12B0017_Amnd0002_Specs.pdf

US ARMY ENGINEER DISTRICT, PHILADELPHIA

POC: EMILY GIARDINO

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04 EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

THIS AMENDMENT EXTENDS THE BID OPENING DATE UNTIL 30 AUGUST 2012 AT 2:00 PM

(CONTINUED)

1. CONTRACT ID CODE PAGE OF PAGES

J 1

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA 15C. DATE SIGNED 15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer) (Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912BU-12-B-0017

X 9B. DATED (SEE ITEM 11)

12-Jul-2012

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required) Cobbs Creek Watershed (Indian Creek) Habitat Improvement, Philadelphia, PA

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-Aug-2012

CODE

US ARMY ENGINEER DISTRICT, PHILADELPHIA

CONTRACTING DIVISION

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

W912BU 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE W912BU

FACILITY CODE CODE

EMAIL: TEL:

THIS PAGE INTENTIONALLY LEFT BLANK

Amendment No. 0002 Invitation for Bids

W912BU-12-B-0017

14. DESCRIPTION OF AMENDMENT (continued)

a. GENERAL NOTE - The following specification sections have been amended. Some pages have been provided that contain no changes in order to enable double-sided printing, or to provide information that has moved as a result of changes that were made on other sheets. All pages have been annotated with “Amendment No. 0002” in the header. With the exceptions of the added attachments for Section 01 57 20.00 10, all revisions are shown in bold italics.

b. SPECIFICATIONS - Please delete the following specification sections or pages in their entirety and substitute new sections or pages of the same title and number attached hereto, unless otherwise described.

(1) SECTION 00800 – SPECIAL CLAUSES

(2) SECTION 00815 – WAGE RATES, Pages 1 through 14

(3) SECTION 01 11 00 - SUMMARY OF WORK

(4) SECTION 01 32 33.01 21 - CONSTRUCTION PHOTOGRAPHY: WITHOUT VIDEO

(5) SECTION 01 35 26 - GOVERNMENTAL SAFETY REQUIREMENTS, Pages 13 through 19

(6) SECTION 01 57 20.00 10 - ENVIRONMENTAL PROTECTION

(7) SECTION 01 57 23 - TEMPORARY STORM WATER POLLUTION CONTROL

(8) SECTION 01 72 00 - SURVEY REQUIREMENTS

(9) SECTION 31 00 00 - EARTHWORK

c. SPECIFICATIONS - Please add the following new specification sections or pages to the contract specifications.

(1) SECTION 01 57 20.00 10 - ENVIRONMENTAL PROTECTION – Please add three new attachments (Pages 15 through 100) to the end of this section.

d. Please indicate receipt of this amendment on Standard Form 30 (AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT) as Amendment No. 0002. Failure to acknowledge all amendments may be cause for rejection of the offer.

SECTION 00800

SPECIAL CLAUSES

INDEX

PARA TITLE

SC-1 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

SC-2 LIQUIDATED DAMAGES - CONSTRUCTION

SC-3 CONTRACT DRAWINGS, MAPS AND SPECIFICATIONS

SC-4 PHYSICAL CONDITIONS

SC-5 DAMAGE TO WORK

SC-6 LAYOUT OF WORK

SC-7 PERFORMANCE OF WORK BY THE CONTRACTOR

SC-8 ENVIRONMENTAL LITIGATION

SC-9 QUANTITY SURVEYS

SC-10 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

SC-11 PERFORMANCE EVALUATION OF CONTRACTOR

SC-12 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

SC-13 INSURANCE REQUIREMENTS

Section 00800 Page 1

SPECIAL CLAUSES

SC-1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete and have ready for use all work included in the contract, not later than 360 calendar days after the Contractor receives the notice to proceed.

The time stated for completion shall include final cleanup of the premises.

SC-2 LIQUIDATED DAMAGES - CONSTRUCTION

a. If the Contractor fails to complete the base bid work within the time specified above, the Contractor shall pay to the Government as liquidated damages, the sum of $1,200 for each calendar day of delay.

b. If the Government terminates the Contractor's right to proceed, the resulting damage will consist of liquidated damages until such reasonable time as may be required for final completion of the work together with any increased costs occasioned the Government in completing the work.

c. If the Government does not terminate the Contractor's right to proceed, the resulting damage will consist of liquidated damages until the work is completed or accepted.

SC-3 CONTRACT DRAWINGS, MAPS AND SPECIFICATIONS

a. Upon obtaining the plans and specifications, the Contractor shall:

(1) Immediately check the specifications and all drawings;

(2) Compare the specifications and all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies; and

(4) Be responsible for any errors which might have been avoided by complying with this paragraph .

b. Large scale drawings shall, in general, govern small scale drawings.

Figures marked on drawings shall, in general, be followed in preference to scale measurements.

c. Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, shall not relieve the contractor from performing such omitted or misdescribed details of the work, but shall be performed as if fully and correctly set forth and described in the drawings and specifications.

d. The work shall conform to the specifications and the contract drawings identified on the following, all of which are available in electronic bid set format on the internet at the following address: https://www.fbo.gov.

