W912BU-09-R-0046.pdf

CODE

(Hour)

PAGE(S)

until 03:30 PM local time 26 Aug 2009

X

A X B X C X D

EX

X

G F 26 - 39

40 - 43 H edward.a.boddie@usace.army.mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA FAR (48 CFR) 53.214(c)

1 43

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W912BU 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 2 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

EDWARD A BODDIE 215-656-6786

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 3

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT

PACKAGING AND MARKING

4 - 12

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

14 - 15

16 - 17 X K REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 18 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIONS AND INSTRUCTIONS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

19 - 25

PART II - CONTRACT CLAUSES

US ARMY ENGINEER DISTRICT, PHILADELPHIA

CONTRACTING DIVISION

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.

W25PHS99062409

5. DATE ISSUED

12 Aug 2009

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W912BU-09-R-0046

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lump Sum

1MW MICROGRID

FFP

The contractor shall deliver to the Government a ruggedized micro grid power distribution system. The microgrid replaces spot generators with prime power generators, with some utility-like controls, set up as a power plant. The first step is to “grid” the FOB and establish the infrastructure. The power plant or microgrid will be configured for power to be delivered based on actual demand, not peak demand for the overall system. Design will allow for the future addition of renewable energy (solar, wind, and/or battery storage).

All work to accomplished ian accordance with the Statement of Work

PLACE OF PERFORMANCE: The microgrid will be installed at the National Training Center (NTC), Ft Irwin, California.

FOB: Destination

PURCHASE REQUEST NUMBER: W25PHS99062409

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Sack

MICROGRID SITE SERVICES

FFP

The contractor shall is expected to prepare the designated site to receive/establish/operate the microgrid. To this end and in accordance with final scope of work the contractor will at contractor expense, provide all equipment with certified operators, supplies, material, and qualified personnel and labor required to:

- Prepare the final site to receive the micro-grid,

- Install the microgrid,

- Safely place/install the major components such as generators and switch gear,

- Make all necessary connections for power generation and distribution for the grid

FOB: Destination

NET AMT

Section C - Descriptions and Specifications

STATEMENT OF WORK

STATEMENT OF WORK

FOR

1MW MICROGRID, FOB DENVER, FT IRWIN

1. Introduction: The purpose of this Joint Capabilities Technology Demonstration (JCTD) is to show that, through a combination of increase energy productivity, intelligent power distribution and alternative/ renewable/hybrid power, the use and transportation of fossil fuels for power generation at an enduring Forward Operating Base can be drastically decreased or potentially eliminated.

1.1. Quality Control Plan: Establish and maintain an effective quality control (QC) system. QC consists of plans, procedures, and organization necessary to produce a product, which complies with the contract requirements. Cover all manufacturing operations, both onsite and offsite, and be keyed to the proposed project sequence. The project superintendent will be held responsible for the quality of work and is subject to removal by the Contracting Officer for non-compliance with the quality requirements specified in the contract. In this context, the highest-level manager responsible for the overall project activities, including quality and production is the project superintendent.

The project superintendent must maintain a physical presence during all site activities except as otherwise acceptable to the Contracting Officer.

1.1.1. Content of the QC Plan: Include, as a minimum, the following to cover all project operations, both onsite and offsite, including work by subcontractors:

o The name, qualifications, duties, responsibilities, and authorities of each person assigned.

o A description of the quality control organization, including a chart showing lines of authority.

o A copy of the letter to the QC System Manager signed by an authorized official of the firm which describes the responsibilities and delegates sufficient authorities to adequately perform the functions of the QC System Manager, including authority to stop work which is not in compliance with the contract.

1.2. Safety Requirements

1.2.1. Regulatory Requirements: The contractor shall comply with USACE EM 385-1-

1, NFPA 241, the APP, the AHA, Federal and/or State OSHA regulations, related Federal, state and local laws and regulations, and other related submittals and activity fire and safety regulations. The most stringent standard shall prevail. Submit matters of interpretation of standards to the appropriate administrative agency for resolution before starting work. Where the requirements of this specification, applicable laws, criteria, ordinances, regulations, and referenced documents vary, the most stringent requirements shall apply

1.2.2. Accident Prevention Plan (APP): The APP shall be job-specific and shall address any unusual or unique aspects of the project or activity for which it is written.

