shelterhouse_RFP.pdf

NAME: GROUP CAMP SHELTER HOUSE PAINTING AND ROOF REPAIRS IN SANTA FE TRAIL AND CANNING CREEK COVE PARKS COUNCIL

GROVE LAKE, KANSAS

This is a 100% Small Business Set-Aside

The NAICS code for this project is 236220, size standard if $36.5M

The magnitude of construction is : $100,000.00 - $250,000.00

The Request for Proposal (RFP) date is 09/07/2017 at 1400 ( 2:00PM CT)

SINA C SULLIVAN

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

18-Aug-2017

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO.

918-669-7279

(Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______10 calendar days and complete it within ________90 calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________ 07 Sep 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 90 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIV

USACE, TULSA 1645 S 101 E AVE

TULSA OK 74128-4609

W912BV

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W912BV17R0062 51

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE 27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code) 14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror)OFFER

W912BV17R0062

Section 00 11 00 - SF 1442 and CLIN Schedule

BID SCHEDULE

BID SCHEDULE FOR ROOF REPLACEMENT AND PAINTING OF SHELTER

HOUSES IN SANTA FE TRAIL AND CANNING CREEK COVE PARKS

COUNCIL GROVE LAKE, KANSAS

Appendix No. Description Quantity Unit Amount

Option 1 Replacement of Roof Santa Fe Trail 1 LS $__________

Option 2 Replacement of Roof Canning Creek Cove 1 LS $__________

TOTAL $______________

BID SCHEDULE FOR REPLACEMENT OF RESTROOM IN

OUTLET CHANNEL WEST PARK

COUNCIL GROVE LAKE, KANSAS

Appendix No. Description Quantity Unit Amount

Option 1 Placement of New Building (CXT) 1 LS $__________

Option 2 Placement of Sidewalks 1 LS $__________

Option 3 Removal of Old Restrooms 1 LS $__________

TOTAL $______________

Section 00 21 00 - Instructions, Conditions & Notices to Offerors

INSTRUCTIONS TO OFFERORS

INSTRUCTIONS TO OFFERORS

SECTION 00 21 00

INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

1.0 GENERAL INFORMATION

1.1 COPIES OF SOLICITATION DOCUMENTS AND AMENDMENTS

1.2 OFFEROR’S QUESTIONS AND COMMENTS

1.3 SITE VISIT

1.4 ACCURACY IN PROPOSALS

1.5 PROPOSAL SUBMITTALS

1.6 EVALUATION CRITERIA

1.0 GENERAL INFORMATION

1.1 COPIES OF SOLICITATION DOCUMENTS AND AMENDMENTS

Copies of the solicitation and amendments are available by INTERNET ACCESS ONLY. All solicitation documents will be posted through the Army’s Single Face to Industry (AFSI) to the Federal Business Opportunities (FBO) website at: http://www.fbo.gov

Solicitation number: W912BV17R0062

It shall be the contractor’s responsibility to check the websites for any amendments. The offeror shall submit all requested information specified in this solicitation. There will be no public opening of the proposals received as a result of this solicitation.

1.2 OFFEROR'S QUESTIONS AND COMMENTS

REQUEST FOR INFORMATION (RFIs).

For information regarding this solicitation, the USACE Point of Contact is Ms. Sina Sullivan, 918-669-7279, sina.c.sullivan@usace.army.mil or MS. Diane Cianci, 918-669-7458, diane.cianci@usace.army.mil. Please email any questions you may have regarding this effort to sina.c.sullian@usace.army.mil and the Contracting Officer will coordinate a response. All questions must be received no later than 31 August 2017 @ 1400 (2:00PM) Central Time.

1.3 SITE VISIT

All vendors are highly encouraged to attend the Site Visit which is scheduled for August 24, 2017 at 1000 (10:00AM) CST. Location: Council Grove Lake Office, 945 Lake Road, Council Grove, KS 66846-9322. For information, please contact the Site POC, Mr. Michael Lowry, 620- 767-5195, michael.lowry@usace.army.mil.

1.4 ACCURACY IN PROPOSALS

Proposals must set forth full, accurate, and complete information as required by this RFP, (including attachments). The penalty for making false statements is prescribed in 18 U.S.C.

1001.

1.5 PROPOSAL SUBMITTALS

All proposals shall be submitted electronically to sina.c.sullivan@usace.army.mil.

Proposals will be received until the time and date shown on Standard Form SF 1442 or as amended on SF30.

1.5 EVALUATION CRITERIA

Award will be made as a Firm-Fixed Price contract to the vendor that can fulfill the requirements specified in the Statement of Work (SOW). No formal source selection, listed under FAR part 15, will be used for this requirement. This requirement will be awarded to the lowest priced proposal meeting or exceeding the acceptability standards and time frame specified in the solicitation.