Drawings are titled: Cobbs Creek Watershed (Indian Creek) Habitat Improvement, City of Philadelphia and have the drawing numbers, subtitles, and dates as listed on Sheet Number 1.

Section 00800 Page 2

SC-4 PHYSICAL CONDITIONS

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

a. The indications of physical conditions on the reference drawings and in the specifications are the result of site investigations by topographic surveysconducted in May 2009 and February 2012, and by subsurface explorations conducted in October 2008. See specification Section 00850 for the associated geotechnical report which includes boring logs.

b. Weather Conditions. The climate of the area is referred to as "continental" by climatologists, characterized by cold winters and moderately hot summers. Complete weather records and reports may be obtained from the local U.S. Weather Bureau Office nearest to the work site. The Contractor shall satisfy himself as to the hazards likely to arise from weather conditions during the construction period.

c. Transportation Facilities. The work site is accessible from Lansdowne Avenue. The Contractor shall be responsible for all investigations of load carrying capacities of bridges and roadways.

d. Survey Controls. All horizontal and vertical control will be established by the Philadelphia District Corps of Engineers Surveys Section in the vicinity of the project, after contract award and in coordination with the Contractor. The Contractor shall contact the Philadelphia District Surveys Section at least 10 business days prior to the start of Contractor survey and/or layout operations, to determine the best locations for the control points based on project requirements. The District Surveys Section will establish up to 4 project control points in locations that are mutually agreed upon by the Contractor and the Surveys Section. The points of contact in the District Surveys Section for this project are Jeff McAleer at (267) 446-2417 and Stephen Farrell at (215) 656-6753.

e. Magnitude of the Contract Work. The estimated value of the contract work is $1,000,000 to $5,000,000.

f. Hours of Work. Unless otherwise specified, the Contractor shall be permitted to perform the contract work between the hours of 7:45 am and 4:30 pm, Monday through Friday. Federal holidays (New Year's Day, Martin Luther King Jr's Birthday, Presidents Day, Memorial Day, Independence Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, and Christmas Day) that fall within the work week will not be considered as work days. Prior to performing any work during hours other than those specified, the Contractor shall submit an overtime request to the Contracting Officer for review and approval. Overtime requests shall be submitted not less than 24 hours prior to the time the Contractor desires to perform the overtime work. The Contractor shall provide at least a 24 hour advanced notification to establish when on-site work will commence and prior to restarting on-site work following any stoppage of work lasting longer than five normal workdays. Notification shall be provided by phone, or person, or in writing, and shall be given directly to the Contracting Officer.

SC-5 DAMAGE TO WORK

The responsibility for damage to any part of the permanent work shall be as set forth in the clause of the contract entitled "Permits and Responsibilities". However, if, in the judgement of the Contracting

Section 00800 Page 3

Officer, any part of the permanent work performed by the Contractor is damaged by flood or hurricane, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor shall make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or lump sum prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or lump sum prices applicable to any part of such work, and equitable adjustment pursuant to Contract Clause entitled "Changes," will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except as herein provided, damages to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense regardless of the cause of such damage. (CENAP)

SC-6 LAYOUT OF WORK

The Contractor shall lay out its work from the Government-established baselines and benchmarks provided (see paragraph SC-4.d above, entitled "Survey Controls"), and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor. All quantity surveys shall be conducted by a licensed Surveyor, currently licensed in the State of Pennsylvania, with at least 10 years of current experience.

SC-7 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifty (50) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government. (FAR 52.236-1)

SC-8 ENVIRONMENTAL LITIGATION (1974 NOV OCE)

a. If the performance of all or any part of the work is suspended, delayed, or interrupted due to an order of a court of competent jurisdiction as a result of environmental litigation, as defined below, the Contracting Officer, at the request of the Contractor, shall determine whether the order is due in any part to the acts or omissions of the Contractor or a Subcontractor at any tier not required by the terms of the contract. If it is determined that the order is not due in any part to acts or omissions of the Contractor or a Subcontractor at any tier other than as required by the terms of this contract, such suspension, delay, or interruption shall be considered as if ordered by the Contracting Officer in the administration of this contract under the terms of the SUSPENSION OF WORK clause of this contract. The period of such suspension, delay, or interruption shall be

Section 00800 Page 4 considered unreasonable, and an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) as provided in that clause, subject to all the provisions thereof.

b. The term "environmental litigation", as used herein, means a lawsuit alleging that the work will have an adverse effect on the environment or that the Government has not duly considered, either substantively or procedurally, the effect of the work on the environment. (CENAP)

SC-9 QUANTITY SURVEYS

a. Quantity surveys shall be conducted, and the data derived from these surveys shall be used in computing the quantities of work performed and the actual construction completed and in place.

b. All quantity surveys shall be conducted by a licensed Surveyor, currently licensed in the State of Pennsylvania, with at least 10 years of current experience.

c. The Contractor shall conduct the original and final surveys and make the computations based on them. The Contractor shall conduct the surveys for any periods for which progress payments are requested and shall make the computations based on these surveys. All surveys conducted by the Contractor shall be conducted under the direction of a representative of the Contracting Officer, unless the Contracting Officer waives this requirement in a specific instance. All surveys shall be conducted in accordance with Section 01 72 00 SURVEY REQUIREMENTS of these specifications.

d. Promptly upon completing a survey, the Contractor shall furnish the originals of all field notes and all other records relating to the survey or to the layout of the work to the Contracting Officer, who shall use them as necessary to determine the amount of progress payments. The Contractor shall retain copies of all such material furnished to the Contracting Officer.