1.2.2.1.The APP shall interface with the Contractor's overall safety and health program. Any portions of the Contractor's overall safety and health program referenced in the APP shall be included in the applicable APP element and made site-specific.

1.2.2.2.The Government considers the Prime Contractor to be the "controlling authority" for all work site safety and health of the subcontractors. Contractors are responsible for informing their subcontractors of the safety provisions under the terms of the contract and the penalties for noncompliance, coordinating the work to prevent one craft from interfering with or creating hazardous working conditions for other crafts, and inspecting subcontractor operations to ensure that accident prevention responsibilities are being carried out.

1.2.2.3.The APP shall be signed by the person and firm (senior person) preparing the

APP, the Contractor, the on-site superintendent, the designated site safety and health officer.

1.2.2.4. Submit the APP to the Contracting Officer 5 calendar days prior to the date of the preconstruction conference for acceptance. Work cannot proceed without an accepted APP. Once accepted by the Contracting Officer, the APP and attachments will be enforced as part of the contract. Disregarding the provisions of this contract or the accepted APP will be cause for stopping of work, at the discretion of the Contracting Officer, until the matter has been rectified.

1.3. Work Restrictions: Contractor personnel shall become familiar with and obey Nation Training Center, Fort Irwin, Ca regulations. Keep within the avenues of ingress and egress. To minimize traffic congestion, delivery of material shall be outside of peak traffic hours (6:30 to 8:00 AM and 3:30 to 5:00 PM)

1.3.1. Do not enter any restricted areas unless required to do so and until cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification

1.3.2. Subcontractors and Personnel Contacts: Furnish a list of contact personnel of the

Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists

1.3.3. Identification badges, if required, will be furnished without charge. Application for and use of badges will be as directed. Furnish a completed EMPLOYMENT ELIGIBILITY VERIFICATION (DHS FORM I-9) form for all personnel requesting badges. This form is available at http://uscis.gov/graphics/formsfee/forms/files/i- 9.pdf. Immediately report instances of lost or stolen badges to the Contracting Officer

1.3.4. At the time of award specific information required for access to NTC, FT Irwin, Ca. will be relayed to the successful offeror and incorporated into the contract.

2. Scope of Work: The objective of this effort is to deliver to the Government a ruggedized microgrid power distribution system. The microgrid will be installed at the National Training Center (NTC), Ft Irwin, California. The microgrid replaces spot generators with prime power generators, with some utility-like controls, set up as a power plant. The first step is to “grid” the FOB and establish the infrastructure. The power plant or microgrid will be configured for power to be delivered based on actual demand, not peak demand for the overall system. Design will allow for the future addition of renewable energy (solar, wind, and/or battery storage).

2.1. General Requirements: The contractor shall install a 1MW power generation system connected to the “grid”. Included in the project is all underground cabling, step down and step up transformers and panel boxes, paralleling gear with load sequencing capabilities (turning on/off generators). The power distribution system or microgrid will provide 480vac, 208vac, and 110/120vac to meet all power requirements.

2.2. Period of Performance: The anticipated period of performance is one hundred and twenty (120) calendar days months from notice to proceed. Offerors may submit an alternative period of number of days in accordance with FAR 52.211-9 Alt III in Section E.

3. Site Description: The Contractor shall construct a microgrid at FOB Denver, with specific location determined by NTC at site survey. A ten-digit grid will be provided and a survey marker will be in the ground to determine actual layout.