Price and Past Performance will be evaluated in accordance with in DFARS 213.106- 2(b)(i)(B)&(C). Past Performance history shall be evaluated for each supplier’s past performance history in the Past Performance Information Retrieval System (PPIRS). Special attention will be given to the PSC of the construction services being purchased. Award will be made to the supplier whose proposal represents the best value to the Government quoting the lowest price and that has anything other than an “Unsatisfactory” rating in PPIRS.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

CLAUSES INCORPORATED BY REFERENCE

52.211-7 Alternatives to Government-Unique Standards NOV 1999 52.211-13 Time Extensions SEP 2000 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017

52.215-22 Limitations on Pass-Through Charges--Identification of Subcontract Effort

OCT 2009

52.217-4 Evaluation Of Options Exercised At The Time Of Contract Award

JUN 1988

52.217-5 Evaluation Of Options JUL 1990 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.236-28 Preparation of Proposals--Construction OCT 1997 252.236-7008 Contract Prices-Bidding Schedules DEC 1991 252.236-7013 Requirement for Competition Opportunity for American Steel

Producers, Fabricators, and Manufacturers

JUN 2013

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price (FFP) contract resulting from this solicitation.

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Diane Cianci, Contracting Officer, 1645 S. 101st E. Ave, Suite 350, Tulsa, OK. 74128-4609

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/VFFARA.HTM http://www.acquisition.gov/far/

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulations Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations & Certifications

52.204-7 System for Award Management OCT 2016 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.204-20 Predecessor of Offeror (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

Section 00 72 00 - Contract Clauses

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-19 Incorporation by Reference of Representations and Certifications.

DEC 2014

52.204-22 Alternative Line Item Proposal JAN 2017 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-32 Construction Wage Rate Requirements--Price Adjustment (Actual Method)

JAN 2017

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-59 Compliance with Labor Laws (Executive Order 13673) DEC 2016 52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.244-5 Competition In Subcontracting DEC 1996 52.244-6 Subcontracts for Commercial Items JAN 2017 52.246-21 Warranty of Construction MAR 1994 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 236220- assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.222-57 REPRESENTATION REGARDING COMPLIANCE WITH LABOR LAWS (EXECUTIVE ORDER

13673) (DEC 2016)

(a)(1) Definitions.

Administrative merits determination, arbitral award or decision, civil judgment, DOL Guidance, enforcement agency, labor compliance agreement, labor laws, and labor law decision as used in this provision have the meaning given in the clause in this solicitation entitled 52.222-59, Compliance with Labor Laws (Executive Order 13673).

(2) Joint ventures. If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision.

(b)(1) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million.

(2) For solicitations issued after April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000.

(c) If the Offeror checked ``does'' in paragraph (b)(1) or (2) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]:

[ ___ ](1) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or

[ ___ ](2) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter.

(d)(1) If the box at paragraph (c)(2) of this provision is checked and the Contracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide--

(i) For each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, the following, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS):

(A) The labor law violated.

(B) The case number, inspection number, charge number, docket number, or other unique identification number.

(C) The date rendered.

(D) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision;

(ii) The administrative merits determination, arbitral award or decision, or civil judgment document to the Contracting Officer, if the Contracting Officer requires it;

(iii) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as Offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and

(iv) The information in paragraphs (d)(1)(i) and (d)(1)(iii) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see 4.1102(a)).

(2)(i) The Contracting Officer will consider all information provided under (d)(1) of this provision as part of making a responsibility determination.

(ii) A representation that any labor law decisions were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(iii) The representation in paragraph (c) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in part 49.

(e) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (c) of this provision is no longer accurate.

(f) The representation in paragraph (c) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS).

Note to 52.222-57: By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined section will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000)

(a) The Contractor shall submit one of the following payment protections:

Performance Bond or Irrevocable Letter of Credit.

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within 10 days of contract award.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

(a) “Irrevocable letter of credit” (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit.

(b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used.

(c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and--

(1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period;

(2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be:

(i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of--

(A) One year following the expected date of final payment;

(B) For performance bonds only, until completion of any warranty period; or

(C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment.

(ii) For contracts not subject to the Miller Act, the later of--

(A) 90 days following final payment; or

(B) For performance bonds only, until completion of any warranty period.

(d)(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC.

(2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year.

(3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC.

(4) The current rating for a financial institution is available through any of the following rating services registered with the U.S. Securities and Exchange Commission (SEC) as a Nationally Recognized Statistical Rating Organization (NRSRO). NRSRO's can be located at the Web site http://www.sec.gov/answers/nrsro.htm maintained by the SEC.

(e) The following format shall be used by the issuing financial institution to create an ILC:

[Issuing Financial Institution's Letterhead or Name and Address]

Issue Date _ ___

IRREVOCABLE LETTER OF CREDIT NO. ___

Account party's name ___ _

Account party's address ___ _

For Solicitation No. W912BV17R0062

TO: U.S. ARMYCORPS OF ENGINNERS

1645 S 101 E AVE, SUITE 350

TULSA OK 74128-4609

1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United States $ ___ . This Letter of Credit is payable at [issuing financial institution's and, if any, confirming financial institution's] office at [ ___ issuing financial institution's address and, if any, confirming financial institution's address] and expires with our close of business on ___ , or any automatically extended expiration date.

2. We hereby undertake to honor your or the transferee's sight draft(s) drawn on the issuing or, if any, the confirming financial…