SC-10 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995)

a. This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals, and FAR Part 49.

b. Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by the Contractor or sub-contractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the Contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the Contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, "Construction Equipment Ownership and Operating Expense Schedule," Region II. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply.

For retrospective pricing, the schedule in effect at the time the work was performed shall apply.

Section 00800 Page 5

c. Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

d. When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the Contracting Officer shall request the Contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, "Contract Pricing Proposal Cover Sheet."

(EFARS 52.231.5000)

NOTE #1: The small purchase threshold is $100,000.

NOTE #2: By submitting cost or pricing data, the Contractor grants to the Contracting Officer or an authorizing representative the right to examine those books, records, documents and other supporting data that will permit evaluation of the proposed equipment costs. This right shall extend for two years after expiration of contract performance. After price agreement the Contractor shall certify that the equipment costs or pricing data submitted are accurate, complete and current.

SC-11 PERFORMANCE EVALUATION OF CONTRACTOR

a. As a minimum, the Contractor's performance will be evaluated upon final acceptance of the work. However, interim evaluation may be prepared at any time during contract performance when determined to be in the best interest of the Government.

b. The format for the evaluation will be DD 2626, and the Contractor will be rated either outstanding, above average, satisfactory, marginal or unsatisfactory in the areas of Contractor Quality Control, Timely Performance, Effectiveness of Management, Compliance with Labor Standards, and Compliance with Safety Standards. The Contractor will be advised of any unsatisfactory rating, either in an individual element or in the overall rating, prior to completing the evaluation, and all Contractor comments will be made a part of the official record. Performance Evaluation Reports will be available to all DOD Contracting offices for their future use in determining Contractor responsibility, in compliance with DFARS 236.201(c)(1). (CENAP)

SC-12 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This clause specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled: "Default (Fixed-Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to

Section 00800 Page 6 the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. For the purpose of this contract, unusually severe weather is defined as daily precipitation equal to or exceeding 0.5 inches and/or maximum daily temperature not exceeding 32 degrees F.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

6 4 2 2 2 2 2 2 2 2 2 3

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normal scheduled work. Actual adverse weather days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b.

above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled: "Default (Fixed Price Construction)".

SC-13 INSURANCE REQUIREMENTS

Evidence of the following types of insurance shall be provided to the Contracting Officer prior to commencement of work and shall be maintained throughout the period of performance.

a. General Liability Insurance (Comprehensive form of policy): Bodily Injury Liability - $500,000 per occurrence.

b. Automobile Liability Insurance (Comprehensive form of policy): Bodily Injury Liability - $200,000 per person and $500,000 per accident. Property Damage Liability - $20,000 per accident.

c. Workmen's Compensation and Employer's Liability Insurance: Compliance with applicable workmen's compensation and occupational disease statutes is required. Employer's liability coverage in the minimum amount of $100,000 is also required."

d. Others as required by State.

-- End of Section --

Section 00800 Page 7

00815 - 1

General Decision Number: PA120006 08/03/2012 PA6

Superseded General Decision Number: PA20100006

State: Pennsylvania

Construction Types: Heavy and Highway

Counties: Bucks, Chester, Delaware, Montgomery and Philadelphia Counties in Pennsylvania.

HEAVY AND HIGHWAY CONSTRUCTION PROJECTS

Modification Number Publication Date 0 01/06/2012 1 02/24/2012 2 04/13/2012 3 04/20/2012 4 05/11/2012 5 05/25/2012 6 06/15/2012 7 07/13/2012 8 08/03/2012

BOIL0013-003 01/01/2011

Rates Fringes

BOILERMAKER......................$ 37.35 30.02

CARP0454-003 07/01/2011

Rates Fringes

PILEDRIVERMAN....................$ 38.15 28.27

Footnote: PAID HOLIDAYS: Washington's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, and Christmas Day (provided the employee works the day before the holiday and the day after the holiday).