3.1. Site-Prep Services: The contractor is expected to prepare the designated site to receive/establish/operate the microgrid. To this end and in accordance with final statement of work the contractor will provide all equipment with certified operators, supplies, material, and qualified personnel and labor required to:

3.1.1. :Prepare the final site to receive the micro-grid,

3.1.2. Install the microgrid,

3.1.3. Safely place/install the major components such as generators and switch gear,

3.1.4. Make all necessary connections for power generation and distribution for the grid

Site Access.

3.2. Site Access: The Contractor shall follow the following site access

3.3. All Contractor personnel working at the construction site are subject to a mandatory”Range Training Class” prior to accessing this location. The class is held on Tuesdays at 1300 hr (if necessary we may be able to schedule a one-time class for all personnel).

3.3.1. The Contractor shall not drive or set material and equipment off designated roads, access areas, right-of-ways, staging, or laying down areas, etc... In addition, no excavation, grading, leveling, grubbing, backfilling, etc. shall be performed beyond the area designated on the plans unless pre-approved by Government POC.

4. Conceptual Designs: See submittals

5. Microgrid Installation: The Contractor shall conduct the followings “work sets” required for the construction of the microgrid.

5.1. Earthwork:

5.1.1. Site Visit

5.1.2. Site Excavation

5.1.3. Inspection of Site

5.2. Microgrid Manufacturing and Deployment: The Contractor shall fabricate (2) 40’

ISO containers, & (1) 20’ ISO container modified for desert conditions for housing below equipment

5.2.1. Generators and Major End Items: Generator engines are brand name or equal specifications:

1 each - 400 kW Caterpillar engine 1 each - 300 kW Caterpillar engine 2 each - 230 kW Caterpillar engine

5.2.2. Management Control System Interface Requirements: Proposals for work statements regarding the Control System Interface must address the following minimum requirements:

• Synchronization of all available power sources

• Engine acknowledgement and recognition on grid

• Changeable system parameters to explore different site conditions

• Ability to minimize fossil fuel consumption by smart grid technology

• Maximize engine efficiency by utilizing real time load profile data

• Minimize engine maintenance by effective management controls

• Full external remote monitoring and system control functions available

• Automatic system acknowledgement and correction/action of available power sources

• Capability to integrate future alternative energy sources

• Redundant interface bypass

5.3. Container(s) Requirements: The Contractor shall erect the containers to meet the specified requirements.

5.3.1. Personnel access doors, 2 each, lockable, 36” wide.

5.3.2. Shipping straps for all equipment to eliminate vibration, and covers for all fixed container openings to protect from contamination by foreign debris or harsh environment during transport of the unit

5.3.3. Interior walls and Ceiling of container lined with Rockwool Thermo insulation and protected with a 16 gauge metal liner white finish coated

5.3.4. Installed 18” interlocking Rubber floor system

5.3.5. Fluorescent lights and available housekeeping power installed in each container

5.3.6. Standard ISO container shipping eyes on all 8 corners with D-Ring tie downs on sides

5.3.7. Forklift slots on sides for lifting by all terrain forklift

5.3.8. Finish paint with Endura Arctic White finish

5.3.9. Sand Intake louver

5.3.10. Exhaust Fan

5.3.11. Connection Box (Distribution Exit)

5.4. Grid Infrastructure: All distribution lines to be buried 3’ below grade from containers to termination points.

5.5. Electrical – Specific Requirements: The contractor shall be responsible for furnishing all materials, labor and equipment necessary to deliver, set-up and maintain the grid and provide power to FOB Denver-located 1.0 hour from main post (terrain-rough). The FOB consists of ten (10) tents and three (3) TOCs.

5.5.1. Electrical Systems – The generators, major end items, containers and all other components for the microgrid (power distribution system) will be procured and paid for by the contractor. The contractor will tie into existing infrastructure/cabling.

Cable sizes, runs, and distribution requirements will be discussed at the site visit.

5.5.2. Develop and submit electrical wiring (drawings & schematics) for FOB Denver to the PSTF (JCTD Manager), prior to installation. The SPT BDE and the NTC G-3 Box coordinator will review plans to ensure that the wiring does not interfere with any of the current infrastructure on the FOB. All “as-built” drawings and schematics are deliverables at the completion of the project. Additionally, designs wiring layout and runs will incorporate the potential and provide for future expansion.

