mil or MS. Diane Cianci, 918-669-7458, diane.cianci@usace.army.mil. Please email any questions you may have regarding this effort to sina.c.sullian@usace.army.mil and the Contracting Officer will coordinate a response. All questions must be received no later than 9 September 2017 @ 1400 (2:00PM) Central Standard Time.

1.3 SITE VISIT

All vendors are highly encouraged to attend the Site Visit which is scheduled for August 31, 2017 at 1000 (10:00AM) CST. Location: Council Grove Lake Office, 945 Lake Road, Council Grove, KS 66846-9322. For information, please contact the Site POC, Mr. Michael Lowry, 620- 767-5195, michael.lowry@usace.army.mil.

1.4 ACCURACY IN PROPOSALS

Proposals must set forth full, accurate, and complete information as required by this RFP, (including attachments). The penalty for making false statements is prescribed in 18 U.S.C.

1001.

1.5 PROPOSAL SUBMITTALS

All proposals shall be submitted electronically to sina.c.sullivan@usace.army.mil.

Proposals will be received until the time and date shown on Standard Form SF 1442 or as amended on SF30.

1.5 EVALUATION CRITERIA

Award will be made as a Firm-Fixed Price contract to the vendor that can fulfill the requirements specified in the Statement of Work (SOW). No formal source selection, listed under FAR part 15, will be used for this requirement. This requirement will be awarded to the lowest priced proposal meeting or exceeding the acceptability standards and time frame specified in the solicitation.

Price and Past Performance will be evaluated in accordance with in DFARS 213.106- 2(b)(i)(B)&(C). Past Performance history shall be evaluated for each supplier’s past performance history in the Past Performance Information Retrieval System (PPIRS). Special attention will be given to the PSC of the construction services being purchased. Award will be made to the supplier whose proposal represents the best value to the Government quoting the lowest price and that has anything other than an “Unsatisfactory” rating in PPIRS.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

CLAUSES INCORPORATED BY REFERENCE

52.211-7 Alternatives to Government-Unique Standards NOV 1999 52.211-13 Time Extensions SEP 2000 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.217-5 Evaluation Of Options JUL 1990

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.236-28 Preparation of Proposals--Construction OCT 1997 252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil http://www.acquisition.gov/far/

(End of provision)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulations Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations & Certifications

52.204-7 System for Award Management OCT 2016 52.204-8 Annual Representations and Certifications JAN 2017 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7004 Alt A System for Award Management Alternate A FEB 2014

52.204-20 Predecessor of Offeror (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (OCT 2014) - ALTERNATE I (SEPT 2015)

(a) Definitions. As used in this provision--

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (b) of this provision.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned small business concern means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237130.

(2) The small business size standard is $36,500,000.00

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(c) Representations. (1) The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern. (2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(3) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ --.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (c)(4) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ --.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(6) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ --.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(9) (Complete if offeror represented itself as disadvantaged in paragraph (c)(2) of this provision.) The offeror shall check the category in which its ownership falls:

___ Black American.

___ Hispanic American.

___ Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians).

___ Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru).

___ Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal).

___ Individual/concern, other than one of the preceding.

(d) Notice.

(1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished.

(2) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall—

(i) Be punished by imposition of fine, imprisonment, or both;

(ii) Be subject to administrative remedies, including suspension and debarment; and

(iii) Be ineligible for participation in programs conducted under the authority of the Act.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

14.8 6.9

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Southwest Division District (SWT) boundaries of the U.S. Army Corps of Engineers.

Council Lake, Kansas

52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS--

REPRESENTATION (DEC 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard.

(2) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program.

(c) If the Offeror checked ``does'' in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:

Section 00 72 00 - Contract Clauses

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-19 Incorporation by Reference of Representations and Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-58 Subcontractor Responsibility Matters Regarding Compliance with Labor Laws (Executive Order 13673)

DEC 2016

52.222-59 Compliance with Labor Laws (Executive Order 13673) DEC 2016 52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-17 Interest MAY 2014

52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Items JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.247-7023 Transportation of Supplies by Sea APR 2014

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237130- assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.222-57 REPRESENTATION REGARDING COMPLIANCE WITH LABOR LAWS (EXECUTIVE ORDER

13673) (DEC 2016)

(a)(1) Definitions.

Administrative merits determination, arbitral award or decision, civil judgment, DOL Guidance, enforcement agency, labor compliance agreement, labor laws, and labor law decision as used in this provision have the meaning given in the clause in this solicitation entitled 52.222-59, Compliance with Labor Laws (Executive Order 13673).

(2) Joint ventures. If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision.

(b)(1) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million.

(2) For solicitations issued after April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000.

(c) If the Offeror checked ``does'' in paragraph (b)(1) or (2) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]:

[ ___ ](1) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or

[ ___ ](2) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter.

(d)(1) If the box at paragraph (c)(2) of this provision is checked and the Contracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide--

(i) For each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, the following, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS):

(A) The labor law violated.

(B) The case number, inspection number, charge number, docket number, or other unique identification number.

(C) The date rendered.

(D) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision;

(ii) The administrative merits determination, arbitral award or decision, or civil judgment document to the Contracting Officer, if the Contracting Officer requires it;

(iii) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as Offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and

(iv) The information in paragraphs (d)(1)(i) and (d)(1)(iii) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see 4.1102(a)).

(2)(i) The Contracting Officer will consider all information provided under (d)(1) of this provision as part of making a responsibility determination.

(ii) A representation that any labor law decisions were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(iii) The representation in paragraph (c) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in part 49.

(e) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (c) of this provision is no longer accurate.

(f) The representation in paragraph (c) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS).

Note to 52.222-57: By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined section will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000)

(a) The Contractor shall submit one of the following payment protections:

Performance Bond or Irrevocable Letter of Credit.

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within 10 days of contract award.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by…