CARP0845-005 05/01/2012

Rates Fringes

CARPENTER........................$ 39.66 24.44

FOOTNOTE:

A. PAID HOLIDAY: LABOR DAY

CARP1906-001 07/01/2011

Rates Fringes

MILLWRIGHT.......................$ 35.78 26.84

00815 - 2

ELEC0098-001 05/02/2011

BUCKS COUNTY: Starting at the Delaware River and following the west limits of the Borough of Bristol, along the continuation of U.S. Highway 13 and under the Pennsylvania Railroad Bridge to Route 09113, north 09113 to Route 152, north along Route 152 to the Humeville Road, east on Humeville Road to Route 333, north on Route 344 to the junction of Spurs 281 and 252, continue north on Spur 252 to Route 09028, west on 09028 to Route 152, north on 152 to TR 232, north on TR 532 to Tr 113, north on TR 113 to TR 232 at Anchor Inn, northeast on TR 232 and continue northeast along Rounte 659 to Route 09060, west on 09060 to Route 402, north on 402 to the Borough line at the southwest corner of the Borough of New Hope. The Bouough of New Hpoe is excluded.Starting at the Delaware at the Delaware River and proceeding southwest along the Plumstead-Solebury and the Plumstead-Buckingham Township lines to Route 09064, northwest on 09064 to U.S. Highway 611 south on 611 to the spur of Route 270, northwest along the spur to Route 397, Southwest on 397 to Route 350, southeast on 350 to Route 395, southwest on 395 to Route 09060, southeast on 09069 to Route 09041 southwest on 09041 to the Montgomery County line.

DELAWARE COUNTY: That portion east of a line following State Highway 320 from Montgomery County to Maple, then along the Springfield Road to Saxer Ave, along Saxer Avenue to Powell Road, along Powell Road to State Highway 420 and continuing in a straight line to the Delaware River. MONTGOMERY COUNTY:

That portion southeast of a line following Lower State Road from Bucks County southwest to the Bethlehem Pike (U.S Highway 309), south on the Bethlehem Pike to the Penllyn Pike, southwest on the Penllyn and Blue Bell Pikes to the Wissahickon Creek, southeast on the Wissahickon Creek to the Butler Pike to North Lane near Conshohocken Borough, southwest on North Lane to Schuylkill River and continuing southeast in a line to the Spring Mill Road and southwest on the Spring Mill Road to Delaware County. PHILADELPHIA COUNTY

ELECTRICIAN......................$ 46.85 28.86

ELEC0102-003 06/04/2012

BUCKS COUNTY (Plumstead, Bedminister, Tinicum, Nockomixon, Bridgeton and Durham Townships in their entireties, and that portion of Haycock and Springfield Townships east of a line following State Highway 412, from Northampton County south to Route 09071 to State Highway 212, along Highway 212 to Route 09068, and along 09068 to State Highway 313. Also included is that portion of Bublin Borough east of State Highway 313

ELECTRICIAN......................$ 48.93 55.5%

00815 - 3

ELEC0126-002 05/28/2012

CHESTER, DELAWARE, MONTGOMERY, PHILADELPHIA, AND REMAINDER OF

BUCKS COUNTY

Line Construction:

Groundman...................$ 28.63 26%+7.50 Lineman.....................$ 47.72 26%+7.50 Truck driver................$ 31.02 26%+7.50 Winch truck operator........$ 33.40 26%+7.50

ELEC0269-001 01/01/2010

BUCKS COUNTY (Area East of a line starting at the Delaware River and following the west limits of the Borough of Bristol, along the continuation of U.S. Highway 13 and under the Pennsylvania Railroad Bridge to Route 09113, north along 09113 to route 152, north along route 152 to the Hulmeville Rd., east on the Hulmeville to Route 344, north on route 344 to the junction of Spurs 281 and 252 continue north on spur 252 and route 09028, west on 09028 to Route 152, north on 152 to TR 532, north on TR 532 to TR 113, north on TR 113 to TR 232 as Anchor Inn, northeast on TR 232 and continue northeast along 659 to Route 09060, West on 09060 to Route 402, north on 402 to the Borough Line at the southwest corner of the Borough of New Hope; including the Boroughs of New Hope and Bristol)

ELECTRICIAN......................$ 47.34 53.3%+.25

ELEC0269-002 10/02/2006

BUCKS COUNTY - That portion east of a line starting at the Delaware River and following the west limits of the Borough of Bristol, along the continuation of U.S. Highway 13 and under the Pennsylvania Railroad Bridge to Route 09113, north along 09113 to route 152, north along route 152 to the Hulmeville Rd., east on the Hulmeville to Route 344, north on route 344 to the junction of Spurs 281 and 252 continue north on spur 252 and route 09028, west on 09028 to Route 152, north on 152 to TR 532, north on TR 532 to TR 113, north on TR 113 to TR 232 as Anchor Inn, northeast on TR 232 and continue northeast along 659 to Route 09060, West on 09060 to Route 402, north on 402 to the Borough Line at the southwest corner of the Borough of New Hope. The Boroughs of New Hope and Bristol are included.