5.5.3. Electrical connections will be made in interior of spray foam tents unless safety or quality issues preclude an interior connection. Cables will be buried, as needed, under roads and access ways unless expressly directed otherwise by the Contracting

Officer. Electrical components shall meet applicable requirements of the National Electrical Code (NEC) for temporary outdoors, wet and windy locations. All electrical distribution equipment systems shall be grounded according to NEC requirements. To reduce downtime and outages, twist lock connections are required of all 120vac electrical wiring and components.

5.5.4. Qualified electricians must be used for all electrical work. Minimum standards are

5 years verifiable experience in Commercial and Residential electrical work and or a Certificate of Journeyman Status from a registered Labor Union.

6. Power Generation: Power generation includes the delivery of the generators identified in

4.2.1, installation/set-up of the generators, and operation and maintenance of the generators.

The contractor shall be responsible for furnishing all materials, labor and equipment necessary to deliver, set-up and maintain power generation on FOB Denver. The following salient elements apply to this requirement.

6.1. Installation method minimizes voltages drops/spikes to consumption points regardless of system demand

6.2. Fuel capacity supports twelve (12) hours continuous operation with all generators running at peak load.

6.3. Fuel type is JP8

6.4. Refueling must be able to occur while generators are running to ensure that the micro-grid is operational twenty (24) hours a day, seven (7) days a week through the period of performance.

6.5. Generators installed to allow “load sharing” and an equitable distribution of running hours that minimizes over use of anyone generator. The periodic cycling of generators without service interruption will be accomplished to prove the load sharing and document effectiveness of grid.

6.6. Redundancy: The power generation must also include a bypass in the system for redundancy. The bypass will allow the interface within the system to be routed around in the case of malfunctions.

6.6.1. This redundancy enables the power plant to distribute power to all required end users without interruption.

6.6.2. At the main distribution panel (MDP), their must be a wiring system that facilitates a manual layer of redundancy for quick disconnect of existing generators in case of systematic failure.

7. Schedule, Planning & Testing Requirement. The Contractor will develop and submit a master project schedule, which will be the basis for the As Planned Schedule, and the As

Built Schedule.

7.1. The As Planned Schedule must address and timeline project from notice to proceed through delivery based on targeted milestones and work breakdown structure (WBS) in the Statement of Work, which will be incorporated into the award document. This master schedule will determine the planned start and finish dates for project activities.

7.2. The As Built Schedule shall incorporate; the milestones and timeline agreed to in the As

Planned Schedule and will be the baseline for project performance against progress. This As Built will become part of performance evaluation and must document, delays and other anticipated or new risk events.

7.3. Project & Site-Prep/Layout Plans: Part of the planning for the contractor will include the submission of two (2) copies of the project and site-prep/layout plans to the JCTD Project Manager.

7.4. Progress & Daily Status Reports: The contractor will provide information on project performance against progress. The designated project t manager and COR will receive daily reports sufficient for oversight, weekly detailed reports documenting progress, delays and risks either identified or resolved. Additionally there will be ad-hoc reports as needed to communicate issues that are critical to the milestones and may cause schedule performance problems in the future.

7.5. Factory Witness Test. Functional and Full load testing will be required at factory prior to shipment and consistent with commercial practices. The contractor must submit test plan and planned dates two weeks prior to actual testing.

7.6. Onsite commissioning and startup: Contractor will provide factory-trained personnel to give instruction and training on equipment topology as well as function. Three-day minimum onsite training required, 8-hour sessions per day.

8. Miscellaneous:

8.1. Inspections: Contractor will make site available for the following inspections by the

Government.