Line Construction:

Groundman, Truck Driver, 00815 - 4 and Winch Operato...........$ 35.58 51%+.25 Lineman, Cable Splicer, Heavy Equipment Operator....$ 44.48 51%+.25

ELEC0313-003 06/01/2011

DELAWARE COUNTY :(That portion south of U.S. Highway No. 1 and west of U.S. Highway No. 202) Chester County (That portion South and east of U. S. Highway 1)

ELECTRICIAN......................$ 35.00 23.70

* ELEC0375-001 06/01/2012

BUCKS COUNTY (East Rock Hill, West Rock Hill, Milford and Richland Towships in their entirety and that portion of Haycock and Springfield Townships west of a line following State Highway 212 from Northampton County South to Route 09071 along 09071 to state Highway 212, along Highway 212 to Route 09068 and along 09068 to State Highway 313) MONTGOMERY COUNTY(Upper Hanover Twp.in its entirety)

ELECTRICIAN......................$ 38.53 13.93

ELEC0380-001 09/06/2010

BUCKS COUNTY (Hilltown and New Britain Townships in their entirety; that portion of Telford Borough Northeast of County Line Road (Main Street) and bounded by West Rock Hill and Hilltown Township that portion of Dublin Borough West of State Highway 313, and that portion of Doylestown and Warrington Townships and Doylestown Borough Northwest of a line following U.S. Highway 611 South from Route 09064 to the spur of Route 270, and proceeding Northwest along the spur to Route 397, Southwest on 397 to Route 350, Southeast on 350 to Route 395, Southwest on 395 to Route 09069, Southeast on 09069 to Route 09041, Southwest on 09041 to the Montgomery County Line) DELAWARE COUNTY (The portion of Radnor Township North of U.S Highway 30 and West of State Highway 320) MONTGOMERY COUNTY (The portion Northwest of a line following Lower State Road from Bucks County Southwest to Bethlehem Pike (U.S. Highway 309), South on Bethlehem Pike to Penllyn Pike, Southwest on the Penllyn and Blue Bell Pikes to Wissahickon Creek to the Butler Pike, Southwest Wissahickon Creek to Butler Pike, Southwest on Butler Pike, to North Lane near Conshohocken Borough, Southeast on North Lane to the Schuylkill River and continuing Southeast in a line to Spring Mill Road, Southwest on Spring Mill Road to Delaware County; but excluding Upper Hanover, Douglas, Upper Pottsgrove, West Pottsgrove Townships and also excluding that portion of the Borough of Pottstown North and West of a line drawn Northeast on Kein Street from

00815 - 5 the Schuylkill River to Reading Railroad Northwest on the railroad to Madison Street, to High Street, East on High Street to Green Street, North on Green Street and Northeast on Mintzer Street to Lower Pottsgrove Township Line, along this township line and the borough line Northwest to Adams Street and Beehive Road, Northeast on Beehive Road to the Township Line at Mervine Street)

CHESTER COUNTY (East Coventry. East Vincent, West Vincent, East Pikeland, West Pikeland, Uwchlan, Upper Uwchlan, East Brandywine, Schuylkill and Charleston Townships in their entirety, and that portion of Clan, East Clan, East Whiteland & West Whiteland, Tredyffrin, Willistown, Easttown Townships and Borough of Downingtown north of U. S.Highway 30 )

ELECTRICIAN......................$ 39.47 22.82

ELEC0654-001 05/27/2012

DELAWARE COUNTY (The portion south of U.S. Highway 30 and north of that part U.S. Highway 1 between U.S. Highway 202 and the Chester County Line, and east of that part of U.S. Highway 202 between U.S. Highway 1 and the Delaware Line, and west of a line extending from Montgomery County along State Route 320 to Maple, then along the Springfield Road to Saxer Avenue, along Saxer Avenue to Powell Road; along Powell Road to State Highway 420; along 420 and continuing in a straight line to the Delaware River in the State of Pennsylvania) CHESTER COUNTY (That portion south of U. S. Highway 30 and north of that part of U.S. Highway 1)

ELECTRICIAN......................$ 39.38 17.41%+16.19

ELEC0743-001 09/01/2010

CHESTER (Coatesville, Honey Brook, South Coventy, Valley, Wallace, Warwich, West Brandywine, West Clan, and West Nantmeal Twps); AND MONTGOMERY (Douglas, Pottstown, Upper Pottsgrove, and West Pottsgrove, Twps) COUNTIES

ELECTRICIAN......................$ 37.87 3%+15.50

New Year's Day, Good Friday, Memorial Day, Fourth of July, Labor Day, Veterans' Day, Thanksgiving Day, and Christmas Day.

ELEC0743-007 09/01/2010

00815 - 6

CHESTER COUNTY (The portion of Sadsbury and West Sadsbury Township north of U.S. Highway 30)

ELECTRICIAN......................$ 31.87 3%+15.50

* ENGI0542-005 05/01/2012

Rates Fringes

Power equipment operators:

(HEAVY, HIGHWAY, AND WATER

LINE CONSTRUCTION (Off Plant Site))

GROUP 1....................$ 40.43 24.48+A

GROUP 1a...................$ 43.43 25.37+A

GROUP 2....................$ 40.18 24.41+A

GROUP 2a...................$ 43.18 25.30+A

GROUP 3....................$ 36.10 23.20+A

GROUP 4....................$ 35.79 23.12+A

GROUP 5....................$ 34.07 22.61+A

GROUP 6....................$ 33.08 22.32+A

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Handling steel and stone in connection with erection, cranes doing hook work, any machine handling machinery, helicopters, concrete pumps building machines similar to the above, including remote control equipment.

GROUP 1a: Machines handling steel, or the functional equivalent, and stone in connection with erection 15 ton and over factory rating; Cranes doing hook work 15 ton and over factory rating; Any machines handling machinery; HIgh Rail/Burro Crane 15 ton and over factory rating; Rail Loader (Winch Boom Type) 15 ton and over factory rating;

Concrete Pumps (Building) 120 feet of Boom length or less (200 yard pour or less); Machines similar to above, including remote control equipment; Equipment in this Wage Group that does not require an oiler.

GROUP 2: All types of cranes, All types of backhoes, Cableways, Draglines, Keystones, all types of shovels, Derricks, Pavers 21E and over, Trenching machines, Trench shovel, Graddalls, Front-End loaders, Boat Captain, Pippin type backhoes, Tandems scrapers, Towers type crane operation erecting, Dismantling, Jumping or Jacking, Drills (self-containes), (drillmaster type) forklift (20 ft. and over), Moter patrols (fine grade), Batch plant with mixer, Carryalls, Scraper, Trounapulls, Roller (Hith Grade Finishing), Spreaders (asphalt), Bulldozers and Tractors, Mechanic welder, Conveyor loaders (euclid-type wheel), Concrete pump, Milling Machines, Hoist with two towers, Building hoist double drum (unless used as a single drum), Mucking machines in tunnel, All auto grade and concrete

00815 - 7 finishing machines, Bundle pullers/extractors (tublar), toxic/hazardous waste removal rate 20 per cent added to all classificiation, bobcat, side broom, directional boring machines, vermeet saw type machines ( other than hand held) tractor mounted hydro axe, chipper with boom, all machine similar to the above includidng remote control equipment.

3: Asphalt plant engineers, Well drillers, Ditch witch (small trencher), Motor patrols, Fine grade machines, Ten-ton roller (grade fill stone base), Concrete breaking machines, Guilloline only, Stump grinder, Conveyors (except building conveyors), Fork lift trucks of all types, High pressure boliers, Machine similar to the above, including remote control equipment.

GROUP 2a: Crawler backhoes and Crawler gradalls over one cublic yard factory rating; Hydraulic backhoes over one cubic yard factory rating; All types of cranes 15 ton and over factory rating; Single person operation truck cranes 15 ton and over factory rating; Cherry picker type machinery and equipment 15 ton and over factory rating;

Concrete Pumps (Heavy/Highway); Machines similar to above, including remote control equipment; Equipment in this Wage Group that does not require an oiler.

GROUP 3: Asphalt plant engineers, Well drillers, Ditch witch (small trencher), Motor patrols, Fine grade machines, Ten-ton roller (grade fill stone base), Concrete breaking machines, Guilloline only, Stump grinder, Conveyors (except building conveyors), Fork lift trucks of all types, High pressure boliers, Machine similar to the above, including remote control equipment.

GROUP 4: Seaman, Pulverzer form line grader, Farm tractors, road finishing, Concrete spreader, Power broom (self-contained), Seed spreader, Grease truck.

GROUP 5: Compressors pumps, Well point pumps, Welding machines Tireman, Power equipment, Maintenance engineer (power boats), and macnines similar to the above.

GROUP 6: Fireman, Oilers and deck hands (personnel Boats), grease truck.

FOOTNOTE: A. PAID HOLIDAYS: New Year's Day; Memorial Day;

Independence Day; Labor Day; Thanksgiving Day and Christmas Day

**TOXIC/HAZARDOUS WASTE REMOVAL***

Add 20 per cent to basic hourly rate for all classifications

IRON0068-003 07/01/2011

BUCKS COUNTY (Remainder)

00815 - 8

Ironworkers:.....................$ 34.35 18.78 Structural, Ornamental, and Reinforcing

IRON0401-001 07/01/2011

BUCKS (Includes the towns of BEnsalem, Breadysville, Bristol Churchville, Cornwells Heights, Davisville, Eddington, Feasterville, Hartsville, Johnsville, Line Lexington, Neshaminy, Southampton, Tradesville, Trevose, Unionville, Warminster, and Warrington): DELAWARE (North of a line running along State Rt 352 to right on State Rt 291 to State Line);

CHESTER (Includes the towns of Aldham, Anselma, Bacton, Berwyn, Cedar Hollow, Charlestown, Chester Springs, Cromby, Devon, Devault, Daylesford, Diamond Rock, Dutton Mill, Frazer, Goshenville, Howellville, Kimberton, Ludwigs Corner, Paoli, Matthews, Perkiomen Junction, Phoenixville, Rapps Corner, Rocky Hill, Strattford, Sugartown, Tanguy, Valley Forge, Valley Store, White Horse, Williams Corner, and Wilsons Corner);