• Site Assessment

• Site-Prep & Progress Inspection

• Safety Analysis

• Occupancy

• Walk through and Punch list

• Final Inspection

8.2. Delivery:

8.2.1. Microgrid: In accordance with this final period of performance, anticipated to be four (4) months from NTP, the microgrid is deliverable within one-hundred and twenty days. Delivery of the microgrid is to include a one (1) year, from date of acceptance, warranty, on all major components and workmanship.

8.2.2. Owner's Manual. The Contractor is responsible to provide owner’s manuals for the functionality of the microgrid and all system components of the project.

8.2.3. Warranty of Construction Components: The Contractor is responsible for submitting all warranty documents per component.

8.3. Maintenance & Repair Plan: Contractor to furnish owners' manual, information on structural and electrical maintenance and schedules. Also to include structural and electrical repair and/or trouble shooting procedures.

8.4. Submittals: Other submittals that are required but not previously mentioned include the following: Past performance, cost breakdown by major end items or components, and any other drawing(s) and/or documentation not specified but relevant to the project and/or technical review.

8.5. Maintenance: The contractor will perform maintenance on the gen sets every 250 hrs.

Routine maintenance will be conduct and/or scheduled around the rotational units occupying the box. Maintenance will need to be conducted 10-12 times annually; again based on rotational units.

9. Site-Prep & Installation – Site Demobilization:

9.1. Staging and Debris Disposal Areas: The Contractor shall conduct continual daily cleanup of the job site and the final cleanup when complete. Debris must be handled in accordance with commercial practices and local regulations. Proper cleanup and disposal of all materials is solely a contractor responsibility. Contractor is responsible for clean up of all construction debris generated by Contractor crew(s) or their subcontractors and vendors. Job site and staging areas should be contained at the end of each workday. Contractor must haul debris or spoils away from job site.

9.2. Final Inspections: Final inspections will be in accordance with commercial practices, FAR, and performed at site.

9.3. USACE EM385-1-1 regulations: The contractor is responsible to be in accordance with the latest USACE EM385-1-1 regulations.

9.4. Hazardous and Construction Waste Material Disposal: The Contractor shall properly dispose of all building material and byproducts from this construction site in accordance to Federal law.

10. Distribution/Release Limitation Statements: All information provided to the contractor by the Government shall be protected from disclosure in accordance with the markings contained on the document and as described in the following text:

11. “Dissemination or public disclosure includes, but is not limited to: permitting access to such information by foreign nationals or by any other person or entity; publication of technical or scientific papers; advertising; or, any other proposed public release. The contractor shall provide adequate physical protection to such information so as to preclude access by any person or entity not authorized such access by the Government.”

12. Security: This project is UNCLASSIFIED.

Section D - Packaging and Marking

PACKAGING AND MARKING

D-1 PACKAGING AND MARKING

Packaging and marking of deliverables shall be in accordance with the industry and Contractor’s standard commercial practices unless specifically directed by Contrracting Officer..

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government

CLAUSES INCORPORATED BY REFERENCE

52.246-4 Inspection Of Services--Fixed Price AUG 1996 52.246-5 Inspection Of Services Cost-Reimbursement APR 1984 52.246-6 Inspection--Time-And-Material And Labor-Hour MAY 2001 52.246-7 Inspection Of Research And Development Fixed Price AUG 1996 52.246-16 Responsibility For Supplies APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.04-4003 INSPECTION AND ACCEPTANCE

Inspection and Acceptance will be made at Destination by Representative of the Contracting Officer.

52.246-9 INSPECTION OF RESEARCH AND DEVELOPMENT (SHORT FORM) (APR 1984)

The Government has the right to inspect and evaluate the work performed or being performed under the contract, and the premises where the work is being performed, at all reasonable times and in a manner that will not unduly delay the work. If the Government performs inspection or evaluation on the premises of the Contractor or a subcontractor, the Contractor shall furnish and shall require subcontractors to furnish all reasonable facilities and assistance for the safe and convenient performance of these duties.

(End of clause)

COR INSPECTION/ACCEPTANCE

Appointed Contracting Officer’s Representative (COR) will participate in the administration of this contract specifically to evaluate contractor’s performance, inspect services for Government, and support the Government COR program. This designation does not include authority to direct and/or authorize the Contractor to make changes in the scope of terms of the contract without written authority of the Contracting Officer. The Contracting Officer will notify the Contractor in writing of names; duties and limitations of appointed COR(s).

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

52.242-15 Stop-Work Order AUG 1989 52.247-34 F.O.B. Destination NOV 1991

52.004-4001 PLACE OF DELIVERY

Shipment shall be made to the following destination:

FOB Denver, specific site TBD, National Traing Center, Fort Irwin, CA

52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY (JUN 1997) - ALTERNATE III (APR 1984)

(a) The Government desires delivery to be made according to the following schedule:

DESIRED DELIVERY SCHEDULE

Commence work in accordance with As Planned Schedule within five (5) work days after Notice to proceed.

If the offeror is unable to meet the desired delivery schedule, it may, without prejudicing evaluation of its offer, propose a delivery schedule below. However, the offeror's proposed delivery schedule must not extend the delivery period beyond the time for delivery in the Government's required delivery schedule as follows:

REQUIRED DELIVERY SCHEDULE

Commence work in accordance with As Planned Schedule within TBD or 120 calendar days whichever is the earlier after Notice to Proceed

Offers that propose delivery of a quantity under such terms or conditions that delivery will not clearly fall within the applicable required delivery period specified above, may be considered nonresponsive and rejected. If the offeror proposes no other delivery schedule, the desired delivery schedule above will apply.

Offerors are expected to submit, an initial master project schedule (As Planned Schedule) addressing the targeted milestones and work breakdown structure (WBS). This master schedule will determine the planned start and finish dates for project activities.

OFFEROR'S PROPOSED DELIVERY SCHEDULE

WITHIN DAYS

ITEM NO. QUANTITY AFTER DATE

OF CONTRACT

52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT

(SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $____ per calendar day of delay [Contracting Officer insert amount].

(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and Service clause in this contract.

Section G - Contract Administration Data

Section I - Contract Clauses

52.202-1 Definitions JUL 2004 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees APR 1984 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures JUL 1995 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

SEP 2007

52.203-15 Whstleblower Protections Under the American Recovery and Reinvestment Act of 2009

MAR 2009

52.204-2 Security Requirements AUG 1996 52.204-4 Printed or Copied Double-Sided on Recycled Paper AUG 2000 52.204-11 American Recovery and Reinvestment Act--Reporting

Requirements

MAR 2009

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

SEP 2006

52.215-2 Alt I Audit and Records--Negotiation (Mar 2009) Alternate I MAR 2009 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.215-10 Price Reduction for Defective Cost or Pricing Data OCT 1997 52.215-12 Subcontractor Cost or Pricing Data OCT 1997 52.215-14 Integrity of Unit Prices OCT 1997 52.215-15 Pension Adjustments and Asset Reversions OCT 2004 52.215-17 Waiver of Facilities Capital Cost of Money OCT 1997 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-21 Requirements for Cost or Pricing Data or Information Other Than Cost or Pricing Data--Modifications

OCT 1997

52.219-8 Utilization of Small Business Concerns MAY 2004 52.219-9 (Dev) Small Business Subcontracting Plan (Deviation) APR 2008 52.222-3 Convict Labor JUN 2003 52.222-21 Prohibition Of Segregated Facilities FEB 1999 52.222-26 Equal Opportunity MAR 2007 52.222-35 Equal Opportunity For Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans

SEP 2006

52.222-36 Affirmative Action For Workers With Disabilities JUN 1998 52.222-37 Employment Reports On Special Disabled Veterans, Veterans

Of The Vietnam Era, and Other Eligible Veterans

SEP 2006

52.222-50 Combating Trafficking in Persons FEB 2009 52.226-1 Utilization Of Indian Organizations And Indian-Owned

Economic Enterprises

JUN 2000

52.227-2 Notice And Assistance Regarding Patent And Copyright Infringement

DEC 2007

52.229-3 Federal, State And Local Taxes APR 2003 52.232-2 Payments Under Fixed-Price Research And Development

Contracts

APR 1984

52.232-9 Limitation On Withholding Of Payments APR 1984

52.232-23 Alt I Assignment of Claims (Jan 1986) - Alternate I APR 1984 52.232-25 Prompt Payment OCT 2008 52.232-33 Payment by Electronic Funds Transfer--Central Contractor

Registration

OCT 2003

52.233-1 Disputes JUL 2002 52.233-3 Protest After Award AUG 1996 52.242-2 Production Progress Reports APR 1991 52.242-13 Bankruptcy JUL 1995 52.243-1 Alt V Changes--Fixed-Price (Aug 1987) - Alternate V APR 1984 52.244-5 Competition In Subcontracting DEC 1996 52.244-6 Subcontracts for Commercial Items MAR 2009 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-2 Termination For Convenience Of The Government (Fixed- Price)

MAY 2004

52.249-9 Default (Fixed-Priced Research And Development) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

JAN 2009

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A Central Contractor Registration (52.204-7) Alternate A SEP 2007 252.204-7009 Requirements Regarding Potential Access to Export-

Controlled Items

JUL 2008

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.215-7000 Pricing Adjustments DEC 1991 252.215-7002 Cost Estimating System Requirements DEC 2006 252.217-7008 Bonds DEC 1991 252.217-7008 Bonds DEC 1991 252.219-7003 (Dev) Alt I

Smal Business Subcontracting Plan (DoD Contracts) (Deviation) Alternate I

APR 2007

252.225-7002 Qualifying Country Sources As Subcontractors APR 2003 252.225-7012 Preference For Certain Domestic Commodities DEC 2008 252.227-7033 Rights in Shop Drawings APR 1966 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

MAR 2008

252.232-7010 Levies on Contract Payments DEC 2006 252.235-7010 Acknowledgment of Support and Disclaimer MAY 1995 252.235-7011 Final Scientific or Technical Report NOV 2004 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment MAR 1998 252.244-7000 Subcontracts for Commercial Items and Commercial

Components (DoD Contracts)

JAN 2009

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

(a) The Contractor shall make the following notifications in writing:

(1) When the Contractor becomes aware that a change in its ownership has occurred, or is certain to occur, that could result in changes in the valuation of its capitalized assets in the accounting records, the Contractor shall notify the Administrative Contracting Officer (ACO) within 30 days.

(2) The Contractor shall also notify the ACO within 30 days whenever changes to asset valuations or any other cost changes have occurred or are certain to occur as a result of a change in ownership.

(b) The Contractor shall--

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the ACO or designated representative ready access to the records upon request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of the Contractor's ownership changes;

and

(4) Retain and continue to maintain depreciation and amortization schedules based on the asset records maintained before each Contractor ownership change.

The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(k).

52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS

CONCERNS (JUL 2005)

(a) Definition. HUBZone small business concern, as used in this clause, means a small business concern that appears on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration.

(b) Evaluation preference. (1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except--

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(2) The factor of 10 percent shall be applied on a line item basis or to any group of items on which award may be made. Other evaluation factors described in the solicitation shall be applied before application of the factor.

(3) A concern that is both a HUBZone small business concern and a small disadvantaged business concern will receive the benefit of both the HUBZone small business price evaluation preference and the small disadvantaged business price evaluation adjustment (see FAR clause 52.219-23). Each applicable price evaluation preference or adjustment shall be calculated independently against an offeror's base offer.

These individual preference amounts shall be added together to arrive at the total evaluated price for that offer.

(c) Waiver of evaluation preference. A HUBZone small business concern may elect to waive the evaluation preference, in which case the factor will be added to its offer for evaluation purposes. The agreements in paragraph

(d) of this clause do not apply if the offeror has waived the evaluation preference.

___ Offeror elects to waive the evaluation preference.

(d) Agreement. A HUBZone small business concern agrees that in the performance of the contract, in the case of a contract for

(1) Services (except construction), at least 50 percent of the cost of personnel for contract performance will be spent for employees of the concern or employees of other HUBZone small business concerns;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), at least 50 percent of the cost of manufacturing, excluding the cost of materials, will be performed by the concern or other HUBZone small business concerns;

(3) General construction, at least 15 percent of the cost of the contract performance incurred for personnel will be spent on the concern's employees or the employees of other HUBZone small business concerns; or

(4) Construction by special trade contractors, at least 25 percent of the cost of the contract performance incurred for personnel will be spent on the concern's employees or the employees of other HUBZone small business concerns.

(e) A HUBZone joint venture agrees that in the performance of the contract, the applicable percentage specified in paragraph (d) of this clause will be performed by the HUBZone small business participant or participants.

(f) A HUBZone small business concern nonmanufacturer agrees to furnish in performing this contract only end items manufactured or produced by HUBZone small business manufacturer concerns. This paragraph does not apply in connection with construction or service contracts.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2009)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code - assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.228-16 PERFORMANCE AND PAYMENT BONDS--OTHER THAN CONSTRUCTION (NOV 2006) -

ALTERNATE I (JUL 2000)

(a) Definitions. As used in this clause-

"Original contract price" means the award price of the contract or, for requirements contracts, the price payable for the estimated quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity.

Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) The Contractor shall furnish a performance bond (Standard Form 1418) for the protection of the Government in an amount equal to 100% percent of the original contract price.

(c) The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within ten (10) days, but in any event, before starting work.

(d) The Government may require additional performance bond protection if the contract price is increased. The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(e) The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register, or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.

As prescribed in 28.103-4, insert a clause substantially as follows:

52.228-5016 PERFORMANCE AND PAYMENT BONDS - OTHER THAN CONSTRUCTION (SEP 1996)

(a) Definitions. As used in this clause-- "Contract price" means the total amount of the contract for the term of the contract (excluding options, if any) or, for requirements contracts, the price payable for the estimated quantity; or for indefinite-delivery type contracts, the price payable for the specified minimum quantity.

(b) The Contractor shall furnish a performance bond (Standard Form 1418) for the protection of the Government in an amount equal to (*****) percent of the contract price and a payment bond (Standard Form 1416) in an amount equal to **7599 percent of the contract price.

(c) The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within *****) days, but in any event, before starting work.

(d) The Government may require additional performance bond protection when the contract price is increased.

The Government may secure additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(e) The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual securities, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Registrar, or may be obtained from the U.S. Department of Treasury, Financial Management Service, Surety Bond Branch, 401 14th Street, NW., 2nd Floor, West Wing, Washington, DC 20227.

(End of clause) Alternate I (SEP 1996). As prescribed in 28.103-4, substitute the following paragraph (b) for paragraph (b) of the basic clause:

(b) The Contractor shall furnish a performance bond, (Standard Form 1418) for the protection of the Government in an amount equal to (*****) percent of the contract price.

52.239-1 PRIVACY OR SECURITY SAFEGUARDS (AUG 1996)

(a) The Contractor shall not publish or disclose in any manner, without the Contracting Officer's written consent, the details of any safeguards either designed or developed by the Contractor under this contract or otherwise provided by the Government.-

(b) To the extent required to carry out a program of inspection to safeguard against threats and hazards to the security, integrity, and confidentiality of Government data, the Contractor shall afford the Government access to the Contractor's facilities, installations, technical capabilities, operations, documentation, records, and databases.-

(c) If new or unanticipated threats or hazards are discovered by either the Government or the Contractor, or if existing safeguards have ceased to function, the discoverer shall immediately bring the situation to the attention of the other party.

252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991)

(a) "Definition. Contracting officer's representative" means an individual designated in accordance with subsection 201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions.

(b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract.

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a…