MONTGOMERY (Remainder); and PHILADELPHIA COUNTIES

IRONWORKER, STRUCTURAL AND

ORNAMENTAL.......................$ 44.70 27.15

* IRON0405-001 07/01/2012

BUCKS (Includes the towns of Bensalem, Breadysville, Bristol, Churchville, Cornwell Heights, Davisville, Eddington, Festerville, Hartsville, Johnsville, Line Lexington, Neshaminy, Southhampton, Transville, Trevose, Unionville, Warminister, and Warrington), DELAWARE (North of a line running along State Route 352 to right on State Route 291 to State Line); CHESTER (Includes the towns of Aldham, Anselma, Bacton, Berwyn, Cedar Hollow, Charlestown Chester Springs, Cromby, Devon, Devault, Daylesford, Diamaond Rock, Dutton Mill, Frazer, Goshenville, Howellville, Kimberton, Ludwigs Corner, Paoli, Mathews, Perkiomen Junction, Phoenixville, Rapps Corner, Rocky Hill, Strafford, Sugartown, Tanguy, Valley Forge, Valley Store, White Horse, Williams Corner, and Wilsons Corner); MONTGOMERY (Remainder); AND PHILDELPHIA COUNTIES

IRONWORKER.......................$ 38.83 25.50

Reinforcing Steel Mesh, Rebar Work

* IRON0405-003 07/01/2012

BUCKS COUNTY (Includes the towns of Bensalem, Breadysville, Bristol, Churchville, Cornwells Heights, Davisville, Eddington, Feasterville, Hartsville, Johnsville, Line Lexington, Neshaminy, Southhampton, Tradesville, Trevose, Unionville, Warminster, and Warrington), DELAWARE (North of a line running along State Route 352 to right on Stae Route 291 to State

00815 - 9

Line); CHESTER (Includes the towns of Alsham, Anselma, Bacton, Berwyn, Cedar Hollow, Charlestown, Chester Springs, Cromby, Devon, Devault, Daylesford, Diamond Rock, Dutton Mill, Frazer, Goshenville, Howellville, Kimberton, Ludwig Corner, Paoli, Mattews, Perkiomen Junction, Phoenixville, Rapps Corner, Rocky Hill, Strafford, Sugartown, Tanguy, Valley Forge, Valley Store, White Horse, Williams Corner); MONTGOMERY (Remainder); and

PHILADELPHIA COUNTIES

IRONWORKER (Rigger and Machinery Mover).................$ 36.22 24.45

* IRON0420-007 07/01/2012

MONTGOMERY COUNTY (Anise, Berguy, Congo, Douglas, East Greenfield, East Limerick, East Slaford, East Zieglerville, Engleville, Fagleysville, Ford, Gilbertsville, Green Lane, Hanover, New Perksionenville, Niato, Palm, Obelish, Pennsburg, Perkiomen, Pottstown, Royerfored, Roytown, Sammamansville, Tylerport, Upper Hanover, Upper Pottsgrove, Upper Wodall, West Limerick, West Salford, and West Zieglerville Townships)

Ironworkers:

Projects $200,000,000 and greater, all work...........$ 31.00 23.00 Projects less than $200,000,000................$ 30.00 23.00

IRON0451-004 07/01/2009

CHESTER (Remainder of County), AND DELAWARE (Remainder of County) COUNTIES

Ironworkers: (Structural, Ornamental, and Reinforcing).....$ 31.60 23.90

LABO0413-003 05/01/2012

Rates Fringes

Laborers:

GROUP 1.....................$ 26.00 22.70

GROUP 2.....................$ 26.20 22.70

GROUP 3.....................$ 26.20 22.70

GROUP 4.....................$ 20.80 22.70

GROUP 5.....................$ 26.85 22.70

GROUP 6.....................$ 26.90 22.70

GROUP 7.....................$ 26.75 22.70

00815 - 10

GROUP 8.....................$ 26.50 22.70

GROUP 9.....................$ 26.35 22.70

GROUP10.....................$ 26.40 22.70

GROUP11.....................$ 26.40 22.70

GROUP12.....................$ 30.13 22.70

GROUP13.....................$ 26.25 22.70

LABORERS CLASSIFICATIONS

GROUP 1: Yardwork Laborers; Scale Mixermen; Bunermen;

Feeders; Dustmen

GROUP 2: General Laborer; Asphalt Shovelers; Sheeting, Shoring & Lagging Laborers; Stone, Granite & Artificial Stone Setting Laborer; Hod Carriers; Scaffold Builders;

Relief Joints & Approach Slabs; Assembling & Placing Gabions; Pneumatic Tool Laborers; Concrete Forms & Stripping Laborers; Concrete & Lumber Material Laborers;

Steel & Steel Mesh (Carrying & Handling); Form Pinners;

Mortar Mixers; Pouring & Placing Concrete; Grade Men

GROUP 3: Vibrator Laborer; Finish Surface Asphalt Rackers;

Jackhammer Operators; Paving Breaker Operator; Pipelayer & Caulker (all joints up to within 5 feet of the Building Foundation Line); Conduit & Duct Layers

GROUP 4: Flagperson

GROUP 5: Miners

GROUP 6: Burners

GROUP 7: Miner Bore Driver; Blasters; Drillers; Pneumatic Shield Operator

GROUP 8: Form Setters

GROUP 9: Trackmen; Brackmen; Groutmen; Bottom Shaft Men; All Other Laborers in Free Air Tunnels; Underpinning (When an underpinning excavation is dug eight feet or more below the natural grade or where an excavation for a pier hole of five feet square or less and eight feet or more dep is dug, the rate shall apply only after a depth of eight feet is reached, to the men working in the bottom)

GROUP 10: Circular Caissons (Where an excavation for circular caissons are dug eight feet or more below the natural grade level adjacent to the starting point of the caisson hole, at ground level, for the men working in the bottom);

Welders, Burners & Air Tuggers

GROUP 11: Powderman; Multiple Wagon Drill Operator

GROUP 12: Toxic/Hazardous Waste Handler

GROUP 13: Wagon Drill/Hydraulic Track Drill Operator

00815 - 11

LABO0413-005 04/01/2012

Landscaping Farm Tractor Driver, Hydroseeder Nozzleman, Mulcher Nozzleman...........$ 18.71 21.03+A

FOOTNOTE:

A. PAID HOLIDAYS: Independence Day, Labor Day, and Thanksgiving Day

PAIN0021-003 11/01/2011

Rates Fringes

Painters:

Bridge......................$ 44.17 20.96 All Other Work..............$ 36.17 20.57

PLAS0592-008 05/01/2012

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 31.35 27.46

PLUM0420-001 05/01/2011

Rates Fringes

Steamfitter Bucks, Chester, Delaware, Montgomery and Philadelphia Counties.......$ 44.93 26.18

* PLUM0690-008 05/01/2012

Rates Fringes

PLUMBER..........................$ 42.93 28.61

TEAM0470-002 05/01/2009

Rates Fringes

Truck drivers:

GROUP 1.....................$ 25.25 13.1225+A

GROUP 2.....................$ 25.35 13.1225+A

GROUP 3.....................$ 25.60 13.1225+A

TRUCK DRIVERS CLASSIFICATIONS

GROUP 1 - Stake body truck (single axle, dumpster)

GROUP 2 - Dump trucks, tandem and batch trucks, 00815 - 12 semi-trailers, agitator mixer trucks, and dumpcrete type vehicles, asphalt distributors, farm tractor when used for transportation, stake body truck (tandem)

GROUP 3 - Euclid type, off-highway equipment or belly dump trucks and double hitched equipment, staddle (ross) carrier, low-bed trailers

GROUP 1 - Stake body truck (single axle), dumpster

GROUP 2 - Dumpt trucks, tandem and batch trucks, semi-trailers, agitator mixer trucks, and dumpcrete type vehicles, asphalt distributors, farm tractor when used for transportation, stake body truck (tandem)

GROUP 3 - Euclid type, off-highway equipment or bell dump trucks and double hitched equipment, staddle (ross) carrier, low-bed trailers

FOOTNOTE:

A. PAID HOLIDAYS: Memorial Day, Independence Day, Labor Day, Thanksgiving Day and five personal holidays provided employee works at least one day in the three work days before and at least one day in the three work days after the said holiday. Emloyee earns a personal holiday every two months, provided employee has worked twenty-six day in each consecutive two month period, up to a maximum of five per calendar year. After 130 work days the employee is entitled to all five personal holidays.

B. PAID VACATION: Employee will earn one vacation day for every two months, provided employee has worked twenty-six day in each consecutive two month period, up to a maximum of five vacation days per calendar year. After 130 workdays the employee is entitled to all five days of vacation. Employees with 5 years of seniority, earn an additional week of vacation, accrued in the same way.

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the

00815 - 13 cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is union or non-union.

Union Identifiers

An identifier enclosed in dotted lines beginning with characters other than "SU" denotes that the union classification and rate have found to be prevailing for that classification. Example: PLUM0198-005 07/01/2011. The first four letters , PLUM, indicate the international union and the four-digit number, 0198, that follows indicates the local union number or district council number where applicable , i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2011, following these characters is the effective date of the most current negotiated rate/collective bargaining agreement which would be July 1, 2011 in the above example.

Union prevailing wage rates will be updated to reflect any changes in the collective bargaining agreements governing the rate.

Non-Union Identifiers

Classifications listed under an "SU" identifier were derived from survey data by computing average rates and are not union rates; however, the data used in computing these rates may include both union and non-union data. Example: SULA2004-007 5/13/2010. SU indicates the rates are not union rates, LA indicates the State of Louisiana; 2004 is the year of the survey; and 007 is an internal number used in producing the wage determination. A 1993 or later date, 5/13/2010, indicates the classifications and rates under that identifier were issued as a General Wage Determination on that date.

Survey wage rates will remain in effect and will not change until a new survey is conducted.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour

00815 - 14

Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon…